Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
IP #930
COUNCII Vii' Request for Action Originating Department Approved for Agenda Agenda Section Public Works June 23, 2014 Development & Planning Item No. By: Bob Paschke, Director By: Kirk McDonald, City Manager 8.2 Resolution approving plans and specifications for the 2014 seal coat and crack repair project and ordering advertisement for bids (improvement project no. 9 0) Requested Action Staff recommends approval of a resolution approving the 2014 seal coat plans and specifications and ordering advertisement for bids. Once bids are received they will be presented to Council for consideration. Policy/Past Practice To maximize the life of the pavement on city streets, New Hope annually schedules crack repair and seal coating of selected city streets. This is an activity that is critical to the city's current Pavement Management Strategy. If delayed, maintenance costs increase and may also result in premature expenditures for pavement overlays or reconstruction. Background The city's street infrastructure management plan identifies and prioritizes street maintenance activities to maximize the return on each dollar invested in maintenance. A recently revised management plan has identified areas to be seal coated and/or crack repaired this year. This year's propos-ed seal coat and crack repair project are scheduled on previously reconstructed and milled/overlaid roads as indicated on the attached plan sheets. The City of Brooklyn Park has also requested cost sharing on the city border roadway of 62nd Avenue for Brooklyn Park's sealcoat/crack fill project in 2014. The 2012 New Hope seal coat project had a large percentage of release of seal coat chips from the oil that was applied. That year the chips continued to let go from the street surface even after several sweepings. This resulted in a substantial amount of chips being deposited on the boulevards during snow plowing. Motion by Second by To: 1; / RFA/Public Works/2014/930 2014 Seal Coat & Crack repair Approving Plans and Specs Request for Action June 23, 2014 Page 2 A number of communities in the metropolitan area experienced similar issues with regards to excessive amounts of loose seal coat chips that year. Industry professionals suggested using fewer pounds of seal coat chips per square yard and changing to a more expensive polymer modified emulsion (oil) from the current practice of using water based emulsion. This process was used for the 2013 sealcoat project. The polymer modified off did have a better success of holding onto the rock; however, there was still a moderate amount of release in 2013 after snowplowing. An additional sweeping on roads and raking loose rock from a few yards was necessary this past spring. Technology has advanced in addressing rock release. It is now widely accepted to fog an additional layer of emulsion over the top of sealcoat rock after sweeping. This asphaltic layer encapsulates the entire rock locking the product in on all surfaces; rock release has virtually been eliminated with this process. The need for polymer for rapid set of rock into the emulsion is therefore no longer required, and the polymer expense can then be offset within the cost to apply fog. The additional asphalt emulsion in the fogging process will double seal out moisture which is the leading cause of asphalt failure. The added benefit to fogging is the road will be given the appearance of a jet black surface, which will last many years, and resembles a new paved surface. The primary drawback to the fogging process is that vehicles will be required to remain off the streets for up to 4 hours. Staff is recommending that all areas receive a seal coat application and be crack repaired prior, with some areas only to receive crack repair either the year of sealcoat or the year prior. The crack repairing process also will be modified. Not only road surface cracks will be addressed, but also the longitudinal crack along the curb line. Both longitudinal and transverse horizontal joints will be sealed to direct moisture to the curb, allowing fluids to drain off without falling through unsealed joints and cracks. Seal coating is most effective in the early stages of the pavement's life, and crack repair is effective in reducing decay that results from moisture entering into asphalt and roadbeds. The streets recommended for seal coating and crack repair are identified on the accompanying maps. Prior to commencement of seal coating by the contractor, Public Works staff will have completed infrastructure maintenance such as asphalt patching and curb repairs throughout the areas recommended for seal coating. The project would take approximately 30 days and would occur during the late summer months. Funding The engineer's total estimate for the entire seal coat project is $226,000. Funding for the project would be from the city's street infrastructure fund. Attachments • Resolution • Plan sheets • City Engineer memorandum I: / RFA/Public Works/2014/930 2014 Seal Coat & Crack repair Approving PIans and Specs City of New Hope Resolution No. 14- 95 Resolution approving plans and specifications for the 2014 crack repair and seal coat project and ordering advertisement for bids (improvement project No. 930) WHEREAS, funding is available in the 2014 street infrastructure fund for a crack repair and seal coat project; and, WHEREAS, this activity is an integral component of the city's pavement management strategy; and, WHEREAS, this activity is recommended for the area identified in the street infrastructure pian developed by staff and engineering. NOW, THEREFORE, BE IT RESOLVED by the City Council of the city of New Hope, Hennepin County, Minnesota: 1. Such plans and specifications are hereby approved. 2. The city clerk shall prepare and cause to be inserted in the official paper, an advertisement for bids for crack repair and seal coating in accordance with said specifications. The advertisement shall be published for fourteen (14) days, and shall state that the bids will be opened at 10:00 a.m. CDT on July 18, 2014, at the New Hope City Hall, 4401 Xylon Avenue North, New Hope, Minnesota. Any bidder whose responsibility is questioned during consideration of the bid shall be given an opportunity to address the City Council on the issue of responsibility. No bids shall be considered unless sealed and filed with the city clerk and accompanied by a cash deposit, cashier's check, bid bond or certified check payable to the city for five percent (5%) of the amount of such bid. Adopted by the City Council of the city of New Hope, Hennepin County, Minnesota, this 23th day of June, 2014. Mayor Attest:. City Clerk I: / RFA/Public Works/2014/930 2014 Seal Coat & Crack repair Approving Plans and Specs C*1 Stantec June 18, 2014 Pile: 193802836 Stantec Consulting Services Inc, 2335 Highway 36 West St. Paul MN 55113 Tel: (651) 636-4600 Fax: (651) 636-1311 Attention: Bob Paschke, Director of Public Works City of New Hope ,sJUV ��u�iii�anuiiui rU[KVVUy New Hope, MN 55428 Reference: 2014 Crack Repair and Seal Coat - Approve Plans and Specifications - City Project No.: 930 Dear Bob, The City of New Hope completes annual crack repair and seal coat application projects to extend the useful life of streets throughout the City. The project streets this year were selected for crack repair and seal coat based upon the new Pavement Management Strategy. We analyzed all streets and past improvements completed. Only streets which were previously fully reconstructed in the past and streets which are in need for an improvement were selected. This year's project will include additional improvements as compared to previous year's seal coat projects. Additional crack repair along the curb lines and the longitudinal joints will be completed. Also, we are planning to fog seal all seal coated streets, which will decrease the chip rock release and improve the seal coat effectiveness. In concurrence with New Hope's project, the City of Brooklyn Park is planning to seal coat 62nd Avenue North. This street is a shared street with New Hope and Brooklyn Park, as the border runs directly through the center of 62nd Avenue North. Brooklyn Park will administer this project and invoice the City of New Hope for half the costs of the improvements (shown in the table on the next page). Since we are proposing fog seal for all seal coat streets, we are proposing to bid an Alternate to apply fog seal on 62"d Avenue North after Brooklyn Park's seal coat project is complete. We will review the bids received and continue our discussions with Brooklyn Park to determine if a fog seal is appropriate. Plans and specifications for the 2014'seal coat project have been prepared and are ready for review. June 18, 2014 Mr. Bob Paschke Pane 2 of 2 Reference: 2014 Crack Repair and Seal Coat -- Approve Plans and Specifications This project involves approximately 2.5 miles of streets within the city (see attached plans). The anticipated project costs for New Hope are estimated below: Base Bid Construction Cost $180,000 Alternate 1 - 62nd Avenue North Fog Seal $6,000 Indirect Costs $20,000 Subtotal (New Hope Project) $206,000 62nd Avenue North fBrooklyn Park Project 20,000 Total Estimated Costs $226,000 If Council chooses to move forward with this project, approval of plans and specifications and authorization to advertise for contractor bids could be given at the June 23rd Council Meeting. Bids could then be opened on July 18th and brought back to Council for review at the July 28th Council Meeting. The work under this contract would be completed in August and September of 2014. If you have any questions or require further information please call me at (651)604-4808. Sincerely, STANTEC Christopher W. Long, P.E. Attachments: 2014 Crack Repair and Seal Coat Plans Cc: John Blasiak, Shawn Markham, Bernie Weber- New Hope; Jeremy Hauser, Rohini Ray, Adam Martinson - Stantec. PUBLIC WONKLS I, Cm Hut BID SITE ALTERNATE #1 - 62ND AVE N LOCATION clea CITY OF NEW HOPE 2014 CRACK REPAIR AND SEAL COAT CITY PROJECT NUMBER 930 2014 MA TmEsI OULI LOM M RAM Nm IOCATIOM HAM mm Lx 1p Mr HAM a•�mna KATHIHEMKEN JOHN ELDER ANDY HOFFE ERIC LAMMLE DANIEL STAUNER KIRK MRDONALD BOB PASCHKE STEVE SONDRALL MAYOR COUNCILMEMBER COUNCILMEMBER COUNCILMEMBER COUNCILMEMBER CITY MANAGER PUBLIC WORKS DIRECTOR CITY ATTORNEY Z I W Z a U 6R z= gx 2 .Ol ALTERNATE *1 - 62ND AVE N (FRONTAGE RD TO LOUISIANA AVE) 62Nb AVE N _4rgq.�N41� ---f 'i -4 MEADOW LAKE 61112 AVE N DOROTHY T' ELEMENTARY El -Z SCHOOL 6iff CIlL N 615r AVE N BL PARK Hif�SBQp, 60112 AVE N wz --Jp jj� 601/2 AVE K 6lp�kVE N MEADOW LIBERTY wLAKE PARK Z w V PARK L or J LEGEND. CRACK REPAIR CRACK REPAIR, SEAL COAT, & FUG SEAL CRACK REPAIR & FOG SEAL GENERAL mom 1. INLET PROMMON Ugfi= WILL NMFM=lffCM. PRO A KO OF 48 HRS NDrF=T= FWR70 SUL CDATIN OPEPATIOM I STREET SR133-MG - RUM Snip; 1-3 DAYS AFTER Sm aW .2m : MIN. 10 DAYS AFTER HTIAL SAWAND PRMTC) FOG SM 3. FX SEALCOHRETION DATE; SEMN6IRM3024. .VICTORY ORY VXMRY PARK PAPMG LOT ------- LE PUBLIC o WORKS .GARAGE 'Fart z MARY PARK 60112 AVE N 60M AVE N VILLAGE GREEN GOLF COURSE ST. THERESE NURSING HOME (k i a mo qt CONTPMTD LOUMIM AVN N u —w — 62ND AVE 1 klsT --T A- NvuRrvr:w —1 co.ol 2! < 0 0 o m z Lj < 0 wLq Lu Z NvuRrvr:w —1 co.ol r ' h- _- - 49TH AYE y. v 47I12AWN g ,47"Fti � AVE I w 1 r ---i I � _ S 47tH AV6 N .-` --- Z �z- > 0�` ...�: AVE - I 46TH, --- r _ • V _457HAVEN._� -- �� F - Lum . r .- I L_._�� c I -'- BRETH- I RacLo-oRDi�ati ---- .._ .449TH AVE N _ z � 1 4BTH AVEN- j-- -_ _ z I .5 6 1 47TH AVE N LEGEND CRACK REPAIR CRACK REPAIR, SEAL COAT, & FOG SEAL CRACK REPAIR & PDG SEAL C GENERAL NOTES! L mEr PROTWnON OEVLCES WNA BE RISTALIIDRY QTY. PKMDE A MNNINOM OF 46 NRS NOPBiOOQP PR30R TO 'SEAL GRATING OPERATIONS, Z SIREEr SWEEPING -INMAL SWEEP: L-3 DAYS AFnFtSULCOKr -2ND SNEER MIN, LG DAYS AFTHLINITIALSAEEP AND MOR M FOG SEAL 3. FOG SEAL COMPLEITON DATA BWEMBBILIANW3 I I n Inn One z� ti LL, O O� I 45TH LT I I —r. z w u 46TH a• it --i -�__. F-- _-!NMA AVEN ` AS¢p-I I z - i is . I LEGEND CRACK REPAIR CRACK REPAIR, SEAL COAT, & FOG SEAL CRACK REPAIR & PDG SEAL C GENERAL NOTES! L mEr PROTWnON OEVLCES WNA BE RISTALIIDRY QTY. PKMDE A MNNINOM OF 46 NRS NOPBiOOQP PR30R TO 'SEAL GRATING OPERATIONS, Z SIREEr SWEEPING -INMAL SWEEP: L-3 DAYS AFnFtSULCOKr -2ND SNEER MIN, LG DAYS AFTHLINITIALSAEEP AND MOR M FOG SEAL 3. FOG SEAL COMPLEITON DATA BWEMBBILIANW3 42ND AVE N u .°3 4A Z Ld d O z w z U I �T L.1 n Inn One z� ti LL, O O� I 45TH LT I I —r. z w u - -_� 43RDAVE N --- wi a• it --i -�__. 42ND AVE N u .°3 4A Z Ld d O z w z U hNhAVE ---N - - - - - - AVE N i 21 NORTHL OR -7 31STAVFN z jisT AVE R WISOONSM 3: AVEN AVE N 30TH AVE N - lgi� -4? ....... — _(AVE Hm . VEE #cp 4,r -2M AVE N, m 0 > X z I 17rH :A3 DE;z ) p lz- 0 CITY OF GOLDEN VALLEY 27rH AVE N (NEMC NE LAKE RD) �—a ;21 0 TL z z (5r6 LEGEND � CRACK PJ32MR X o SPP 1m ---------- CRACK REPAIR, SEAL COAT, & FOG SEAL i t CRACK REPAIR & FOG SEAL GENERAL NOM 1. INLET PROMIM DEMOS WILL BE INSMIM Bf C". :ROME A mMmum OP NRS NOrnPrATMN PRIOR70 SEAL COATWG OPERAMN& q 2. STREET 9NEEPING CITY -QF NEW HOPE - INITIAL WNEEP: 1-3 DAYS AFTUIALODAT .2ND WWMP: MM. 10 DAYS WERChUMMEEPAND PRIOR TO FOr SOL CITY OF GOLDEN VALLEY 2TFH AVE % 3. FOG SMCOMBrIONOATS: MEPTEMBERIZ201A �—a ;21 0 TL z z (5r6 CITY OF NEW HOPE ADWRTISEMENT FOR BIDS Se. Bids will be received by the City of New Hope, Minnesota, in the City Hall at 4401 $ylon Avenue North, until 10 AM., CDT, Friday, July 16, 2014, at which time they will be publicly opened and read aloud for the famishing of all labor, materials, and all else neces- sary for the fallowing: 2014 Crack Ripsk and Beal Coat• _fits Project Nm 990 In general, Work consists of the Wowing approximate quantities: 39,400 SY Seal (bat Aggregate, FA -2 (Mod), Trap Rock 11,000 GAL Bituminous Material fcr Seal Coat 47,300 SY Bituminous Material for Fog Seal 61,000 LBS Crack Seal Complete digital Bidding Doctunents are available at www.questcdncom for $20 by inputting 9nestCDN Prgject #W -4W8 on the websites Project Search page. Paper Bidding Documents may also be viewed at the office of the Qty of New Hope and Stantee, 2335 Highway 36 West, St. Paul, MN 55118, (651) 936-4600. Direct inquiries to Engineer's Project Manager, Chris Long, at (651) 604-4808. Bid Security in the amount of 6 percent of the amount of the Bid must accompany each Bid in accordance with the Instructions to Bidders. The Owner reserves the right to retain the � 'M of the S lowest Bidders for a perm, t to exceed 60 days after the date and time set far the Opening of Bids. No Bids may be withdrawn for a period of 60 days after the date and time set for the Opening of Bids. The Owner reserves the right to reject any and all Bids, to waive irregularities and informalities therein, and further reserves the right to award the Contract to the best interests of the Omisr. KIRK MCDONALD, Qty Manager Qty of New Hope, Minnesota (Published in Finance and Commerce June 26, July $, 2014) 10567459 Page 1 of 1 Affidavit of Publication STATE OF MINNESOTA ) (SS. COUNTY OF HENNEPIN } Description: Bids for New Hope RE: 2014 Crack Repair and Seal Coat Peggy Lewis , being duly sworn on oath say she/he is and during all times herein stated has been the publisher or the publishers designated agent in charge of the newspaper known as Finance and Commerce (MN) and has full knowledge of the facts herein stated as follows: (A) The newspaper has cornplied with all of the requirements constituting qualifications as a legal newspaper, as provided by !•linneso:s Satutc 331A.02, and 331A,077, and other applicable Iaws, as amended. (B) She/He further states on that the printed Construction 10567459 hereto printed as part as it was printed and published there in the English language; that it was first so published on June 26, 2014 for 2 time($): e su seglwclit dates of publications being as Mows: 6/26/2014 7/3!2014 And that the following is a printed copy of the lower case alphabet from A to Z, both inclusive, and is hereby acknowledged as being the size and kind of type used in the X akdefghijklm-pgrstuvwxyz abcdefRhijklmnopgrstuvwxyz E Subscribed and Sworn to before me this 3rd day of July, 2014 (Notarial Seal) No Publ Hennepin County, Minnesota CARRIE ANN R� �4 NO�IY P'uLil;o•-P ;S tr!Bso6a MY Commisa,or, cz rres lan 3t, 8018 `�ntYtVSE RATE INFORMATION: 1. Lowest classified rate paid by $ commercial users for comparable space: 2. Maximum rate allowed by law for $ the above matter: 3. Rate actually charged for the above $ matter: 16.0000 0.48809 0.4437 CGFe1IP[am it.Request for Action Originating Department Approved for Agenda Agenda Section Public Works July 28, 2014 Development & Planning Item No. By: Bob Paschke, Director By: Kirk McDonald, City Manager 8.1 Resolution awarding a contract to Allied Blacktop Company for the 2014 crack repair and seal coat project for $267,625 (improvement project no. 930) Requested Action Staff is recommending that Council pass a resolution approving a contract between the city of New Hope and the Allied Blacktop Company in the amount of $267,625.00 for the 2014 seal coat project. Due to high bids received and budget constraints, we are not recommending awarding Alternate 1 (62nd Avenue N. fog seal) unless Council is comfortable with increasing this year's budget. Policy/Past Practice To maximize the life of the pavement on city streets, New Hope annually schedules crack repair and seal coating of selected city streets. This is an activity that is critical to the city's current Pavement Management Strategy. Background The city's street infrastructure management plan identifies and prioritizes street maintenance activities to maximize the return on each dollar invested in maintenance. A recently revised management plan has identified areas to be seal coated and/or crack repaired this year. This year's proposed seal coat and crack repair project are scheduled on previously reconstructed and milled/overlaid roads as indicated on the attached plan sheets. The City of Brooklyn Park has also requested cost sharing on the city border roadway of 62nd Avenue for Brooklyn Park's sealcoat/crack fill project in 2014. The 2012 New Hope seal coat project had a large percentage of release of seal coat chips from the oil that was applied. That year the chips continued to let go from the street surface even after several sweepings. This resulted in a substantial amount of chips being deposited on the boulevards during snow plowing. Motion by G� Second by e9w,,4,-� To: _d -r OU 7 4 d5- t 3 5r.s-= IVb X: / RFA/Public Works/2014/930 2014 Seal Coat & Crack repair Approving Plans and Specs Request for Action July 28, 2014 Page 2 A number of communities in the metropolitan area experienced similar issues with regards to excessive amounts of loose seal coat chips that year. Industry professionals suggested using fewer pounds of seal coat chips per square yard and changing to a more expensive polymer modified emulsion (oil) from the current practice of using water based emulsion. This process was used for the 2013 sealcoat project. The polymer modified oil did have a better success of holding onto the rock; however, there was still a moderate amount of release in 2013 after snowplowing. An additional sweeping on roads and raking loose rock from a few yards was necessary this past spring. Technology has advanced in addressing rock release. It is now widely accepted to fog an additional layer of emulsion over the top of sealcoat rock after sweeping. This asphaltic layer encapsulates the entire rock locking the product in on all surfaces; rock release has virtually been eliminated with this process. The need for polymer for rapid set of rock into the emulsion is therefore no longer required, and the polymer expense can then be offset within the cost to apply fog. The additional asphalt emulsion in the fogging process will double seal out moisture which is the leading cause of asphalt failure. The added benefit to fogging is the road will be given the appearance of a jet black surface, which will last many years, and resembles a new paved surface. The primary drawback to the fogging process is that vehicles will be required to remain off the streets for up to 4 hours. Staff is recommending that all areas receive a seal coat application and be crack repaired prior, with some areas only to receive crack repair either the year of sealcoat or the year prior. The crack repairing process also will be modified. Not only road surface cracks will be addressed, but also the longitudinal crack along the curb line. Both longitudinal and transverse horizontal joints will be sealed to direct moisture to the curb, allowing fluids to drain off without falling through unsealed joints and cracks. Public Works staff will have completed infrastructure maintenance such as asphalt patching and curb repairs throughout the areas recommended for seal coating. The project improvements will occur in August and early September. Funding The engineer's estimated construction cost was $180,000. The lowest responsible bid was $267,625.00 which is $87,625.00 over the original estimate. The detailed breakdown of costs is shown in the table below: Base Bid Construction Cost *Alternate 1- 62nd Avenue North Fog Seal Original Estimate Post Bid Costs $180,000 $267,625.00 $6,000 $19,757.50 Indirect Costs $20,000 $20,000.00 Subtotal (New Hope Project) $206,000 $307,382.50 62nd Avenue North (Brooklyn Park Project) $20,000 $20,000.00 Total Estimated Costs $226,000 $327,382.50 I: / RFA/Public Works/2014/930 2014 Seal Coat & Crack repair Approving Plans and Specs Funding for the project would be from the ci-h/s street infrastructure fund. It is felt that quantities relative to the crack repair portion of the project may very well be lower than the bid as quoted which could bring the project within realm of the budgeted amount. Sealcoat and Crack repair projects in the future will, be bid separately in order to receive more competitive bids, by opening projects to the direct field of service offered by individual contractors. Attachments • Resolution • City Engineer memorandum • Bid Tab I: / RFA/Public Works/2014/930 2014 Seal Coat & Crack repair Approving Plans and Specs City of New Hope Resolution No, 14- 105 Resolution awarding a contract to Allied BIactop Company for the 2014 crack repair and seal coat project for $307,140 (improvement project No. 930) WHEREAS, the Council approved plans and specifications and ordered bids for implementation of the 2014 crack repair and seal coat improvement project, and, WHEREAS, this activity is an integral component of the city's pavement maintenance program; and, WHEREAS, the Council does hereby determine to proceed with the 2014 crack repair and seal coat improvement project; and, WHEREAS, the advertisement for bids for construction of the 2014 crack repair and seal coat improvement project was published in Finance & Commerce and the New Hope -Golden Valley Sun Post, the official newspaper of the city, on July 3, 2014and, WHEREAS, the bid for construction of the 2014 crack repair and seal coat improvement project was duly opened at the New Hope City Hall, 4401 Xylon Avenue North, at 10:00 a.m. on July 18, 2014; and, WHEREAS, the city engineer has recommended that Council award the contract to Allied Blacktop Company. NOW, THEREFORE, BE IT RESOLVED by the City Council of the city of New Hope, Hennepin County, Minnesota: That the contract for construction of the 2014 crack repair and seal coat improvement project is awarded to Allied Blacktop Company; and, 2. That the mayor and city manager are authorized and directed to sign the same. Adopted by the City Council of the city of New Hope, Hennepin County, Minnesota, this 28th day of July 2014. Mayor Attest: City Clerk I: / RFA/Public Works/2014/930 2014 Seal Coat & Crack repair Approving Plans and Specs 5tantec July 21, 2014 Stantec Consulting Services Inc. 2335 Highway 36 West St. Paul MN 551 13 Tel: (651) 636-4600 Fax: (651) 636-1311 Honorable Mayor and City Council City of New Hope 4401 Xyion Avenue North New Hope, MN 55428 Re: 2014 Crack Repair & Seal Coat City Project No. 930 Stantec Project No. 193802836 Bid Results Dear Honorable Mayor and City Council: Bids were opened for the Project stated above on July 18, 2014. Transmitted herewith is a copy of the Bid Tabulation for your information and file. Copies will also be distributed to each Bidder once the Project has been awarded. One bid was received. The following summarizes the results of the Bid received: Contractor Tota! Base Bid Total Alternate 1 Low Allied Blacktop Company $267,625.00 $39,515.00 The low Bidder on the Project was Allied Blacktop Company with a Total Base Bid Amount of $267,905.00. This compares to the Engineer's Opinion of Probable Costs of $180,000. This Bid has been reviewed and found to be in order. If the City Council wishes to award the Project to the low Bidder, then Allied Blacktop Company should be awarded the Project on the Total Base Bid Amount of $267,625.00. If the City Council wishes to award the Project to the low Bidder, Allied Blacktop Company, on the Total Base Bid Amount plus Alternate No. 1, then the Adjusted Total Bid Amount would be $307,140. Should you have any questions, please fee! free to contact me of (651) 604-4808. Sincerely, STANTEC CONSULTING SERVICES INC. Christopher W. Long, PE Enclosure (10 Stantec Project Name: 2014 Crack.Repair & Seal Coat IAs-ebycww bwffi& is an exact 19 86 -*M BT -1 A*M7&AUMO)FA srec&md. EDA Project ND.: 930 Project No.: 193802836 Bid Opening: Frlday, July 18 2014, at 10 A.M., CDT Owner: City of New HoM Minnesota aris&0-W. LOW L ense MO. 471016 Bidder No.1 BID TABULATION Ailed Blacktop Company Item Num Item Units Qty Unit Prke Total BASE BID; 1 MOBILIZATION LS 1 $5,000.00 $5,000.00 2 TRAFFIC CONTROL LS 1 $30,000.00 $30,000.00 3 CRACK SEAL (CLEAN AND SEAL) LBS 61000 $2.40 $146,400.00 .1 BITUMINOUS MATERIAL FOR SEAL COAT, CRS -2 GAL 10400 $3.50 $36,400.00 5 SEAL COAT AGGREGATE, FA -2 (MOD), TRAP ROCK SY 40400 $0.60 $24,240.00 6 BITUMINOUS MATERIAL FOR FOG SEAL. SY 40850 $0.40 $16,340.00 7 BITUMINOUS MATERIAL FOR FOG SEAL - CUL DE SAC OR PAF SY 6450 $0.50 $3,225.00 6 4" BROKEN LINE, YELLOW PAINT LF 150 $5.00 $750.00 9 4" DOUBLE SOLID LINE, YELLOW PAINT LF 700 $3.00 $2,100.00 10 12" SOLID LINE, YELLOW PAINT LF 50 $10.00 $500.00 it 24" SOLID LINE, WHITE PAINT LF 40 $20.00 $800.00 12 PAVEMENT MESSAGE, LEFT ARROW EA 4 $150.00 $600.00 13 PAVEMENT MESSAGE, THRU ARROW EA 2 $10.00 $20.00 14 PAVEMENT MESSAGE, RIGHT-THRU ARROW EA 2 $175.00 $350.00 15 CROSSWALK MARKING, 3' x 6 BLOCKS, WHITE PAINT SF 90 $10.00 $900.00 TOTAL BASE BID $267,625.00 ALTERNATE NO. 1: 62ND AVENUE N 16 BITUMINOUS MATERIAL FOR FOG SEAL SY 32900 $0.85 $27,965.00 17 4" BROKEN LINE, WHITE PAINT LF 1D0 $5.00 $500.00 18 4" SOLID LINE, WHITE PAINT LF 4300 $0.50 $2,150.00 19 4" BROKEN LINE, YELLOW PAINT LF 1200 $1.00 $1,200.00 20 4- DOUBLE SOLID LINE, YELLOW PAINT LF 1600 $1.00 $1,600.00 21 24" SOLID LINE, WHITE PAINT LF 250 $10.00 $2,500.00 22 CROSSWALK MARKING, 3'x6' BLOCKS, WHITE PAINT SF 1,200 $3.00 $3,600.00 TOTAL ALTERNATE NO. 2 $39,515.00 ContracbDr Name and Address: Allied Bladdop Company 10503 89th Avenue North Maple Grove, MN 55369 Phone: 763-425-0575 Fax 763-425-1046 Signed By; Peter M. Capistrant Title: President Bid Security: B;d Bond Addenda Acknowledged: 1 19 86 -*M BT -1 C�S� o n�iL July 29, 2014 Mr. Peter Capistrant Allied Blacktop Company 10503 89th Avenue North Maple Grove, MN 55369 Stantec Consulting Services Inc. 2335 Highway 36 West 5t. Paul MN 55113 Tel: (651) 636-4600 Fax: (651) 636-1311 Re: City of New Hope, Minnesota 2014 Crack Repair & Seal Coat City Project No. 930 Project No_ 193802836 Notice of Award/Contract Documents Dear Mr. Capistrant: You are notified that your Bid dated July 18, 2014 for the above -referenced Project has been considered. You are the successful Bidder and are awarded a Contract for the amount of $307,140.00 for the Total Base Bid plus Alternate No_ 1. Enclosed are four Contract Documents between you and the City of New Hope covering the above -referenced Project. Please complete Specification Document 00 52 10 Agreement Form, Document 00 61 13.13 Performance Bond, and Document 00 61 13.16 Payment Bond. The insurance and indemnity requirements shall be provided. After the bonding company has completed the Contract Documents, forward them to the attorney listed below who will review them for the City of New Hope: Mr. Steven Sondrall Jensen & Sondrall PA 8525 Edinbrook Crossing, Ste. 201 Brooklyn Park, MN 55443-1968 After the necessary officials have signed the Contracts, the City will distribute the Contracts as follows: 2 copies Allied Blacktop Company (1 - your file, 1 - your bond company) 1 copy City of New Hope, Attention: Valerie Leone 1 copy Stantec, Attention: Chris Long Upon receipt of a signed Contract and a filed Certificate of Insurance, approved by the City of New Hope's attorney, a pre -construction conference will be scheduled with you and the City of New Hope to review the Project. Sincerely, Christopher W. Long, P.E. Enclosures: Four Contract Documents cc: Valerie Leone, City of New Hope Steven Sondrall, City Attorney Design with community In mind GORDON L. JENSEN' MELANIE P. PERSELLIN" STEvEN A.SONDRALL STAGY A. Woonsr 'Real Property Law Specialist Certified By The Minnesota State Bar Association 'Licensed in IDic"s/Colorado 3Qualified Neutral Mediator under Rule 114 JENSEN SONDRALL & PERSELLIN, P.A. Attorneys At .Law 8525 EwNBROQK CROSSING, STE. 201 BROOKLYN PARK, MINNESOTA 55443-1968 TELEPHONE (763) 424-8811$ TELEFAX (763) 493-5193 o -mail law@jspattorneys.com August 13, 2014 Valerie Leone City Clerk City of New Hope 4401 Xylon Avenue North New Hope, MN 55428 Re: 2014 Crack Repair and Seal Coat City Project No.: 930 Our File No.: 99.10030 Dear Val: Writer's Direct Dial No.: (763) 201-0265 e-mail saw gispattorneys.com personal delivery Enclosed please find four copies of the contract and bonds for the above -referenced project, as well as the Certificate of Liability Insurance received from Allied Blacktop Company. All are in order from a legal standpoint. Please call me if you have any questions. Ve truly yours, f l O / tacy A. W ods, Assistant City Attorney, City of New Hope Enclosures cc: Jeff Sargent, Community Development Director Bob Paschke, Public Works Director Chris Long, City Engineer Business Filing Details Home (0 Search (/Business/Search) Search » Business Filings Business Record Details)) Filings (/Business/Filings) Page 1 of 2 « Back to Search Results File Amendment or Renewal (Business/Amendments?filingGuid=975f24da-bOd4-e011-x886-00lec94ffe7f) Order Copies Order a Certificate (/Business/Certificates?businessMasterGuid=g75f24da-bOd4-e011-a886- 001 ec94ffe7f&route=filing&pmductld=023dd338-fad3-e011-a888- 001 ec94ffe7f&originalFilingGuid=2cged2es-04d5-eO11-a886-001 ec94ffe7f) Minnesota Business Name Allied Blacktop Company Business Type Business Corporation (Domestic) File Number V-138 Filing Date 0310911959 Renewal Due Date: 1213112016 Number of Shares 2,000 Chief Executive Officer Peter M Caplstrant 10503 89th Ave N Maple Grove MN 65369 USA MN Statute 302A Home Jurisdiction Minnesota Status Active I In Good Standing Registered Office Address 10503 89th Ave N Maple Grove MN 56369 USA Registered Agent(s) (Optional) None provided Principal Executive Office Address 10503 89th Ave N Maple Grove MN 65369 USA Filing History 03109/1959 Original Filing - Business Corporation (Domestic) 031091`1959 Business Corporation (Domestic) Business flame _ _ ..... _....... .. __._ - ......_ .. 03/1111971 Registered Office andlor Agent - Business Corporation (Domestic) 08/0211979 Business Corporation (Domestic) Active Status Report 09/16/1988 Registered Office andlor Agent - Business Corporation (Domestic) _ ..............0511312011 Amendment - Business Corporation (Domestic) http:llmblsportal. sos. state.mn.us/Businessf SearchDetails?filingGuid=975 f24da-bOd4-e011-... 8/13/2014 August 18, 2014 Mr. Peter Capistrant Allied Blacktop Company 10503 8911, Avenue North Maple Grove, MN 55369 SUBJECT: Crack Repair/Seal Coat - Project 930 At its meeting of July 28, 2014, the New Hope City Council approved the contract with your company for project no. 930 for $307,140. Enclosed please find two contract documents. Please submit one to your bonding company. Also enclosed is a Withholding Affidavit for Contractors/IC-134 form (we cannot make final payment to contractors until this is approved by the Minnesota Department of Revenue and submitted to our office per Minnesota Statute 290.97). Please contact Chris Long at Stantec at 651-604-4938 if you have any questions regarding the project. Sincerely, Valerie Leone City Clerk, CMC Enclosures — Contract, IC -134 cc: Bob Paschke, director of public works Chris Long, city engineer Shawn Markham, contract manager CITY OF NEW HOPE 4401 Xylon Avenue North + New Hope, Minnesota 55428-4898 • www. ci.new-hope.r n.us City Hall: 763-531-5100 • Police (non -emergency): 763-531-5170 • Public Works: 763-592-6777 • TDD: 763-531-5109 City Hall Fax: 763-531-5136 • Police Fax: 763-531-5174 + Public Works Fax: 763-592-6776 41 up Request for Action Originating Department Approved for Agenda Agenda Section Consent Public Works October 27, 2014 Item No. By: Bob Paschke, Director By: Kirk McDonald, City Manager 6.9 Resolution authorizing final payment of $22,663.84 to Allied Blacktop Company for the 2014 crack repair and seal coat project (improvement project No. 930) Requested Action Staff is recommending that Council pass a resolution authorizing final payment to Allied Blacktop Company in the amount of $22,663.84 for the 2014 seal coat & crack repair project. Policy/Past Practice To maximize the life of the pavement on our city streets, New Hope has traditionally practiced seal coating and crack repair. This activity is critical to the city's current pavement management strategy, when delayed, maintenance costs increase and premature expenditures for pavement overlays or reconstruction may result. Background The Pavement Management Strategy identified and prioritized street maintenance activities for 2014's seal coat and crack repair project, which included selected streets that were previously reconstructed and milled/overlaid roads. The City of Brooklyn Park has also participated in cost sharing on the city border roadway of 62nd Avenue for Brooklyn Park's sealcoat/crack fill project in 2014. The project plans and specifications were authorized on June 23, 2014 by council, bids were advertised June 27th, 2014, opened on July 18, 2014 and approved July 28, 2014. The 2012 New Hope seal coat project had a large percentage of release of seal coat chips from the oil that was applied. In the 2013 sealcoat project a polymer was added to the oil to achieve higher adhesion, success was greater on preventing release but still occurring. The 2014 project had eliminated the polymer and added and emulsion asphalt fog as an additional layer of over the top of sealcoat rock after sweeping. This asphaltic layer encapsulated the entire rock lockind the product in on all surfaces; rock release has virtually been eliminated Motion by ��& Second by Auv?� To: Old r 7/ I:rfa\Pubwoxics\2014\930 Authorizing final payment 2014 Seal Coat Request for Action, page 2 October 27, 2014 with this process. The streets now have a higher degree of seal to prevent moisture infiltration and the appearance of a newly paved road. The primary issue to the fogging process was that vehicles were required to remain off the streets for a longer period of time. All areas receiving a seal coat application were crack repaired prior. The crack repairing process was also modified. Not only road surface cracks will be addressed, but also both longitudinal and transverse horizontal joints will be sealed to direct moisture to the curb, allowing fluids to drain off without falling through unsealed joints and cracks. The Original Contract Amount as indicated on the Contractor's Request for Payment is $307,140.00. The contract included no change orders. The Final Construction Amount is $232,411.35, which is less than the Original Contract Amount. This project had a $74,728.65 under run primarily due to less materials required for the crack seal portion of the project. Funding Funding for the seal coat/crack repair project is from the city's street infrastructure fund. Attachments • Resolution City engineer memorandum Final pay request City of New Hope I:rfa\Pubworks\2014\930 Authorizing final payment 2014 Seal Coat Resolution No. 14-141 Resolution authorizing final payment of $22,663.84 to Allied Blacktop Company for the 2014 crack repair and seal coat project (improvement project No. 930) WHEREAS, the Council approved plans and specifications and ordered bids for implementation of the 2014 crack repair and seal coat improvement project; and, WHEREAS, this activity is an integral component of the city's pavement maintenance program, and, WHEREAS, plans, specifications, and contract terms for have been followed and work completed; and, WHEREAS, the city engineering firm, Stantec, has inspected and accepted the work described in the plans and specifications; and, WHEREAS, engineering and staff find the work and product satisfactory and acceptable; and, WHEREAS, staff recommends that Council authorize final payment of $22,663.84 to Allied Blacktop Company. NOW, THEREFORE, BE IT RESOLVED by the City Council of the city of New Hope, Hennepin County, Minnesota: 1. That the City Council authorizes final payment of $22,663.84 to Allied Blacktop Company for the 2014 crack repair and seal coat project 930. 2. That the city manager is hereby directed to authorize final payment to Allied Blacktop Company for the 2014 crack repair and seal coat project (improvement project 930). 3. That the funding source will be the street infrastructure fund. Adopted by the City Council of the city of New Hope, Hennepin County, Minnesota, this 27th day of October, 2014. Mayor Attest: . City Clerk I;rfa\Pubworks\2014\930 Authorizing final payment 2014 Seal Coat Stantec Consulting Services Inc. 2335 Highway 36 West St. Paul MN 55113 Tei: (651) 636-4600 Fax: (651) 636-1311 October 21, 2014 File: 193802836 Attention: Bob Paschke Director of Public Works City of New Hope 5500 International Parkway New Hope, MN 55428 Reference: 2014 Crack Repair and Seal Coat -- Final Payment City Project No.: 930 Dear Bob, Enclosed find the final pay request and the IC -134 forms for the above referenced project. The contractor, Allied Blacktop Company, has completed this work in accordance with the contract plans and specifications; therefore, it is recommended that final payment of $22,663.84 is made and the City of New Hope accepts the project. The Original Contract Amount as indicated on the Contractor's Request for Payment is $307,140.00. The contract included no change orders. The Final Construction Amount is $232,411.35, which is less than the Original Contract Amount. This project had a $74,728.65 under run primarily due to less materials required for the crack seal portion of the project. If you have any questions or require further information please call me at (651)604-4808 Regards, STANTEC CONSULTING SERVICES INC. Christopher W. Long, P. E. c. John Blasiak, Bernie Weber, Shawn Markham New Hope; Adam Martinson, Ann Dienhart — Stantec. hUps:llwww.umdorstate.mn.us/tp/eservices/ /Retrieve/0/b-/PWwkg5... MINNESOTA- REVENUE Contractor Affidavit Submitted Thank you, your Contractor Affidavit has been approved. Confirmation Summary Confirmation Number: 0-121-687-680 Submitted Date and Time: 9 -Oct -2014 10:39:20 AM Legal Name: ALLIED BLACKTOP COMPANY Federal Employer ID: 41-0827871 User Who Submitted: N10503 Type of Request Submitted: Contractor Affidavit Affidavit Summary Affidavit Number: Account Number: Project Owner: Project Number: Project Begin Date: Project End Date: Project Location: Project Amount: 1475510272 8606387 CITY OF NEW HOPE CP 930 14 -Aug -2014 07 -Sep -2014 VARIOUS ROADS AND STREETS $232,411.35 Subcontractor Summary Name ID Affidavit Number TRAFFIC MARKING SERVICE INC 8462102 2086551552 Important Messages A copy of this page must be provided to the contractor or government agency that hired you. Contact Us If you need further assistance, contact our Withholding Tax Division at (Metro Area) 651-282-9999, (Greater Minnesota) 800-657-3594, (TTY Users) Call 711 for Minnesota Relay, or (email) Withholding.tax@state.mn.us. Business hours are 8:00 am. - 4:30 p.m. Monday - Friday. How to View and Print this Request You can see copies of your requests by going to the History Tab. Please print this confirmation page for your records using the print or save functionality built into your browser. 1 of 1 10/9/2014 10:39 AM rage 1 of i MINNESOTA- REVENUE Contractor Affidavit Submitted Thank you, your Contractor Affidavit has been approved. Confirmation Summary Confirmation Number: 0-465-129-088 Submitted Date and Time: 8 -Oct -2014 2:39:35 PM Legal Name: TRAFFIC MARKING SERV INC Federal Employer ID: 41-0744761 User Who Submitted: Trai$c2011 Type of Request Submitted: Contractor Affidavit Affidavit Summary Affidavit Number: Account Number: Project Owner: Project Number: Project Begin Date: Project End Date: Project Location: Project Amount: Subcontractors: 2086551552 8462102 CITY OF NEW HOPE 2014 SEALCOAT 16 -Sep -2014 16 -Sep -2014 CITY OF NEW HOPE,MN $7,077.80 No Subcontractors Important Messages A copy of this page must be provided to the contractor or government agency that hired you. Contact Us If you need finther assistance, contact our Withholding Tax Division at (Metro Area) 651-282-9999, (Greater Minnesota) 800-657-3594, (TTY Users) Call 711 for Minnesota Relay, or (email) Withholding,tax@state.mn.us. Business hours are 8:00 a.m. - 4:30 p.m. Monday - Friday. Hove to View and Print this Request You can see copies of your requests by going to the History Tab. Pleaserift this confirmation page for your records using the print or save functionality built into your browser. https:llwww.mndor.state.mn.usltpleservicesl lRetrieve101b-IXkI X7Or8rtAXNGLySiKbfw... 10/8/2014 ® Stantec Dwner: City of New Hope, 4401 Xylon Ave. N., New Hope, MN 55428 Date: October 2, 2014 For Period: 9/13/2014 to 10/2/2014 Request No: 2/FINAL contractor: Allied Blacktop Co., 10503 89th Ave. N., Maple Grove, MN 55369 CONTRACTOR'S REQUEST FOR PAYMENT 2014 CRACK REPAIR AND SEAL COAT STANTEC PROJECT NO. 193802836 CITY PROJECT NO. 930 SUMMARY 1 Original Contract Amount 2 Change Order - Addition 3 Change Order- Deduction 4 Revised Contract Amount 5 Value Completed to Date 6 Material on Hand 7 Amount Earned 8 Less Retainage 0% 9 Subtotal 10 Less Amount Paid Previously 11 Liquidated damages - 12 AMOUNT DUE THIS REQUEST FOR PAYMENT NO Recommended for Approval by: STANTEC Approved b ontract_or: ALLlE LACKT Y. Specified Contract Completion Date: 19380283GREWF I NAL.xis m $ 307,140.00 $ 0.00 $ 0.00 $ 307,140.00 $ 232,411.35 $ 0.00 $ 232,411.35 $ 0.00 $ 232, 411.35 $ 209,747.51 $ 0.00 2/FINAL $ 22,663.84 Approved by Owner: CI F NEW HOP Date: TOTAL BASE BID: $198,196.80 TOTAL ALTERNATE NO. 1: 62ND AVENUE N $34,214.55 TOTAL WORK COMPLETED TO DATE $232,411.35 9 93802836REQ2 R NALAsm Contract Unit Current Quantity Amount No. Item Unit Quantity Price Quantity to Date to Date BASE BID: 1 MOBILIZATION LS 1 5000.00 $5,000.00 2 TRAFFIC CONTROL LS 1 30000.00 $30,000.00 3 CRACK SEAL (CLEAN AND SEAL) LBS 61000 2.40 32670 $78,408.00 4 BITUMINOUS MATERIAL FOR SEAL COAT, CRS -2 GAL 10400 3.50 11850 $41,475.00 5 SEAL COAT AGGREGATE, FA -2 (MOD), TRAP ROCK SY 40400 0.60 33948 $20,368.80 6 BITUMINOUS MATERIAL FOR FOG SEAL SY 40850 0.40 40850 $16,340.00 7 BITUMINOUS MATERIAL FOR FOG SEAL - CUL DE SAC OR PARKING LOT SY 6450 0.50 6450 $3,225.00 8 N' BROKEN LINE, YELLOW PAINT LF 150 5.00 $0.00 9 N' DOUBLE SOLID LINE, YELLOW PAINT LF 700 3.00 710 710 $2,130.00 10 12" SOLID LINE, YELLOW PAINT LF 50 10.00 $0.00 11 24" SOLID LINE, WHITE PAINT LF 40 20.00 $0.00 12 PAVEMENT MESSAGE, LEFT ARROW EA 4 150.00 4 4 $600.00 13 PAVEMENT MESSAGE, THRU ARROW EA 2 150.00 2 2 $300.00 14 PAVEMENT MESSAGE, RIGHT-THRU ARROW EA 2 175.00 2 2 $350.00 15 CROSSWALK MARKING, 3'x 6' BLOCKS, WHITE PAINT SF 90 10.00 $0.00 TOTAL BASE BID: $198,196.80 ALTERNATE NO. 1: 62ND AVENUE N 16 BITUMINOUS MATERIAL FOR FOG SEAL SY 32900 0.85 30553 $25,970.05 17 N' BROKEN LINE, WHITE PAINT LF 100 5.00 30 30 $150.00 18 4"SOLID UNE, WHITE PAINT LF 4300 0.50 3661 3661 $1,830.50 19 4" BROKEN LINE, YELLOW PAINT LF 1200 1.00 979 979 $979.00 20 4" DOUBLE SOLID LINE, YELLOW PAINT LF 1600 1.00 1198 1198 $1,198.00 21 2N'SOLID LINE, WHITE PAINT LF 250 10.00 14.5 14.5 $145.00 22 CROSSWALK MARKING, 3'x6' BLOCKS, WHITE PAINT SF 1200 3.00 1314 1314 $3,942.00 TOTAL ALTERNATE NO. 1: 62ND AVENUE N $34,214.55 TOTAL BASE BID: $198,196.80 TOTAL ALTERNATE NO. 1: 62ND AVENUE N $34,214.55 TOTAL WORK COMPLETED TO DATE $232,411.35 9 93802836REQ2 R NALAsm PROJECT PAYMENT STATUS OWNER CITY OF NEW HOPE CITY PROJECT NO. 930 STANTEC PROJECT NO. 193802836 CONTRACTOR ALLIED BLACKTOP CO. CHANGE ORDERS No. Date Total Change Orders Description Amount PAYMENT SUMMARY No. From To Payment Retainage Completed 1 09/01/2014 09/12/2014 110/02/2014 209,747.51 11,039.34 4-220,786-85 2/FINAL 09/13/2014 Total Amount Earned 22,663.84 Revised Contract 232,411.35 Material on Hand Total Payment to Date $22,663.84 Original Contract $307,140.00 Retainage Pay No. 2/FINAL Change Orders Total Amount Earned $22,663.84 Revised Contract $307,140.00 193802836RE02FINALxism B $ - ALTERNATE #I - 62ND AVE N VVLi �s CITY OF NEW HOPE PUBLIC WORKS ACEs 2014 CRACK REPAIR AND gra = © all SEAL COAT i a a C1TY PROJECT NUMB 930 ° 2014 ; PROIECf LOCATION CIfY HALL -,�,; "� „r BID SITE SHEErl r ... Gam TME SHsr EOAe LcCgnm PLAN in mm LcMrm PLM r MN inurvi PLAN 4 rad i � ruwq 4-sHFETSToru- 0 e = Z OS i Z <z Ld r Q u r $ w KATHIHEMKEN MAYOR z v JOHN ELDER COUNCILMEMBER r !� [ ANDY HOFFE COUNCILMEMBER - ERIC LAMMLE COUNCILMEMBER DANIEL STAUNER COUNCILMEMBER KIRK MCDONALD CITY MANAGER - BOB PASCHKE PUBLIC WORKS DIRECTOR w ae _ STEVE SONDRALL CITY ATTORNEY i NN VICINITY MAP CBNE AL NOTE'1 1. rNLEr PROTECMN OEVM WILL BE ENSTAllID 5V aTY. PRVIIDEA m=MUM OF 4B HRS NOTEICATIONT4T17RTO SEAL CD14TDIG OPaiAFIONS 2. Sfwfswnmc - INFFL VL SNEEP: 1-3 DAYS AFTERSFA.CUAT -7.M<SWM: MIN. LO DAYS AFFIR INIiULSVIIEEPNO PNMM TOG SEAL 3. FOG SEAL OWLErION We Stlp0MRR17 2nC ALTERNATE #1 - 62ND AVE N (FRONTAGE RD TO LOUISIANA AVE) cm or ePoanrx vxa M 50TH AVE N _- I] I I E I I I I I I I II ALTERNATE #I - FDG SAL �W I! 1 I I 7 I I I I F-�--� Iz IWy 14 I �, , I I ST. THERESE i 1. OWK REPAIR AND SFAL CDATTNGNR.LBE DONE IM ixF- I---� E-- OTHERS BY AUGUST 1% 2014, Ir I N I I I Z WG SEAL ODMMErION DATE: Eil MR1120SA. '--i F -- I 4-1 I { n -f-- i -- -- F-� - -41 - I V , 1 I I I I I I I I I -AVE N DOROTHY r --t--1 MARY F--+--�xi --� PARK i Nf__+L-- I� Ir --t--11 i i TyyL- --1 `l f-4--1 � T6a1l_AVE -� r -T -r -r -T- 1 I I I I I I I 1-4 �T_�1TlT_T_�-_i �� 1 J I I I I 1 I I I 11 I I I I _ 60TH AVE N r-T-Y-TTTTTT-i r-T-T-Y--r- �J / T 1 / ! T.� II I 1I1 I III I I II I I I II II I IL �� �,_1 i z�� r I I �- �FF -- 1 59 !Z3 AVE N! LAKE ---_T SMAVE N T-T-T--T-T4 PARK �mTo �® AVER _ _.J= y LEGEND ALTERNATE #I - FDG SAL �W BEEN I E ---_. I 1! L J I I Iz IWy 14 I ALTBtMTE NOTES: ST. THERESE i 1. OWK REPAIR AND SFAL CDATTNGNR.LBE DONE IM NURSING Ilz OTHERS BY AUGUST 1% 2014, Ir I N I I I Z WG SEAL ODMMErION DATE: Eil MR1120SA. �mTo �® AVER _ _.J= y as Z z=g 19� Ld d 0. �H Cs U6 IR C0.01 BEEN I E ---_. I 1! L J I I Iz IWy 14 I 1 ST. THERESE i li NURSING Ilz ------- HOME i Ir I N I I I 1 { n I J V as Z z=g 19� Ld d 0. �H Cs U6 IR C0.01 I I I C -_— L ---__.i --------- I 1 I _�_____J L__1___-__L_____l__� 45tH AVEN -.r-. I. i , " I 1 .. I I LEGEND CRACK REPAIR CRACK REPAIR, SEAL COAT & FOG SEAL CRACK REPAIR & FOG SEAL _rte 3. INLET PROTECTION DEVICES WELL eERUAUE011YC1TY. PROYMEA MMMUM OF 48 HRSN6fF1OLTION PRWRTO SEAL COATING OPBNTIONS 2. STFAET 9NEEPING - P TIAL SNL:EP: L-3 LAYS AF1ER93LCW •2NDSlIE®I MIN. IO DAYS AFT9EAlIIE1-9NEEP AND PRIOR TO FOG SEAL 3. FOG SEAL. CDMPLLT! )N DATE: le NI ----1 —�—aa 01 ¢ o II i ---- Al 51 } 11 4581 1 1 r-- T I S I I I I I I I 1 I I I I I I I F WA I YI I I _1 I 43RD AMEN L w1 I I =1 1 I I I I I I I 1 F --J"---r-- I l I I E ------f` I I I I �_- I 42ND AVE N 'r-T�� u Js ;Z Za CO."`! NORMIMN OR 31ST AVE N r �t VaSWNSIN 1 1 11 z I 1 p...._ • I 1 rTTTT � rT-T�-� .r..�_.�.r.._I.._.I I _ IAVBN \ I I I I I I I I I I I I I 1 I I I I I I I I I I I 1 I I I I I I I 1 I I V I I I I I I I I I I I I I I I I I I I DRRN I I d1/F M I I {fl I Sz . Ln2 cn L- I I I I F --t-- '1 i r� � �-TlT1r-t-t L__1__LL_______________J l-1_1_1_1_1 _.CrTYOF NEW HOPE_.._.._..._..._..._...__._..._..._......_.,._.._.._.._.._..._..._.._..._..._..._..._..._.. 271}1 AVE N CITY OF GOLDEN VALLEY LEGEND CRACK REPAIR CRACK REPAIR, SEAL COAT, & FOG CRACK REPAIR & FOG SEAL GENERAL NOrgx 1, RVL.Er PROTECMN bEnrES wIL BE INSTALLED IY CNy. PROVIDE A P@l1NL94 OF 48 HRS NOTEMATION PRIOR TO SEAL WATIM OPERMIME 2. STREEr SWEEPING •LU ALSVYEEP: 1.3 DAYS AFnMSCALCOAT - 2ND SWELL. 1M. 16 DAYS AFTER RATIALSAWA19D PRIORTO FOGSEFL 3. FOG SEAL ODMPIErMW DATE: NLFi LPl@ 17,,201./. -LTA- -I•i�- I I I I i I I I I I I I I a i i i I I i T I I ]N I I JI ® ha_1 s y l l l l l l l l I �— 4 �--4? I I I I i I I 1__�-_- __' __A__14 T I ITFGGE. pow f I (MED�.._. - _..._ �. _..._... _... _... _..-.., _... _... _... _..._.. -... IQNE LAKE RD) L-... AVE 1 '-T-T-T-TTT-T-I I I I i I I I I I I I I a i i i I I i I I I I I I 1 I I ! I I I I I I I I I I V ® ha_1 s y l l l l l l l l I �— 4 �--4? I I I I i I I 1__�-_- __' __A__14 T I ITFGGE. pow 3m N AVE N 1 1 1 1 1 1 1 1 1 ' Yl EV E5lLAl I I 1 I r -d I r.—TJ 1 __ T-------� --_ I I I i _�-------- 0 00o al�- r ® ha_1 s 4 ii f I ZI I I I I ' ' ' I I I -_-CO-OFLNEWHan--- -----J CITY OF GOLDEN VALLEY 27tH AVE N u S V'1 ti U to �s Z s � Z Fll a�z 0 uU� Z 'r 2 .03 Project Manual For 2014 Crack Repair and Seal Coat Prepared for: City of New Hope, Minnesota City Project No. 930 (�' S -6L, � �I r �- " �- rZlt C June 2014 CONTRACT Stantec Project No. 193802836 DOCUMENTS DOCUMENT 00 91 13 ADDENDUM 1 2014 CRACK REPAIR AND SEAL COAT CITY PROJECT NO. 930 PROJECT NO. 193802836 NEW HOPE, MINNESOTA July 16, 2014 Number of Pages: 8 (includes this sheet) To: All Planholders of Record From: Stantec 2335 Highway 36 West St. Paul, Minnesota 55113 (651) 636-4600 - General Office (651) 651-4808 - Chris Long, Project Manager The following changes, additions, and deletions are hereby made a part of the Bidding Documents. Bidder shall acknowledge receipt of this Addendum on the Bid Form. Failure to do so may result in rejection of the Bid. Please acknowledge receipt of this Addendum by signing and faxing this page back to Stantec at Fax No. (651) 636-131 1 as soon as you receive it. ADDENDUM 1 0 2014 Stantec 193802836 0091 13 - 1 SECTION 00 41 10 -BID FORM . Replace the Bid Form in its entirety with the revised Bid Form attached. Revisions completed include the following: Bid Item # 11 - 24" Solid Line, White Paint: Revised quantity. * Added Bid Item #15 to Base Bid -Crosswalk Marking, 3' x 6' Blocks, White Paint SECTION 3212 80 1. Remove Article 3.04, Heating Joints in its entirety. LIST OF ATTACHMENTS 1. Revised Bid Form, Section 00 41 1 OR. END OF DOCUMENT ADDENDUM 1 02014 Stantec , 193802836 0091 13-2 (3 BODER: DOCUMENT 00 41 10 REVISED BID FORM REVISED BY ADDENDUM NO. 1 2014 CRACK REPAIR AND SEAL COAT CITY PROJECT NO. 930 PROJECT NO. 193802836 NEW HOPE, MINNESOTA 2014 THIS BID IS SUBMITTED TO: City of New Hope City Hall 4401 Xylon Avenue North New Hope, MN 55428 1.01 The undersigned Bidder proposes and agrees, if this Sid is accepted, to enter into an Agreement with Owner in the form included in the Bidding Documents to perform all Work as specified or indicated in the Bidding Documents for the prices and within the times indicated in this Bid and in accordance with the other terms and conditions of the Bidding Documents. 2.01 Bidder accepts all of the terms and conditions of the Instructions to Bidders, including without limitation those dealing with the disposition of Bid Security. The Bid will remain subject to acceptance for 60 days after the Bid Opening, or for such longer period of time that Bidder may agree to in writing upon request of Owner, 3.01 In submitting this Bid, Bidder represents that: A. Bidder has examined and carefully studied the Bidding Documents, the other related data identified in the Bidding Documents, and the following Addenda, receipt of all which is hereby acknowledged: Addendum Number Addendum Date B. Bidder has visited the Site and become familiarwith and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. C. Bidder is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the Work. D. Bidder has carefully studied all: (T) reports of explorations and tests of subsurface conditions at, or contiguous to, the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at, or contiguous to, the Site (except Underground Facilities) which have been identified in SC -4.02, and (2) reports and drawings of Hazardous Environmental Conditions that have been identified in SC -4,06. E. Bidder has obtained and carefully studied (or accepts the consequences for not doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at, or contiguous to, the Site which may affect cost, progress, or performance of the work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including applying the specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents to be employed by Bidder, and safety precautions and proqrams incident thereto. F. Bidder does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the determination of this Bid for performance of the Work at the price(s) Bid and within the times and in accordance with the other terms and conditions of the Bidding Documents. G. Bidder is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Bidding Documents. 0 2014 Stantec 1193802836 REVISED BY ADDENDUM NO. 1 00 41 10-1(R) REVISED BID FORM H. Bidder has correlated the information known to Bidder, information and observations obtained from visits to the Site, reports and drawings identified in the Bidding Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Bidding Documents. Bidder has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder has discovered in the Bidding Documents, and the written resolution thereof by Engineer is acceptable to Bidder. J. The Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for the performance of the Work for which this Bid is submitted. K. Bidder will submit written evidence of its authority to do business in the state where the Project is located not later than the date of its execution of the Agreement. 4.01 Bidder further represents that: A. The prices in Phis Bid have been arrived at independently, without consultation, communication, or agreement as to any matters relating to such prices with any other Bidder or with any competitor for the purpose of restricting competition. B. The prices in this Bid have not or wilt not be knowingly disclosed to any other Bidder or competitor prior to opening of the Bids. C. No attempt has been made or will be made by the Bidder to induce any other person or firm to submit or not to submit a Bid for the purpose of restricting competition. 4.02 Bidder understands that the law may require the Owner, or Engineer at the Owner's direction, to undertake an investigation and submit an evaluation concerning Bidder's responsiveness, responsibility, and qualifications before awarding a contract. Bidder hereby waives any and all claims, of whatever nature, against Owner, Engineer and their employees and agents, which arise out of or relate to such investigation and evaluation, and statements made as a result thereof, except for statements that can be shown by clear and convincing evidence to be intentionally false and made with actual malice. Nothing in this paragraph is intended to restrict Bidder's rights to challenge a contract pursuant to law. 5.01 Bidder will complete the Work in accordance with the Contract Documents for the following price(s): All specific cash allowances are included in the price(s) set forth below and have been computed in accordance with Paragraph 11.02 of the General Conditions. Unit Prices have been computed in accordance with Paragraph 11.03.B of the General Conditions Bidder acknowledges that estimated quantities are not guaranteed, and are solely for the purpose of comparison of Bids, and final payment for all Unit Price Bid items will be based on actual quantities provided, determined as provided in the Contract Documents. No. Item Units Qty Unit Price Total Price BASE BID: 1 MOBILIZATION 2 TRAFFIC CONTROL 3 CRACK SEAL (CLEAN AND SEAL) 4 BITUMINOUS MATERIAL FOR SEAT_ COAT, CRS -2 5 SEAL COAT AGGREGATE, FA -2 (MOD), TRAP ROCK 6 BITUMINOUS MATERIAL FOR FOG SEAL 7 BITUMINOUS MATERIAL FOR FOG SEAL - CUL DE SAC OR PARKING LOT 0 2014 Stantec 1193802836 REVISED BY ADDENDUM NO. 1 00 41 10-2(R) LS 1 LS 1 $ LBS 61,000 $ ..._ GAL 10,400 .— SY 40,400 f S ..— SY 40,850 ._ SY 6,450 $ REVISED BID FORM No. Item Units Qty Unit Price Total Price S 4' BROKEN LINE, YELLOW PAINT LF 150 $ $ SF 1,200 $ $ 9 4" DOUBLE SOLID LINE, YELLOW PAINT LF 700 $ $ 10 17' SOLID LINE, YELLOW PAINT LF 50 $ $ 11 24" SOLID LINE, WHITE PAINT LF 40 $ $ 12 PAVEMENT MESSAGE, LEFT ARROW EA 4 $ $ 13 PAVEMENT MESSAGE, THRU ARROW EA 2 $ $ 14 PAVEMENT MESSAGE, RIGHT-THRU ARROW EA 2 $ $ 15 CROSSWALK MARKING, 3'x 6' BLOCKS, WHITE PAINT SF 90 $ $ TOTAL BASE BID $ ALTERNATE NO. 1: 62ND AVENUE N 16 BITUMINOUS MATERIAL FOR FOG SEAL 17 C BROKEN LINE, WHITE PAINT 18 47SOLID LINE, WHITE PAINT 19 4' BROKEN LINE, YELLOW PAINT 20 4' DOUBLE SOLID LINE, YELLOW PAINT 21 24"SOLID LINE, WHITE PAINT 22 CROSSWALK MARKING, 3'x6' BLOCKS, WHITE PAINT TOTAL ALTERNATE NO. 1 02014Starifec 1 193802836 REVISED BY ADDENDUM NO. 1 00 41 10,31R) SY 32,900 $ $ LF 100 $ $ LF 4,300 $ LF 1,200 $ LF 1,600 LF 250 _. $ SF 1,200 $ $ REVISED BID FORM 6.01 Bidder agrees that the Work will be Substantially Completed and completed and ready for Final Payment in accordance with Paragraph 14.07.13 of the General Conditions on or before the dates or within the number of calendar days indicated in the Agreement. 6.02 Bidder accepts the provisions of the Agreement as to liquidated damages in the event of failure to complete the Work within the times specified above, which shall be stated in the Agreement. 7.01 The following documents are attached to and made a condition of this Bid: A. Required Bid Security in the form of 5 percent. 8.01 The terms used in this Bid with initial capital letters have the meanings stated in the Instructions to Bidders, the General Conditions, and the Supplementary Conditions. If Bidder Is: A Corporation SUBMITTED on Corporation Name: State of Incorporation: Type (General Business, Professional, Service, Limited Liability): By: _ (Signature) Name (typed or printed): Title: Attest (CORPORATE SEAL) (Signature of Corporate Secretary) Business Street Address (No P.O. Box Ws): Phone No.: Email: Fox No.: 0 2014 Stantec 1 193802836 REVISED BY ADDENDUM NO. 1 00 41 10-41R1 REVISED BID FORM An Individual A Partnership Name (typed or printed): By: (Individual's signature) Doing business as: Business Street Address (No P.O. Box #'s): Phone No.: Email: Partnership Name: By: Fax No.: (Signature of general partner) Name (typed or printed): Business Street Address (No P.O. Box #'s): Phone No.: Fax No.: Email: ® 2014 Stantec I i 93802836 REVISED BY ADDENDUM NO. 1 00 41 10-5[R] (SEAL.) EAL) REVISED BID FORM A Joint Venture Joint Venture Name: By: (Signature of joint venture partner) Name (typed or printed): Title: Business address: Phone No.: Fax No.: Joint Venturer Name: By: (Signature) Name (typed or printed): Business Street Address (No P.O. Box #'s): Phone No.: Fax No.: Phone and Fax Number, and Address for receipt of official communications: (Each joint venturer must sign. The manner of signing for each individual, partnership, and corporation that is a party to the joint venture should be in the manner indicated above). END OF DOCUMENT 0 2014 Stantec 1 193802836 REVISED BY ADDENDUM NO. 1 0041 10-6(R) REVISED BID FORM SECTION 00 01 05 PROFESSIONAL CERTIFICATIONS PROFESSIONAL ENGINEER hereby certify that this plan, specification, or report was prepared by me or under my direct supervision and that I am a duly Licensed Professional Engineer under the laws of the State of Minnesota. a4404- W. Christopher W. Long Date: June 27, 2014 License # 47106 END OF SECTION PROFESSIONAL CERTIFICATIONS © 2014 Stantec 193802836 0001 05-1 SECTION 00 01 10 TABLE OF CONTENTS PROCUREMENT AND CONTRACTING REQUIREMENTS GROUP Division 00 - Procurement and Contracting Requirements Introductory Information 0001 05 Certifications Page 0001 10 Table of Contents Procurement Requirements 0011 13 Advertisement for Bids 0021 13 Instructions to Bidders 0041 10 Bid Form Contracting Requirements 00 52 10 Agreement Form 0061 13.13 Performance Bond 0061 13.16 Payment Bond 00 72 05 EJCDC C-700 Std General Conditions of the Construction Contract (2007 Edition) 00 73 05 Supplementary Conditions SPECIFICATIONS GROUP GENERAL REQUIREMENTS SUBGROUP Division 01 - General Requirements 01 1000 Summary 01 2000 Price and Payment Procedures 01 31 00 Project Management and Coordination 01 3300 Submittal Procedures 01 4000 Quality Requirements 01 5000 Temporary Facilities and Controls 01 7000 Execution Requirements SITE AND INFRASTRUCTURE SUBGROUP Division 32 - EXTERIOR IMPROVEMENTS 32 12 36 Seal Coats and Fog Seals 32 12 80 Flexible Paving Joint Construction 32 17 23 Pavement Markings END OF SECTION TABLE OF CONTENTS © 2014 Stantec 193802836 0001 10-1 SECTION 00 11 13 ADVERTISEMENT FOR BIDS Sealed Bids will be received by the City of New Hope, Minnesota, in the City Hall at 4401 Xylon Avenue North, until 10 A.M., CDT, Friday, July 18, 2014, at which time they will be publicly opened and read aloud for the furnishing of all labor, materials, and all else necessary for the following: 2014 Crack Re alr and Seal Coat City Pro ect No. 930 In general, Work consists of the following approximate quantities: 39,400 SY Seal Coat Aggregate, FA -2 (Mod), Trap Rock 11,000 GAL Bituminous Material for Seal Coat 47,300 SY Bituminous Material for Fog Seal 61,000 LBS Crack Seal Complete digital Bidding Documents are available at www.questcdn.com for $20 by inputting uestCDN Project #3394958 on the websites Project Search page. Paper Bidding Documents may also be viewed at the office of the City of New Hope and Stantec, 2335 Highway 36 West, St. Paul, MN 55113, (651) 636-4600. Direct inquiries to Engineer's Project Manager, Chris Long, at (651 ) 604-4808. Bid Security in the amount of 5 percent of the amount of the Bid must accompany each Bid in accordance with the Instructions to Bidders. The Owner reserves the right to retain the deposits of the 3 lowest Bidders for a period not to exceed 60 days after the date and time set for the Opening of Bids. No Bids may be withdrawn for a period of 60 days after the date and time set for the Opening of Bids. The Owner reserves the right to reject any and all Bids, to waive irregularities and informalities therein, and further reserves the right to award the Contract to the best interests of the Owner. Kirk McDonald, City Manager City of New Hope, Minnesota 0 2014 Stantec 11 193802836 0011 13-1 SECTION 00 21 13 INSTRUCTIONS TO BIDDERS ARTICLE i - DEFINED TERMS .01 Terms used in these Instructions to Bidders have the meanings indicated in the General Conditions and Supplementary Conditions. Additional terms used in these Instructions to Bidders have the meanings indicated below: A. Issuing Office -The office from which the Bidding Documents are to be issued and where the Bidding procedures are to be administered. ARTICLE 2 - COPIES OF BIDDING DOCUMENTS 2.01 Complete sets of the Bidding Documents in the number and for the deposit sum, if any, stated in the Advertisement or Invitation for Bids may be obtained from the Issuing Office. 2.02 Complete sets of Bidding Documents shall be used in preparing Bids; neither Owner nor Engineer assumes any responsibility for errors or misinterpretations resulting from the use of incomplete sets of Bidding Documents. 2.03 Owner and Engineer, in making copies of Bidding Documents available on the above terms, do so only for the purpose of obtaining Bids for the Work and do not authorize or confer a license for any other use. 2.04 Neither Owner nor Engineer assumes any responsibility for errors or misinterpretations resulting from Bidder's use of electronic downloadable Bidding Documents (Electronic Bidding Documents). In addition to the above items, Bidders using Electronic Bidding Documents are solely responsible for use of such documents, including, but not limited to: A. It is the responsibility of the Bidder to go to QuestCDN's Projects (www.QuestCDN.corn), check for the presence of Bidding Documents (including Addenda), and download documents as they become available. Bidder shall regularly check QuestCDN's Projects for Addenda or other additions or revisions to the Bidding Documents through the Bid Opening date, whether or not Bidder has received email notice of Addenda from Stantec or QuestCDN. B. It is the responsibility of the Bidder to verify the intended document size (sheet dimensions) and to verify proper colors (color, or black and white) of the Electronic Bidding Documents prior to reproduction. Bidder shall ensure that the Electronic Bidding Documents are reproduced to the correct and exact scale, and correct colors. C. It is the responsibility of the Recipient of Electronic Bidding Documents from this site to check the electronic data for computer viruses or other harmful coding. D. Bidders are subject to the Terms of Use and Limitations on Use detailed in the Bidding Documents. _.. 0 2014 Stant— t 9.'"RmR-AA ARTICLE 3 - QUALIFICATIONS OF BIDDERS 3.01 To demonstrate Bidder's qualifications to perform the Work, within 5 days of Owner's request, Bidder shall submit written evidence such as financial data, previous experience, present commitments, and such other data as may be coiled for below: A. Evidence of Bidder's authority to do business in the state where the Project is located. B. Evidence of genuineness of Bid and lack of collusion in conjunction therewith. ARTICLE 4 - EXAMINATION OF BIDDING DOCUMENTS, OTHER RELATED DATA, AND SITE 4.01 Subsurface and Physical Conditions A. The Supplementary Conditions identify: 1. Those reports known to Owner of explorations and tests of subsurface conditions at or contiguous to the Site. 2. Those drawings known to Owner of physical conditions relating to existing surface or subsurface structures at the Site (except Underground Facilities). Copies of reports and drawings referenced in Paragraph 4.01.A will be made available by Owner to any Bidder on request. Those reports and drawings are not part of the Contract Documents, but the "technical data" contained therein upon which Bidder is entitled to rely as provided in Paragraph 4.02 of the General Conditions has been identified and established in Paragraph 4.02 of the Supplementary Conditions. Bidder is responsible for any interpretation or conclusion Bidder draws from any "technical data" or any other data, interpretations, opinions, or information contained in such reports or shown or indicated in such drawings. 4.02 Underground Facilities A. Information and data shown or indicated in the Bidding Documents with respect to existing Underground Facilities at or contiguous to the Site is based upon information and data furnished to Owner and Engineer by owners of such Underground Facilities, including Owner or others. 4.03 Hazardous Environmental Condition A. The Supplementary Conditions identify any reports and drawings known to Owner relating to a Hazardous Environmental Condition identified at the Site. Copies of reports and drawings referenced in Paragraph 4.03.A will be made available by Owner to any Bidder on request. Those reports and drawings are not part of the Contract Documents, but the "technical data" contained therein upon which Bidder is entitled to rely as provided in Paragraph 4.06 of the General Conditions has been identified and established in Paragraph 4.06 of the Supplementary Conditions. Bidder is responsible for any interpretation or conclusion Bidder draws from any "technical data" or any other data interpretations, opinions, or information contained in such reports or shown or indicated in such drawings. 4.04 Provisions concerning responsibilities for the adequacy of data furnished to prospective Bidders with respect to subsurface conditions, other physical conditions, and Underground Facilities, and possible changes in the Bidding Documents due to differing or unanticipated ry _' © 2014 Stantec 193802836 0021 13-2 subsurface or physical conditions appear in Paragraphs 4.02, 4.03, and 4.04 of the General Conditions. Provisions concerning responsibilities for the adequacy of data furnished to prospective Bidders with respect to a Hazardous Environmental Condition at the Site, if any, and possible changes in the Contract Documents due to any Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in the Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work, appear in Paragraph 4.06 of the General Conditions. 4.05 On request, Owner will provide Bidder access to the Site to conduct such examinations, investigations, explorations, tests, and studies as Bidder deems necessary for submission of a Bid. Bidder shall fill all holes and clean up and restore the Site to its former condition upon completion of such explorations, investigations, tests, and studies. Bidder shall comply with all applicable Laws and Regulations relative to excavation and utility locates. 4.06 Reference is made to Article 7 of the Supplementary Conditions for the identification of the general nature of other work that is to be performed at the Site by Owner or others (such as utilities and other prime contractors) that relates to the Work contemplated by these Bidding Documents. On request, Owner will provide to each Bidder for examination access to or copies of contract documents (other than portions thereof related to p(ice) for such other work. 4.07 It is the responsibility of each Bidder before submitting a Bid to: A. examine and carefully study the Bidding Documents, and the other related data identified in the Bidding Documents; B. visit the Site and become familiar with and satisfy Bidder as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work; C. become familiar with and satisfy Bidder as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the Work; D. consider the information known to Bidder; information commonly known to contractors doing business in the locality of the Site; information and observations obtained from visits to the Site; the Bidding Documents; and the Site -related reports and drawings identified in the Bidding Documents, with respect to the effect of such information, observations, and documents on (1) the cost, progress, and performance of the Work; (2) the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including applying any specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents; and (3) Bidder's safety precautions and programs; E. agree at the time of submitting its Bid that no further examinations, investigations, explorations, tests, studies, or data are necessary for the determination of its Bid for performance of the Work at the prices) Bid and within the times required, and in accordance with the other terms and conditions of the Bidding Documents; F. become aware of the general nature of the work to be performed by Owner and others at the Site that relates to the Work as indicated in the Bidding Documents; G. promptly give Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder discovers in the Bidding Documents and confirm that the written resolution thereof by Engineer is acceptable to Bidder; and INSTRUCTIONS TO BIDDERS © 2014 Stantec 1 193802836 0021 13-3 H. determine that the Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for the performance of the Work. 4.08 The submission of a Bid will constitute an incontrovertible representation by Bidder that Bidder has complied with every requirement of this Article 4, that without exception the Bid is premised upon performing and furnishing the Work required by the Bidding Documents and applying any specific means, methods, techniques, sequences, and procedures of construction that may be shown or indicated or expressly required by the Bidding Documents, that Bidder has given Engineer written notice of all conflicts, errors, ambiguities, and discrepancies that Bidder has discovered in the Bidding Documents and the written resolutions thereof by Engineer are acceptable to Bidder, and that the Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performing and furnishing the Work. ARTICLES- PRE-BID CONFERENCE 5.01 There will be no Pre -Bid Conference. ARTICLE 6 - SITE AND OTHER AREAS 6.01 The Site is identified in the Bidding Documents. Easements for permanent structures or permanent changes in existing facilities are to be obtained and paid for by Owner, unless otherwise provided in the Bidding Documents. All additional lands and access thereto required for temporary construction facilities, construction equipment, or storage of materials and equipment to be incorporated in the Work are to be obtained and paid for by Contractor. ARTICLE 7 - INTERPRETATIONS AND ADDENDA 7.01 All questions about the meaning or intent of the Bidding Documents are to be submitted to Engineer in writing. Interpretations or clarifications considered necessary by Engineer in response to such questions will be issued by Addendum mailed or delivered to all parties recorded by Engineer as having received the Bidding Documents. Questions received less than 10 days prior to the date for Opening of Bids may not be answered. Only questions answered by Addendum will be binding. Oral and other interpretations or clarifications will be without legal effect. 7.02 Addenda may be issued to clarify, correct, or change the Bidding Documents as deemed advisable by Owner or Engineer. ARTICLE 8 - BID SECURITY 8.01 A Bid must be accompanied by Bid Security made payable to Owner in an amount of 5 percent of Bidder's maximum Bid price and in the form of a certified check, bank money order, or a Bid Bond issued by a surety meeting the requirements of Paragraphs 5.01 and 5.02 of the General Conditions. 8.02 The Bid Security of the successful Bidder will be retained until such Bidder has executed the Contract Documents, furnished the required Contract Security and met the other conditions of the Notice of Award, whereupon the Bid Security will be returned. If the successful Bidder fails to execute and deliver the Contract Documents and furnish the required Contract Security within 15 days after the Notice of Award, Owner may consider Bidder to be in default, annul the Notice of Award, and the Bid Security of that Bidder will be forfeited. Such forfeiture shall be Owner's exclusive remedy if Bidder defaults. The Bid Security of other Bidders whom Owner INSTRUCTIONS TO BIDDERS © 2014 Stantec 1 193802836 0021 13-4 believes to have a reasonable chance of receiving the award may be retained by Owner until the earlier of 7 days after the Effective Date of the Agreement or 61 days after the Bid Opening, whereupon Bid Security furnished by such Bidders will be returned. 8.03 Bid Security of other Bidders whom Owner believes do not have a reasonable chance of receiving the award will be returned within 7 days after the Bid Opening. ARTICLE 9 - CONTRACT TIMES 9.01 The number of days within which, or the dates by which, Milestones are to be achieved and the Work is to be Substantially Completed and ready for Final Payment are set forth in the Agreement. ARTICLE 10 - LIQUIDATED DAMAGES 10.01 Provisions for liquidated damages, if any, are set forth in the Agreement. ARTICLE 11 -SUBSTITUTE AND "OR -EQUAL" ITEMS 11.01 The Contract, if awarded, will be on the basis of materials and equipment specified or described in the Bidding Documents without consideration of possible substitute or "or -equal" items. Whenever it is specified or described in the Bidding Documents that a substitute or "or - equal" item of material or equipment may be furnished or used by Contractor if acceptable to Engineer, application for such acceptance will not be considered by Engineer until after the Effective Date of the Agreement. ARTICLE 12 - SUBCONTRACTORS, SUPPLIERS, AND OTHERS 12.01 If the Supplementary Conditions require the identity of certain subcontractors, suppliers, individuals, or entities to be submitted to Owner in advance of a specified date prior to the Effective Date of the Agreement, the apparent successful Bidder, and any other Bidder so requested, shall within 5 days after Bid Opening, submit to Owner a list of all such subcontractors, suppliers, individuals, or entities proposed for those portions of the Work for which such identification is required. Such list shall be accompanied by an experience statement with pertinent information regarding similar projects and other evidence of qualification for each such subcontractor, supplier, individual, or entity if requested by Owner. If Owner or Engineer, after due investigation, has reasonable objection to any proposed subcontractor, supplier, individual, or entity, Owner may, before the Notice of Award is given, request apparent successful Bidder to submit a substitute, in which case apparent successful Bidder shall submit an acceptable substitute, Bidder's Bid price will be increased (or decreased) by the difference in cost occasioned by such substitution, and Owner may consider such price adjustment in evaluating Bids and making the Contract award. 12.02 If apparent successful Bidder declines to make any such substitution, Owner may award the Contract to the next lowest Bidder that proposes to use acceptable subcontractors, suppliers, individuals, or entities. Declining to make requested substitutions will not constitute grounds for forfeiture of the Bid Security of any Bidder. Any subcontractor, supplier, individual, or entity so listed and against which Owner or Engineer makes no written objection prior to the giving of the Notice of Award will be deemed acceptable to Owner and Engineer subject to revocation of such acceptance after the Effective Date of the Agreement as provided in Paragraph 6 06 of the General Conditions, INSTRUCTIONS TO BIDDERS 0 2014 Stantec 1 193802836 0021 13-5 12.03 Contractor shall not be required to employ any subcontractor, supplier, individual, or entity against whom Contractor has reasonable objection. ARTICLE 13 - PREPARATION OF BID 13.01 The Bid Form is included with the Bidding Documents. 13.02 All blanks on the Bid Form shall be completed in ink and the Bid Form signed in ink. Erasures or alterations shall be initialed in ink by the person signing the Bid Form. A Bid price shall be indicated for each section, Bid Item, Alternate, adjustment Bid Unit Price Bid Item, and Bid Unit Price Bid Item listed therein. 13.03 A Bid by a corporation shall be executed in the corporate name by the president or a vice- president or other corporate officer accompanied by evidence of authority to sign. The corporate seal shall be affixed and attested by the secretary or an assistant secretary. The corporate address and state of incorporation shall be shown. 13.04 A Bid by a partnership shall be executed in the partnership name and signed by a partner (whose title must appear under the signature), accompanied by evidence of authority to sign. The official address of the partnership shall be shown. 13.05 A Bid by a limited liability company shall be executed in the name of the firm by a member and accompanied by evidence of authority to sign. The state of formation of the firm and the official address of the firm shall be shown. 13.06 A Bid by an individual shall show the Bidder's name and official address. 13.07 A Bid by a joint venture shall be executed by each joint venturer in the manner indicated on the Bid Form. The official address of the joint venture shall be shown. 13.08 All names shall be printed in ink below the signatures. 13.09 The Bid shall contain an acknowledgment of receipt of all Addenda, the numbers of which shall be filled in on the Bid Form. 13.10 Postal and e-mail addresses and telephone and fax numbers for communications regarding the Bid shall be shown. 13.1 . The Bid shall contain evidence of Bidder's authority and qualification to do business in the state where the Project is located, or Bidder shall covenant in writing to obtain such authority and qualification prior to award of the Contract and attach such covenant to the Bid. Bidder's state contractor license number, if any, shall also be shown on the Bid Form. ARTICLE 14 - BASIS OF BID; COMPARISON OF BIDS 14.01 Unit Price with Alternates A, Bidders shall submit a Bid on a Bid Unit Price basis for each Bid Item of Work listed in the Bid Form and include a separate price for each Alternate described in the Bidding Documents as provided on the Bid Form. The price for each Alternate will be the amount added to the Base Sid if the Owner selects the Alternate. In the evaluation of Bids, Owner may select any combination of Alternates or Owner may choose not to accept any Alternate Bids. INSTRUCTIONS TO BIDDERS © 2014 Stantec 193802836 0021 13-6 B. The total of all estimated prices will be the sum of the products of the estimated quantity of each Bid Item and the corresponding Bid Unit Price. The final quantities and Contract Price will be determined in accordance with Paragraph 11.03 of the General Conditions. C. Discrepancies between the multiplication of units of work and Bid Unit Prices will be resolved in favor of the Bid Unit Prices. Discrepancies between the indicated sum of any column of figures and the correct sum thereof will be resolved in favor of the correct sum. D. Bids will be compared on the basis of the "Adjusted Total Base Bid" and this amount will be the basis for determining the lowest Bidder. The sum of the Total Base Bid and any combination of Alternates accepted by the Owner will determine the "Adjusted Total Base Bid." The Owner may choose to not accept any Alternates Bids. ARTICLE 15 - SUBMITTAL OF BID 15.01 Bid shall be submitted no later than the date and time prescribed and at the place indicated in the Advertisement or Invitation for Bids and shall be enclosed in a plainly marked package with the Project title (and, if applicable, the designated portion of the Project for which the Bid is submitted), the name and address of Bidder, and shall be accompanied by the Bid Security and other required documents. If a Bid is sent by mail or other delivery system, the sealed envelope containing the Bid shall be enclosed in a separate package plainly marked on the outside with the notation "BID ENCLOSED." A mailed Bid shall be addressed to Owner's office. 15.02 The Bid shall include the entire Document 00 41 10 - Bid Form. This includes all attachments listed in Article 7,01 of the Bid Form and/or all forms included with the Bid Form. The Contractor may remove or copy these sheets from the Project Manual. 15.03 The entire Project Manual should not be submitted with the Bid. ARTICLE 16 - MODIFICATION AND WITHDRAWAL OF BID 16.01 A Bid may be modified or withdrawn by an appropriate document duly executed in the some manner that a Bid must be executed and delivered to the place where Bids are to be submitted prior to the date and time for the Opening of Bids. 16.02 Bids may be withdrawn after Bid Opening only in accordance with the law. ARTICLE 17 - OPENING OF BIDS 17.01 Bids will be opened at the time and place indicated in the Advertisement for Bids and, unless obviously non-responsive, read aloud publicly. An abstract of the amounts of the Base Bids and major Alternates, if any, will be made available to Bidders after the Project is awarded. ARTICLE 18 - BIDS TO REMAIN SUBJECT TO ACCEPTANCE 18.01 All Bids will remain subject to acceptance for the period of time stated in the Bid Form, but Owner may, in its sole discretion, release any Bid and return the Bid Security prior to the end of this period. ARTICLE 19 - EVALUATION OF BIDS AND AWARD OF CONTRACT 19.01 If the Contract is awarded, award will be made on the basis of the lowest responsive, responsible, qualified Bidder determined by the Adjusted Total Base Bid. B 2014 5tantPr ° 191RmRIA )IO 21 13 - 7 19.02 Owner reserves the right to reject any or all Bids, including without limitation, nonconforming, nonresponsive, unbalanced, or conditional Bids. Owner further reserves the right to reject the Bid of any Bidder whom it finds, after reasonable inquiry and evaluation, to not be responsible. Owner may also reject the Bid of any Bidder if Owner believes that it would not be in the best interest of the Project to make an award to that Bidder. Owner also reserves the right to waive all informalities not involving price, time, or changes in the Work and to negotiate contract terms with the successful Bidder. 19.03 More than 1 Bid for the same Work from an individual or entity under the some or different names will not be considered. Reasonable grounds for believing that any Bidder has an interest in more than 1 Bid for the Work may be cause for disqualification of that Bidder and the rejection of all Bids in which that Bidder has an interest. 19.04 In evaluating Bids, Owner will consider whether or not the Bids comply with the prescribed requirements, and such Alternates, Bid Unit Prices and other data, as may be requested in the Bid Form or prior to the Notice of Award. T 9.05 In evaluating Bidders, Owner will consider the qualifications of Bidders and may consider the qualifications and experience of subcontractors, suppliers, and other individuals or entities proposed for those portions of the Work for which the identity of subcontractors, suppliers, and other individuals or entities must be submitted as provided in the Supplementary Conditions. 19.06 Owner may conduct such investigations as Owner deems necessary to establish the responsibility, qualifications, and financial ability of Bidders, proposed subcontractors, suppliers, individuals, or entities proposed for those portions of the Work in accordance with the Contract Documents. As a condition of its Bid, Bidder is required to waive any and all claims of whatever nature against Owner, Engineer, and their employees and agents which arise out of or relate to such investigations and statements made as a result thereof, except for statements that can be shown by clear and convincing evidence to be intentionally false and made with actual malice. This waiver is not intended to restrict Bidder's rights to challenge a Contract pursuant to law. 19.07 If the Contract is to be awarded, Owner will award the Contract to the Bidder whose Bid is in the best interests of the Project. ARTICLE 20 - CONTRACT SECURITY AND INSURANCE 20.01 Article 5 of the General Conditions, as may be modified by the Supplementary Conditions, sets forth Owner's requirements as to performance and payment bonds and insurance. When the successful Bidder delivers the executed Agreement to Owner, it shall be accompanied by such bonds. ARTICLE 21 - SIGNING OF AGREEMENT 21.01 When Owner issues a Notice of Award to the successful Bidder, it shall be accompanied by the required number of unsigned counterparts of the Agreement along with the other Contract Documents which are identified in the Agreement as attached thereto. Within 15 days thereafter, successful Bidder shall sign and deliver the required number of counterparts of the Agreement and attached documents to Owner. Within 10 days thereafter, Owner shall deliver 2 fully signed counterparts to successful Bidder with a complete set of the Drawings with appropriate identification. END OF SECTION 0 2014 Stantec 193802836 INSTRUCTIONS TO BIDDERS 0021 13-8 BIDDER: A111 'NaIcKtcp ro Stantec D OCUMENT 00 41 10 REVISED BID FORM REVISED BY ADDENDUM NO. 1 2014 CRACK REPAIR AND SEAL COAT CITY PROJECT NO. 930 PROJECT NO. 193842836 NEW HOPE, MINNESOTA 2014 THIS BID 15 SUBMITTED TO: City of New Hope City Hall 4401 Xylon Avenue North New Hope. MN 55428 1.01 The undersigned Bidder proposes and agrees, if this Bid is accepted, to enter into an Agreement with Owner in the form included in the Bidding Documents to perform all Work as specified or indicated in the Bidding Documents for the prices and within the times indicated in this Bid and in accordance with the other terms and conditions of the Bidding Documents. 2,01 Bidder accepts all of the terms and conditions of the Instructions to Bidders, including without limitation those dealing with the disposition of Bid Security. The B1d will remain subject to acceptance for 60 days after the Bid Opening, or for such longer period of time that Bidder may agree to in writing upon request of Owner. 3.01 In submitting this Bid, Bidder represents that: A. Bidder has examined and carefully studied the Bidding Documents, the other related data identified in the Bidding Documents, and the following Addenda, receipt of all which is hereby acknowledged: Ade Number B. Bidder has visited the Site and become familiar with and is satisfied as to the general, IocaL and Site conditions that may affect cost, progress, and performance of the Work. C. Bidder is familiar with and is satisfied as to all federal, state, and local Lows and Regulations that may affect cost, progress, and performance of the Work. D. Bidder has carefully studied all: (1 j reports of explorations and tests of subsurface conditions at, or contiguous to, the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at, or contiguous to, the Site (except Underground Facilities) which have been identified in 5C-4.02 and (2) reports and drawings of Hazardous Environmental Conditions that have been identified in SC -4.06. E Bidder has obtained and carefully studied (or accepts the consequences for not doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions {surface, subsurface, and Underground Facilities) at, or contiguous to, the Site which may off ect cost, progress, or performance of the work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including apptying the specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents to be employed by Bidder, and safety precautions and programs incident thereto. F. Bidder does not consider that any further examinations, investigations, explorations, lents, studies, or data are necessary for the determination of this Bid for performance of the Work at the price(s) Bid and within the times and in accordance with the other terms and condifions of the Bidding Documents, G. Bidder is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Bfdd'Ing Documents, Fa 2014 S1anIec 1493902836 REVISED BY ADDENDUM NO. 1 0041 10-1IR1 REVISED BID FORM H. Bidder has correlated the information known to Bidder, information and observations obtained from visits to the Site, reports and drawings identified in the Bidding Documents. and all additional examinations, investigations, explorations, tests, studies, and data with the Bidding Documents. L Bidder has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder has discovered in the Bidding Documents, and the written resolution thereof by Engineer is acceptable to Bidder. J. The Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for the performance of the Work for which this Bid is submitted. K. Bidder will submit written evidence of its authority to do business in the state where the Project Is located not later than the date of its execution of the Agreement. 4.01 Bidder further represents that: A. The prices in this Bid have been arrived at independently, without consultation, communication, or agreement as to any matters relating to such prices with any other Bidder or with any competitor for the purpose of restricting competition. B. The prices In this Bid have not or wilt not be knowingly disclosed to any other Bidder or competitor prior to opening of the Bids. C. No attempt has been made or will be made by the Bidder to induce any other person or firm to submit or not to submit a Bid for the purpose of restricting competition. 4.02 Bidder understands that the law may require the Owner, or Engineer at the Owner's direction, to undertake an investigation and submit an evaluation conceming Bidder's responsiveness, responsibility, and qualifications before awarding a contract. Bidder hereby waives any and all claims, of whatever nature, against Owner, Engineer and their employees and agents, which arise out of or relate to such investigation and evaluation, and statements made as a result thereof, except for statements that can be shown by clear and convincing evidence to be intentionally false and made with actual malice. Nothing in this paragraph is intended to restrict Bidder's rights to challange a contract pursuant to law. 5.01 Bidder will complete the Work in accordance with the Contract Documents for the following price(s); All specific cash allowances are included in the price(s) set forth below and have been computed in accordance with Paragraph 11.02 of the General Conditions. Unit Prices have been computed in accordance with Paragraph 11.03.13 of the General Conditions Bidder acknowledges that estimated quantities are not guaranteed, and ore solely for the purpose of comparison at Bids, and final payment for all Unit Price Bid items will be based on actual quantities provided, determined as provided in the Contract Documents. No. Item ur& Qty knit Pike Total Prlca BASE BID; MOBILIZATION 2 TRAFFIC CONTROL 3 CRACK SEAL {CLEAN AND SEAL) 4 BITUMINOUS MATERIAL FOR SEAL COAT, CRS -2 5 SEAL COAT AGGREGATE, FA -2 {MOD), TRAP ROCK 6 BITUMINOUS MATERIAL FOR FOG SEAL 7 BITUMINOUS MATERIAL FOR FOG SEAL- CUL DE SAC OR PARKING LOT 0201451antec 1 193802836 REVISED BY ADDENDUM NO. 1 00 41 10-21R1 REVISED BiD FORM -190 LS 1 $ (9 000.6v $ 3 d sm LBS 61,000 $ -Jt Yo $ rLi&,tieaBO GAL 10,400 $ 3' !;0 $ ?4100 -co SY 40,400 $ .60 $ aLi r�� 00 � Sy 40,850 $ M 'T/ 0 Sy 6,450 $ • 50 $ �{O r F341%. ®d $ 7.,5-, ',0D 0201451antec 1 193802836 REVISED BY ADDENDUM NO. 1 00 41 10-21R1 REVISED BiD FORM No. Item Units Qty LIM We Price 8 4" BROKEN LINE, YELLOW PAINT LF 150 $ .9100 -yTotal $ l SO' 00 9 4" DOUBLE SOLID UNE, YELLOW PAINT LF 700 $ 7400 $ go 1 vaso 10 12" SOLID LINE, YELLOW PAINT LF 50 $ ids. m o $ 600' ®d 11 24" SOLID LINE, WHITE PAINT LF 40 $ a0` 0D $ '90a vo 12 PAVEMENT MESSAGE. LEFT ARROW EA 4 $ vb ■d $ 600.80 13 PAVEMENT MESSAGE, THRU ARROW EA 2 $ 11 6 00,00 $ 300%do 14 PAVEMENT MESSAGE, RIGHT-THRU ARROW EA 2 $ 179. vV $ 35-a.190 15 CROSSWALK MARKING, 3'x 6' BLOCKS, WHITE PAINT SF 90 $ 10.00 $ q&&• BO TOTAL BASE BID TOTAL ALTERNATE NO. i $ a6 -7s 0 2014 Stantec 1 193802836 REVISED BY ADDENDUM NO. 1 00 41 10-3(R) REVISED BID FORM ALTERNATE NO. 1: 62ND AVENUE N a % 4� m� 16 BITUMINOUS MATERIAL FOR FOG SEAL SY 32,90D $ ' $ `� 17 4" BROKEN LINE, WHITE PAINT LF 100 $ X. 3 600.60 18 4" SOLID LINE, WHIR: PAINT LF 4,300 $ * SLS $ ", l sO. 00 19 4" BROKEN LINE, YELLOW PAINT LF 1,200 $ J'00 $ JI i7 0(Q, 0O 20 4" DOUBLE SOLID LINE, YELLOW PAINT LF 1,600 $ 1.100 $ 11 6 00,00 21 24" SOLID UNE, WHITE PAINT LF 250 $ 1406 60 $ r 00 22 CROSSWALK MARKING, 3'x6 BLOCKS, WHITE PAINT SF 1,200 $ 3' d� $ TOTAL ALTERNATE NO. i $,3q,!919"VO 0 2014 Stantec 1 193802836 REVISED BY ADDENDUM NO. 1 00 41 10-3(R) REVISED BID FORM 6.01 Bidder agrees that the Work will be Substantially Completed and completed and ready for Final Payment in accordance with Paragraph 14.07.8 of the General Conditions on or before the dates or within the number of calendar days indicated in the Agreement. 6.D2 Bidder accepts the provisions of the Agreement as to liquidated damages in the event of failure to complete the Work within the times specified above, which shall be stated in the Agreement. 7.01 The following documents are attached to and made a condition of this Bid: A. Required Bid Security in the form of 5 percent. 6.01 The terms used in this Bid with initial capital letters have the meanings stated in the Instructions to Bidders, the General Conditions, and the Supplementary Conditions. If Bidder Is: SUBMITTED on -2014. Cor,,:�oration Name: FAL Type {General Business, Professional, Service, Limited Liability): � V��C_C By: wc;lh (Signature) Title:1 Attest (CORPORATE SEAL) (Jm+ Cc -Of IFN 0)1 (signature of Corporate Secrretary) Business Street Address (No P.O. Box #'s): Allied Blacktop Company 10503 89th Avenue North Maple Grove, MN 55359 Phone No. '72G`�5`75 Fax No.: !1pZ— itn 0 2014 Stantec 1193802836 REVISED BY ADDENDUM NO. 1 00 41 10-4(Ri REVISED BID FORM BID BOND KNOW ALL MEN BY THESE PRESENTS, that we Allied Blacktop Company 10503 -89th Avenue North, Maple Grove, MN 55369 as Principal, hereinafter called the Principal, and Western Surety COmparty 101 South Phillips Avenue,_ Sioux Falls, SD 57104 a corporation duly organized under the laws of the State ot South Dakota as Surety, hereinafter called the Surety, are held and firmly bound unto_.` as Obligee, hereinafter called the Obligee, in the sum of Fl Pf �; Dollars 5c'1'Q ! 9�irH 1, fior the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitteda bld far a c l' 04\1 Prn �Pr+ On. c) L NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documentswith good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not W exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good With contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this r "U day of Allied Blacktop Company (PdQ C By: At�— M /—Alf Peter M Capistrant, President Western Surety Company B. (TWO)John G. , Attorney-in-fact Printed in cooperation withthe American Institute of Architects (AIA) by the CNA Insurance Companies. The language in this document conforms exactly to the language used in AIA Document A310- Bid Bond - February 9970 Edition. G-108041-11 ACKNOWLEDGMENT OF PRINCIPAL (individual) STATE OF COUNTY OF ss.: On this clay of , in the year before me Personally comets) to me known and known to me to be the persons) who (is) (are) described in and who executed the foregoing instrument and acknowledge(s) to me that he executed the same. NOTARY PUBLIC ACKNOWLEDGMENT OF PRINCIPAL (Partnership) STATE OF COUNTY OF On this day of , in the year , before me personally come(s) a member of the ca -partnership of to me known and known to me to be the person who is described in and who executed the foregoing instrument, and acknowledges to me that he executed the same as and for the act and deed of the said co -partnership. NOTARY PUBLIC ACKNOWLEDGMENT OF PRINCIPAL (Corporation) STATE OF Minnesota COON T Y OF Hennepin On this ft) day or AA�J , . in the year � before me personallycome(s) peter M Ca istrant a me ,d known, who, being by me duly sworn, deposes and says that he resides in the City of g Lake that %isa President, ofthe Allied Blacktop Company the corporation described in and which executed rhe foregoing instrument; that he knows the seal of the said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed by the order of the Board of Directors of said corporation, and that he signed his name thereto by like order, n 6 x :^ NAO11 - ; : CTARY i U8l_IC ^,! ; :ESo /, NOTARY PUBLI KNDWLEDGMENT OF SURETY STATE OF__ Minnesota COUNTY OF Henne, Rin On this _ _day t►f, ��... _ in the years Y before me personally corne(s) John G. ex Attorneys) -in -Fact o; Western Soret Co with whom i am personally acquainted, and who, being by me duly sworn, says that he reside(s) .in that he is (ace) the Attorneys) -in -Fact of the company described in and which executed the within instrument; that he knows) the corporate seal of such Company; and that the seal affixed to the within instrument is such corporate seal grid that it was affixed by order of the Board of Directors of said Company, and that he signed said instrument as Attorney(s)-in-Fart of said Company by like order. 1(&.JOYCE HAGBERG 0TARY B LI F.9713 — s/ai a VVestern Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These (Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duty organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby mala:, constitute and appoint John G Hagberg, Judith L Jorissen, Garth R Fisher, Individually of Bloomington, MN, its true and lawful Attorney(s)-in-Fact with full power and authority hereby conrerred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By-l-aw printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 28th day of April, 2014. TWESTERN SURETY COMPANY LA0 o 4erc f $ aul T. Bruflat, Vice President State of South Dakotaso I County of Minnehaha On [his 28th day of April, 2014, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires J. -MOOR June 23, 2015 NOTAFN PUBLIC SOUTH DMOM fJwf V � J. Mohr, Notary Public CERTIFICATE 1, t- Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof yis still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this � _ day of J �' }-q , 2�O Ig WESTERN SURETY COMPANY V L, Nelson, Assistant Secretary Form F428u-7-20t2 Authorizing By -Law ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. SECTION 00 52 10 AGREEMENT FORM THIS AGREEMENT is by and between the City of New Hope, Minnesota (hereinafter called Owner) and Allied Blacktop CompanX (hereinafter called Contractor). Owner and Contractor, in consideration of the mutual covenants hereinafter set forth, agree as follows: ARTICLE 1 - WORK 1.01 Contractor shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: crack repair, seal coat, and fog seal street improvements. ARTICLE 2 - THE PROJECT 2.01 The Project for which the Work under the Contract Documents may be the whole or only a part is generally described as follows: 2014 Crack Repair and Seal Coat, City Project No. 930 for the City of New Hope, Minnesota. ARTICLE 3 - ENGINEER 3.01 The Project has been designed by Stantec (Engineer), who is to act as Owner's representative, assume all duties and responsibilities, and will have the rights and authority assigned to Engineer in the Contract Documents in connection with the completion of the Work in accordance with the Contract Documents. ARTICLE 4 - CONTRACT TIMES 4.01 Time of the Essence A. All time limits for Milestones, if any, Substantial Completion, and completion and readiness for Final Payment as stated in the Contract Documents are of the essence of the Contract. 4.02 Dates for Substantial Completion and Final Payment A. The Work will not begin until August 1, 2014. B. All work will be Substantially Completed on or before September 12, 2014. This includes crack seal, seal coat, first and second sweeping, and fog seal. C. All work shall be completed and ready for Final Payment in accordance with Paragraph 14.07 of the General Conditions on or before November 1, 2014. 4.03 Liquidated Damages A. Contractor and Owner recognize that time is of the essence of this Agreement and that Owner will suffer financial loss if the Work is not completed within the times specified in Paragraph 4.02 above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. The parties also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration preceding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty), AGREEMENT FORM 02014 Stantec 193802836 005210-1 Contractor shall pay Owner $500 for each day that expires after the time specified in Paragraph 4.02 for Milestones and Substantial Completion until the Work is Substantially Complete. B. Atter Substantial Completion, if Contractor shall neglect, refuse, or fail to complete the remaining work within the Contract Time or any proper extension thereof granted by Owner, Contractor shall pay Owner $500 for each day that expires after the time specified in Paragraph 4.02 for completion and readiness for Final Payment until the Work is completed and ready for Final Payment. ARTICLE 5 - CONTRACT PRICE 5.01 Owner shall pay Contractor for completion of the Work in accordance with the Contract Documents an amount in current funds as follows: A. For all Work at the prices stated in Contractor's Bid, attached hereto as an exhibit. The Bid prices for Unit Price Work set forth as of the Effective Date of the Agreement are based on estimated quantities. As provided in Paragraph 11.03 of the General Conditions, estimated quantities are not guaranteed, and determinations of actual quantities and classifications are to be made by Engineer as provided in Paragraph 9.07 of the General Conditions. B. Original Contract Amount is based on the Total Base Bid plus Alternate No. 1 for a total of Three Hundred Seven Thousand, One Hundred Forty Dollars and No Cents ($307,140.00). ARTICLE 6 - PAYMENT PROCEDURES 6.01 Submittal and Processing of Payments A. Contractor shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Applications for Payment will be processed by Engineer as provided in the General Conditions. 6.02 Progress Payments; Retainage A. Owner shall make progress payments on account of the Contract Price on the basis of Contractor's Applications for Payment, monthly during performance of the Work as provided in Paragraphs 6.02.A1 and 6.02.A2 below. All such payments will be measured by the Schedule of Values established in Paragraph 2.07.A of the General Conditions (and in the case of Bid Unit Price Work based on the number of units completed) or, in the event there is no Schedule of Values, as provided in the General Requirements: 1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below, but in each case, less the aggregate of payments previously made and less such amounts as Engineer may determine or Owner may Withhold, including but not limited to liquidated damages, in accordance with Paragraph 14.02 of the General Conditions: a. 95 percent of Work completed (with the balance being retainage). b. 95 percent of cost of materials and equipment not incorporated in the Work (with the balance being retainage). 2. Upon Substantial Completion, Owner shall pay an amount sufficient to increase total payments to Contractor to 100 percent of the Work completed, less such amounts as Engineer shall determine in accordance with Paragraph 14.02.85 of the General Conditions and less 200 percent of Engineer's estimate of the value of Work to be ® 2014 Stantec 1 193802836 AGREEMENT FORM 005210-2 completed or corrected as shown on the tentative list of items to be completed or corrected attached to the certificate of Substantial Completion. 6.03 Final Payment A. Upon Final Completion and acceptance of the Work, in accordance with Paragraph 14.07 of the General Conditions, Owner shall pay the remainder of the Contract Price as recommended by Engineer as provided in said Paragraph 14.07. ARTICLE 7 - INTEREST 7.01 All moneys not paid when due, as provided in Article 14 of the General Conditions, shall bear interest at the maximum rate allowed by law at the place of the Project. ARTICLE S - CONTRACTOR'S REPRESENTATIONS 8.01 In order to induce Owner to enter into this Agreement, Contractor makes the following representations: A. Contractor has examined and carefully studied the Contract Documents arid the other related data identified in the Bidding Documents. B. Contractor has visited the Site and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. C. Contractor is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the Work. D. Contractor has carefully studied all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions relating to existing surface or subsurface structures at the Site, and all drawings of physical conditions relating to existing surface or subsurface structures at the Site (except Underground Facilities), if any, that have been identified in the Supplementary Conditions as containing reliable "technical data," and (2) reports and drawings of Hazardous Environmental Conditions, if any, at the Site that have been identified in the Supplementary Conditions as containing reliable "technical data." Contractor considered the information known to Contractor, information commonly known to contractors doing business in the locality of the Site; information and observations obtained from visits to the Site; the Contract Documents, with respect to the effect of such information, observations, and documents on (1) the cost, progress, and performance of the Work, (2) the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, including any specific means, methods, techniques, sequences, and procedures of construction expressly required by the Contract Documents; and (3) Contractor's safety precaution programs. F Based on the information and observations referred to in Paragraph 8.01.E above, Contractor does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times. and in accordance with the other terms and conditions of the Contract Documents. AGREEMENT FORM 0 2014 Stantec 1 193802836 005210-3 G. Contractor is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Contract Documents. H. Contractor has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Contractor has discovered in the Contract Documents, and the written resolution thereof by Engineer is acceptable to Contractor. I. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. ARTICLE 9 - CONTRACT DOCUMENTS 9.01 Contents A. The Contract Documents consist of the following: 1. This Agreement. 2. Performance Bond, Payment Bond, and other Bonds. 3. General Conditions. 4. Supplementary Conditions. 5. Specifications as listed in the table of contents of the Project Manual. 6. Drawings bearing the following general title: 2014 Crack Repair and Seal Coat. 7. Addendum No. 1. 8. Exhibits to this Agreement (enumerated as follows): a. Contractor's Bid Form. b. Documentation submitted by Contractor prior to Notice of Award. 9. The following which may be delivered or issued on or after the Effective Date of the Agreement and are not attached hereto: a. Notice to Proceed. b. Work Change Directives. c. Change Order(s). B. The documents listed in Paragraph 9.01.A are attached to this Agreement (except as expressly noted otherwise above). C. There are no Contract Documents other than those listed above in this Article 9. D. The Contract Documents may only be amended, modified, or supplemented as provided in Paragraph 3.04 of the General Conditions. ARTICLE 10- MISCELLANEOUS 10.01 Terms A. Terms used in this Agreement will have the meanings stated in the General Conditions and the Supplementary Conditions. 10.02 Assignment of Contract A. No assignment by a party hereto of any rights under or interests in the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to AGREEMENT FORM © 2014 Stantec 1 193802836 005210-4 the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 10.03 Successors and Assigns A. Owner and Contractor each binds itself, its partners, successors, assigns, and legal representatives to the other party hereto, its partners, successors, assigns, and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. 10.04 Severability A. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. 10.05 Contractor's Certifications A. Contractor certifies that it has not engaged in corrupt, fraudulent, collusive, or coercive practices in competing for or in executing the Contract. For the purposes of this Paragraph 10.05: 1. "corrupt practice" means the offering, giving, receiving, or soliciting of any thing of value likely to influence the action of a public official in the Bidding process or in the Contract execution; 2. "fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the Bidding process or the execution of the Contract to the detriment of Owner, (b) to establish Bid or Contract prices at artificial non-competitive levels, or (c) to deprive Owner of the benefits of free and open competition; 3. "collusive practice" means a scheme or arrangement between 2 or more Bidders, with or without the knowledge of Owner, a purpose of which is to establish Bid prices at artificial, non-competitive levels; and 4. "coercive practice" means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the bidding process or affect the execution of the Contract. ® 2{314 Stantec 193802836 AGREEMENT FORM 005210-5 IN WITNESS WHEREOF, Owner and Contractor have signed this Agreement. Counterparts have been delivered to Owner and Contractor. All portions of the Contract Documents have been signed or have been identified by Owner and Contractor or on their behalf. l This Agreement will be effective on a l , 2014 (which is the Effective Date of the Agreement). Owner: City ope, Minn oto By:. Attest: Address CfAriMes: CITY OF NEW HOPE 4401 XYLON AVE NO. HOPE,NEW Valli 0542-8 Designated Representative: Name: KIRK MCDONALD Title: CITY MANAGER 4401 XYLON AVE NO Address: NEW 763-531-5100 Phone: —75-3-531-5136 Facsimile: 0 2014 5tantec 193802836 Contractor: Address forgiving notices: Allied Blacktop Company 1050S 89th Avdnue North Maple Grove, MN 55369 License No.: (Where Applicable) Designated Representative: Name:5 }� Title: T Address: Allied Blacktop Company !i n503 89th Avenue North Maple Grove, MN 55369 Phone: :&7 9 1 ZS - 05^75 Facsimile: W3 qx� - IPLIQ END OF SECTION AGREEMENT FORM 005210-6 This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the controlling Laws and Regulations. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly by .�._............._ A UU-L CE American Society V . �-4�t-�a; 4;0—w oi. of Civil Engineers ° M0=50,9`x!'1"1`&J,kee` z (PMAMIana! Eng roam in PAWN Practice AMERICAN COUNCIL OF ENGINEERING COMPANIES ASSOCIATED GENERAL CONTRACTORS OF AMERICA AMERICAN SOCIETY OF CIVIL ENGINEERS PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE A Practice Division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS Endorsed by 4 CONSTRUCTION SPECIFICATIONS INSTITUTE EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. An rights reserved. 00 72 05 These General Conditions have been prepared for use with the Suggested Forms of Agreement Between Owner and Contractor (EJCDC C-520 or C-525, 2007 Editions). Their provisions are interrelated and a change in one may necessitate a change in the other. Comments concerning their usage are contained in the Narrative Guide to the EJCDC Construction Documents (EJCDC C-001, 2007 Edition). For guidance in the preparation of Supplementary Conditions, see Guide to the Preparation of Supplementary Conditions (EJCDC C-800, 2007 Edition). Copyright C 2007 National Society of Professional Engineers 1420 King Street, Alexandria, VA 22314-2794 (703) 684-2882 www.nspe.or American Council of Engineering Companies 1015 15th Street N.W., Washington, DC 20005 (202) 347-7474 www.acee.or American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 (800) 548-2723 vurww.asce.or Associated General Contractors of America 2300 Wilson Boulevard, Suite 400, Arlington, VA 22201-3308 (703) 548-3118 www.agc.org The copyright for this EJCDC document is owned jointly by the four EJCDC sponsoring organizations and held in trust for their benefit by NSPE. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. 00 72 05 STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT TABLE OF CONTENTS Page Article 1 — Definitions and Terminology .............................. 1.01 Defined Terms.................................................................................................................... 1 1.02 Terminology........................................................................................................................5 Article2 — Preliminary Matters............................................................................................................... 6 2.01 Delivery of Bonds and Evidence of Insurance...................................................................... 6 2.02 Copies of Documents.......................................................................................................... 6 2.03 Commencement of Contract Times; Notice to Proceed........................................................ 6 2.04 Starting the Work................................................................................................................ 7 2.05 Before Starting Construction............................................................................................... 7 2.06 Preconstruction Conference; Designation of Authorized Representatives ............................. 7 2.07 Initial Acceptance of Schedules........................................................................................... 7 Article 3 — Contract Documents: Intent, Amending, Reuse.................................................................... 8 3.01 Intent.................................................................................................................................. 8 3.02 Reference Standards............................................................................................................ 8 3.03 Reporting and Resolving Discrepancies............................................................................... 9 3.04 Amending and Supplementing Contract Documents ............................................................ 9 3.05 Reuse of Documents.................................................................. ............ 10 ........................... 3.06 Electronic Data................................................................................................................. 10 Article 4 — Availability of Lands; Subsurface and Physical Conditions; Hazardous Environmental Conditions; Reference Points................................................................................... 4.01 Availability of Lands.................................................•-----.................................................. 11 4.02 Subsurface and Physical Conditions................................................................................... 11 4.03 Differing Subsurface or Physical Conditions...................................................................... 12 4.04 Underground Facilities...................................................................................................... 13 4.05 Reference Points............................................................................................................... 14 4.06 Hazardous Environmental Condition at Site ................. ................... 14 .................................. Article 5 — Bonds and Insurance.......................................................... .. 16 5.01 Performance, Payment, and Other Bonds........................................................................... 16 5.02 Licensed Sureties and Insurers........................................................................................... 16 5.03 Certificates of Insurance.................................................................................................... 17 5.04 Contractor's Insurance...................................................................................................... 17 5.05 Owner's Liability Insurance............................................................................................... 19 5.06 Property Insurance ............................................. .............. 19 ................................................. 5.07 Waiver of Rights............................................................................................................... 20 5.08 Receipt and Application of Insurance Proceeds ............................ EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pagel 00 72 05 5.09 Acceptance of Bonds and Insurance; Option to Replace .................................................... 21 5.10 Partial Utilization, Acknowledgment of Property Insurer ................................................... 22 Article 6 - Contractor's Responsibilities............................................................................................... 22 6.01 Supervision and Superintendence...................................................................................... 22 6.02 Labor; Working Hours...................................................................................................... 22 6.03 Services, Materials, and Equipment................................................................................... 23 6.04 Progress Schedule............................................................................................................. 23 6.05 Substitutes and "Or-Equals".............................................................................................. 23 6.06 Concerning Subcontractors, Suppliers, and Others............................................................ 26 6.07 Patent Fees and Royalties.................................................................................................. 27 6.08 Permits..............................................................................................................................28 6.09 Laws and Regulations....................................................................................................... 28 6.10 Taxes................................................................................................................................ 28 6.11 Use of Site and Other Areas.............................................................................................. 28 6.12 Record Documents............................................................................................................ 29 6.13 Safety and Protection........................................................................................................ 29 6.14 Safety Representative........................................................................................................ 30 6.15 Hazard Communication Programs..................................................................................... 31 6.16 Emergencies......................................................................................................................31 6.17 Shop Drawings and Samples............................................................................................. 31 6.18 Continuing the Work......................................................................................................... 33 6.19 Contractor's General Warranty and Guarantee.................................................................. 33 6.20 Indemnification................................................................................................................. 34 6.21 Delegation of Professional Design Services....................................................................... 34 Article 7 - Other Work at the Site........................................................................................................ 35 7.01 Related Work at Site......................................................................................................... 35 7.02 Coordination.....................................................................................................................36 7.03 Legal Relationships........................................................................................................... 36 Article 8 - Owner's Responsibilities..................................................................................................... 36 8.01 Communications to Contractor.......................................................................................... 36 8.02 Replacement of Engineer................................................................................................... 37 8.03 Furnish Data..................................................................................................................... 37 8.04 Pay When Due.................................................................................................................. 37 8.05 Lands and Easements; Reports and Tests........................................................................... 37 8.06 Insurance.......................................................................................................................... 37 8.07 Change Orders.................................................................................................................. 37 8.08 Inspections, Tests, and Approvals..................................................................................... 37 8.09 Limitations on Owner's Responsibilities............................................................................ 37 8.10 Undisclosed Hazardous Environmental Condition.............................................................. 38 8.11 Evidence of Financial Arrangements.................................................................................. 39 8.12 Compliance with Safety Program....................................................................................... 38 Article 9 - Engineer's Status During Construction................................................................................ 38 9.01 Owner's Representative.................................................................................................... 38 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright �P 2007 National Society of Professional Engineers for EJCDC. Ali rights reserved. Paee ii 00 72 05 9.02 Visits to Site..................................................................................................................... 38 9.03 Project Representative................................................................. ....... 39 9.04 Authorized Variations in Work.......................................................................................... 39 9.05 Rejecting Defective Work ......................................................... ....... 39 ................................. 9.06 Shop Drawings, Change Orders and Payments.................................................................. 39 9.07 Determinations for Unit Price Work.................................................................................. 40 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work ................. 40 9.09 Limitations on Engineer's Authority and Responsibilities ..................... 9.10 Compliance with Safety Program....................................................................................... 41 Article 10 - Changes in the Work; Claims............................................................................................. 41 10.01 Authorized Changes in the Work....................................................................................... 41 10.02 Unauthorized Changes in the Work................................................................................... 41 10.03 Execution of Change Orders.............................................................................................. 41 10.04 Notification to Surety........................................................................................................ 42 10.05 Claims...............................................................................................................................42 Article 11 - Cost of the Work; Allowances; Unit Price Work................................................................ 43 11.01 Cost of the Work.............................................................................................................. 43 11.02 Allowances....................................................................................................................... 46 11.03 Unit Price Work................................................................................................................ 46 Article 12 Change of Contract Price; Change of Contract Times ........................................................ 47 12.01 Change of Contract Price.................................................................................................. 47 12.02 Change of Contract Times................................................................................................. 48 12.03 Delays...............................................................................................................................48 Article 13 - Tests and Inspections; Correction, Removal or Acceptance of Defective Work .................. 49 13.01 Notice of Defects.............................................................................................................. 49 13.02 Access to Work.............................................................................................................. 49 13.03 Tests and Inspections........................................................................................................ 49 13.04 Uncovering Work.............................................................................................................. 50 13.05 Owner May Stop the Work............................................................................................... 51 13.06 Correction or Removal of Defective Work........................................................................ 51 13.07 Correction Period.............................................................................................................. 51 13.08 Acceptance of Defective Work.......................................................................................... 52 13.09 Owner May Correct Defective Work................................................................................. 52 Article 14 - Payments to Contractor and Completion........................................................................... 53 14.01 Schedule of Values............................................................................................................ 53 14.02 Progress Payments............................................................................................................ 53 14.03 Contractor's Warranty of Title.......................................................................................... 56 14.04 Substantial Completion...................................................................................................... 56 14.05 Partial Utilization.............................................................................................................. 57 14.06 Final Inspection................................................................................................................. 58 14.07 Final Payment.................................................................................................................... 58 14.08 Final Completion Delayed................................................................................................. 59 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee iii 00 72 05 14.09 Waiver of Claims............................................................................................................... 59 Article 15 — Suspension of Work and Termination................................................................................ 60 15.01 Owner May Suspend Work............................................................................................... 60 15.02 Owner May Terminate for Cause....................................................................................... 60 15.03 Owner May Terminate For Convenience........................................................................... 61 15.04 Contractor May Stop Work or Terminate.......................................................................... 61 Article16 — Dispute Resolution............................................................................................................ 62 16.01 Methods and Procedures................................................................................................... 62 Article17 — Miscellaneous.................................................................................................................... 62 17.01 Giving Notice.................................................................................................................... 62 17.02 Computation of Times....................................................................................................... 63 17.03 Cumulative Remedies........................................................................................................ 63 17.04 Survival of Obligations ............................... 63 ....................................................................... 17.05 Controlling Law................................................................................................................ 63 17.06 Headings........................................................................................................................... 63 EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page iv 00 72 05 ARTICLE 1— DEFINITIONS AND TERMINOLOGY 1.01 Defined Terms A. Wherever used in the Bidding Requirements or Contract Documents and printed with initial capital letters, the terms listed below will have the meanings indicated which are applicable to both the singular and plural thereof. In addition to terms specifically defined, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Addenda—Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the proposed Contract Documents. 2. Agreement—The written instrument which is evidence of the agreement between Owner and Contractor covering the Work. 3. Application for Payment—The form acceptable to Engineer which is to be used by Contractor during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 4. Asbestos—Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 5. Bid—The offer or proposal of a Bidder submitted on the prescribed form setting forth the prices for the Work to be performed. 6. Bidder—The individual or entity who submits a Bid directly to Owner. 7. Bidding Documents—The Bidding Requirements and the proposed Contract Documents (including all Addenda). 8. Bidding Requirements�--The advertisement or invitation to bid, Instructions to Bidders, Bid security of acceptable form, if any, and the Bid Form with any supplements. 9. Change Order—A document recommended by Engineer which is signed by Contractor and Owner and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, issued on or after the Effective Date of the Agreement. 10. Claim—A demand or assertion by Owner or Contractor seeking an adjustment of Contract Price or Contract Times, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. 11. Contract—The entire and integrated written agreement between the Owner and Contractor concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 9 2007 National Society of Professional Engineers for EJCDC. All rights reserved Page 1 of 62 00 72 05 12. Contract Documents—Those items so designated in the Agreement. Only printed or hard copies of the items listed in the Agreement are Contract Documents. Approved Shop Drawings, other Contractor submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 13. Contract Price—The moneys payable by Owner to Contractor for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of Paragraph 11.03 in the case of Unit Price Work). 14. Contract Times --The number of days or the dates stated in the Agreement to: (i) achieve Milestones, if any; (ii) achieve Substantial Completion; and (iii) complete the Work so that it is ready for final payment as evidenced by Engineer's written recommendation of final payment. 15. Contractor—The individual or entity with whom Owner has entered into the Agreement. 16. Cost of the Work—See Paragraph 11.01 for definition. 17. Drawings—That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings and other Contractor submittals are not Drawings as so defined. 18. Effective Date of the Agreement --The date indicated in the Agreement on which it becomes effective, but if no such date is indicated, it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. 19. Engineer—The individual or entity named as such in the Agreement. 20. Field Order—A written order issued by Engineer which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 21. General Requirements ---Sections of Division 1 of the Specifications. 22. Hazardous Environmental Condition—The presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto. 23. Hazardous Waste—The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 24. Laws and Regulations; Laws or Regulations—Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee 2 of 62 00 72 05 25. Liens—Charges, security interests, or encumbrances upon Project funds, real property, or personal property. 26. Milestone—A principal event specified in the Contract Documents relating to an intermediate completion date or time prior to Substantial Completion of all the Work. 27. Notice of Award—The written notice by Owner to the Successful Bidder stating that upon timely compliance by the Successful Bidder with the conditions precedent listed therein, Owner will sign and deliver the Agreement. 28. Notice to Proceed—A written notice given by Owner to Contractor fixing the date on which the Contract Times will commence to run and on which Contractor shall start to perform the Work under the Contract Documents. 29. Owner—The individual or entity with whom Contractor has entered into the Agreement and for whom the Work is to be performed. 30. PCBs—Polychlorinated biphenyls. 31. Petroleum—Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non -Hazardous Waste and crude oils. 32. Progress Schedule—A schedule, prepared and maintained by Contractor, describing the sequence and duration of the activities comprising the Contractor's plan to accomplish the Work within the Contract Times. 33. Project—The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 34. Project Manual—The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 35. Radioactive Material—Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 36. Resident Project Representative—The authorized representative of Engineer who may be assigned to the Site or any part thereof 37. Samples Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 38. Schedule of Submittals --A schedule, prepared and maintained by Contractor, of required submittals and the time requirements to support scheduled performance of related construction activities. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 3 of 62 39. Schedule of Values—A schedule, prepared and maintained by Contractor, allocating portions of the Contract Price to various portions of the Work and used as the basis for reviewing Contractor's Applications for Payment. 40. Shop Drawings All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 41. Site—Lands or areas indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights-of-way and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 42. Specifications—That part of the Contract Documents consisting of written requirements for materials, equipment, systems, standards and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable thereto. 43. Subcontractor—An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 44. Substantial Completion—The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. 45. Successful Bidder—The Bidder submitting a responsive Bid to whom Owner makes an award. 46. Supplementary Conditions—That part of the Contract Documents which amends or supplements these General Conditions. 47. Supplier—A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or Subcontractor. 48, Underground Facilities—All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 49. Unit Price Work—Work to be paid for on the basis of unit prices. 50. Work—The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. Ali rights reserved. Pape 4 of 62 00 72 05 construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. 51. Work Change Directive—A written statement to Contractor issued on or after the Effective Date of the Agreement and signed by Owner and recommended by Engineer ordering an addition, deletion, or revision in the Work, or responding to differing or unforeseen subsurface or physical conditions under which the Work is to be performed or to emergencies. A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the change ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times. 1.02 Terminology A. The words and terms discussed in Paragraph 1.02.B through F are not defined but, when used in the Bidding Requirements or Contract Documents, have the indicated meaning. B. Intent of Certain Terms or Adjectives: 1. The Contract Documents include the terms "as allowed," "as approved," "as ordered," "as directed" or terms of like effect or import to authorize an exercise of professional judgment by Engineer. In addition, the adjectives `reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of like effect or import are used to describe an action or determination of Engineer as to the Work. It is intended that such exercise of professional judgment, action, or determination will be solely to evaluate, in general, the Work for compliance with the information in the Contract Documents and with the design concept of the Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective is not intended to and shall not be effective to assign to Engineer any duty or authority to supervise or direct the performance of the Work, or any duty or authority to undertake responsibility contrary to the provisions of Paragraph 9.09 or any other provision of the Contract Documents. C. Day: 1. The word "day" means a calendar day of 24 hours measured from midnight to the next midnight. D. Defective: 1. The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it: a. does not conform to the Contract Documents; or b. does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents; or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page a of 62 00 72 05 c. has been damaged prior to Engineer's recommendation of final payment (unless responsibility for the protection thereof has been assumed by Owner at Substantial Completion in accordance with Paragraph 14.04 or 14.05). E. Furnish, Install, Perform, Provide: 1. The word "furnish," when used in connection with services, materials, or equipment, shall mean to supply and deliver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install," when used in connection with services, materials, or equipment, shall mean to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3. The words "perform" or `provide," when used in connection with services, materials, or equipment, shall mean to furnish and install said services, materials, or equipment complete and ready for intended use. 4. When "furnish," "install," `perform," or "provide" is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of Contractor, "provide" is implied. F. Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2 — PRELIMINARY MATTERS 2.01 Delivery of Bonds and Evidence of Insurance A. When Contractor delivers the executed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner such bonds as Contractor may be required to furnish. B. Evidence of Insurance: Before any Work at the Site is started, Contractor and Owner shall each deliver to the other, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance which either of them or any additional insured may reasonably request) which Contractor and Owner respectively are required to purchase and maintain in accordance with Article 5. 2.02 Copies of Documents A. Owner shall fii nish to Contractor up to ten printed or hard copies of the Drawings and Project Manual. Additional copies will be furnished upon request at the cost of reproduction. 2.03 Commencement of Contract Times; Notice to Proceed A. The Contract Times will commence to run on the thirtieth day after the Effective Date of the Agreement or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the EJCDC C-700 standard General Conditions of the Construction Contract Copyright @ 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 6 of 62 00 72 05 Agreement. In no event will the Contract Times commence to run later than the sixtieth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date is earlier. 2.04 Starting the Work A. Contractor shall start to perform the Work on the date when the Contract Times commence to run. No Work shall be done at the Site prior to the date on which the Contract Times commence to run. 2.05 Before Starting Construction A. Preliminary Schedules: Within 10 days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), Contractor shall submit to Engineer for timely review: 1. a preliminary Progress Schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2. a preliminary Schedule of Submittals; and 3. a preliminary Schedule of Values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. 2.06 Preconstruction Conference; Designation of Authorized Representatives A. Before any Work at the Site is started, a conference attended by Owner, Contractor, Engineer, and others as appropriate will be held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to in Paragraph 2.05.A, procedures for handling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. B. At this conference Owner and Contractor each shall designate, in writing, a specific individual to act as its authorized representative with respect to the services and responsibilities under the Contract. Such individuals shall have the authority to transmit instructions, receive information, render decisions relative to the Contract, and otherwise act on behalf of each respective party. 2.07 Initial Acceptance of Schedules A. At least 10 days before submission of the first Application for Payment a conference attended by Contractor, Engineer, and others as appropriate will be held to review for acceptability to Engineer as provided below the schedules submitted in accordance with Paragraph 2.05.A. Contractor shall have an additional 10 days to make corrections and adjustments and to EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 7 of 62 00 72 05 complete and resubmit the schedules. No progress payment shall be made to Contractor until acceptable schedules are submitted to Engineer. 1. The Progress Schedule will be acceptable to Engineer if it provides an orderly progression of the Work to completion within the Contract Times. Such acceptance will not impose on Engineer responsibility for the Progress Schedule, for sequencing, scheduling, or progress of the Work, nor interfere with or relieve Contractor from Contractor's full responsibility therefor. 2. Contractor's Schedule of Submittals will be acceptable to Engineer if it provides a workable arrangement for reviewing and processing the required submittals. 3. Contractor's Schedule of Values will be acceptable to Engineer as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. ARTICLE 3 — CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.01 Intent A. The Contract Documents are complementary; what is required by one is as binding as if required by all. B. It is the intent of the Contract Documents to describe a functionally complete project (or part thereof) to be constructed in accordance with the Contract Documents. Any labor, documentation, services, materials, or equipment that reasonably may be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the indicated result will be provided whether or not specifically called for, at no additional cost to Owner. C. Clarifications and interpretations of the Contract Documents shall be issued by Engineer as provided in Article 9. 3.02 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations 1. Reference to standards, specifications, manuals, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. 2. No provision of any such standard, specification, manual, or code, or any instruction of a Supplier, shall be effective to change the duties or responsibilities of Owner, Contractor, or Engineer, or any of their subcontractors, consultants, agents, or employees, from those set forth in the Contract Documents. No such provision or instruction shall be effective to assign to Owner, Engineer, or any of their officers, directors, members, partners, EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page S of 62 fiIfWM79 employees, agents, consultants, or subcontractors, any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies: 1. Contractor's Review of Contract Documents Before Starting Work: Before undertaking each part of the Work, Contractor shall carefully study and compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error, ambiguity, or discrepancy which Contractor discovers, or has actual knowledge of, and shall obtain a written interpretation or clarification from Engineer before proceeding with any Work affected thereby. 2. Contractor's Review of Contract Documents During Performance of Work. If, during the performance of the Work, Contractor discovers any conflict, error, ambiguity, or discrepancy within the Contract Documents, or between the Contract Documents and (a) any applicable Law or Regulation , (b) any standard, specification, manual, or code, or (c) any instruction of any Supplier, then Contractor shall promptly report it to Engineer in writing. Contractor shall not proceed with the Work affected thereby (except in an emergency as required by Paragraph 6.16.A) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in Paragraph 3.04. 3. Contractor shall not be liable to Owner or Engineer for failure to report any conflict, error, ambiguity, or discrepancy in the Contract Documents unless Contractor had actual knowledge thereof. B. Resolving Discrepancies: 1. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and: a. the provisions of any standard, specification, manual, or code, or the instruction of any Supplier (whether or not specifically incorporated by reference in the Contract Documents); or b. the provisions of any Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Documents would result in violation of such Law or Regulation). 3.04 Amending and Supplementing Contract Documents A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof by either a Change Order or a Work Change Directive. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 9 of 62 00 72 05 B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may be authorized, by one or more of the following ways: 1. A Field Order; 2. Engineer's approval of a Shop Drawing or Sample (subject to the provisions of Paragraph 6.17.D.3); or 3. Engineer's written interpretation or clarification. 3.05 Reuse of Documents A. Contractor and any Subcontractor or Supplier shall not: 1. have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of Engineer or its consultants, including electronic media editions; or 2. reuse any such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of Owner and Engineer and specific written verification or adaptation by Engineer. B. The prohibitions of this Paragraph 3.05 will survive final payment, or termination of the Contract. Nothing herein shall preclude Contractor from retaining copies of the Contract Documents for record purposes. 3.06 Electronic Data A. Unless otherwise stated in the Supplementary Conditions, the data furnished by Owner or Engineer to Contractor, or by Contractor to Owner or Engineer, that may be relied upon are limited to the printed copies (also known as hard copies). Files in electronic media format of text, data, graphics, or other types are furnished only for the convenience of the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. B. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60 -day acceptance period will be corrected by the transferring party. C. When transferring documents in electronic media format, the transferring party makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the data's creator. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 10 of 62 00 72 05 ARTICLE 4 — AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; HAZARDOUS ENVIRONMENTAL CONDITIONS; REFERENCE POINTS 4.01 Availability of Lands A. Owner shall furnish the Site. Owner shall notify Contractor of any encumbrances or restrictions not of general application but specifically related to use of the Site with which Contractor must comply in performing the Work. Owner will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. If Contractor and Owner are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, as a result of any delay in Owner's famishing the Site or a part thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. B. Upon reasonable written request, Owner shall filrnish Contractor with a current statement of record legal title and legal description of the lands upon which the Work is to be performed and Owner's interest therein as necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with applicable Laws and Regulations. C. Contractor shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. 4.02 Subsurface and Physical Conditions A. Reports and Drawings: The Supplementary Conditions identify: 1. those reports known to Owner of explorations and tests of subsurface conditions at or contiguous to the Site; and 2. those drawings known to Owner of physical conditions relating to existing surface or subsurface structures at the Site (except Underground Facilities). B. Limited Reliance by Contractor on Technical Data Authorized- Contractor may rely upon the accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions, or information. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. Ali rights reserved. Page 11 of 52 00 72 05 4.03 Differing Subsurface or Physical Conditions A. Notice: If Contractor believes that any subsurface or physical condition that is uncovered or revealed either: 1. is of such a nature as to establish that any "technical data" on which Contractor is entitled to rely as provided in Paragraph 4.02 is materially inaccurate; or 2. is of such a nature as to require a change in the Contract Documents; or 3. differs materially from that shown or indicated in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then Contractor shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), notify Owner and Engineer in writing about such condition. Contractor shall not further disturb such condition or perform any Work in connection therewith (except as aforesaid) until receipt of written order to do so. B. Engineer's Review: After receipt of written notice as required by Paragraph 4.03.A, Engineer will promptly review the pertinent condition, determine the necessity of Owner's obtaining additional exploration or tests with respect thereto, and advise Owner in writing (with a copy to Contractor) of Engineer's findings and conclusions. C. Possible Price and Times Adjustments: 1. The Contract Price or the Contract Times, or both, will be equitably adjusted to the extent that the existence of such differing subsurface or physical condition causes an increase or decrease in Contractor's cost of, or time required for, performance of the Work; subject, however, to the following: a. such condition must meet any one or more of the categories described in Paragraph 4.03.A; and b. with respect to Work that is paid for on a unit price basis, any adjustment in Contract Price will be subject to the provisions of Paragraphs 9.07 and 11.03. 2. Contractor shall not be entitled to any adjustment in the Contract Price or Contract Times if. a. Contractor knew of the existence of such conditions at the time Contractor made a final commitment to Owner with respect to Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract; or b. the existence of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, exploration, test, or study of the Site and EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee 12 of 62 7205 contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for Contractor prior to Contractor's making such final commitment; or c. Contractor failed to give the written notice as required by Paragraph 4.03.A. 3. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, a Claim may be made therefor as provided in Paragraph 10.05. However, neither Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors shall be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. 4.04 Underground Facilities A. Shown or Indicated. The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the Site is based on information and data furnished to Owner or Engineer by the owners of such Underground Facilities, including Owner, or by others. Unless it is otherwise expressly provided in the Supplementary Conditions: 1. Owner and Engineer shall not be responsible for the accuracy or completeness of any such information or data provided by others; and 2. the cost of all of the following will be included in the Contract Price, and Contractor shall have full responsibility for: a. reviewing and checking all such information and data; b. locating all Underground Facilities shown or indicated in the Contract Documents; c. coordination of the Work with the owners of such Underground Facilities, including Owner, during construction; and d. the safety and protection of all such Underground Facilities and repairing any damage thereto resulting from the Work. B. Not Shown or Indicated. 1. If an Underground Facility is uncovered or revealed at or contiguous to the Site which was not shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, Contractor shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), identify the owner of such Underground Facility and give written notice to that owner and to Owner and Engineer. Engineer will promptly review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to reflect and document the EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee 13 of 62 05 consequences of the existence or location of the Underground Facility. During such time, Contractor shall be responsible for the safety and protection of such Underground Facility. 2. If Engineer concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflect and document such consequences. An equitable adjustment shall be made in the Contract Price or Contract Times, or both, to the extent that they are attributable to the existence or location of any Underground Facility that was not shown or indicated or not shown or indicated with reasonable accuracy in the Contract Documents and that Contractor did not know of and could not reasonably have been expected to be aware of or to have anticipated. if Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment in Contract Price or Contract Times, Owner or Contractor may make a Claim therefor as provided in Paragraph 10.05. 4.05 Reference Points A. Owner shall provide engineering surveys to establish reference points for construction which in Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.06 Hazardous Environmental Condition at Site A. Reports and Drawings: The Supplementary Conditions identify those reports and drawings known to Owner relating to Hazardous Environmental Conditions that have been identified at the Site. B. Limited Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences and procedures of construction to be employed by Contractor and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions or information. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright (ED 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 14 of 62 00 72 05 C. Contractor shall not be responsible for any Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work. Contractor shall be responsible for a Hazardous Environmental Condition created with any materials brought to the Site by Contractor, Subcontractors, Suppliers, or anyone else for whom Contractor is responsible. D. If Contractor encounters a Hazardous Environmental Condition or if Contractor or anyone for whom Contractor is responsible creates a Hazardous Environmental Condition, Contractor shall immediately: (i) secure or otherwise isolate such condition; (ii) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by Paragraph 6.16.A); and (iii) notify Owner and Engineer (and promptly thereafter confirm such notice in writing). Owner shall promptly consult with Engineer concerning the necessity for Owner to retain a qualified expert to evaluate such condition or take corrective action, if any. Promptly after consulting with Engineer, Owner shall take such actions as are necessary to permit Owner to timely obtain required permits and provide Contractor the written notice required by Paragraph 4.06.E. E. Contractor shall not be required to resume Work in connection with such condition or in any affected area until after Owner has obtained any required permits related thereto and delivered written notice to Contractor: (i) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work; or (ii) specifying any special conditions under which such Work may be resumed safely. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, or both, as a result of such Work stoppage or such special conditions under which Work is agreed to be resumed by Contractor, either party may make a Claim therefor as provided in Paragraph 10.05. F. If after receipt of such written notice Contractor does not agree to resume such Work based on a reasonable belief it is unsafe, or does not agree to resume such Work under such special conditions, then Owner may order the portion of the Work that is in the area affected by such condition to be deleted from the Work. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of an adjustment in Contract Price or Contract Times as a result of deleting such portion of the Work, then either party may make a Claim therefor as provided in Paragraph 10.05. Owner may have such deleted portion of the Work performed by Owner's own forces or others in accordance with Article 7. G. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hazardous Environmental Condition: (i) was not shown or indicated in the Drawings or Specifications or identified in the Contract Documents to be included within the scope of the Work, and (ii) was not created by Contractor or by anyone for whom Contractor is EJCDC C-704 standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace 15 of 62 00 72 05 responsible. Nothing in this Paragraph 4.06.G shall obligate Owner to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. H. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.H shall obligate Contractor to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. I. The provisions of Paragraphs 4.02, 4.03, and 4.04 do not apply to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 5 — BONDS AND INSURANCE 5.01 Performance, Payment, and Other Bonds A. Contractor shall furnish performance and payment bonds, each in an amount at least equal to the Contract Price as security for the faithful performance and payment of all of Contractor's obligations under the Contract Documents. These bonds shall remain in effect until one year after the date when final payment becomes due or until completion of the correction period specified in Paragraph 13.07, whichever is later, except as provided otherwise by Laws or Regulations or by the Contract Documents. Contractor shall also furnish such other bonds as are required by the Contract Documents. B. All bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All bonds signed by an agent or attorney-in-fact must be accompanied by a certified copy of that individual's authority to bind the surety. The evidence of authority shall show that it is effective on the date the agent or attorney-in-fact signed each bond. C. If the surety on any bond furnished by Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in any state where any part of the Project is located or it ceases to meet the requirements of Paragraph 5.01.B, Contractor shall promptly notify Owner and Engineer and shall, within 20 days after the event giving rise to such notification, provide another bond and surety, both of which shall comply with the requirements of Paragraphs 5.01.B and 5.02. 5.02 Licensed Sureties and Insurers A. All bonds and insurance required by the Contract Documents to be purchased and maintained by Owner or Contractor shall be obtained from surety or insurance companies that are duly EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 16 of 62 0072 05 ALLIEI2 OP ID: BL DATE (MMJDD(YYYY) CERTIFICATE OF LIABILITY INSURANCE 07131/14 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(iss) must be endorsed. If SUBROGATION IS WAIVED, sub]'eat to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). —CONTACT PRODUCER Phone: 952-996-8618 NBrenda L Parker AME: Narth'ern Capital insurance Gro Fax: 952-829-0482 N E ; 952-996-8866 No): 952-82FAI 9-0482 Wayne Mann Agency P.O. Box 9396 AODRLEss: brendaparker@northerncapital-mn.com Mlnneapalls, MN 55440-9396 Paul Domaas INSURER(s) AFFORDING COVERAGE Nous s PISURI RA: Harleysville Insurance Co. - 23582 INSURED Allied Blacktop Company INSURER B: TBG Markel Ins. Co. 10503 89th Avenue No INSURERC: Maple Grove, MN 55369 . INSl1RER D � --- INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO C_ ERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR 01 -HER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED. HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONSAND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAYHAVE BEEN REDUCED BY PAID CLAIMS. ILS TYPE OF INSURANCE GENERAL LIABILITY POLICY NUMBER MIDO MMIO LIMITS EACH OCCURRENCE $ 1,000,00 DA AO RLNTEU PREMISES Ea occurrence $ 300,000 A X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE ® OCCUR X BLKT ADDTL INSD MPA79618E. CG7254 (12110) 04130114 04130175 MED EXP (Any one person) $ 15,000 PERSONAL a ADV INJURY $ 1,000,000 X CMPLTD OPS AA GENERAL AGGREGATE $ 2,000,00 C07263 (12110) FEN -L AGGREGATE LIMIT APPLIES PER POLICYFXJ PRO- L] LOC JECT-. AUTOMOBILE LIABILITY PRODUCTS- COMPIOP AGG $ 2,000,000 PD DED $ CEOs aBINED SINGLE LIMIT$ 500 1,000,00 BODILY INJURY'(Perperson) $ A X ANY ALTO ALL OWNEDSCHEDULED AUTOSAUTOS ' NON -OWNED X HIRED AUTOS X AUTOS BA827777E 04130/14 04/30115 BODILY INJURY (Per ecddenL) $ PERTY DAMA. $ Peraccitlent A X UMBRELLA LIAR' X OCCUR EXCESS LrAe CLAIM.&MADE CMB82749E 04/30114 .04130115 EACH OCCURRENCE $ 5,000,00 'AGGREGATE $ 5,000,000 UID X I RETENTION $ 10,000 *C RS COMPENSATION $ X ORY'IMIT I OTH- WCSWo B AND EMPLOYERS' LIABILITY ANY PROPRIETORJPARTNERJEXECUTIVE Y J N OFFICER"EMBER.E>(CLUDED7 (Mandatory in Nil) If yes, describe under DESCRIPTION OF OPERATIONS belaar NIA 12-0000303 01/01/14 01141115 E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE• EA EMPLOYEE $ 1,000,000 E.L. DISEASE- POLICY LIMIT $ 1,000,000 A JEquipment Floater MPA79818E 04/30114 04130415 Equipment Q Rental Equipment MPA7961SE Blanket 2,385,977 175,00 DESCRIPTION OF OPERATIC NS J LOCATIONS I VERCLES (Attach ACORD 101, Additional Remarks Schedule, If more space Is requirede City of blew Hope and Engineer (Stanec Cons-ulting) are included as additional insured on the general liability insurance wizen required by written contract/agreement, and provided the contract was executed prior to a loss. Re.: 2014 Crack Repair & Seal Coat, Project Number 930, Project #: 193802836 CERTIFICATE HOLDER CANCELLATION CITNE-3 SHOULD ANY OF THE ABOVE DESCRIBED POLICES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of New Hope ACCORDANCE WITH THE POLICY PROVISIONS. 4401 Xyion Avenue N New Hope, MN 55428 AUrHORIZEDREPRESENTATIYE O 1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010105) The ACORD name and logo are registered marks of ACORD PERFORNUN CE BOND Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. CONTRACTOR (Name and Address) Allied Blacktop Company 10503 - 89th Avenue North Maple Grove, MN 55369 OWNER (Name and Address): City of New Hope 4401 %ylon Avenue North New Hope, MN 55428 SURETY (Name, and Address of Principal Place of Business): Western Surety Company 101 South Phillips Avenue Sioux Falls. SD 57104 CONTRACT Effective Date of Agreement: July 29, 2014 Amount: $307,140.00 Description (Name and Location): 2014 Crack Repair & Seal Coat City Project No. 930 BOND City of New Hope, MN Bond Number: 929598951 Date (Not earlier than effective Date of August 4, 2014 Agreement): Amount: $307,140.00 Modifications to this Bond Form: NONE Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause this Performance Bond to be duly executed by an authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL �Yi 9AgI _ Allied Blacktop CompoMy (Seal) Western Surety Cam an (Seal) Contractor's Name and Corporate Seal Surety's Nam d orp t a C By:P07�—MBy: Signature Signa (Attach Power of Attorney) Qom- M r� Print Name Attest: Signature _ 1rj0nnS6! -- Title ;john G. HaRbere ^Print Name Attorney -in -Fact Title Attest: Signator Witness Title Note: Provide execution by additional parties, such as joint venturers, if necessary. EJCDC C -6I0 Performance Bond (2007) Prepared by the Engineers Joint Contract Documents Committee. 0061i113F%geI of3 Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to Owner for the performance of the Contract, which is incorporated herein by reference. 1. If Contractor perforins the Contract, Surety and Contractor have no obligation under this Bond, except to participate in conferences as provided in Paragraph 2.1. 2. If there is no Owner Default, Surety's obligation under this Bond shall arise after: 2.1 Owner has notified Contractor and Surety, at the addresses described in Paragraph 9 below, that Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with Contractor and Surety to be held not later than 15 days after receipt of such notice to discuss methods of performing the Contract. If Owner, Contractor, and Surety agree, Contractor shall be allowed a reasonable time to perform the Contract, but such an agreement shall not waive Owner's right, if any, subsequently to declare a Contractor Default; and 2.2 Owner has declared a Contractor Default and formally terminated Contractor's right to complete the Contract. Such Contractor Default shall not be declared earlier than 24 days after Contractor and Surety have received notice as provided in Paragraph 2.1; and 2.3 Owner has agreed to pay the Balance of the Contract Price to: 1. Surety in accordance with the terms of the Contract; or 2. Another contractor selected pursuant to Paragraph 3.3 to perform the Contract. 3. When Owner has satisfied the conditions of Paragraph 2, Surety shall promptly, and at Surety's expense, take one of the following actions: 3.1 Arrange for Contractor, with consent of Owner, to perform and complete the Contract; or 3.2 Undertake to perform and complete the Contract itself, through its agents or through independent contractors; or 3.3 Obtain bids or negotiated proposals from qualified contractors acceptable to Owner for a contract for performance and completion of the Contract, arrange for a contract to be prepared for execution by Owner and contractor selected with Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Contract, and pay to Owner the amount of damages as described in Paragraph 5 in excess of the Balance of the Contract Price incurred by Owner resulting from Contractor Default; or 3.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor, and with reasonable promptness under the circumstances: 1. After investigation, determine the amount for which it may be liable to Owner and, as soon as practicable after the amount is determined, tender payment therefor to Owner; or 2. Deny liability in whole or in part and notify Owner citing reasons therefor. 4. If Surety does not proceed as provided in Paragraph 3 with reasonable promptness, Surety shall be deemed to be in default on this Bond 15 days after receipt of an additional written notice from Owner to Surety demanding that Surety perform its obligations under this Bond, and Owner shall be entitled to enforce any remedy available to Owner. If Surety proceeds as provided in Paragraph 3.4, and Owner refuses the payment tendered or Surety has denied liability, in whole or in part, without ffxrther notice Owner shall be entitled to enforce any remedy available to Owner. 5. After Owner has terminated Contractor's right to complete the Contract, and if Surety elects to act under Paragraph 3.1, 3.2, or 3.3 above, then the responsibilities of Surety to Owner shall not be greater than those of Coratractor under the Contract, and the responsibilities of Owner to Surety shall not be greater than those of Owner under the Contract. To the limit of the amount of this Bond, but subject to commitment by Owner of the Balance of the Contract Price to mitigation of costs and damages on the Contract, Surety is obligated without duplication for: EJCDC C-610 Performance Bond (2007) Prepared by the Engineers Joint Contract documents Committee. 00 6113.13 Page 2 of 3 5.1 The responsibilities of Contractor for correction of defective Work and completion of the Contract? 5.2 Additional legal, design professional, and delay costs resulting from Contractor's Default, and resulting from the actions of or failure to act of Surety under Paragraph 3; and 5.3 Liquidated damages, or if no liquidated damages are specified in the Contract, actual damages caused by delayed performance or non-performance of Contractor. 6. Surety shall not be liable to Owner or others for obligations of Contractor that are unrelated to the Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Boyd to any person or entity other than Owner or its heirs, executors, administrators, or successors. 7. Surety hereby waives notice of any change, including changes of time, to Contract or to related subcontracts, purchase orders, and other obligations. 8. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the Work or part of the Work is located, and shall be instituted within two years after Contractor Default or within two years after Contractor ceased working or within two years after Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 9. Notice to Surety, Owner, or Contractor shall be mailed or delivered to the address shown on the signature page. 10. When this Bond has been furnished to comply with a statutory requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory requirement shall be deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 11. Definitions. 11.1 Balance of the Contract Price: The total amount payable by Owner to Contractor under the Contract after all proper adjustments have been made, including allowance to Contractor of any amounts received or to be received by Owner in settlement of insurance or other Claims for damages to which Contractor is entitled, reduced by all valid and proper payments made to or on behalf of Contractor under the Contract. 11.2 Contract: The agreement between Owner and Contractor identified on the signature page, including all Contract Documents and changes thereto. 11.3 Contractor Default: Failure of Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Contract_ 11.4 Owner Default: Failure of Owner, which has neither been remedied nor waived, to pay Contractor as required by the Contract or to perform and complete or otherwise comply with the other terms thereof. FOR INFORMATION ONLY - (Name, Address and Telephone) Northern Capital Insurance P.O. Box 9396 Surety Agency or Broker: Minneapolis, MN 55440-9396 Owner's Re resentative En ineer or other r : Telephone: 952-996-8829 EJCDC C-610 Performance Bond (2007) Prepared by the Engineers Joint Contract Documents Committee. 00 6113.13 Paze 3 of 3 PAYME;, s Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): Allied Blacktop Company 10503 — 89th Avenue North Maple Grove, MN 55369 OWNER (Name and Address): City of New Hope A401HXeonAv 8North CO1, Effective Date of Agreement: July 29, 2014 Amount: $307,140.00 SURETY (Naive, and Address of Principal Place of Business): Western Surety Company 101 South Phillips Avenue Sioux Falls, SD 57104 Description (Name and Location): 2014 Crack Repair & Seal Coat City Poject No. 930 BOND City of New Hope, MN Bond Number: 929598951 Date (Not earlier than Effective Date of August 4, 2014 Agreement): Amount: $307,140.00 Modifications to this Bond Form: NONE Surety and Contractor, intending to be legally bound hereby, subject to the tends set forth below, do each cause this Payment Bond to be duly executed by an authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL SURETY Allied Blacktop Company (Seal) Western Surety Com an (Seal) Contract 's Name and Corporate Seal Surety's Name d C a C By: L%r77�By: Signature Sign/6e (Attach Po of Attorney) P- �A Print Name ' � ,�f/i//� vrrifir�s�s Title John G. Hagberg Print Name Attorney -in -Fact Title Attest: I�A ��� S ignatur Witness Title Note: Provide execution by additional parties, such as joint venturers, f necessary. EJCDC C-615 Payment Bond (2007) Prepared by the Engineers Joint Contract Documents Committee. 006113.16P eIof3 1. Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to Owner to pay for labor, materials, and equipment finmished by Claimants for use in the performance of the Contract, which is incorporated herein by reference. 2. With respect to Owner, this obligation shall be null and void if Contractor: 2.1 Promptly makes payment, directly or indirectly, for all sums due Claimants, and 2.2 Defends, indemnifies, and holds harmless Owner from all claims, demands, liens, or suits alleging non-payment by Contractor by any person or entity who furnished labor, materials, or equipment for use in the performance of the Contract, provided Owner has promptly notified Contractor and Surety (at the addresses described in Paragraph 12) of any claims, demands, liens, or suits and tendered defense of such claims, demands, liens, or suits to Contractor and Surety, and provided there is no Owner Default. 3. With respect to Claimants, this obligation shall be null and void if Contractor promptly makes payment, directly or indirectly, for all sums due. 4. Surety shall have no obligation to Claimants under this Bond until: 4.1 Claimants who are employed by or have a direct contract with Contractor have given notice to Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2 Claimants who do not have a direct contract with Contractor: I . Have furnished written notice to Contractor and sent a copy, or notice thereof, to Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials or equipment were furnished or supplied, or for whom the labor was done or performed; and 2. Have either received a rejection in whole or in part from Contractor, or not received within 30 days of furnishing the above notice any communication from Contractor by which Contractor had indicated the claim will be paid directly or indirectly; and 3. Not having been paid within the above 30 days, have sent a written notice to Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to Contractor. 5. If a notice by a Claimant required by Paragraph 4 is provided by Owner to Contractor or to Surety, that is sufficient compliance. 6. When a Claimant has satisfied the conditions of Paragraph 4, the Surety shall promptly and at Surety's expense take the following actions: 6.1 Send an answer to that Claimant, with a copy to Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed. 6.2 Pay or arrange for payment of any undisputed amounts. 7. Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by Surety. 8. Amounts owed by Owner to Contractor under the Contract shall be used for the performance of the Contract and to satisfy claims, if any, under any performance bond. By Contractor furnishing and Owner accepting this Bond, they agree that all funds earned by Contractor in the performance of the Contract are dedicated to satisfy obligations of Contractor and Surety under this Bond, subject to Owner's priority to use the funds for the completion of the Work. EJCDC C-615 Payment Bond (2007) Prepared by the Engineers Joint Contract Docaments Committee. 00 6113-16 Page 2 of 3 9. Surety shall not be liable to Owner, Claimants, or others for obligations of Contractor that are unrelated to the Contract. Owner shall not be liable for payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligations to make payments to, give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 10. Surety hereby waives notice of any change, including changes of time, to the Contract or to related subcontracts, purchase orders, and other obligations. 11. No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the location in which the Work or part of the Work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by Paragraph 4.1 or Paragraph 4.2.3, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Contract, whichever of (1) or (2) first occurs. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12. Notice to Surety, Owner, or Contractor shall be mailed or delivered to the addresses shown on the signature page. Actual receipt of notice by Surety, Owner, or Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13. When this Bond has been furnished to comply with a statutory requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory requirement shall be deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory Bond and not as a common law bond. 14. Upon request of any person or entity appearing to be a potential beneficiary of this Bond, Contractor shall promptly furnish a copy of this Bond or shall permit a copy to be made. 15. Definitions 15.1 Claimant: An individual or entity having a direct contract with Contractor, or with a first-tier subcontractor of Contractor, to furnish labor, materials, or equipment for use in the performance of the Contract. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service, or rental equipment used in the Contract, architectural and engineering services required for performance of the Work of Contractor and Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials, or equipment were furnished. 15.2 Contract: The agreement between Owner and Contractor identified on the signature page, including all Contract Documents and changes thereto. 15.3 Owner Default: Failure of Owner, which has neither been remedied nor waived, to pay Contractor as required by the Contract, nr to perform and complete nr otherwke comply with the other terms thereof. FOR INFORMATION ONLY -- (Name, Address, and Telephone) Northern Capital insurance Surety Agency or Broker: P • 0 • Box 9396 Representative (Engineer or other): Minneapolis MN 55440-9396 Owner's Rrese e� -e - ) Telephone: 452-996-8829 EJCDC C-615 Payment Bond (2007) Prepared by the Engineers Joint Contract Documents Committee. 00 61 13.16 Page3of3 STAT OF_ COUNTY OF ACKNOWLEDGMENT OF PRINCIPAL (individual) ss.: On this day oi, in the year . before me personalty comes) to me known and known to me to be the person(s) who (is) (are) described in and who executed the ioreping instrument and s&nowladg.W to me that he executed the same. NOTARY PUBLIC ACKNOWLEDGMENT OF PRINCIPAL (Partnership) STATE OF .. _ COUNTY OF On this day of , in the year _ before me personally corne(s) a member of the co -partnership of ;o me [mown and known to me to be the person who is described in and who executed the foregoing instrument, and acknowledges to me that he executed the sar;+e as and For the act and deed of the said co -partnership. NOTA RY P ua LI C ACKNOWLEDGMENT OF PRINCIPAL {Corporation; A +ra-ft E 0:4400, M On in the year 2Q4 before me personally come(s) Nil i ?7]i &-fYr2wr- to me known, wh being bygma duly sworn, deposis and says that he resides in the Ci of that he is they, sl.� of the the corporation described in and which executed the foregoing instrument; that he knows the seal of tha said corps tion, that the seal affixed to the said instrument is such corporate seal; that it was so affixed by the order of the Board of Directors of said corporation, and that he signed his name thereto by line order. a M\^+ti %e.W.N .. , ..-.-"W'-'VVVVVVVW s �~ NAOMI N. A. BRETZ NOTARY PUBLIG•MIIVNE50TA NOTARY FUSUC = ff' k1yron;missionExpiresJan.31,2015 ACKNOWLEDGMENT OF SURETY 3 w STATE OF _ Minmesota COUNT Y OF . He=giain on this 4 day of August , in the year 2014 _ before me Personally come(s) John G. _Hacrbercr Attomey(s)-in•Fact of _ _ Western Surety Comply- - _ with whom I am personally acquainted, and who, being by me duly sworn, says that he reside(s) in PI uth, 'MN that he is (are) the Attorneys) -in -Fact of Western Surety Coma any company described in and which- executed the within instrument; that he know(s) the corporate seal of such Company; and that the seal affixed to the within instrument Is such corporate seal srld that it was affixed by order of the Board of Directors of said Company, and that he signed said instrument as Attorney(s)-in-Fact of he said parry by like order. DONNAJOYCEHAGBERG ArOiARY P LIG F.$:: 3 — =1a! p, NOTANPII9UG-MINNESOTA W OOMMISSION DR0 00112016 Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These Presents, That WESTERN SURETY COMPANY,.a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint John G Hagberg, Judith L Jorissen, Garth R Fisher, Individually of Bloomington, MN, its true and lawful Attorneys) -in -Pact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 28th day of April, 2014. yuRerr WESTERN SURETY COMPANY o X ;za�__ EA%. aul T. Bruflat, Vice President State of South Dakota 1 County of Minnehaha I ss On this 28th day of April, 7014, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires • ' J. MOHR June 23, 2015N07Arrr Puauc SOUTH DAKOTA SEAL SEAL I. Mohr, Notary Public CERTIFICATE 1, L Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this 4 day of August 2014 '�`E'�'e WESTERN SURETY COMPANY _X MEQx-wi ; lk L. Nelson, Assistant Secretary Form F4280-7-2012 Authorizing By -Law ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. licensed or authorized in the jurisdiction in which the Project is located to issue bonds or insurance policies for the limits and coverages so required. Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided in the Supplementary Conditions. 5.03 Certificates of Insurance A. Contractor shall deliver to Owner, with copies to each additional insured and loss payee identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Owner or any other additional insured) which Contractor is required to purchase and maintain. B. Owner shall deliver to Contractor, with copies to each additional insured and loss payee identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Contractor or any other additional insured) which Owner is required to purchase and maintain. C. Failure of Owner to demand such certificates or other evidence of Contractor's full compliance with these insurance requirements or failure of Owner to identify a deficiency in compliance from the evidence provided shall not be construed as a waiver of Contractor's obligation to maintain such insurance. D. Owner does not represent that insurance coverage and limits established in this Contract necessarily will be adequate to protect Contractor. E. The insurance and insurance limits required herein shall not be deemed as a limitation on Contractor's liability under the indemnities granted to Owner in the Contract Documents. 5.04 Contractor's Insurance A. Contractor shall purchase and maintain such insurance as is appropriate for the Work being performed and as will provide protection from claims set forth below which may arise out of or result from. Contractor's performance of the Work and Contractor's other obligations under the Contract Documents, whether it is to be performed by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers' compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of Contractor's employees; 3. claims for damages because of bodily injury, sickness or disease, or death of any person other than Contractor's employees; 4. claims for damages insured by reasonably available personal injury liability coverage which are sustained: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 17 of 62 00 72 05 a. by any person as a result of an offense directly or indirectly related to the employment of such person by Contractor, or b. by any other person for any other reason; 5. claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 6. claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle. B. The policies of insurance required by this Paragraph 5.04 shall: 1. with respect to insurance required by Paragraphs 5.04.A.3 through 5.04.A.6 inclusive, be written on an occurrence basis, include as additional insureds (subject to any customary exclusion regarding professional liability) Owner and Engineer, and any other individuals or entities identified in the Supplementary Conditions, all of whom shall be listed as additional insureds, and include coverage for the respective officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of all such additional insureds, and the insurance afforded to these additional insureds shall provide primary coverage for all claims covered thereby-, 2. include at least the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or required by Laws or Regulations, whichever is greater; 3. include contractual liability insurance covering Contractor's indemnity obligations under Paragraphs 6.11 and 6.20; 4. contain a provision or endorsement that the coverage afforded will not be canceled, materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance has been issued (and the certificates of insurance furnished by the Contractor pursuant to Paragraph 5.03 will so provide); 5. remain in effect at least until final payment and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work in accordance with Paragraph 13.07; and 6. include completed operations coverage: a. Such insurance shall remain in effect for two years after final payment. b. Contractor shall furnish Owner and each other additional insured identified in the Supplementary Conditions, to whom a certificate of insurance has been issued, evidence satisfactory to Owner and any such additional insured of continuation of such insurance at final payment and one year thereafter. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 18 of 62 00 72 05 5.05 Owner's Liability Insurance A. In addition to the insurance required to be provided by Contractor under Paragraph 5.04, Owner, at Owner's option, may purchase and maintain at Owner's expense Owner's own liability insurance as will protect Owner against claims which may arise from operations under the Contract Documents. 5.06 Property Insurance A. Unless otherwise provided in the Supplementary Conditions, Owner shall purchase and maintain property insurance upon the Work at the Site in the amount of the full replacement cost thereof (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). This insurance shall: 1. include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as a loss payee; 2. be written on a Builder's Risk "all-risk" policy form that shall at least include insurance for physical loss or damage to the Work, temporary buildings, falsework, and materials and equipment in transit, and shall insure against at least the following perils or causes of loss: fire, lightning, extended coverage, theft, vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, water damage (other than that caused by flood), and such other perils or causes of loss as may be specifically required by the Supplementary Conditions. 3. include expenses incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers and architects); 4. cover materials and equipment stored at the Site or at another location that was agreed to in writing by Owner prior to being incorporated in the Work, provided that such materials and equipment have been included in an Application for Payment recommended by Engineer; 5. allow for partial utilization of the Work by Owner; 6. include testing and startup; and 7. be maintained in effect until final payment is made unless otherwise agreed to in writing by Owner, Contractor, and Engineer with 30 days written notice to each other loss payee to whom a certificate of insurance has been issued. B. Owner shall purchase and maintain such equipment breakdown insurance or additional property insurance as may be required by the Supplementary Conditions or Laws and Regulations which will include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, E+JCDC C-700 Standard General Conditions of the Construction Contract Copyright Chi 2007 National Society of Professional Engineers for EJCDC. Alt rights reserved. Page 19 of 62 007205 members, partners, employees, agents, consultants and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as a loss payee. C. All the policies of insurance (and the certificates or other evidence thereof) required to be purchased and maintained in accordance with this Paragraph 5.06 will contain a provision or endorsement that the coverage afforded willnot be canceled or materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other loss payee to whom a certificate of insurance has been issued and will contain waiver provisions in accordance with Paragraph 5.07. D. Owner shall not be responsible for purchasing and maintaining any property insurance specified in this Paragraph 5.06 to protect the interests of Contractor, Subcontractors, or others in the Work to the extent of any deductible amounts that are identified in the Supplementary Conditions. The risk of loss within such identified deductible amount will be borne by Contractor, Subcontractors, or others suffering any such loss, and if any of them wishes property insurance coverage within the limits of such amounts, each may purchase and maintain it at the purchaser's own expense. E. If Contractor requests in writing that other special insurance be included in the property insurance policies provided under this Paragraph 5.06, Owner shall, if possible, include such insurance, and the cost thereof will be charged to Contractor by appropriate Change Order. Prior to commencement of the Work at the Site, Owner shall in writing advise Contractor whether or not such other insurance has been procured by Owner. 5.07 Waiver of Rights A. Owner and Contractor intend that all policies purchased in accordance with Paragraph 5.06 will protect Owner, Contractor, Subcontractors, and Engineer, and all other individuals or entities identified in the Supplementary Conditions as loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) in such policies and will provide primary coverage for all losses and damages caused by the perils or causes of loss covered thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any of the insureds or loss payees thereunder. Owner and Contractor waive all rights against each other and their respective officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them for all losses and damages caused by, arising out of or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive all such rights against Subcontractors and Engineer, and all other individuals or entities identified in the Supplementary Conditions as loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) under such policies for losses and damages so caused. None of the above waivers shall extend to the rights that any party making such waiver may have to the proceeds of insurance held by Owner as trustee or otherwise payable under any policy so issued. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright B 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee 20 of 62 00 72 05 B. Owner waives all rights against Contractor, Subcontractors, and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them for: 1. loss due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to Owner's property or the Work caused by, arising out of, or resulting from fire or other perils whether or not insured by Owner; and 2. loss or damage to the completed Project or part thereof caused by, arising out of, or resulting from fire or other insured peril or cause of loss covered by any property insurance maintained on the completed Project or part thereof by Owner during partial utilization pursuant to Paragraph 14.05, after Substantial Completion pursuant to Paragraph 14.04, or after final payment pursuant to Paragraph 14.07. C. Any insurance policy maintained by Owner covering any loss, damage or consequential loss referred to in Paragraph 5.07.8 shall contain provisions to the effect that in the event of payment of any such loss, damage, or consequential loss, the insurers will have no rights of recovery against Contractor, Subcontractors, or Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them. 5.08 Receipt and Application of Insurance Proceeds A. Any insured loss under the policies of insurance required by Paragraph 5.06 will be adjusted with Owner and made payable to Owner as fiduciary for the loss payees, as their interests may appear, subject to the requirements of any applicable mortgage clause and of Paragraph 5.08.13. Owner shall deposit in a separate account any money so received and shall distribute it in accordance with such agreement as the parties in interest may reach. If no other special agreement is reached, the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof, and the Work and the cost thereof covered by an appropriate Change Order. B. Owner as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within 15 days after the occurrence of loss to Owner's exercise of this power. If such objection be made, Owner as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach. If no such agreement among the parties in interest is reached, Owner as fiduciary shall adjust and settle the loss with the insurers and, if required in writing by any party in interest, Owner as fiduciary shall give bond for the proper performance of such duties. 5.09 Acceptance of Bonds and Insurance; Option to Replace A. If either Owner or Contractor has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and maintained by the other parry in accordance with Article 5 on the basis of non-conformance with the Contract Documents, the objecting party shall so notify the other party in writing within 10 days after receipt of the certificates (or other evidence requested) required by Paragraph 2.01.13. Owner and Contractor shall each provide to the other such additional information in respect of insurance provided as the other may reasonably request. If either party does not purchase or maintain all of the bonds EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. AN rights reserved. Page 21 of 62 T 00 72 05 and insurance required of such party by the Contract Documents, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. Without prejudice to any other right or remedy, the other party may elect to obtain equivalent bonds or insurance to protect such other party's interests at the expense of the party who was required to provide such coverage, and a Change Order shall be issued to adjust the Contract Price accordingly. 5.10 Partial Utilization, Acknowledgment of Property Insurer A. If Owner finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in Paragraph 14.05, no such use or occupancy shall commence before the insurers providing the property insurance pursuant to Paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6 — CONTRACTOR'S RESPONSIBILITIES 6.01 Supervision and Superintendence A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. Contractor shall not be responsible for the negligence of Owner or Engineer in the design or specification of a specific means, method, technique, sequence, or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. B. At all times during the progress of the Work, Contractor shall assign a competent resident superintendent who shall not be replaced without written notice to Owner and Engineer except under extraordinary circumstances. 6.02 Labor; Working Hours A. Contractor shall provide competent, suitably qualified personnel to survey and lay out the Work and perform construction as required by the Contract Documents. Contractor shall at all times maintain good discipline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during regular working hours. Contractor will not permit the performance of Work on a Saturday, Sunday, or any legal holiday without Owner's written consent (which will not be unreasonably withheld) given after prior written notice to Engineer. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace 22 of 62 00 72 05 6.03 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start-up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit of Owner. If required by Engineer, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. C. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 6.04 Progress Schedule A. Contractor shall adhere to the Progress Schedule established in accordance with Paragraph 2.07 as it may be adjusted from time to time as provided below. 1. Contractor shall submit to Engineer for acceptance (to the extent indicated in Paragraph 2.07) proposed adjustments in the Progress Schedule that will not result in changing the Contract Times. Such adjustments will comply with any provisions of the General Requirements applicable thereto. 2. Proposed adjustments in the Progress Schedule that will change the Contract Times shall be submitted in accordance with the requirements of Article 12. Adjustments in Contract Times may only be made by a Change Order_ 6.05 Substitutes and "Or -Equals" A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or --equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be submitted to Engineer for review under the circumstances described below. 1. "Or -Equal" Items: If in Engineer's sole discretion an item of material or equipment proposed by Contractor is fimetionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by Engineer as an "or -equal" item, in which case review and approval of the proposed item may, in Engineer's sole discretion, be accomplished without compliance with some or all of the requirements EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. Allrights reserved. Page 23 of 62 00 72 05 for approval of proposed substitute items. For the purposes of this Paragraph 6.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if- a. f a. in the exercise of reasonable judgment Engineer determines that: 1) it is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; 2) it will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole; and 3) it has a proven record of performance and availability of responsive service. b. Contractor certifies that, if approved and incorporated into the Work: 1) there will be no increase in cost to the Owner or increase in Contract Times; and 2) it will conform substantially to the detailed requirements of the item named in the Contract Documents. 2. Substitute Items: a. If in Engineer's sole discretion an item of material or equipment proposed by Contractor does not qualify as an "or -equal" item under Paragraph 6.05.A.1, it will be considered a proposed substitute item. b. Contractor shall submit sufficient information as provided below to allow Engineer to determine if the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by Engineer from anyone other than Contractor. c. The requirements for review by Engineer will be as set forth in Paragraph 6.05.A.2.d, as supplemented by the General Requirements, and as Engineer may decide is appropriate under the circumstances. d. Contractor shall make written application to Engineer for review of a proposed substitute item of material or equipment that Contractor seeks to furnish or use. The application: 1) shall certify that the proposed substitute item will: a) perform adequately the functions and achieve the results called for by the general design, b) be similar in substance to that specified, and c) be suited to the same use as that specified; EJCDC C-700 Standard General Conditions of the Construction Contract Copyright Q 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 24 of 62 00 72 05 2) will state: a) the extent, if any, to which the use of the proposed substitute item will prejudice Contractor's achievement of Substantial Completion on time, b) whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for other work on the Project) to adapt the design to the proposed substitute item, and c) whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty; 3) will identify: a) all variations of the proposed substitute item from that specified, and b) available engineering, sales, maintenance, repair, and replacement services; and 4) shall contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and claims of other contractors affected by any resulting change. B. Substitute Construction Methods or Procedures: If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by Engineer. Contractor shall submit sufficient information to allow Engineer, in Engineer's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The requirements for review by Engineer will be similar to those provided in Paragraph 6.05.A.2. C. Engineer's Evaluation: Engineer will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs 6.05.A and 6.05.13. Engineer may require Contractor to furnish additional data about the proposed substitute item. Engineer will be the sole judge of acceptability. No "or equal" or substitute will be ordered, installed or utilized until Engineer's review is complete, which will be evidenced by a Change Order in the case of a substitute and an approved Shop Drawing for an "or equal." Engineer will advise Contractor in writing of any negative determination. D. Special Guarantee: Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. E. Engineer's Cost Reimbursement: Engineer will record Engineer's costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs 6.05.A.2 and 6.05.13. Whether or not Engineer approves a substitute so proposed or submitted by Contractor, Contractor shall reimburse Owner for the reasonable charges of Engineer for evaluating each such proposed substitute. Contractor shall also reimburse Owner for the reasonable charges of EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C) 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 25 of 62 007205 Engineer for making changes in the Contract Documents (or in the provisions of any other direct contract with Owner) resulting from the acceptance of each proposed substitute. F. Contractor's Expense: Contractor shall provide all data in support of any proposed substitute or "or -equal" at Contractor's expense. 6.06 Concerning Subcontractors, Suppliers, and Others A. Contractor shall not employ any Subcontractor, Supplier, or other individual or entity (including those acceptable to Owner as indicated in Paragraph 6A63), whether initially or as a replacement, against whom Owner may have reasonable objection. Contractor shall not be required to employ any Subcontractor, Supplier, or other individual or entity to furnish or perform any of the Work against whom Contractor has reasonable objection. B. If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers, or other individuals or entities to be submitted to Owner in advance for acceptance by Owner by a specified date prior to the Effective Date of the Agreement, and if Contractor has submitted a list thereof in accordance with the Supplementary Conditions, Owner's acceptance (either in writing or by failing to make written objection thereto by the date indicated for acceptance or objection in the Bidding Documents or the Contract Documents) of any such Subcontractor, Supplier, or other individual or entity so identified may be revoked on the basis of reasonable objection after due investigation. Contractor shall submit an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity, and the Contract Price will be adjusted by the difference in the cost occasioned by such replacement, and an appropriate Change Order will be issued. No acceptance by Owner of any such Subcontractor, Supplier, or other individual or entity, whether initially or as a replacement, shall constitute a waiver of any right of Owner or Engineer to reject defective Work. C. Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor's own acts and omissions. Nothing in the Contract Documents: 1. shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between Owner or Engineer and any such Subcontractor, Supplier or other individual or entity; nor 2. shall create any obligation on the part of Owner or Engineer to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or other individual or entity except as may otherwise be required by Laws and Regulations. D. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. E. Contractor shall require all Subcontractors, Suppliers, and such other individuals or entities performing or furnishing any of the Work to communicate with Engineer through Contractor. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 9 2007 National Society of Professional Engineers for EJCDC. All rights reserved. PaEe 26 of 62 00 72 05 F. The divisions and sections of the Specifications and the identifications of any Drawings shall not control Contractor in dividing the Work among Subcontractors or Suppliers or delineating the Work to be performed by any specific trade. G. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appropriate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of Owner and Engineer. Whenever any such agreement is with a Subcontractor or Supplier who is listed as a loss payee on the property insurance provided in Paragraph 5.06, the agreement between the Contractor and the Subcontractor or Supplier will contain provisions whereby the Subcontractor or Supplier waives all rights against Owner, Contractor, Engineer, and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or loss payees (and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them) for all losses and damages caused by, arising out of, relating to, or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work. If the insurers on any such policies require separate waiver forms to be signed by any Subcontractor or Supplier, Contractor will obtain the same. 6.07 Patent Fees and Royalties A. Contractor shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if, to the actual knowledge of Owner or Engineer, its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by Owner in the Contract Documents. B. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, and its officers, directors, members, partners, employees, agents, consultants, and subcontractors from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals, and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device specified in the Contract Documents, but not identified as being subject to payment of any license fee or royalty to others required by patent rights or copyrights. C. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved Page 27 of 62 00 72 05 Work of any invention, design, process, product, or device not specified in the Contract Documents. 6.08 Permits A. Unless otherwise provided in the Supplementary Conditions, Contractor shall obtain and pay for all construction permits and licenses. Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. Owner shall pay all charges of utility owners for connections for providing permanent service to the Work. 6.09 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither Owner nor Engineer shall be responsible for monitoring Contractor's compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor's responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall nor relieve Contractor of Contractor's obligations under Paragraph 3.03. C. Changes in Laws or Regulations not known at the time of opening of Bids (or, on the Effective Date of the Agreement if there were no Bids) having an effect on the cost or time of performance of the Work shall be the subject of an adjustment in Contract Price or Contract Times. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. 6.10 Taxes A. Contractor shall pay all sales, consumer, use, and other similar taxes required to be paid by Contractor in accordance with the Laws and Regulations of the place of the Project which are applicable during the performance of the Work. 6.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas: 1. Contractor shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. Contractor shall assume full EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EdCDC. All rights reserved. Paee 28 of 62 7205 responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. Should any claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against Owner, Engineer, or any other party indemnified hereunder to the extent caused by or based upon Contractor's performance of the Work. B. Removal of Debris During Performance of the Work During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to applicable Laws and Regulations. C. Cleaning: Prior to Substantial Completion of the Work Contractor shall clean the Site and the Work and make it ready for utilization by Owner. At the completion of the Work Contractor shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D. Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 6.12 Record Documents A. Contractor shall maintain in a safe place at the Site one record copy of all Drawings, Specifications, Addenda, Change Orders, Work Change Directives, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved Samples and a counterpart of all approved Shop Drawings will be available to Engineer for reference. Upon completion of the Work, these record documents, Samples, and Shop Drawings will be delivered to Engineer for Owner. 6.13 Safety and Protection A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations. Contractor shall E JCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 29 of 62 00 72 05 take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. C. Contractor shall comply with the applicable requirements of Owner's safety programs, if any. The Supplementary Conditions identify any Owner's safety programs that are applicable to the Work. D. Contractor shall inform Owner and Engineer of the specific requirements of Contractor's safety program with which Owner's and Engineer's employees and representatives must comply while at the Site. E. All damage, injury, or loss to any property referred to in Paragraph 6.13.A.2 or 6.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of Owner or Engineer or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of Contractor or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them). F Contractor's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and Engineer has issued a notice to Owner and Contractor in accordance with Paragraph 14.073 that the Work is acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.14 Safety Representative A. Contractor shall designate a qualified and experienced safety representative at the Site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EdCDC. All rights reserved Page 30 of 62 11IMPAM 6.15 Hazard Communication Programs A. Contractor shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations. 6.16 Emergencies A. In emergencies affecting the safety or protection of persons or the Work or property at the Site or adjacent thereto, Contractor is obligated to act to prevent threatened damage, injury, or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby or are required as a result thereof. If Engineer determines that a change in the Contract Documents is required because of the action taken by Contractor in response to such an emergency, a Work Change Directive or Change Order will be issued. 6.17 Shop Drawings and Samples A. Contractor shall submit Shop Drawings and Samples to Engineer for review and approval in accordance with the accepted Schedule of Submittals (as required by Paragraph 2.07). Each submittal will be identified as Engineer may require. 1. Shop Drawings: a. Submit number of copies specified in the General Requirements. b. Data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Engineer the services, materials, and equipment Contractor proposes to provide and to enable Engineer to review the information for the limited purposes required by Paragraph 6.17.D. 2. Samples: a. Submit number of Samples specified in the Specifications. b. Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as Engineer may require to enable Engineer to review the submittal for the limited purposes required by Paragraph 6.17.D. B. Where a Shop Drawing or Sample is required by the Contract Documents or the Schedule of Submittals, any related Work performed prior to Engineer's review and approval of the pertinent submittal will be at the sole expense and responsibility of Contractor. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright (P 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 31 of 62 007205 C. Submittal Procedures: 1. Before submitting each Shop Drawing or Sample, Contractor shall have: a. reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents; b. determined and verified all field measurements, quantities, dimensions, specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; c. determined and verified the suitability of all materials offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and d. determined and verified all information relative to Contractor's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto. 2. Each submittal shall bear a stamp or specific written certification that Contractor has satisfied Contractor's obligations under the Contract Documents with respect to Contractor's review and approval of that submittal. 3. With each submittal, Contractor shall give Engineer specific written notice of any variations that the Shop Drawing or Sample may have from the requirements of the Contract Documents. This notice shall be both a written communication separate from the Shop Drawings or Sample submittal; and, in addition, by a specific notation made on each Shop Drawing or Sample submitted to Engineer for review and approval of each such variation. D. Engineer's Review: 1. Engineer will provide timely review of Shop Drawings and Samples in accordance with the Schedule of Submittals acceptable to Engineer. Engineer's review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 2. Engineer's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3. Engineer's review and approval shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Paragraph 6.17.C.3 and Engineer has given written approval of EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 32 of 62 00 72 05 each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample. Engineer's review and approval shall not relieve Contractor from responsibility for complying with the requirements of Paragraph 6.17.C.1. E. Resubmittal Procedures: 1. Contractor shall make corrections required by Engineer and shall return the required number of corrected copies of Shop Drawings and submit, as required, new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous submittals. 6.18 Continuing the Work A. Contractor shall carry on the Work and adhere to the Progress Schedule during all disputes or disagreements with Owner. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by Paragraph 15.04 or as Owner and Contractor may otherwise agree in writing. 6.19 Contractor's General Warranty and Guarantee A. Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Engineer and its officers, directors, members, partners, employees, agents, consultants, and subcontractors shall be entitled to rely on representation of Contractor's warranty and guarantee. B. Contractor's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, modification, or improper maintenance or operation by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2. normal wear and tear under normal usage. C. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents. or a release of Contractor's obligation to perform the Work in accordance with the Contract Documents: 1. observations by Engineer; 2. recommendation by Engineer or payment by Owner of any progress or final payment; 3. the issuance of a certificate of Substantial Completion by Engineer or any payment related thereto by Owner; 4. use or occupancy of the Work or any part thereof by Owner; 5. any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of acceptability by Engineer; MCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for E7CDC. All rights reserved. Page 33 of 62 00 72 05 6. any inspection, test, or approval by others; or 7. any correction of defective Work by Owner. 6.20 Indemnification A. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to the performance of the Work, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom but only to the extent caused by any negligent act or omission of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Wnrk- nr anyone for whose acts any of them may be liable . B. In any and all claims against Owner or Engineer or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors by any employee (or the survivor or personal representative of such employee) of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under Paragraph 6.20.A shall not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for Contractor or any such Subcontractor, Supplier, or other individual or entity under workers' compensation acts, disability benefit acts, or other employee benefit acts. C. The indemnification obligations of Contractor under Paragraph 6.20.A shall not extend to the liability of Engineer and Engineer's officers, directors, members, partners, employees, agents, consultants and subcontractors arising out of - 1. the preparation or approval of, or the failure to prepare or approve maps, Drawings, opinions, reports, surveys, Change Orders, designs, or Specifications; or 2. giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage. 6.21 Delegation of Professional Design Services A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to carry out Contractor's responsibilities for construction means, methods, techniques, sequences and procedures. Contractor shall not be required to provide professional services in violation of applicable law. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright m 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 34 of 62 00 72 05 B. If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of Contractor by the Contract Documents, Owner and Engineer will specify all performance and design criteria that such services must satisfy. Contractor shall cause such services or certifications to be provided by a properly licensed professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, Shop Drawings and other submittals prepared by such professional. Shop Drawings and other submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional's written approval when submitted to Engineer. C. Owner and Engineer shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided Owner and Engineer have specified to Contractor all performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 6.21, Engineer's review and approval of design calculations and design drawings will be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. Engineer's review and approval of Shop Drawings and other submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 6.17.D.1. E. Contractor shall not be responsible for the adequacy of the performance or design criteria required by the Contract Documents. ARTICLE 7 — OTHER WORK AT THE SITE 7.01 Related Work at Site A. Owner may perform other work related to the Project at the Site with Owner's employees, or through other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Contract Documents, then: 1. written notice thereof will be given to Contractor prior to starting any such other work; and 2. if Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim may be made therefor as provided in Paragraph 10.05. B. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner, and Owner, if Owner is performing other work with Owner's employees, proper and safe access to the Site, provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and properly coordinate the Work with theirs. Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that Contractor may cut or alter others' work with the written consent of Engineer and the others whose work will be EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 35 of 62 00 72 05 affected. The duties and responsibilities of Contractor under this Paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. C. If the proper execution or results of any part of Contractor's Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly report to Engineer in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects and deficiencies in such other work. 7.02 Coordination A. If Owner intends to contract with others for the performance of other work on the Project at the Site, the following will be set forth in Supplementary Conditions: 1. the individual or entity who will have authority and responsibility for coordination of the activities among the various contractors will be identified; 2. the specific matters to be covered by such authority and responsibility will be itemized; and 3. the extent of such authority and responsibilities will be provided. B. Unless otherwise provided in the Supplementary Conditions, Owner shall have sole authority and responsibility for such coordination. 7.03 Legal Relationships A. Paragraphs 7.01.A and 7.02 are not applicable for utilities not under the control of Owner. B. Each other direct contract of Owner under Paragraph 7.01.A shall provide that the other contractor is liable to Owner and Contractor for the reasonable direct delay and disruption costs incurred by Contractor as a result of the other contractor's wrongful actions or inactions. C. Contractor shall be liable to Owner and any other contractor under direct contract to Owner for the reasonable direct delay and disruption costs incurred by such other contractor as a result of Contractor's wrongful action or inactions. ARTICLE 8 — OWNER'S RESPONSIBILITIES 8.01 Communications to Contractor A. Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee 36 of 62 00 72 05 8.02 Replacement of Engineer A. In case of termination of the employment of Engineer, Owner shall appoint an engineer to whom Contractor makes no reasonable objection, whose status under the Contract Documents shall be that of the former Engineer. 8.03 Furnish Data A. Owner shall promptly furnish the data required of Owner under the Contract Documents. 8.04 Pay When Due A. Owner shall make payments to Contractor when they are due as provided in Paragraphs 14.02.0 and 14.07.C. 8.05 Lands and Easements; Reports and Tests A. Owner's duties with respect to providing lands and easements and providing engineering surveys to establish reference points are set forth in Paragraphs 4.01 and 4.05. Paragraph 4.02 refers to Owner's identifying and making available to Contractor copies of reports of explorations and tests of subsurface conditions and drawings of physical conditions relating to existing surface or subsurface structures at the Site. 8.06 Insurance A. Owner's responsibilities, if any, with respect to purchasing and maintaining liability and property insurance are set forth in Article 5. 8.07 Change Orders A. Owner is obligated to execute Change Orders as indicated in Paragraph 10.03. 8.08 Inspections, Tests, and Approvals A. Owner's responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 13.03.B. 8.09 Limitations on Owner's Responsibilities A. The Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 37 of 62 00 72 05 8.10 Undisclosed Hazardous Environmental Condition A. Owner's responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in Paragraph 4.06. 8.11 Evidence of Financial Arrangements A. Upon request of Contractor, Owner shall furnish Contractor reasonable evidence that financial arrangements have been made to satisfy Owner's obligations under the Contract Documents. 8.12 Compliance with Safety Program A. While at the Site, Owner's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which Owner has been informed pursuant to Paragraph 6.13.D. ARTICLE 9 — ENGINEER'S STATUS DURING CONSTRUCTION 9.01 Owner's Representative A. Engineer will be Owner's representative during the construction period. The duties and responsibilities and the limitations of authority of Engineer as Owner's representative during construction are set forth in the Contract Documents. 9.02 Visits to Site A. Engineer will make visits to the Site at intervals appropriate to the various stages of construction as Engineer deems necessary in order to observe as an experienced and qualified design professional the progress that has been made and the quality of the various aspects of Contractor's executed Work. Based on information obtained during such visits and observations, Engineer, for the benefit of Owner, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. Engineer will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. Engineer's efforts will be directed toward providing for Owner a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, Engineer will keep Owner informed of the progress of the Work and will endeavor to guard Owner against defective Work. B. Engineer's visits and observations are subject to all the limitations on Engineer's authority and responsibility set forth in Paragraph 9.09. Particularly, but without limitation, during or as a result of Engineer's visits or observations of Contractor's Work, Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 38 of 62 00 72 05 9.03 Project Representative A. If Owner and Engineer agree, Engineer will furnish a Resident Project Representative to assist Engineer in providing more extensive observation of the Work. The authority and responsibilities of any such Resident Project Representative and assistants will be as provided in the Supplementary Conditions, and limitations on the responsibilities thereof will be as provided in Paragraph 9.09. If Owner designates another representative or agent to represent Owner at the Site who is not Engineer's consultant, agent or employee, the responsibilities and authority and limitations thereon of such other individual or entity will be as provided in the Supplementary Conditions. 9.04 Authorized Variations in Work A. Engineer may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on Owner and also on Contractor, who shall perform the Work involved promptly. If Owner or Contractor believes that a Field Order justifies an adjustment in the Contract Price or Contract Times, or both, and the parties are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. 9.05 Rejecting Defective Work A. Engineer will have authority to reject Work which Engineer believes to be defective, or that Engineer believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Engineer will also have authority to require special inspection or testing of the Work as provided in Paragraph 13.04, whether or not the Work is fabricated, installed, or completed. 9.06 Shop Drawings, Change Orders and Payments A. In connection with Engineer's authority, and limitations thereof, as to Shop Drawings and Samples, see Paragraph 6.17. B. In connection with Engineer's authority, and limitations thereo% as to design calculations and design drawings submitted in response to a delegation of professional design services, if any, see Paragraph 6.21. C. In connection with Engineer's authority as to Change Orders, see Articles 10, 11, and 12. D. In connection with Engineer's authority as to Applications for Payment, see Article 14. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 9 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 39 of 62 00 72 05 9.07 Determinations for Unit Price Work A. Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor. Engineer will review with Contractor the Engineer's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). Engineer's written decision thereon will be final and binding (except as modified by Engineer to reflect changed factual conditions or more accurate data) upon Owner and Contractor, subject to the provisions of Paragraph 10.05. 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work A. Engineer will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. All matters in question and other matters between Owner and Contractor arising prior to the date final payment is due relating to the acceptability of the Work, and the interpretation of the requirements of the Contract Documents pertaining to the performance of the Work, will be referred initially to Engineer in writing within 30 days of the event giving rise to the question. B. Engineer will, with reasonable promptness, render a written decision on the issue referred. If Owner or Contractor believes that any such decision entitles them to an adjustment in the Contract Price or Contract Times or both, a Claim may be made under Paragraph 10.05. The date of Engineer's decision shall be the date of the event giving rise to the issues referenced for the purposes of Paragraph 10.05.B. C. Engineer's written decision on the issue referred will be final and binding on Owner and Contractor, subject to the provisions of Paragraph 10.05. D. When functioning as interpreter and judge under this Paragraph 9.08, Engineer will not show partiality to Owner or Contractor and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. 9.09 Limitations on Engineer's Authority and Responsibilities A. Neither Engineer's authority or responsibility under this Article 9 or under any other provision of the Contract Documents nor any decision made by Engineer in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by Engineer shall create, impose, or give rise to any duty in contract, tort, or otherwise owed by Engineer to Contractor, any Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them. B. Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Engineer will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 40 of 62 00 72 05 C. Engineer will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work. D. Engineer's review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by Paragraph 14.07.A will only be to determine generally that their content complies with the requirements of, and in the case of certificates of inspections, tests, and approvals that the results certified indicate compliance with, the Contract Documents. E. The limitations upon authority and responsibility set forth in this Paragraph 9.09 shall also apply to the Resident Project Representative, if any, and assistants, if any. 9.10 Compliance with Safety Program A. While at the Site, Engineer's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which Engineer has been informed pursuant to Paragraph 6.13.D. ARTICLE 10 — CHANGES IN THE WORK; CLAIMS 10.01 Authorized Changes in the Work A. Without invalidating the Contract and without notice to any surety, Owner may, at any time or from time to time, order additions, deletions, or revisions in the Work by a Change Order, or a Work Change Directive. Upon receipt of any such document, Contractor shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). B. if Owner and Contractor are unable to agree on entitlement to, or on the amount or extent, if any, of an adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Work Change Directive, a Claim may be made therefor as provided mi Paragraph 10.05. 10.02 Unauthorized Changes in the Work A. Contractor shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented as provided in Paragraph 3.04, except in the case of an emergency as provided in Paragraph 6.16 or in the case of uncovering Work as provided in Paragraph 13.04.D. 10.03 Execution of Change Orders A. Owner and Contractor shall execute appropriate Change Orders recommended by Engineer covermg: E7CDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EdCDC. All rights reserved. Page 41 of 62 00 72 05 1. changes in the Work which are: (i) ordered by Owner pursuant to Paragraph 10.01.A, (ii) required because of acceptance of defective Work under Paragraph 13.08.A or Owner's correction of defective Work under Paragraph 13.09, or (iii) agreed to by the parties; 2. changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive; and 3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by Engineer pursuant to Paragraph 10.05; provided that, in lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal, Contractor shall carry on the Work and adhere to the Progress Schedule as provided in Paragraph 6.18.A. 10.04 Notification to Surety A. If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times), the giving of any such notice will be Contractor's responsibility. The amount of each applicable bond will be adjusted to reflect the effect of any such change. 10.05 Claims A. Engineer's Decision Required: All Claims, except those waived pursuant to Paragraph 14.09, shall be referred to the Engineer for decision. A decision by Engineer shall be required as a condition precedent to any exercise by Owner or Contractor of any rights or remedies either may otherwise have under the Contract Documents or by Laws and Regulations in respect of such Claims. B. Notice: Written notice stating the general nature of each Claim shall be delivered by the claimant to Engineer and the other parry to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto. The responsibility to substantiate a Claim shall rest with the party making the Claim. Notice of the amount or extent of the Claim, with supporting data shall be delivered to the Engineer and the other party to the Contract within 60 days after the start of such event (unless Engineer allows additional time for claimant to submit additional or more accurate data in support of such Claim). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of Paragraph 12.01.13. A Claim for an adjustment in Contract Times shall be prepared in accordance with the provisions of Paragraph 12.02.B. Each Claim shall be accompanied by claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The opposing party shall submit any response to Engineer and the claimant within 30 days after receipt of the claimant's last submittal (unless Engineer allows additional time). EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee 42 of 62 00 72 05 C. Engineer's Action: Engineer will review each Claim and, within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any, take one of the following actions in writing: 1. deny the Claim in whole or in part; 2. approve the Claim; or 3. notify the parties that the Engineer is unable to resolve the Claim i� in the Engineer's sole discretion, it would be inappropriate for the Engineer to do so. For purposes of further resolution of the Claim, such notice shall be deemed a denial. D. In the event that Engineer does not take action on a Claim within said 30 days, the Claim shall be deemed denied. E. Engineer's written action under Paragraph 10.05.0 or denial pursuant to Paragraphs 10.05.C.3 or 10.05.D will be final and binding upon Owner and Contractor, unless Owner or Contractor invoke the dispute resolution procedure set forth in Article 16 within 30 days of such action or denial. F. No Claim for an adjustment in Contract Price or Contract Times will be valid if not submitted in accordance with this Paragraph 10.05. ARTICLE 11-- COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK 11.01 Cost of the Work A. Costs Included: The term Cost of the Work means the sura of all costs, except those excluded in Paragraph 11.01.B, necessarily incurred and paid by Contractor in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to Contractor will be only those additional or incremental costs required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by Owner, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall not include any of the costs itemized in Paragraph 11.01.B, and shall include only the following items: 1. Payroll costs for employees in the direct employ of Contractor in the performance of the Work under schedules of job classifications agreed upon by Owner and Contractor. Such employees shall include, without limitation, superintendents, foremen, and other personnel employed full time on the Work. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits, which shall include social security contributions, unemployment, excise, and payroll taxes, workers' compensation, health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on Saturday, Sunday, or legal holidays, shall be included in the above to the extent authorized by Owner. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pace 43 of 62 00 72 05 2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts shall accrue to Contractor unless Owner deposits funds with Contractor with which to make payments, in which case the cash discounts shall accrue to Owner. All trade discounts. rebates and refunds and returns from sale of surplus materials and equipment shall accrue to Owner, and Contractor shall make provisions so that they may be obtained. 3. Payments made by Contractor to Subcontractors for Work performed by Subcontractors. If required by Owner, Contractor shall obtain competitive bids from subcontractors acceptable to Owner and Contractor and shall deliver such bids to Owner, who will then determine, with the advice of Engineer, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee shall be determined in the same manner as Contractor's Cost of the Work and fee as provided in this Paragraph 11.01. 4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed for services specifically related to the Work. 5. Supplemental costs including the following: a. The proportion of necessary transportation, travel, and subsistence expenses of Contractor's employees incurred in discharge of duties connected with the Work. b. Cost, including transportation and maintenance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site, and hand tools not owned by the workers, which are consumed in the performance of the Work, and cost, less market value, of such items used but not consumed which remain the property of Contractor. c. Rentals of all construction equipment and machinery, and the parts thereof whether rented from Contractor or others in accordance with rental agreements approved by Owner with the advice of Engineer, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs shall be in accordance with the terms of said rental agreements. The rental of any such equipment, machinery, or parts shall cease when the use thereof is no longer necessary for the Work. d. Sales, consumer, use, and other similar taxes related to the Work, and for which Contractor is liable, as imposed by Laws and Regulations. e. Deposits lost for causes other than negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. f. Losses and damages (and related expenses) caused by damage to the Work, not compensated by insurance or otherwise, sustained by Contractor in connection with the performance of the Work (except losses and damages within the deductible amounts of EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 44 of 62 00 72 05 property insurance established in accordance with Paragraph 5.06.D), provided such losses and damages have resulted from causes other than the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of Owner. No such losses, damages, and expenses shall be included in the Cost of the Work for the purpose of determining Contractor's fee. g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, express and courier services, and similar petty cash items in connection with the Work. i. The costs of premiums for all bonds and insurance Contractor is required by the Contract Documents to purchase and maintain. B. Costs Excluded: The term Cost of the Work shall not include any of the following items: 1. Payroll costs and other compensation of Contractor's officers, executives, principals (of partnerships and sole proprietorships), general managers, safety managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by Contractor, whether at the Site or in Contractor's principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in Paragraph 11.0LA. 1 or specifically covered by Paragraph 11.0 LAA, all of which arc to be considered administrative costs covered by the Contractor's fee. 2. Expenses of Contractor's principal and branch offices other than Contractor's office at the Site. 3. Any part of Contractor's capital expenses, including interest on Contractor's capital employed for the Work and charges against Contractor for delinquent payments. 4. Costs due to the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. 5. Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraphs 11.01.A. C. Contractor's Fee: When all the Work is performed on the basis of cost-plus, Contractor's fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, Cnntrartnr'c fPP shall be determined as set forth in Paragraph 12.01.C. EJCJ)C C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 45 of 62 00 72 05 D. Documentation: Whenever the Cost of the Work for any purpose is to be determined pursuant to Paragraphs 11.01.A and 11.0LB, Contractor will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in a form acceptable to Engineer an itemized cost breakdown together with supporting data. 11.02 Allowances A. It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums and by such persons or entities as may be acceptable to Owner and Engineer. B. Cash Allowances: 1. Contractor agrees that: a. the cash allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and b. Contractor's costs for unloading and handling on the Site, labor, installation, overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment on account of any of the foregoing will be valid. C. Contingency Allowance: 1. Contractor agrees that a contingency allowance, if any, is for the sole use of Owner to cover unanticipated costs. D. Prior to final payment, an appropriate Change Order will be issued as recommended by Engineer to reflect actual amounts due Contractor on account of Work covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.03 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. B. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by Contractor will be made by Engineer subject to the provisions of Paragraph 9.07. C. Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractor's overhead and profit for each separately identified item. FJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 46 of 62 00 72 05 D. Owner or Contractor may make a Claim for an adjustment in the Contract Price in accordance with Paragraph 10.05 if: the quantity of any item of Unit Price Work performed by Contractor differs materially and significantly from the estimated quantity of such item indicated in the Agreement; and 2. there is no corresponding adjustment with respect to any other item of Work; and 3. Contractor believes that Contractor is entitled to an increase in Contract Price as a result of having incurred additional expense or Owner believes that Owner is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. ARTICLE 12 — CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES 12.01 Change of Contract Price A. The Contract Price may only be changed by a Change Order. Any Claim for an adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be determined as follows: where the Work involved is covered by unit prices contained in the Contract Documents, by application of such unit prices to the quantities of the items involved (subject to the provisions of Paragraph 11.03); or 2. where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with Paragraph 12.01.C.2); or 3. where the Work involved is not covered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under Paragraph 12.01.B.2, on the basis of the Cost of the Work (determined as provided in Paragraph 11.01) plus a Contractor's fee for overhead and profit (determined as provided in Paragraph 12.01.C). C. Contractor's Fee: The Contractor's fee for overhead and profit shall be determined as follows: 1. a mutually acceptable fixed fee; or 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: a. for costs incurred under Paragraphs 11.01.A.1 and 11.01.A.2, the Contractor's fee shall be 15 percent; b. for costs incurred under Paragraph 11.01.A.3, the Contractor's fee shall be five percent; EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 47 of 62 00 72 05 c. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of Paragraphs 12.01.C.2.a and 12.01.C.2.b is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under Paragraphs 11.0LA. 1 and 11.01.A.2 and that any higher tier Subcontractor and Contractor will each be paid a fee of five percent of the amount paid to the next lower tier Subcontractor; d. no fee shall be payable on the basis of costs itemized under Paragraphs 11.01.A.4, 11.0l.A.5, and 11.01.B; e. the amount of credit to be allowed by Contractor to Owner for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a deduction in Contractor's fee by an amount equal to five percent of such net decrease; and f. when both additions and credits are involved in any one change, the adjustment in Contractor's fee shall be computed on the basis of the net change in accordance with Paragraphs 12.01.C.2.a through 12.01.C.2.e, inclusive. 12.02 Change of Contract Times A. The Contract Times may only be changed by a Change Order. Any Claim for an adjustment in the Contract Times shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. Any adjustment of the Contract Times covered by a Change Order or any Claim for an adjustment in the Contract Times will be determined in accordance with the provisions of this Article 12. 12.03 Delays A. Where Contractor is prevented from completing any part of the Work within the Contract Times due to delay beyond the control of Contractor, the Contract Times will be extended in an amount equal to the time lost due to such delay if a Claim is made therefor as provided in Paragraph 12.02.A. Delays beyond the control of Contractor shall include, but not be limited to, acts or neglect by Owner, acts or neglect of utility owners or other contractors performing other work as contemplated by Article 7, fires, floods, epidemics, abnormal weather conditions, or acts of God. B. If Owner, Engineer, or other contractors or utility owners performing other work for Owner as contemplated by Article 7, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Price or the Contract Times, or both. Contractor's entitlement to an adjustment of the Contract Times is conditioned on such adjustment being essential to Contractor's ability to complete the Work within the Contract Times. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 48 of 62 00 72 05 C. If Contractor is delayed in the performance or progress of the Work by fire, flood, epidemic, abnormal weather conditions, acts of God, acts or failures to act of utility owners not under the control of Owner, or other causes not the fault of and beyond control of Owner and Contractor, then Contractor shall be entitled to an equitable adjustment in Contract Times, if such adjustment is essential to Contractor's ability to complete the Work within the Contract Times. Such an adjustment shall be Contractor's sole and exclusive remedy for the delays described in this Paragraph 12.03.C. D. Owner, Engineer, and their officers, directors, members, partners, employees, agents, consultants, or subcontractors shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. E. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delays within the control of Contractor. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of Contractor. ARTICLE 13 — TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.01 Notice of Defects A. Prompt notice of all defective Work of which Owner or Engineer has actual knowledge will be given to Contractor. Defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.02 Access to Work A. Owner, Engineer, their consultants and other representatives and personnel of Owner, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor's safety procedures and programs so that they may comply therewith as applicable. 13.03 Tests and Inspections A. Contractor shall give Engineer timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. Owner shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents except: 1. for inspections, tests, or approvals covered by Paragraphs 13.03.0 and 13.03.D below; EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EdCDC. Ali rights reserved. Page 49 of 62 00 72 05 2. that costs incurred in connection with tests or inspections conducted pursuant to Paragraph 13,04.13 shall be paid as provided in Paragraph 13.04.C; and 3. as otherwise specifically provided in the Contract Documents. C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Engineer the required certificates of inspection or approval. D. Contractor shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, or approvals required for Owner's and Engineer's acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to Owner and Engineer. E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of Engineer, Contractor shall, if requested by Engineer, uncover such Work for observation. F Uncovering Work as provided in Paragraph 13.03.E shall be at Contractor's expense unless Contractor has given Engineer timely notice of Contractor's intention to cover the same and Engineer has not acted with reasonable promptness in response to such notice. 13.04 Uncovering Work A. If any Work is covered contrary to the written request of Engineer, it must, if requested by Engineer, be uncovered for Engineer's observation and replaced at Contractor's expense. B. If Engineer considers it necessary or advisable that covered Work be observed by Engineer or inspected or tested by others, Contractor, at Engineer's request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as Engineer may require, that portion of the Work in question, furnishing all necessary labor, material, and equipment. C. If it is found that the uncovered Work is defective, Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. D. If the uncovered Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Times, or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for E7CDC. All rights reserved. Page 50 of 62 00 72 05 parties are unable to agree as to the amount or extent thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. 13.05 Owner May Stop the Work A. If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, Owner may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of Owner to stop the Work shall not give rise to any duty on the part of Owner to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 13.06 Correction or Removal of Defective Work A. Promptly after receipt of written notice, Contractor shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by Engineer, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). B. When correcting defective Work under the terms of this Paragraph 13.06 or Paragraph 13.07, Contractor shall take no action that would void or otherwise impair Owner's special warranty and guarantee, if any, on said Work. 13.07 Correction Period A. If within one year after the date of Substantial Completion (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract Documents) or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made available for Contractor's use by Owner or permitted by Laws and Regulations as contemplated in Paragraph 6.1 LA is found to be defective, Contractor shall promptly, without cost to Owner and in accordance with Owner's written instructions: 1. repair such defective land or areas; or 2. correct such defective Work; or 3. if the defective Work has been rejected by Owner, remove it from the Project and replace it with Work that is not defective, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 51 of 62 00 72 05 B. If Contractor does not promptly comply with the terms of Owner's written instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. C. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications. D. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this Paragraph 13.07, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. E. Contractor's obligations under this Paragraph 13.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 13.07 shall not be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose. 13.08 Acceptance of Defective Work A. If, instead of requiring correction or removal and replacement of defective Work, Owner (and, prior to Engineer's recommendation of final payment, Engineer) prefers to accept it, Owner may do so. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to Owner's evaluation of and determination to accept such defective Work (such costs to be approved by Engineer as to reasonableness) and for the diminished value of the Work to the extent not otherwise paid by Contractor pursuant to this sentence. If any such acceptance occurs prior to Engineer's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and Owner shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work so accepted. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. If the acceptance occurs after such recommendation, an appropriate amount will be paid by Cnntractor to Owner. 13.09 Owner May Correct Defective Work A. If Contractor fails within a reasonable time after written notice from Engineer to correct defective Work, or to remove and replace rejected Work as required by Engineer in accordance with Paragraph 13.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, Owner may, after seven days written notice to Contractor, correct, or remedy any such deficiency. ErCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EdCDC. Ali rights reserved. Page 52 of 62 00 72 05 B. In exercising the rights and remedies under this Paragraph 13.09, Owner shall proceed expeditiously. In connection with such corrective or remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, take possession of Contractor's tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's representatives, agents and employees, Owner's other contractors, and Engineer and Engineer's consultants access to the Site to enable Owner to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount of the adjustment, Owner may make a Claim therefor as provided in Paragraph 10.05. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor's defective Work. D. Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to the exercise by Owner of Owner's rights and remedies under this Paragraph 13.09. ARTICLE 14 — PAYMENTS TO CONTRACTOR AND COMPLETION 14.01 Schedule of Values A. The Schedule of Values established as provided in Paragraph 2.07.A will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to Engineer. Progress payments on account of Unit Price Work will be based on the number of units completed. 14.02 Progress Payments A. 4ppl ications for Payments: 1. At least 20 days before the date established in the Agreement for each progress payment (but not more often than once a month), Contractor shall submit to Engineer for review an Application for Payment filled out and signed by Contractor covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other documentation warranting that Owner has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 53 of 62 00 72 05 arrangements to protect Owner's interest therein, all of which must be satisfactory to Owner. 2. Beginning with the second Application for Payment, each Application shall include an affidavit of Contractor stating that all previous progress payments received on account of the Work have been applied on account to discharge Contractor's legitimate obligations associated with prior Applications for Payment. 3. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. B. Review of Applications: 1. Engineer will, within 10 days after receipt of each Application for Payment, either indicate in writing a recommendation of payment and present the Application to Owner or return the Application to Contractor indicating in writing Engineer's reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the Application. 2. Engineer's recommendation of any payment requested in an Application for Payment will constitute a representation by Engineer to Owner, based on Engineer's observations of the executed Work as an experienced and qualified design professional, and on Engineer's review of the Application for Payment and the accompanying data and schedules, that to the best of Engineer's knowledge, information and belief a. the Work has progressed to the point indicated; b. the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, the results of any subsequent tests called for in the Contract Documents, a final determination of quantities and classifications for Unit Price Work under Paragraph 9.07, and any other qualifications stated in the recommendation); and c. the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe the Work. 3. By recommending any such payment Engineer will not thereby be deemed to have represented that: a. inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in the Contract Documents; or b. there may not be other matters or issues between the parties that might entitle Contractor to be paid additionally by Owner or entitle Owner to withhold payment to Contractor. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 54 of 62 00 72 05 4. Neither Engineer's review of Contractor's Work for the purposes of recommending payments nor Engineer's recommendation of any payment, including final payment, will impose responsibility on Engineer: a. to supervise, direct, or control the Work, or b. for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or c. for Contractor's failure to comply with Laws and Regulations applicable to Contractor's performance of the Work, or d. to make any examination to ascertain how or for what purposes Contractor has used the moneys paid on account of the Contract Price, or e. to determine that title to any of the Work, materials, or equipment has passed to Owner free and clear of any Liens. 5. Engineer may refuse to recommend the whole or any part of any payment if, in Engineer's opinion, it would be incorrect to make the representations to Owner stated in Paragraph 14.02.B.2. Engineer may also refuse to recommend any such payment or, because of subsequently discovered evidence or the results of subsequent inspections or tests, revise or revoke any such payment recommendation previously made, to such extent as may be necessary in Engineer's opinion to protect Owner from loss because: a. the Work is defective, or completed Work has been damaged, requiring correction or replacement; b. the Contract Price has been reduced by Change Orders; c. Owner has been required to correct defective Work or complete Work in accordance with Paragraph 13.09; or d. Engineer has actual knowledge of the occurrence of any of the events enumerated in Paragraph 15.02.A. C. Payment Becomes Due: 1. Ten days after presentation of the Application for Payment to Owner with Engineer's recommendation, the amount recommended will (subject to the provisions of Paragraph 14.02.13) become due, and when due will be paid by Owner to Contractor. D. Reduction in Payment: 1. Owner may refuse to make payment of the full amount recommended by Engineer because: a. claims have been made against Owner on account of Contractor's performance or furnishing of the Work; F TCDC G700 Standard General Conditions of the Construction Contract Copyright C 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Paee 55 of 62 ,s::2 f;5 b. Liens have been filed in connection with the Work, except where Contractor has delivered a specific bond satisfactory to Owner to secure the satisfaction and discharge of such Liens; c. there are other items entitling Owner to a set-off against the amount recommended; or d. Owner has actual knowledge of the occurrence of any of the events enumerated in Paragraphs 14.02.B.5.a through 14.02.B.5.c or Paragraph 15.02.A. 2. If Owner refuses to make payment of the full amount recommended by Engineer, Owner will give Contractor immediate written notice (with a copy to Engineer) stating the reasons for such action and promptly pay Contractor any amount remaining after deduction of the amount so withheld. Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by Owner and Contractor, when Contractor remedies the reasons for such action. 3. Upon a subsequent determination that Owner's refusal of payment was not justified, the amount wrongfully withheld shall be treated as an amount due as determined by Paragraph 14.02.C.1 and subject to interest as provided in the Agreement. 14.03 Contractor's Warranty of Title A. Contractor warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to Owner no later than the time of payment free and clear of all Liens. 14.04 Substantial Completion A. When Contractor considers the entire Work ready for its intended use Contractor shall notify Owner and Engineer in writing that the entire Work is substantially complete (except for items specifically listed by Contractor as incomplete) and request that Engineer issue a certificate of Substantial Completion. B. Promptly after Contractor's notification, Owner, Contractor, and Engineer shall make an inspection of the Work to determine the status of completion. If Engineer does not consider the Work substantially complete, Engineer will notify Contractor in writing giving the reasons therefor. C. If Engineer considers the Work substantially complete, Engineer will deliver to Owner a tentative certificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or corrected before final payment. Owner shall have seven days after receipt of the tentative certificate during which to make written objection to Engineer as to any provisions of the certificate or attached list. If, after considering such objections, Engineer concludes that the Work is not substantially complete, Engineer will, within 14 days after submission of the tentative certificate to Owner, notify Contractor in writing, stating the reasons therefor. If, after consideration of Owner's objections, Engineer considers the Work substantially complete, Engineer will, within said 14 days, execute and deliver to Owner and Contractor a definitive EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. Ali rights reserved. Paee 56 of 62 00 72 05 certificate of Substantial Completion (with a revised tentative lust of items to be completed or corrected) reflecting such changes from the tentative certificate as Engineer believes justified after consideration of any objections from Owner. D. At the time of delivery of the tentative certificate of Substantial Completion, Engineer will deliver to Owner and Contractor a written recommendation as to division of responsibilities pending final payment between Owner and Contractor with respect to security, operation, safety, and protection of the Work, maintenance, heat, utilities, insurance, and warranties and guarantees. Unless Owner and Contractor agree otherwise in writing and so inform Engineer in writing prior to Engineer's issuing the definitive certificate of Substantial Completion, Engineer's aforesaid recommendation will he binding nn Owner and Contractor until final payment. E. Owner shall have the right to exclude Contractor from the Site after the date of Substantial Completion subject to allowing Contractor reasonable access to remove its property and complete or correct items on the tentative list. 14.05 Partial Utilization A. Prior to Substantial Completion of all the Work, Owner may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which Owner, Engineer, and Contractor agree constitutes a separately functioning and usable part of the Work that can be used by Owner for its intended purpose without significant interference with Contractor's performance of the remainder of the Work, subject to the following conditions: 1. Owner at any time may request Contractor in writing to permit Owner to use or occupy any such part of the Work which Owner believes to be ready for its intended use and substantially complete. If and when Contractor agrees that such part of the Work is substantially complete, Contractor, Owner, and Engineer will follow the procedures of Paragraph 14.04.A through D for that part of the Work. 2. Contractor at any time may notify Owner and Engineer in writing that Contractor considers any such part of the Work ready for its intended use and substantially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work. 3. Within a reasonable time after either such request, Owner, Contractor, and Engineer shall make an inspection of that part of the Work to determine its status of completion. If Engineer does not consider that part of the Work to be substantially complete, Engineer will notify Owner and Contractor in writing giving the reasons therefor. If Engineer considers that part of the Work to be substantially complete, the provisions of Paragraph 14.04 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 4. No use or occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of Paragraph 5.10 regarding property insurance. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright (b 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 57 of 62 00 72 05 14.06 Final Inspection A. Upon written notice from Contractor that the entire Work or an agreed portion thereof is complete, Engineer will promptly make a final inspection with Owner and Contractor and will notify Contractor in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 14.07 Final Payment A. Application for Payment: 1. After Contractor has, in the opinion of Engineer, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance, certificates of inspection, marked -up record documents (as provided in Paragraph 6.12), and other documents, Contractor may make application for final payment following the procedure for progress payments. 2. The final Application for Payment shall be accompanied (except as previously delivered) by: a. all documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by Paragraph 5.04.B.6; b. consent of the surety, if any, to final payment; c. a list of all Claims against Owner that Contractor believes are unsettled; and d. complete and legally effective releases or waivers (satisfactory to Owner) of all Lien rights arising out of or Liens filed in connection with the Work. 3. In lieu of the releases or waivers of Liens specified in Paragraph 14.07.A.2 and as approved by Owner, Contractor may furnish receipts or releases in full and an affidavit of Contractor that: (i) the releases and receipts include all labor, services, material, and equipment for which a Lien could be filed; and (ii) all payrolls, material and equipment bills, and other indebtedness connected with the Work for which Owner might in any way be responsible, or which might in any way result in liens or other burdens on Owner's property, have been paid or otherwise satisfied. If any Subcontractor or Supplier fails to furnish such a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to Owner to indemnify Owner against any Lien. B. Engineer's Review of Appl ication and Acceptance: 1. If, on the basis of Engineer's observation of the Work during construction and final inspection, and Engineer's review of the final Application for Payment and accompanying documentation as required by the Contract Documents, Engineer is satisfied that the Work has been completed and Contractor's other obligations under the Contract Documents have been fulfilled, Engineer will, within ten days after receipt of the final Application for EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 58 of 62 00 72 05 Payment, indicate in writing Engineer's recommendation of payment and present the Application for Payment to Owner for payment. At the same time Engineer will also give written notice to Owner and Contractor that the Work is acceptable subject to the provisions of Paragraph 14.09. Otherwise, Engineer will return the Application for Payment to Contractor, indicating in writing the reasons for refusing to recommend final payment, in which cage C',nntractnr shall make the necessary corrections and resubmit the Application for Payment. C. Payment Becomes Due: 1. Thirty days after the presentation to Owner of the Application for Payment and accompanying documentation, the amount recommended by Engineer, less any sum Owner is entitled to set off against Engineer's recommendation, including but not limited to liquidated damages, will become due and will be paid by Owner to Contractor. 14.08 Final Completion Delayed A. If, through no fault of Contractor, final completion of the Work is significantly delayed, and if Engineer so confirms, Owner shall, upon receipt of Contractor's final Application for Payment (for Work fully completed and accepted) and recommendation of Engineer, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by Owner for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if bonds have been furnished as required in Paragraph 5.01, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by Contractor to Engineer with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. 14.09 Waiver of Claims A. The making and acceptance of final payment will constitute: 1. a waiver of all Claims by Owner against Contractor, except Claims arising from unsettled Liens, from defective Work appearing after final inspection pursuant to Paragraph 14.05, from failure to comply with the Contract Documents or the terms of any special guarantees specified therein, or fmm Contractor's continuing obligations under the Contract Documents; and 2. a waiver of all Claims by Contractor against Owner other than those previously made in accordance with the requirements herein and expressly acknowledged by Owner in writing as still unsettled. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright © 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 59 of 62 00 72 05 ARTICLE 15 — SUSPENSION OF WORK AND TERMINATION 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 90 consecutive days by notice in writing to Contractor and Engineer which will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be granted an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension if Contractor makes a Claim therefor as provided in Paragraph 10.05. 15.02 Owner May Terminate for Cause A. The occurrence of any one or more of the following events will justify termination for cause: 1. Contractor's persistent failure to perform the Work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the Progress Schedule established under Paragraph 2.07 as adjusted from time to time pursuant to Paragraph 6.04); 2. Contractor's disregard of Laws or Regulations of any public body having jurisdiction; 3. Contractor's repeated disregard of the authority of Engineer; or 4. Contractor's violation in any substantial way of any provisions of the Contract Documents. B. If one or more of the events identified in Paragraph 15.02.A occur, Owner may, after giving Contractor (and surety) seven days written notice of its intent to terminate the services of Contractor: exclude Contractor from the Site, and take possession of the Work and of all Contractor's tools, appliances, construction equipment, and machinery at the Site, and use the same to the full extent they could be used by Contractor (without liability to Contractor for trespass or conversion); 2. incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere; and 3. complete the Work as Owner may deem expedient. C. If Owner proceeds as provided in Paragraph 15.02.B, Contractor shall not be entitled to receive any further payment until the Work is completed. If the unpaid balance of the Contract Price exceeds all claims, costs, losses, and damages (including but not linlited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Owner arising out of or relating to completing the Work, such excess will be paid to Contractor. If such claims, costs, losses, and damages exceed such unpaid balance, Contractor shall pay the difference to Owner. Such claims, costs, losses, and damages incurred by Owner will be reviewed by Engineer as to their reasonableness and, when so approved by Engineer, incorporated in a Change Order. When exercising any rights or EJCDC C-700 Standard General Conditions of the Construction Contract Copyright ® 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 60 of 62 00 72 05 remedies under this Paragraph, Owner shall not be required to obtain the lowest price for the Work performed. D. Notwithstanding Paragraphs 15.02.B and 15.02.C, Contractor's services will not be terminated if Contractor begins within seven days of receipt of notice of intent to terminate to correct its failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt of said notice. E. Where Contractor's services have been so terminated by Owner, the termination will not affect any rights or remedies of Owner against Contractor then existing or which may thereafter accrue. Any retention or payment of moneys due Contractor by Owner will not release Contractor from liability. F. If and to the extent that Contractor has provided a performance bond under the provisions of Paragraph 5.01.A, the termination procedures of that bond shall supersede the provisions of Paragraphs 15.02.B and 15.02.C. 15.03 Owner May Terminate For Convenience A. Upon seven days written notice to Contractor and Engineer, Owner may, without cause and without prejudice to any other right or remedy of Owner, terminate the Contract. In such case, Contractor shall be paid for (without duplication of any items): I. completed and acceptable Work executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasonable sums for overhead and profit on such Work; 2. expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials, or equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; 3. all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred in settlement of terminated contracts with Subcontractors, Suppliers, and others; and 4. reasonable expenses directly attributable to termination. B. Contractor shall not be paid on account of loss of anticipated profits or revenue or other economic loss arising out of or resulting from such termination. 15.04 Contractor May Stop Work or Terminate A. If, through no act or fault of Contractor, (i) the Work is suspended for more than 90 consecutive days by Owner or under an order of court or other public authority, or (ii) Engineer fails to act on any Application for Payment within 30 days after it is submitted, or (iii) Owner fails for 30 days to pay Contractor any sum finally determined to be due, then Contractor may, EJCDC C-700 Standard General Conditions of the Construction Contract Copyright 0 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 61 of 62 00 72 05 upon seven days written notice to Owner and Engineer, and provided Owner or Engineer do not remedy such suspension or failure within that time, terminate the Contract and recover from Owner payment on the same terms as provided in Paragraph 15.03. B. In lieu of terminating the Contract and without prejudice to any other right or remedy, if Engineer has failed to act on an Application for Payment within 30 days after it is submitted, or Owner has failed for 30 days to pay Contractor any sum finally determined to be due, Contractor may, seven days after written notice to Owner and Engineer, stop the Work until payment is made of all such amounts due Contractor, including interest thereon. The provisions of this Paragraph 15.04 are not intended to preclude Contractor from making a Claim under Paragraph 10.05 for an adjustment in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to Contractor's stopping the Work as permitted by this Paragraph. ARTICLE 16 — DISPUTE RESOLUTION 16.01 Methods and Procedures A. Either Owner or Contractor may request mediation of any Claim submitted to Engineer for a decision under Paragraph 10.05 before such decision becomes final and binding. The mediation will be governed by the Construction Industry Mediation Rules of the American Arbitration Association in effect as of the Effective Date of the Agreement. The request for mediation shall be submitted in writing to the American Arbitration Association and the other party to the Contract. Timely submission of the request shall stay the effect of Paragraph 10.05.E. B. Owner and Contractor shall participate in the mediation process in good faith. The process shall be concluded within 60 days of filing of the request. The date of termination of the mediation shall be determined by application of the mediation rules referenced above. C. If the Claim is not resolved by mediation, Engineer's action under Paragraph 10.05.0 or a denial pursuant to Paragraphs 10.05.C.3 or 10.05.D shall become final and binding 30 days after termination of the mediation unless, within that time period, Owner or Contractor: elects in writing to invoke any dispute resolution process provided for in the Supplementary Conditions; or 2. agrees with the other party to submit the Claim to another dispute resolution process; or 3. gives written notice to the other party of the intent to submit the Claim to a court of competent jurisdiction. ARTICLE 17 — MISCELLANEOUS 17.01 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if: EJCDC C-700 Standard General Conditions of the Construction Contract Copyright V 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Pate 62 of 62 00 72 05 delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended; or 2. delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. 17.02 Computation of Times A. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. 17.03 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 17.04 Survival of Obligations A. All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 17.05 Controlling Law A. This Contract is to be governed by the law of the state in which the Project is located. 17.05 Headings A. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. EJCDC C-700 Standard General Conditions of the Construction Contract Copyright (9 2007 National Society of Professional Engineers for EJCDC. All rights reserved. Page 63 of 62 00 72 05 SECTION 00 73 05 SUPPLEMENTARY CONDITIONS ARTICLE 1 - DEFINITIONS AND TERMINOLOGY SC -1.01.A44 Add the following language at the end of the definition of Substantial Completion: The Work is considered Substantially Complete when the following have been completed: 1. The crack seal, seal coat, and fog seal has been completed on all streets. 2. The initial and second sweeping has been completed and approved by the Engineer. SC -1.02 Add the following new paragraph immediately after Paragraph 1.02.F: G. The Specifications are written in imperative mood and streamlined form. This imperative language is directed to the Contractor, unless specifically noted otherwise. The words "shall be" are included by inference where a colon (:) is used within sentences or phrases. ARTICLE 2 - PRELIMINARY MATTERS SC -2.02 Owner shall furnish to Contractor 1 printed copy and 1 electronic (PDF) version of the Contract Documents. Limitations of use of electronic and printed documents are described in the instructions to Bidders and General Conditions. ARTICLE 4 — AVAILABILITY OF LANDS: SUBSURFACE AND PHYSICAL CONDITIONS, REFERENCE POINTS SC -4.02 Delete Paragraphs 4.02.A and 4.02.8 in their entirety and insert the following: A. No reports of explorations or tests of subsurface conditions at or contiguous to the Site, or drawings of physical conditions relating to existing surface or subsurface structures at the Site, ore known to Owner or Engineer. SC -4.06 Delete Paragraphs 4.06.A and 4.06.6 in their entirety and insert the following: A. No reports or drawings related to Hazardous Environmental Conditions at the Site are known to Owner. B. Not Used. ARTICLES - BONDS AND INSURANCE SC -5.01 Add the following new paragraph immediately after Paragraph 5.01.C: D. Separate Performance and Payment Bonds should be submitted utilizing EJCDC Form C-610 and C-615 (2007 Edition) or a similar bond form if approved by Owner. SC -5.03.6 Delete Paragraph 5.03.6 in its entirety and insert the following: B. Failure of Owner to demand such certificates or other evidence of full compliance with these insurance requirements or failure of Owner to identify a deficiency from © 2014 Stantec 193802836 SUPPLEMENTARY CONDITIONS 007305-1 evidence provided shall not be construed as a waiver of Contractor's obligation to maintain such insurance. C. By requiring such insurance and insurance limits herein, Owner does not represent that coverage and limits will necessarily be adequate to protect Contractor and such coverage and limits shall not be deemed as a limitation on Contractor's liability under the indemnities granted to Owner in the Contract Documents. SC -5.04 Add the following new paragraph immediately after Paragraph 5.04.B: C. The limits of liability for the insurance required by Paragraph 5.04 of the General Conditions shall provide coverage for not less than the following amounts or greater where required by Laws and Regulations: 1. Worker's Compensation and related coverages under Paragraphs 5.04.A.1 and A.2 of the General Conditions a. State Statutory b. Applicable Federal (e.g., Longshoreman's) Statutory c. Employer's Liability $1,000,000 2. Contractor's General Liability under Paragraphs 5.04.A.3 through A.6 of the General Conditions, which shall include completed operations and product liability coverages and eliminate the exclusion with respect to property under the care, custody and control of Contractor a. General Aggregate $2,000,000 b. Products - Completed Operations Aggregate $1,000,000 c. Personal and Advertising Injury $1,000,000 d. Each Occurrence (Bodily Injury and Property Damage) $2,000,000 e. Property Damage liability insurance will provide Explosion, Collapse, and Underground coverages where applicable. f. Excess or Umbrella Liability 1) General Aggregate $1,000,000 2) Each Occurrence $1,000,000 Umbrella excess liability shall be a combined single limit which shall provide excess liability insurance over Commercial General Liability, Comprehensive Automobile Liability, and Employers Liability. 3. Automobile Liability under Paragraph 5.04.A.6 of the General Conditions: a. Combined Single Limit - Bodily injury and property damage. All owned, non -owned, and hired vehicles. $2,000,000 4. The Contractual Liability coverage required by Paragraph 5.04.13.4 of the General Conditions shall provide coverage for not less than the following amounts: a. Bodily Injury: Each Person $1,000,000 Each Accident $1,000,000 b. Property Damage: Each Accident $1,000,000 Annual Aggregate $1,000,000 6. The following persons or entities shall be included as additional insured on the Commercial Liability, Comprehensive Automobile Liability, and Umbrella Excess Liability. This coverage shall be primary and noncontributory: a. Owner b. Engineer SUPPLEMENTARY CONDITIONS 0 2014 Stantec 193802836 007305-2 SC -5.06.A Amend the first sentence of Paragraph 5.06.A to read: A. Contractor shall purchase and maintain during the entire construction period a Builders Risk Property Insurance Policy in the amount of the full replacement cost of the entire Work at the Site. The insurance policy shall comply with the provisions of Paragraph 5.06.A1 through 5.06.A7. A minimum deductible of $1,000 each claim shall apply to this insurance and the risk of loss of the applicable deductible shall be born by Contractor, subcontractor, or others suffering such loss. In addition, the provisions of Paragraphs 5.07, 5.09, and 5.10 shall apply with the exception that Contractor shall act as fiduciary for the insureds as their interest may appear and adjust the loss with the insurance company. SC -5.06.A Add the following new item immediately after Item 5.06.A7: B. The Builder's Risk Insurance required herein shall apply to projects involving construction of structures and buildings only. The requirements of this Section shall be waived on projects involving only underground utilities, grading, street improvements, and similar construction work but any damage or loss to property shall be at the sole responsibility of Contractor until final acceptance of the Work. 9. Comply with the requirements of Paragraph 5.06C of the General Conditions. ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES SC -6.06 Add the following new paragraph immediately after Paragraph 6.06.G: H. Pursuant to Minnesota Statute, Contractor shall be fully responsible to pay subcontractors, suppliers, and other entities within 10 days of the Contractor's receipt of payment for undisputed services provided by the subcontractor, supplier, or other entity. Contractor shall pay interest of 1-1 /2 percent per month or any part of a month to the subcontractor, supplier, or other entity on any amount not paid on time to the subcontractor, supplier, or other entity. The minimum monthly interest penalty payment for an unpaid balance of $100 or more is $10. For an unpaid balance of less than $100, the Contractor shall pay the actual penalty due to the subcontractor, supplier, or other entity. A subcontractor, supplier, or other entity who prevails in a civil action to collect interest penalties from a Contractor must be awarded its costs and disbursements, including attorney's fees included in bringing the action. I. Owner may furnish to any Subcontractor or Supplier, to the extent practicable, information about amounts paid to Contractor on account of Work performed for Contractor by a particular Subcontractor or Supplier. SC -6.08.A Amend the first sentence of Paragraph 6.08.A by replacing the words "the Supplementary Conditions" with the words "Division 01." SC -6.19.A Delete the words "representation of" in the second sentence. SUPPLEMENTARY CONDITIONS 0 2014 Stantec 1 193802836 007305-3 ARTICLE 10 - CHANGES IN THE WORK; CLAIMS SC -10.05.13 Amend the first sentence of Paragraph 10.05.8 by replacing the words "30 days" with the words "10 days." Amend the third sentence of Paragraph 10.05.13 by replacing the words "60 days" with the words "30 days." ARTICLE 11 • COST OF THE WORK; CASH ALLOWANCES; UNIT PRICE WORK SC -11.03 Delete paragraph 11.03.D in its entirety and insert the following in its place: D. Payment for the Bid Items on a Unit Price basis under this Contract shall be on the basis of quantities actually used in the construction, regardless of the estimated quantities shown in the Bid Form. No revision to the Contract Unit Prices for the Bid Items shall be considered or allowed due to variations of the actual quantities from the estimated amounts. ARTICLE 13 • TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK SC -13.07.A Amend the first sentence of Paragraph 13.07.A by striking out the words "one year" and inserting the words "two years." ARTICLE 14 - PAYMENTS TO CONTRACTOR AND COMPLETION SC -14.02.B5 Add the following new item immediately after Item 14.02.135d: e. Contractor's failure to make acceptable submittals in accordance with the accepted schedules. ARTICLE 16 - DISPUTE RESOLUTION SC -16.01 Delete Paragraph 16.01.0 in its entirety and insert the following in its place: C. If the claim is not resolved by mediation, Engineer's action under Paragraph 10.05.0 or a denial pursuant to Paragraphs 10.05.C3 or 10.05.D shall become final and binding 30 days after termination of the mediation, unless within that time period Owner or Contractor: 1. elects in writing to demand arbitration of the claim, pursuant to Paragraph SC -16.02, or 2. agrees with the other party to submit the claim to another dispute resolution process. SC -16.02 Add the following new paragraph immediately after Paragraph 16.01: 16.02 Arbitration A. All claims or counterclaims, disputes, or other matters in question between Owner and Contractor arising out of or relating to the Contract Documents or the breach thereof (except for claims which have been waived by the making or acceptance of Final Payment as provided by Paragraph 14.09), including but not limited to those not resolved under the provisions of Paragraphs SC -16.01.A and 16.01.13, will be decided by arbitration in accordance with the Construction Industry Dispute Resolutions Procedures of the American Arbitration Association then in effect subject to the conditions and limitations of this Paragraph SC -16.02. This agreement SUPPLEMENTARY CONDITIONS © 2014 Stantec 1193802836 007305-4 to arbitrate and any other agreement or consent to arbitrate entered into will be specifically enforceable under the prevailing law of any court having jurisdiction. B. The demand for arbitration will be filed in writing with the other party to the Contract and with the selected arbitrator or arbitration provider and a copy will be sent to Engineer for information. The demand for arbitration will be made within the 30 -day period specified in Paragraph SC -16.01.0 and in all other cases within a reasonable time after the claim or counterclaim, dispute, or other matter in question has arisen, and in no event shall any such demand be made after the date when institution of legal or equitable proceedings based on such claim or other dispute or matter in question would be barred by the applicable statute of limitations. C. No arbitration arising out of or relating to the Contract Documents shall include by consolidation, joinder, or in any other manner any other individual or entity (includ- ing Engineer, Engineer's consultants and the officers, directors, partners, agents, employees, or consultants of any of them) who is not a party to this Contract, unless: 1. the inclusion of such other individual or entity is necessary if complete relief is to be afforded among those who are already parties to the arbitration; and 2. such other individual or entity is substantially involved in a question of law or fact which is common to those who are already parties to the arbitration and which will arise in such proceedings. D. The award rendered by the arbitrator(s) shall be consistent with the agreement of the parties in writing and include: (i) a concise breakdown of the award: (ii) a written explanation of the award specifically citing the Contract Document provisions deemed applicable and relied on in making the award. E. The award will be final. Judgment may be entered upon it in any court having jurisdiction thereof and it will not be subject to modification or appeal, subject to provisions of the Controlling Law relating to vacating or modifying an arbitral award. The fees and expenses of the arbitrators and any arbitration service shall be shared equally by Owner and Contractor. END OF SECTION SUPPLEMENTARY CONDITIONS 0 2014 Stantec 1193802836 00 73 05 - 5 SECTION 01 10 00 SUMMARY PART 1 GENERAL 1.01 SUMMARY A. Section Includes 1. Basic description of the Project and Work restrictions. 1.02 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. All Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. 1.03 SUMMARY OF WORK A. Project Name: 2014 Crack Repair and Seal Coat for the City of New Hope, Minnesota, City Project No. 930. B. Description of Work: Crack repair, seal coat, and fog seal street improvements. 1.04 COMPLETION DATES A. Substantial Completion: Set forth in the Agreement. B. Final Completion: Set forth in the Agreement. '.05 LIQUIDATED DAMAGES A. Provisions for liquidated damages, if any, are set forth in the Agreement. .06 WORK RESTRICTIONS A. Use of Site 1. Location of construction facilities, staging areas, product stockpiles, material storage, and temporary construction are at the Public Works Facility as shown on the Drawings and shall be removed upon completion of Work. 2. Keep existing driveways and entrances clear and available to the public and to the Owner. 3. If additional space is needed, obtain and pay for such space off Site. B. The Owner has the right to limit/eliminate any of the described work to fit budget constraints without adjustment to Bid Unit Prices. C. Construction Hours: Contractor must abide by the following hours per City ordinance: 1. Monday through Friday: 7 A.M. to 9 P.M. 2. Saturday: 9 A.M. to 9 P.M. 3. No work on Sundays or Holidays. 0 2013 Stantec 193802836 SUMMARY 01 1000-1 PART 2 PRODUCTS Not Used. PART 3 EXECUTION Not Used. END OF SECTION SUMMARY © 2013 Stantec 1 193802836 01 1000-2 SECTION 01 20 00 PRICE AND PAYMENT PROCEDURES PART I GENERAL 1.01 SUMMARY A. Section Includes 1. Administrative and procedural requirements for pricing of Work and request for payment procedures. 02 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. All Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. .03 BID UNIT PRICES A. Provide access and assist Engineer in determining actual quantities of Bid Unit Price work. B. Provide documentation to substantiate Bid Unit Price work. C. If the Contractor delivers and places more of any material that is paid for on a Bid Unit Price basis than is required to perform the Work and thereby causes the materials to be wasted, the quantity wasted will be deducted from the final measurement for that Bid Item. .04 PAYMENT PROCEDURES A. Engineer will provide initial Application for Payment Form at the Preconstruction Conference. B. Submit 1 preliminary copy of progress payment application for review, consistent with Article 14 of the General Conditions. Submit 4 signed copies of Application for Payment to Engineer prior to the dates identified at the Preconstruction Conference. C. Attach the following supporting documentation, in addition to the requirements of General Conditions Article 14: 1. Documentation to substantiate Bid Unit Price work. 2. Updated construction schedule consistent with Section 01 33 00. PART 2 PRODUCTS Not Used. PART 3 EXECUTION 1Zni1�:I END OF SECTION © 2014 Stantec 1 1938102836 PRICE AND PAYMENT PROCEDURES 01 2000-1 SECTION 01 31 00 PROJECT MANAGEMENT AND COORDINATION PART 1 GENERAL 1.01 SUMMARY A. Section Includes 1. General requirements for overall Project coordination. ;.02 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. All Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. 1.03 UTILITIES A. Notify Gopher State One Call before starting construction in a given area requesting utility locates in the Site. 1.04 PERMITS A. Apply for, obtain, and comply with other permits, licenses, and approvals which maybe required for the Project. 1.05 SURVEYING AND CONSTRUCTION OBSERVATION A. Provide Engineer a minimum of 48-hour notice in advance of the need for measurements, and observation of Work. 1.06 PROJECT MEETINGS A. Administrative Requirements 1. Project Superintendent or persons designated by the Contractor to attend and participate in the Project meetings shall have all required authority to commit the Contractor to solutions agreed upon in the Project meetings. 2. Engineer will set the time, sites, and prepare the agenda for the meetings. 3. Engineer will prepare meeting minutes and distribute 1 copy to Contractor. Notify Engineer of inaccuracies or discrepancies in the meeting minutes within 5 calendar days of receipt of the minutes. 4. The attendance and cooperation of subcontractors and suppliers may be required. B. Preconstruction Conference 1. Provisions for the Preconstruction Conference are set forth in the General Conditions. 2. Requirements for preconstruction submittals are set forth in the General Conditions. Submittal procedures shall be consistent with Section 01 33 00. PROJECT MANAGEMENT AND COORDINATION © 2014 Stantec 1 193802836 013100-1 C. Progress Meeting Procedures Engineer will schedule construction progress meetings throughout the duration of the Project to assess the progress of the Work, identify and discuss Project related issues, and discuss near-term construction activities. 1.07 CONSTRUCTION SCHEDULING A. Sequencing and Scheduling: 1. Seal coat operations shall not begin until the crack repair has been completed. 2. Fog seal operations shall not begin until the crack repair and seal coat has been completed, and following the second sweeping within the seal coat areas. PART 2 PRODUCTS Not Used. PART 3 EXECUTION Not Used. END OF SECTION PROJECT MANAGEMENT AND COORDINATION 0 2014 Stantec 1 193802836 01 3100-2 SECTION 01 33 00 SUBMITTAL PROCEDURES PART 1 GENERAL 1.01 SUMMARY A. Section Includes 1. General procedures and requirements for submittals during the course of construction. 1.02 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. All Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid, 1.03 SEQUENCING AND SCHEDULING A. Schedule submittals consistent with the Contractor's schedule of shop drawings. PART 2 PRODUCTS Not Used. PART 3 EXECUTION 3.01 CONSTRUCTION SCHEDULE A. Submit preliminary schedule and progress schedule consistent with the General Conditions. B. Prepare schedules on 8.5 inch by 11 inch sheets showing overall sequence of construction. Organize the schedule by work activity. Identify separate stages of each work activity: 1. List work items in chronological sequence. Show beginning and completion dates of each activity. Include all activities with an estimated duration of 3 days or longer. 2. Provide space for revisions and notations. 3. Identify interrelations between activities. 4. Include estimated times for preparation of submittals by Contractor, processing and review of submittals by Engineer, fabrication, delivery, installation, testing, start-up, instruction of Owner, and clean-up. C. As Work progresses, revise, update, and resubmit schedule as requested by Engineer. At a minimum, update schedule with each Application for Payment. Show all activities started or finished since previous schedule was submitted and show percentage of completion for each activity. 0 2014 5tantec 1 193802836 013300-1 3.02 EMERGENCY CONTACT LIST A. Before any Work at the Site is started, submit a typed list on 8.5 inch by 11 inch paper outlining 24-hour on-call contacts for the Project. This list shall include the Contractor's safety representative, key representatives from the Contractor, subcontractors, and suppliers. Include fhe following information for each contact: 1. Company name. 2. Contact person(s). 3. Local and mobile phone numbers. 4. Fax number. 3.03 TEST REPORTS A. Submit 3 copies of all inspections, tests, and approvals required in the Specification. 3.04 MATERIAL AND SAFETY DATA SHEETS A. Furnish Owner with current copies of Material and Safety Data Sheets for all chemicals and products on Site. END OF SECTION © 2014 Stantec : 193802836 SECTION 01 40 00 QUALITY REQUIREMENTS PART 1 GENERAL 1.01 SUMMARY A. Section Includes 1. Information required for conformance to regulatory requirements. 2. Quality assurance. 3. Procedures to measure and report the quality and performance of the Work. 1.02 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. All Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. 1.03 REFERENCE STANDARDS A. Whenever reference is made to the Minnesota Department of Transportation Specifications, such reference shall mean "Standard Specifications for Construction," 2005 Edition (MnDOT Spec.) and all subsequent revisions and supplements. The word "Engineer" is understood to refer to the Engineer for the Owner. 1.04 SUBMITTALS A. Prior to start of Work, submit testing laboratory name for various specified tests for approval by Engineer. B. Laboratory test results or analysis. C. Manufacturer's certificates of quality control or performance. 1.05 WORKMANSHIP A. Comply with industry standards of the region, except where more restrictive tolerances or specified requirements indicate more rigid standards or more precise workmanship. 1.06 TESTS AND INSPECTIONS A. Conform to the requirements of the General Conditions, except as modified herein. B. Notify Engineer 48 hours prior to expected time for operations requiring tests and inspections. 1.07 LABORATORY REPORTS A. After each inspection and test, submit 3 copies of Laboratory Report to Engineer. QUALITY REQUIREMENTS Q 2014 Stantec 1 193802836 014000-1 B. Include: Date issued, Project title and number, name of inspector, date and time of sampling or inspection, identification of product and Specifications Section, location in the Project, type of inspection or test, date of test, results of tests, and conformance with Contract Documents. 1.08 LABORATORY RESPONSIBILITIES A. Test samples and perform field tests. B. Provide qualified personnel. Cooperate with Engineer and Contractor in performance of services. C. Ascertain compliance with the requirements of the Contract Documents. D. When requested by Engineer, provide interpretation of test results. 1.09 LIMITS ON TESTING LABORATORY AUTHORITY A. Laboratory may not release, revoke, alter, or enlarge on requirements of Contract Documents. B. Laboratory may not approve or accept any portion of the Work. C. Laboratory may not assume any duties of Contractor. D. Laboratory has no authority to stop Work. 1.10 MANUFACTURER'S CERTIFICATES A. If requested by Engineer, submit manufacturer's certificate that products meet or exceed specified requirements. 1 1 MANUFACTURER'S FIELD SERVICES A. Provide qualified representative to observe field conditions, conditions of surfaces and installation, and quality of workmanship. PART 2 PRODUCTS Not Used. PART 3 EXECUTION Not Used. END OF SECTION 0 2014 Stantec 193802836 SECTION 01 50 00 TEMPORARY FACILITIES AND CONTROLS PART 1 GENERAL i _01 SUMMARY A. Section Includes 1. Temporary utilities and miscellaneous temporary facilities required during construction. B. Products furnished but not installed under this Section or products installed but not furnished under this Section. .02 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. A Bid Item has been provided for Mobilization. Measurement is Lump Sum. This will be considered payment in full for all work and costs of this Bid Item. The amount of the Lump Sum Bid shall not exceed 5 percent of the Total Base Bid. 2. A Bid Item has been provided for Traffic Control. Measurement is Lump Sum. a. This shall be considered payment in full for all labor, equipment, and materials associated with the required Traffic Control devices for the entire Project, b. This Bid Item shall include but not be limited to furnishing, installing, and relocating the Traffic Control due to various road closures, daily maintenance, and ultimate removal of all such devices used over the duration of the Contract or as directed by the Engineer. c. Traffic Control in areas receiving a fog seal must be maintained for four hours, unless approved otherwise by the Engineer. 3. All other Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2005 Edition (MnDOT Spec.). B. The Minnesota Manual on Uniform Traffic Control Devices (MMUTCD), including the Field Manual on Temporary Traffic Control Zone Layouts - Latest edition. C. Minnesota Department of Transportation Traffic Engineering Manual. 1.04 SUBMITTALS A. Construction Staging Plan consistent with Section 01 33 00, including the following information: 1. Sequence of construction and traffic control. 2. Streets closed or restricted during any stage of construction. 3. Provisions for routing any detoured traffic as permitted. 4. Specific signs, striping, and other traffic control devices to be utilized. TEMPORARY FACILITIES AND CONTROLS © 2014 Stantec 193802836 015000-1 SECTION 01 70 00 EXECUTION REQUIREMENTS PART 1 GENERAL .01 SUMMARY A. Section Includes 1. Requirements for overall execution of the Work and closeout of the Contract for Final Payment. B. Measurement and Payment 1. All Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. 1.02 SUBMITTALS A. Submit the following items consistent with the Conditions of the Contract and Division 01 Sections: 1. Record Documents. 2. Written Notification of Substantial Completion. 3. Executed Certificate of Substantial Completion. 4. Written Notification of Final Completion. 5. Final Application for Payment, including accompanying documentation. 6. IC -134 Form. PART 2 PRODUCTS Not Used. PART 3 EXECUTION 3.01 EXAMINATION A. Acceptance of Conditions: By commencing Work, Contractor construes acceptance of the adjacent work as satisfactory to receive subsequent work. B. Existing Conditions: Before commencing Work, inspect work completed by others that is adjacent to Work. If adjacent conditions prevent completion of Work, Contractor will not commence Work until the conditions are corrected. C. Inspect material prior to installation. Remove materials that do not conform with the specifications. 3.02 GENERAL INSTALLATION REQUIREMENTS A. Install each element of work during weather conditions and Project status to ensure coordination of the Work. 02014 Stantec 193802836 01 7000-1 a) Delivery of material. b) Distributor calibration. c) Distribution and application. 3) This Bid Item is intended for streets that receive a seal coat prior to the fog seal. Bid Form quantity is estimated based on an application rate of 0.10 to 0.13 gallons per square yard. d. Bituminous Material for Fog Seal - Cul de Sac or Parking Lot. 1) Measurement shall be based on square yards of material placed and accepted. 2) Payment shall be made based on the Bid Item provided on the Bid Form and shall include the following: a) Delivery of material. b) Distributor calibration. c) Distribution and application. 3) This Bid Item is intended for Cul de sacs and parking lots that do not receive a seal coat prior to the fog seal. Bid Form quantity is estimated based on an application rate of 0.08 to 0.10 gallons per square yard. 2. The Owner reserves the right to add or decrease the Bid Form quantities without a change in the Bid Unit Price. 3. If any application rate of the aggregate or bituminous material, as determined by the Engineer, is greater than TO percent that designated by the Engineer at the start of the Project, the materials in excess shall be incidental to the remainder of the Project. 4. All other Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2005 Edition (MnDOT Spec.). 1. 2355 - Bituminous Fog Seal. 2. 2356 - Bituminous Seal Coat. 3. 3127 - Fine Aggregate for Bituminous Seal Coat. 4. 3137.2B - Aggregate Classification. 5. 3151 - Bituminous Material. 6. Minnesota Seal Coat Handbook (MSCH). 1.04 SEQUENCING AND SCHEDULING A. The Contractor must provide the Engineer and Owner 1 week notice before starting the Work in general. B. Aggregate must be delivered and stockpiled 7 days prior to the start of construction to allow the Owner time to perform the necessary testing. C. Aggregate stockpiling shall be at New Hope Public Works Facility. The location is shown on the Drawings and will be reviewed at the preconstruction meeting. 1. The Contractor must keep a loader at the stockpile atoll times and maintain the stockpile as necessary. 2. The stockpile must be kept within the designated limits and not be allowed to spread to the extent that it interferes with City and residential activity. © 2014 Stantec 1 193802836 SEAL COATS 321236-2 D. Prior to starting Work, the Contractor shall meet the Engineer and Owner to discuss the method and means of material supply, a work schedule, and a general review of the Specifications. E. The Contractor shall coordinate with the City on any repairs needed to pavement prior to seal coating or fog sealing. F. The Contractor is responsible for notifying the Engineer 72 hours in advance of the seas coating operations for developments to allow the Engineer time to distribute notification to the residents restricting parking and use during the seal coat operation. G. The Contractor is responsible for notifying the Engineer 7 days in advance of the fog sealing operations to allow the Engineer time to distribute notification to residents restricting parking and use during the fog seal operation and curing time. 1. The Contractor should anticipate providing traffic control for a 4 -hour time frame in all areas receiving a fog seal. 2. This time frame maybe reduced if the fog seal has fully cured to the satisfaction of the Contractor and the Engineer. PART 2 PRODUCTS 2.01 MATERIALS A. Bituminous Material for Seal Coat 1. Conform to MnDOT Spec. 3151, Emulsified Asphalt, Cationic Grade, CRS -2. B. Seal Coat Aggregate 1. Conform to MnDOT Spec. 3127 and 3137 a. Aggregate classification, conform to MnDOT Spec. 3137.213. 1) Class A Aggregate. 2) Aggregate gradation, conform to MnDOT Spec. 3127.2B. a) FA - 2 modified. (1) Minimum 75 percent of material by weight retained on 2 consecutive sieves. (2) A material sample may be required prior to approval. C. Bituminous Material for Fog Seal 1. Conform to MnDOT Spec. 3151, Emulsified Asphalt, Cationic Grade, CSS -1h. a. Diluted to a ratio of one part water to one part emulsion at the place of manufacture. PART 3 EXECUTION 3.01 GENERAL A. Prospective Bidders are advised to inspect all streets and verify existing conditions to their own satisfaction prior to submitting a Bid. 3.02 RESTRICTIONS A. Conform to MnDOT Spec. 2356.3A, except as modified herein: 5',EAL COATS 0 2014 Stantec 1 193802836 321236-3 T . Seal coating operations shall be conducted only between 7 A.M. and 9 P.M. Monday through Friday, and 9 A.M. to 9 P.M. on Saturdays. No work is permitted on Sundays or holidays, unless approved by Owner. 2. Fog sealing operations shall be conducted only between 9 A.M. and 4 P.M. Monday through Friday. No fog sealing work is permitted on Saturdays, Sundays or holidays, unless approved by Owner. 3. Any water required can be provided by the Owner. Coordinate with Bernie Weber, 763-592-6762, at Public Works. 4. Assign at least 1 laborer strictly to walk behind the chip spreader operation to hand broom or clean up any missed area or piles of aggregate. 5. Application of bituminous material to concrete curb surfaces and into City storm sewers is prohibited. The Contractor will be responsible for the immediate removal of said material. 6. The seal coat operations may be conducted only when the pavement and air temperature is 70 degrees F or higher and relative humidity is less than 75 percent. 7. The fog seal operations may be conducted only when the pavement and air temperature is 60 degrees F or higher. 3.03 EQUIPMENT A. Seal Coat - Conform to MnDOT Spec. 2356.3B, except as modified herein. 1. Aggregate spreader shall be a self-propelled and computerized. 2. The sweeping broom shall be a power pick up broom. B. Fog Seal - Conform to MnDOT Spec. 2355.3B. 3.04 SURFACE PREPARATIONS A. All street surfaces carefully cleaned, scraped, swept, and approved by the Engineer prior to seal coating or fog sealing. B. Application of water may be required to minimize the creation of air borne dust and assist in the sweeping and cleaning operation. C. Hand cleanup used as necessary. D. Cover all manhole and gate valve box covers with fine aggregate or sand prior to seal coating or fog sealing, so that bituminous material does not adhere to the cover surface. 1. Clean all fine aggregate and bituminous material from manhole and gate valve box covers once Work is completed. 2. Dispose of all fine aggregate and bituminous material at an acceptable location outside the City limits. 3.05 BITUMINOUS MATERIAL APPLICATION A. Seal Coat - Conform to MnDOT Spec. 2356.3D, except as modified herein: 1. Application rates shall be modified only as directed by the Engineer or an authorized representative. 2. Application rates will be determined based on existing surface conditions and traffic volumes. B. Fog Seal - Conform to MnDOT Spec. 2355.3D, except as modified herein: I. Streets receiving seal coat prior to fog seal - 0.10 to 0.13 Gal/SY. O 2014 Sta ntec I 193802836 321236-4 2. Cul de sacs and parking lots that do not receive seal coat prior to fog seal - 0.08 to 0.10 Gal/SY. 3. Temperature of bituminous material at application - 120-175°F. 3.06 AGGREGATE APPLICATION A. Conform to MnDOT Spec. 2356.3E, except as modified herein: 1. Application rates shall be modified only as directed by the Engineer or an authorized representative. 2. The Contractor is responsible to perform the test strip and calibration of the chip spreader in accordance to the "Standard Method for Determining the Transverse Spread Rate for Surface Treatment Application" {Modified Method ASTM D5624-951. a. Complete this procedure on the first day of seal coat application and 1 additional time during construction as requested by the Engineer. b. All cost associated with this test are considered incidental to the aggregate placement Bid Item. 3. Hand spreading or brooming of seal coat aggregate will be required of the Contractor where non-uniform application of seal coat bitumen and/or aggregate occurs, and small irregular areas. 3.07 ROLLING OPERATIONS A. Conform to MnDOT Spec. 2356.3F, except as modified herein: 1. Rolling operations shall be performed to allow the aggregate to properly be embedded into the binder material prior to the binder "breaks." 2. A minimum of 3 rollers will be required. 3. Compact for a minimum of 3 passes over all areas with 5 passes required on heavily traveled roadways with speed limits greater than 30 mph. 4. Roller speed not to exceed 5 mph. 3.08 INITIAL SWEEPING OF EXCESS AGGREGATE A. Sweeping operations shall begin approximately 1 to 3 days after seal coat has been allowed to set up. B. Engineer to determine the exact date to begin sweeping operations. C. In the event that the Contractor has not completed the sweeping within the specified time of the completion of application, a penalty of $100 per calendar day will be charged until the sweeping is completed. D. Utilize more than 1 power pick-up broom if necessary to meet time requirement. E. The Contractor shall be responsible for the sweeping and removal of the excess aggregate from the streets shall be disposed of off Site. F. If sweeping operations are not satisfactory, the Contractor is responsible to return and complete sweeping at no additional cost to the Owner. 0 2014 Stantec ; 193802836 SEAL COATS 321236-5 3.09 SECOND SWEEPING OF EXCESS AGGREGATE A. Schedule a minimum of 10 calendar days from the date of the initial sweeping of the excess aggregate material and schedule prior to fog sealing. B. The Contractor shall notify the Engineer of the schedule for this sweeping. C. Sweeping performed by 1 or more power pick-up brooms. D. Dispose of all loose aggregate material collected by the sweeping operation at an acceptable location outside the City limits. E. If the Contractor fails to perform the second sweeping within the time frame specified, a penalty of $100 per calendar day will be charged until the sweeping is complete. 3.10 FOG SEAL A. Fog seal should not be applied until after the second sweeping in seal coat areas. B. The fog seal should not be applied until the road surface and weather conditions are acceptable to the Engineer. C. At the time of application, the road surface shall be clean and dry as approved by the Engineer. 3.11 PROTECTION A. Seal Coat and Fog Seal - Conform to MnDOT Spec. 2356.3G, except as modified herein: 1. The Contractor shall be responsible for damage done to any adjacent driving surfaces, shoulders, or boulevards. Traffic Control I . Seal Coat - It will be the Contractors responsibility to install and maintain warning signs at the entrances to developments or the ends of the streets being seal coated. a. These signs shall be 36 inches by 36 inches with the wording "Loose Rock." b. Signs equipped with warning lights. c. Signs are to remain in-place until the sweeping of excess aggregate is complete. d. Compensation for all Work related as part of the Bid Item "Traffic Control." 2. Fog Seal - It will be the Contractors responsibility to install and maintain traffic control restricting travel on newly fog sealed areas until the bituminous material has cured and will no longer be tracked or picked up on vehicle tires. a. Compensation for all Work related as part of the Bid Item "Traffic Control." b. Traffic Control in areas receiving a fog seal must be maintained for four hours, unless approved otherwise by the Engineer. 3. Flexible Raised Reflector Pavement Marking Devices. a. Provide new flexible raised reflector pavement marking devices to identify all existing pavement markings where applicable. b. The color must correspond to the existing pavement markings. c. Install these devices 5 days prior to seal coating or fog sealing each specific street. d. The interval or spacing for this work shall be a minimum of 100 feet or where changes are made in the existing stripping. SEAL COATS 0 2014 Stantec 1 193802836 321236-6 e. The cost for this work shall be included in the Traffic Control Bid Item on a Lump Sum basis. 4. Traffic rerouting is the responsibility of the Contractor. 5. All flag persons, barricades, flashers, and safety measures are the sole responsibility of the Contractor. 6. Provide sufficient direction and warning signs on the Project to minimize inconvenience to property owners and the traveling public. 7. Provide reasonable access at all times for abutting property owners and for emergency vehicles. lltiii7P flares or approved flashers from sunset to sunrise if required by the construction. 3.12 FIELD QUALITY CONTROL A. The Contractor shall submit for review by the Engineer at the Pre -Construction Conference, a report from an independent testing laboratory indicating the gradation, median aggregate size, flakiness index, bulk specific gravity, and loose unit weight of the aggregate being supplied for the Project. This information shall be used to determine the design application rates for the aggregate and bituminous material. B. The Contractor shall submit for review by the Engineer at the Pre -Construction Conference information regarding the anticipated residual asphalt content of the proposed binder material. C. The Contractor is responsible for notifying the Engineer of pit location, bituminous supply, scale location, and any other correlated items in advance of starting time, so that adequate control measures can be established. D. Inspections shall be performed in accordance to the MnDOT Seal Coat Handbook. END OF SECTION © 2014 Stantec 193802836 321236-7 SECTION 32 12 80 FLEXIBLE PAVING JOINT CONSTRUCTION PART 1 GENERAL 1.01 SUMMARY A. Section Includes 1. The rehabilitation of longitudinal and traverse cracks in existing bituminous pavements and curb by a method of clean and seal. B. Related Sections 1. Section 32 12 36 - Seal Coats and Fog Seals. 1.02 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. A Bid Item has been provided for Crack Seal (Clean and Seal). Measurement shall be based on pounds of material placed on the Project as determined from the weight tickets and documentation supplied by the contractor. Payment shall include equipment and labor, removals, disposal of existing materials, joint preparation, sealant material and application, paper protection, street sweeping and cleanup, and all other incidentals. a. The method of crack seal shall be Clean and Seal, or formerly known as Blow and Go. 2. All other Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2005 Edition (MnDOT Spec.) 1. 3127 - Fine Aggregate for Bituminous Seal Coat. 2. 3151 - Bituminous Material. 3. 3723 - Joint and Crack Sealer (Hot -Poured Elastic Type). 1.04 SUBMITTALS A. Submit the following items: 1. Product and data sheet for joint sealant material. 2. Manufacturer's recommendations pertaining to heating and application of joint sealant. 1.05 DEFINITIONS A. Crack Seal. Cleaning and sealing of existing random joints of an existing bituminous pavement. 1. The Work shall consist of repairing cracks in the streets shown on the Drawings. Cracks to be repaired shall be as directed by Engineer, including longitudinal and transverse cracks. All longitudinal centerline and lip of curb joints shall be sealed regardless of FLEXIBLE PAVING JOINT CONSTRUCTION © 2014 Stantec 1 193802836 321280-1 visible cracking or crack size. All cracks within the curb from the lip to the face of curb shall be sealed. Cracks repaired in previous years will not be cleaned and refilled unless directed by Engineer. 1.06 SEQUENCING AND SCHEDULING A. Crack seal of existing joints shall be completed prior to bituminous pavement treatments. B. Specific locations of the crack repair work and method of treatment shall be identified by the Engineer prior to the Contractor performing the specified Work. PART 2 PRODUCTS 2.01 JOINT SEALANT MATERIALS A. Conform to MnDOT Spec., except as modified herein. 1. Clean and Seal: Conform to MnDOT Spec. 3723. 2. Protective paper covering for clean and seal shall consist of 2 ply toilet paper. PART 3 EXECUTION 3.01 GENERAL A. The application shall be for longitudinal and traverse cracks. The completed joint repair treatment shall have a homogenous appearance and a uniform texture. B. Perform bituminous joint construction operations during daylight hours. C. Establish traffic control which is compatible to the operations being performed. 3.02 PREPARATION A. Weather Limitations: 1. The existing bituminous surface must be dry prior to performing the joint construction work. 2. Air temperature in the shade and away from artificial heat sources is at least 40 degrees F 3.03 CLEANING JOINTS A. Dry Joints 1. Clean thoroughly with a 100 -psi air blast to remove any dust, dirt, or deleterious matter adhering to the joint walls or in the joint cavity. 2. Blow or brush the dry dust and material off the pavement surface. All streets must be swept after crack sealing to pick up millings. 3.04 HEATING JOINTS A. Dry and warm joints with a hot compressed air heat lance immediately prior to placing the sealant. 1. Temperature of Air at Exiting Orifice: At least 2,800 degrees F. 2. Velocity of Exiting Heated Air: At least 2,800 fps. © 2014 Stantec 193802836 FLEXIBLE PAVING JOINT CONSTRUCTION 321280-2 3.05 SEALING A. Heat sealant material in a kettle or melter constructed as a double boiler with the space between the inner and outer shells filled with oil or other heat transfer medium. B. Heat or insulate applicator wand to maintain the pouring temperature of the sealant during the placement operations. C. Do not use pour pots or similar devices to fill joints. D. Adhere to Manufacturer's Recommendations. 1. Do not let field application equipment exceed the safe heating temperature recommended by manufacturer. E. Do not re -neat sealant material. F, Crack Seal 1. The sealed joint shall have a 4 inch over band of sealant material. 2. The sealed joint shall be protected with a 2 -ply toilet paper to prevent tracking. G. The Contractor shall protect the completed work for the full amount of time required for curing of the materials placed. 3.06 FIELD QUALITY CONTROL A. Final results of cleaning joint subject to Engineer's approval. B. Application time of sealing is subject to Engineer's approval. C. Do not place sealant if Engineer determines the weather and roadbed conditions to be unfavorable. D. Final appearance of sealed joint shall present a neat, fine line. END OF SECTION FLEXIBLE PAVING JOINT CONSTRUCTION ©20T4 Stantec 193802836 321280-3 SECTION 32 17 23 PAVEMENT MARKINGS PARTi GENERAL 1.01 SUMMARY A, Section Includes 1. Pavement markings for control and guidance of traffic. B. Related Sections 1. Section 32 12 36 - Seal Coats and Fog Seals. 1.02 PRICE AND PAYMENT PROCEDURES A. Measurement and Payment 1. Lines a. Lines shall be measured by the lineal foot on the basis of length actually applied T ) Separate measurement made on the basis of color and nominal width. 2) Double yellow lines shall be measured to include both lines per linear foot of quantity because they are applied simultaneously. 3) Paint shall be applied twice, and shall only be paid on the basis of length actually applied; i.e., 1,000 feet of paint shall be applied twice following bituminous wearing course shall be paid as 1,000 feet. 2. Messages a. Messages shall be measured on the basis of each applied 1) Separate measurement will be made for each type of message_ 2) Per each cost for messages includes two applications as specified. 3. Bid Items for pavement markings of each type are provided, Payment of each Bid Item shall be compensation in full for all costs incidental thereto, including but not limited to surface preparation, traffic control measures, maintaining the Work, removal of temporary pavement markers, together with any other expenses incurred in completing the Work that are not specifically included for payment under the Contract Bid items. 4. All other Work and costs of this Section shall be incidental to the Project and included in the Total Base Bid. .03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2005 Edition (MnDOT Spec.) 1. 3591 - High Solids Water Based Traffic Paint. 2. 3592 - Drop -On Glass Beads. 3. The Application Specification for Conventional Pavement Marking Materials. 4. 3 -Minute Dry Alkyd and High Solids Latex. 1.04 SUBMITTALS A. 1 copy of the chosen paint lot or batch formulation. PAVEMENT MARKINGS © 2013 Stantec 1193802836 321723-1 B. Pavement Marking Contractor Qualifications/Certifications. C. MnDOT Certification approvals. .05 SEQUENCING AND SCHEDULING A. Conform to the requirements of MnDOT Specifications. PART 2 PRODUCTS 2.01 MATERIALS A. Paint 1. High Solids Water Based a. Free of toxic heavy metals, including lead, mercury, and cadmium. b. Track Free Time - 3 minutes or less. c. Yellow Prime Pigment - Colour Index Pigment Yellow No. 65 or No. 75. d. White Color- Flat White. e. Yellow Color - Color No. 33538 of Federal Standard 595. 2. 3 -Minute Dry Alkyd a. Free of toxic heavy metals, including lead, mercury, and cadmium. b. Track Free Time - 3 minutes or less. c. Yellow Prime Pigment - Color Index Pigment Yellow No. 65 or No. 75. d. White Calor - Flat White. e. Yellow Color - Color No. 33538 of Federal Standard 595. B. Glass Beads 1. Conform to MnDOT Spec. 3592. 2.02 EQUIPMENT A. General 1. Vehicles used shall be deployed and equipped with traffic control devices set forth in the "Minnesota Manual on Uniform Traffic Control Devices, Field Manual." 2. Shadow vehicle with truck -mounted attenuator shall be used on streets with posted speed equal to or greater than 40 -mph or ADT greater than 1,500 vehicles per day. 3. Equipment used for spray applications shall be capable of applying glass beads by a pressurized system at a rate of at least 25 Ibs/gal. 4. Capable of accumulating footage applied per gun. 5. Stainless steel components in the delivery system required for water-based materials. PART 3 PART 3 EXECUTION 3.01 GENERAL A. The pavement marking crew shall include at least each of the following areas: 1. Equipment operation. 2. Application techniques. 3. Traffic control. 4. Safety regulations. © 2013 Stantec 1 193802836 technical expert knowledgeable in PAVEMENT MARKINGS 321723-2 B. The filling of tanks, pouring of materials, or cleaning of equipment shall not be performed on unprotected pavement surfaces, unless adequate provisions are made to prevent spillage of material. 3,02 SCHEDULE A. Point Pavement Markings 1. Place following completion of fog sealing: a. No sooner than 24 hours after placement of fog seal. b. Within 7 working days of completion of fog seal. 3.03 PREPARATION A. Locations 1. In general accordance with the Drawings a. Location of marking designating no passing zones to be coordinated with corresponding traffic signs. 2. The Engineer will place necessary "Spotting" at appropriate points. a. Horizontal control. b. Starting and stopping points. c. Broken line intervals will not be marked. d. Longitudinal joints, pavement edges, and existing markings shall serve as horizontal control when so directed. e. Contractor shall notify Engineer at least 48 hours in advance when requesting spotting locations. 3. Edge lines and lane lines are to be broken only at intersections with public roads and at private entrances if they are controlled by a yield sign, stop sign, or traffic signal. 4. The break point is to be at the start of the radius for the intersection or at marked stop lines or crosswalks. 5. Temporary pavement marking devices to be installed in accordance with Section 32 12 36. 6. All existing markings are to be repainted upon completion of the seal coat work. B. Street Surface 1. Engineer may direct cleaning of surface as necessary immediately prior to marking application. a. Brushing with non-metallic rotary broom. b. Other cleaning method approved by Engineer. c. Air blast following cleaning. 2. Surface must be dry. 3. Minimum surface temperature is 50 degrees F. 3.04 APPLICATION A. General 1. Tolerance a. Width: A tolerance of 1/4 inch under or 1/4 inch over the specified width will be allowed for striping provided the variation is gradual and does not detract from the general appearance. b. Length: Broken line segments may vary up to 2-3/4 inches from the specified lengths provided the over and under variations are reasonably compensatory. c. Alignment: Deviations from the control guide shall not exceed 2 inches. 0 2013 Stantec 1193802836 321723-3 d. Establishment of application tolerances shall not relieve the Contractor of his responsibility to comply as closely as practicable with the planned dimensions. 2. Material shall not be applied over longitudinal joints. 3. 4 -inch broken line consists of 10 feet of paint and 40 feet space (1 cycle). 4. If some equipment used for different color material with change in color, an amount of material equal to fifteen 10 -foot long stripes shall be wasted prior to beginning application with the new color. 5. Conditions a. Markings shall not be applied when wind or other conditions cause a film of dust to be deposited on the pavement surface after cleaning and before the marking material can be applied. b. Except when used as a temporary marking, pavement markings shall only be applied in seasonable weather when air temperature is 50 degrees F or higher. B. Paint 1. Minimum thickness 15 mil. 2. In accordance with the appropriate MnDOT Spec. 3. Painted lines shall be applied twice. C. Glass Beads 1. Shall be applied immediately after application of paint markings. 2. Rate of application shall be 8 lbs. per gallon. 3.05 CORRECTION OF DEFECTS A. All pavement markings not conforming to the requirements of the Specifications shall be removed and replaced, or otherwise repaired to the satisfaction of the Engineer. B. Where yield computations show a deficiency in material usage of not more than 20 percent, Owner may require satisfactory repair or may accept the Work at a reduced Bid Unit Price that is in direct proportion to the percent of the deficiency. C. Where yield computations show a deficiency in material usage in excess of 20 percent, Owner will require removal and replacement to the satisfaction of the Engineer, unless other means are approved by the Engineer. D. If removal and replacement is required, at least 90 percent of the deficient line shall be removed. E. Width of removal shall be 1 inch wider on all sides than the nominal width of the marking to be removed. F. Removal of unacceptable Work shall be accomplished with suitable blasting or grinding equipment, unless other means are authorized by the Engineer. Bituminous street surfacing shall not be damaged by the removal operation. END OF SECTION PAVEMENT MARKINGS O 2013 Stantec 1 193802835 321723-4