Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
IP #816
PROJECT NO. 816 2007 Infrastructure Item 8.4 2/12/07 Motion authorizing the preparation of a feasibility report for the construction of a 2007 infrastructure project Item 8.2 3/12/07 Presentation and acceptance of the feasibility report and authorizing the preparation of plans and specifications for the proposed 2007 infrastructure improvement project 816. Res. 07-62 4/23/07 Resolution approving plans and specifications for the 2007 street and infrastructure improvements; ordering advertisement for bids (improvement no. 816) Res. 07-85 05/29/07 Resolution Awarding contract to Northwest Asphalt for construction of the 2007 street and park infrastructure improvement (improvement project no. 816) Res. 09-75 6/22/09 Resolution accepting the 2007 street infrastructure improvement project and approving final payment request to Northwest Asphalt Inc. (improvement project no. 816) AYz . COUNCIL Request for Action Originating Department Approved for Agenda Agenda Section Public Works June 22, 2009 Consent Item No. By: Shari French & Guy Johnson By: Kirk Mc Donald, City Manager 6.6 Resolution accepting the 2007 street infrastructure improvement project and approving the final payment request to Northwest Asphalt Inc. (improvement Eroject No. 816) Requested Action Staff recommends that Council approve a resolution to accept the 2007 street infrastructure improvement project and authorize final payment to Northwest Asphalt Inc. in the amount of $2,420.26. Background The 2007 infrastructure project included improvements in the area of Nevada Avenue, from 42nd Avenue to 45th Avenue; 43rd Avenue, east of Nevada Avenue; and Fred Sims Park. The project involved street and utility infrastructure work and park improvements. The construction of this project was considered in 2002, but was delayed in order to coordinate the reconstruction of Nevada Avenue with a larger Crystal street infrastructure project. Once the city of Crystal's project on Nevada Avenue from 45th Avenue to 47th Avenue was complete, New Hope began in June of 2007. With the exception of the final course of asphalt and some boulevard restoration, construction was completed in the fail of 2007. Installation of the final course of asphalt and boulevard restoration was completed in 2008. The park seeding was reviewed in the fall of 2008 and the city required the seeding contractor to reseed the park area adjacent to the pedestrian path. Funding The completed project costs came in at $484,052.09, just under the original contract amount of $485,712.61. Funding sources for the 2007 infrastructure project are a city assessment for Fred Sims Park's street frontage, street and park infrastructure funds, the storm water fund, and the utility fund. Attachments The engineer's memorandum, the final payment request, and the resolution authorizing final payment are attached. a. Motion by ' C . Second by "Iji To: T I: \RFA \PUBW0RKS \2009 \816 2007 infrastructure Improvement Final.doc CITY OF NEW HOPE RESOLUTION NO. 09-75 Resolution accepting the 2007 street infrastructure improvement project and approving the final payment request to Northwest Asphalt Inc. (improvement project No. 816) WHEREAS, the city has entered into a contract with Northwest Asphalt Inc. for construction of the 2007 street infrastructure project; and, WHEREAS, staff is recommending that the Council adopt a resolution to accept the improvement project and approve final payment to Northwest Asphalt Inc. in the amount of $2,420.26; and, WHEREAS, the city engineer has reported that all work has been satisfactorily completed and recommends that final payment be made to Northwest Asphalt Inc. NOW, THEREFORE, BE IT RESOLVED by the City Council of the city of New Hope, Hennepin County, Minnesota: 1. That the City Council accepts the 2007 street infrastructure project from Northwest Asphalt Inc. 2. That the city manager is hereby directed to authorize the final payment of $2,420.26 to Northwest Asphalt Inc. Adopted by the City Council of the city of New Hope, Hennepin County, Minnesota this 22nd day of June, 2009. Mayor Attest: City Clerk 2335 Highway 36 W St. Paul, N1N 55113 Tel 651 - 636 -4600 Fax 651- 636 -1311 www.bonestroo.com June 9, 2009 Guy Johnson New Hope Public Works 5500 International Parkway New Hope, MN 55428 Re: 2007 Infrastructure Improvements — Final Payment Client Project No.: 816 Bonestroo File No.: 000034 - 05175 -0 Dear Guy, The contractor on the 2007 Infrastructure Improvements project, Northwest Asphalt, Inc., has completed all work on under the contract and requested final payment. Enclosed find the signed final pay request in the amount of $2,420.26 for the project. The final contract amount is for $485,712.61. The final value of the work completed under the contract is $484,052.09, or $1,660.52 (0.3 %) less than the contract amount. The savings resulted from less than anticipated quantities for a number of bid items. We recommend approval of final payment in the amount of $2,420.26. Payment should be held until the necessary IC -134 forms have been provided by the contactor and verified for the project. If you have any questions, please contact me at 651- 604 -4938. Yours truly, BONE �S - T - ROO Cam, • `'tea. --r-� ��'� <7 �e� Jason P. Quisberg, PE Copy: Shari French, Parks & Recreation Director Kirk McDonald, City Manager [ e )wner: City of New Hope, 4401 Xylon Ave. N., New Hope, MN 55428 Date: May 27, 2009 =or Period: 12/612008 to 5/27/2009 Request No: 7 AND FINAL - ontractor: Northwest Asphalt, Inc., 1451 Stagecoach Rd., Shakopee, MN 55379 CONTRACTOR'S REQUEST FOR PAYMENT 2007 INFRASTRUCTURE IMPROVEMENTS BONESTR00 FILE NO, 000034 - 05175 -0 CITY PROJECT NO. 816/821 SUMMARY 1 Original Contract Amount 2 Change Order - Addition 3 Change Order - Deduction 4 Revised Contract Amount 5 Value Completed to Date 6 Material on Hand 7 Amount Earned 8 Less Retainage 0% 9 Subtotal 10 Less Amount Paid Previously 11 Liquidated damages - 12 AMOUNT DUE THIS REQUEST FOR PAYMENT NO Recommended for Approval by: BONESTR00 Approved by Contractor: NORTHWEST ASPHALT, INC. Specified Contract Completion Date: 7 aNfY FIN01 $ 484,122.61 $ 1,590.00 $ 0.00 $ 485,712.61 $ 484,052.09 $ 0.00 $ 484,052.09 $ 0.00 $ 484,052.09 $ 481,631.83 $ 0.00 $ 2,420.26 Date: 3405175REWFINAL.xis 45TH AVENUE NORTH 4425 N 4425 4424. t q t , 4421` _. y 4417 r FRED REPLACE 4409 gals RECONSTRUCT SIMS ;;" PEDESTRIAN' ,NEVADA AVENUE PARK BRIDGE BOX CULVERT �a 4305 PROVIDE SEWER &" WATER " 4401 SERVICES (2) TO PROPERTY r FOR FUTURE USE RECONSTRUCT k 1 4x15 BITUMINOUS TRAIL 9 ;P. - 4337 Ln a Z 4315 5`;� D 4311 ' ��a.� POTENTIAL PLAY 4331 m RESURFACE AREA RETAINING Z BASKMALL WALL REPLACEMENT m 4309 j - COURT Z < 4325 4307 GY 1 4305 �i CONSTRUCT ` NEW PARKING 4303 4319 Y" STALLS RECONSTRUCT 43RD AVENUE 43RD AVE i N 4313 REPLACE CONSTRUCT 14307 SANITARY 4230 TURN— AROUND SEWER 7zeo 4301 4225 , 1" 4224 7240 43RD AVE N NEW STORM 4221 SEWER _ MMl 4239 ti f 7220 U - 4217 4220 4233 N- .. ... co _. 7200 co 4215 ' EXTEND CONCRETE WALK TO 43RD AVE 4229 o _ 4216 C) ti 1j_ .. 4215... ro REPLACE-" o WATER MAIN PROVIDE SEWER do WATER SERVICES TO PROPERTY FOR FUTURE USE m 7140 U) 7300 ° 7180 ro 7100 m 3 Q a 42ND AVENUE NORTH v COUNTY ROAD 9 u 0 * 0 75 150 PROPOSED PROJECT AREA �, f NEW HOPE, MINNESOTA FIGURE 1 2007 INFRASTRUCTURE IMPROVEMENTS dn SA 3405175F01.DWG DATE: MARCH 2007 COMM: 000034- 05175 -0 05/21/2009 09:24 9524451056 NORTHWEST ASPHALT IN PAGE 02 Page I of I MTNNTSOU REVENUE Contractor's Withholding Affidavit Confirmation NORTHWEST ASPHALT INC ID 5333310 Please keep this information for your records. Submit a copy of this page to the project owner to receive your final payment. Confirmation number 251972 Thu May 21 08:18:26 CDT 2000 Project owner CITY OF NEW HOPE Project number CP 816 Project begin date June 2007 Project end date November 2008 Project location 2007 INFRASTRUCTURE IMPR NEW HOPE, MN Subcontractors C R FISCHER & SONS INC 1605604 204821 MIDSTATE RECLAMATION INC 1719563 203678 QUALITY RESTORATION SERVICES 1 1626039 205199 SUNRAM CONSTRUCTION INC 1870470 203495 CENTRAL LANDSCAPING INC 7663076 229229 https://www.inndor.state-m.us/we/action/confinnationPrint 5/21/2009 05/21/2009 09:24 9524451056 NORTHWEST ASPHALT IN Jul. 2. 2008 3:58FM CR FISCHER 651.463.7033 Contractor's Withholding Affidavit Confirmation C R FISCHER & SONS INC ID 1608644 Please keep this information for your records. Submit a copy of this pege to the lousiness that hired you to receive yOur final payment. Confirmation number Project owner }project number Project begln date Project end date Project location Subcontractors 204821 Wed Jui 02 18:57:10 CI)T 2008 CITY OF NEW HOPE CP 816 July 2007 June 2008 2007 INFRASTRUCTURE IMPQVEMENTS No subcontractors listed, PAGE 03 Page 1 of 1 05/2112009 09:24 9524451056 JUN- p4 - 2008 10 :130 FROM :MI05TATE d MI KEVENUE Contractor's Withholding Affidavit Confirmation rt'�OS�t'A"fiE. �Ect,A�wlt't'�uN �'nt� NORTHWEST ASPHALT IN 95298%656 T0:95e4451056 10 - 1719563 Please keep this information for your records Submit a copy of this page to the business that hired you to receive your final payment. Confirmation number 203678 Tue Jun 24 11:00:33 CDT 2008 Project owner CITY OF NEW HOPE Project number CP 816 Project begin date July 2007 Project end date July 2007 Project location 2007 INFRASTRUCTURE IMPROVEMENTS Subcontract No subcontractors listed. https://www.mndor.state.imus/we/actioiVconfimationPrint PAGE 04 P.2 Page 1 of 1 6,a4/2P' 05/21/2009 09:24 9524451056 JUL-09-2008 WED 08:14 AM SHERYL XCEL FAX NORTHWEST ASPHALT IN FAX NO, 13034253984 MINNESOTA-MVENLIE Contractor's VAthholding Affidavit Confirmation QUALITY RKSTORATION SERVICES INC 10 1826039 Plasse keep ihis information for your records. Submit a copy of this page to the business that hired you to receive your find payment. Confirmation number 205199 Wed Jul 09(38, CDT 2008 Project owner CITY OF NEW HOPE Project number CP816 Project begin date November 2007 Project and date December 2007 Project location NEW HOPE Subconira0ors No subcontractors listed, PAGE 05 F. ul/uz Page 10' f I . - Tv /k '2 PaO6 b4s-://www.rnndor.state.=i.us/waacdon/conftmationPrint 7/9/2008 05/21/2009 09:24 9524451056 NORTHWEST ASPHALT IN MINNESOTA- REVENUE Contractor's Withholding Affidavit Confirmation SUNRAM CONSTRUCTION INC 10 1$70470 Please keep this irif6rmatlon for your records, Submit *'copy of this page to the business that hired you to receive your final payment. Confirmation number 203496 Mon Jun 2809:18:10 GOT 2008 Project owner CITY OF NEW HOPE Project number CP 816 Project begin date December 2007 Project end date January 2008 Project location 2007 ' INFRASTRUCTURE IMPROVEMENTS NEW HOPE MN Subcontractors No subcontractors listed. PAGE 06 Page I of I https: /Avww.mndor.state.=,us/we/action/oonfimationPrint 6/23/2008 05/21/2009 09:24 9524451056 NORTHWEST ASPHALT IN PAGE 07 11/17/2008 09:20 6514648288 rRkX� U41 U4 Pap I of I tat INNBOTA-REVENVE Contractor's Withholding Affidavit Confirmation CENTRAL LANDSCAPING INC Please keep this.informatlon for your records. ID 7663076 . Subrnitg copy of this page to the business that hifed you to receive your final payment. Conflrmation number Project owner Proloot number Project begin date Project end date Project location Subcontractors 229229 Mon Nov 17 09:12:38 CST 2008 CITY OF NEW HOPE 2007 Infras, Imp September 2007 October 2006 CITY OF N EW HOPE IMPROV No subcontractors listed. https://www.=dor.state,ma.us/wc/action/contlrmationPrint 11/17/2008 INSURED Northwest Asphalt, Inc. 1451 Stagecoach Road Shakopee, MN 55379 DATE (MM /DDNY) RX s.. ,:.. .... 12/02/08 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. COMPANIES AFFORDING COVERAGE COMPANY A General Casualty Co of WI COMPANY B COMPANY C COMPANY D THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE - POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. co T TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE DATE (MM /DD/YY) POLICY EXPIRATION DATE (MM /DDIYY) LIMITS A GENERAL LIABILITY COMMERCIAL GENERAL LIABILITY CLAIMS MADE 17K OCCUR OWNER'S & CONTRACTOR'S PROT Agg per CC10504038 12/01/08 12/01/09 GENERAL AGGREGATE $ 2000000 X PRODUCTS - COMP /O P AGG S 2000000 CCU0504037 PERSONAL & ADV INJURY $ 1000000 EACH OCCURRENCE EACH OCCURRENCE $ 1000000 X FIRE DAMAGE (Any one fire) S 300000 .....;e..+ MED EXP (Anv one person) $ 5000 A AUTOMOBILE LIABILITY CBA0504036 12/01/08 12/01/09 COMBINED SINGLE LIMIT $ X ANY AUTO ALL OWNED AUTOS BODILY INJURY SCHEDULED AUTOS (Per person) $ HIRED AUTOS BODILY INJURY NON -OWNED AUTOS (Per accident) $ PROPERTY DAMAGE $ 1000000 DESCRIPTION OF OPERATIONS /LOCATIONS/VEHICLES /SPECIAL ITEMS Re: 2007 Infrastructure Improvement Project - CP No. 816 - New Hope,MN City of New Hope and Bonestroo are additional insured with respect to General Liability for the above project. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE City of New Hope EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL 4401 Xylon Ave North 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, New Hope, MN 55428 BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND PON THE COMPANY, ITS AGENTS OR REPRESENTATIVES. AUTHORIZED RE ENTATIVE GARAGE LIABILITY ANY AUTO AUTO ONLY - EA ACCIDENT $ OTHER THAN AUTO ONLY: EACH ACCIDENT S AGGREGATE S A EXCESS LIABILITY _ UMBRELLA FORM OTHER THAN UMBR FORM CCU0504037 12/01/08 12/01/09 EACH OCCURRENCE $ 6000000 AGGREGATE $ 6000000 $ WORKERS COMPENSATION AND EMPLOYERS' LIABILITY THE PROPRIETOR/ INCL PARTNERS/EXECUTIVE OFFICERS ARE: EXCL WC STATU- OTH- TORY LIMITS I ER EL EACH ACCIDENT $ EL DISEASE - POLICY LIMIT $ EL DISEASE- EA EMPLOYEE S OTHER DESCRIPTION OF OPERATIONS /LOCATIONS/VEHICLES /SPECIAL ITEMS Re: 2007 Infrastructure Improvement Project - CP No. 816 - New Hope,MN City of New Hope and Bonestroo are additional insured with respect to General Liability for the above project. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE City of New Hope EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL 4401 Xylon Ave North 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, New Hope, MN 55428 BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND PON THE COMPANY, ITS AGENTS OR REPRESENTATIVES. AUTHORIZED RE ENTATIVE COUNCIL Originating Department Public Works By: Shari French & Guy Johnson Approved for Agenda May 29, 2007 Agenda Section Development and Planning Item No. Resolution awarding contract to Northwest Asphalt, Inc. for construction of the 2007 street and park infrastructure improvement (Project No. 816) Requested Action Staff requests approval of a resolution awarding the contract for the 2007 street and park infrastructure improvement to the low and responsible bidder, Northwest Asphalt, Inc., in the amount of $484,122.61 Policy /Past Practice The City Council routinely considers public infrastructure improvement projects to extend the useful life of the infrastructure and /or improve the level of service. The city's street infrastructure management plan has identified this area for maintenance activities. Background The proposed 2007 infrastructure project includes improvements in the area of Nevada Avenue, from 42nd Avenue to 45th Avenue; 43rd Avenue, east of Nevada Avenue; and Fred Sims Park. The proposed project involves street and utility infrastructure work and park improvements. The construction of this project was considered in 2002, but was delayed in order to coordinate the reconstruction of Nevada Avenue with a larger Crystal street infrastructure project. The city of Crystal's project on Nevada Avenue from 45th Avenue to 47th Avenue, this past year, is nearly completed. At the November 30, 2006, work session, staff shared information about the proposed project during a review of the city's proposed 2007 capital improvement plan (CIP). In February of this year, Council authorized the preparation of a feasibility report for the project, accepted the feasibility report, and authorized the Motion by B1&'_ Second by I: \RFA \PUBWORKS \2007 \816 Award Contract.doc Request for Action May 29, 2007 Page 2 preparation of plans and specifications on March 12, 2007. On April 23, Council reviewed the plans and specifications and authorized advertising for bids. Bids were received on May 21. The engineer's cost estimates during the review of the project plans were $418,000 for street infrastructure, $93,000 for water, $93,000 for storm water, $131,000 for sanitary sewer, and $137,000 for park infrastructure, for a total of $872,000. If the Council wishes to proceed, construction would commence in June. With the exception of the final course of asphalt and some boulevard restoration, construction should be completed this fall. The final course of asphalt and boulevard restoration would be completed in the spring of 2008. Funding Bids were received from eight firms on May 21, 2007, with the low bidder being Northwest Asphalt, Inc., at $484,122.61. Funding sources for the proposed 2007 infrastructure project would be from a city assessment for Fred Sims Park's street frontage, street and park infrastructure funds, the storm water fund, and the utility fund. Attachments The engineer's memorandum, copies of the bid tabulations, and the resolution awarding the contract are attached. I: \RFA \PUBWORKS \2007 \816 Award Contract.doc City of New Hope Resolution No. 07 -85 Resolution awarding contract to Northwest Asphalt, Inc. for construction of the 2007 street and park infrastructure improvement (Project No. 816) WHEREAS, this Council approved plans and specifications and ordered bids for construction of the 2007 street and park infrastructure improvement project; and, WHEREAS, this activity is an integral component of the city's street and park infrastructure maintenance programs; and, WHEREAS, this Council does hereby determine to proceed with the 2007 street and park infrastructure improvement project; and, WHEREAS, the advertisement for bids for construction of the 2007 street and park infrastructure improvement project was published in the New Hope - Golden Valley Sun Post, the official newspaper of the city, on May 3, 2007, and in the Construction Bulletin on April 30 and May 3, 2007; and, WHEREAS, the bids for construction of the 2007 street and park infrastructure improvement project were duly opened at the New Hope City Hall, 4401 Xylon Avenue North, at 11:00 a.m. on May 21, 2007; and, WHEREAS, the bid of Northwest Asphalt, Inc. in the amount of $484,122.61 for construction of the 2007 street and park infrastructure improvement project is the lowest responsible bid submitted; and, WHEREAS, the city engineer, Bonestroo, has recommended that Council award the contract to Northwest Asphalt, Inc. NOW, THEREFORE, BE IT RESOLVED, by the City Council of the city of New Hope, Hennepin County, Minnesota: 1. That the contract for construction of the street and park infrastructure improvement project is awarded to Northwest Asphalt, Inc.; and, 2. That the mayor and city manager are authorized and directed to sign the same. Adopted by the City Council of the city of New Hope, Hennepin County, Minnesota, this 29th day of May 2007. 2335 Highway 36 W St. Paul, MN 55113 Tel 651-636-4600 fax 651- 636 -1311 www.bonestroo.com May 21, 2007 Honorable Mayor and City Council City of New Hope 4401 Xylon Avenue North New Hope, MN 55428 -4898 Re: 2007 Infrastructure Improvements Project City Project No. 816 Project No. 000034 - 05175 -0 Bid Results Bids were opened for the Project stated above on Monday, May 21, 2007 at 11:00 A.M. Transmitted herewith is a copy of the Bid Tabulation for your information and file. Copies will also be distributed to each Bidder. There were a total of 8 Bids. The following summarizes the results of the Bids received: The low Bidder on the Project was Northwest Asphalt, Inc, with a Base Bid of $484,122.61. These Bids have been reviewed and found to be in order, If the City Council wishes to award the Project to the low Bidder, then Northwest Asphalt, Inc. should be awarded the Project on the Base Bid Amount of $484,122,61. Should you have any questions, please feel free to contact me at 651- 604 -4938, St. Paul St. Cloud Rochester Milwaukee Chicago Contractor Bid Amount Low Northwest Asphalt, Inc. $484,122.61 #2 Dave Perkins Contracting, Inc. $542,675.00 #3 C & L. Excavating, Inc, $560,363.70 #4 Midwest Asphalt Corporation $577,455.68 #5 Northdale Construction Company, Inc. $603,324.16 #6 Burschville Construction, Inc. $625,346.20 #7 Three Rivers Construction, Inc. $669,182.50 #8 Meyer Contracting, Inc, $670,608.45 The low Bidder on the Project was Northwest Asphalt, Inc, with a Base Bid of $484,122.61. These Bids have been reviewed and found to be in order, If the City Council wishes to award the Project to the low Bidder, then Northwest Asphalt, Inc. should be awarded the Project on the Base Bid Amount of $484,122,61. Should you have any questions, please feel free to contact me at 651- 604 -4938, St. Paul St. Cloud Rochester Milwaukee Chicago City of New Hope May 21, 2007 Sincerely, �� O-Z� Jason P. Quisberg, P.E. Page 2 Enclosure Project Name: 2007 Infrastructure Improvements / hereby certify that this is an exact Client Project No.: 816 BID TABULATION Project No.: 000034 - 05175 -0 reproduction ofbids received. Bid Opening: Monday, May 21, 2007 at 11:00 A.M. Owner: City of New Hope �� a Jason P. Quisberg, P. E, Registration No. 44315 Bidder No. 1 Bidder No. 2 Bidder No. 3 Bidder No. 4 Northwest Asphalt, Inc. Dave Perkins Contracting, Inc. C & L Excavating, Inc. Midwest Asphalt Corporation Item Num Item Units Qty Unit Price Total Unit Price Total Unit Price Total Unit Price Total BASE BID: 1 MOBILIZATION LS 1 $18,144.00 $18,144.00 $8,000.00 $8,000.00 $2,900.00 $2,900.00 $20,000.00 $20,000.00 2 TRAFFIC CONTROL LS 1 $2,750.00 $2,750.00 $3,000.00 $3,000.00 $0.00 $0,00 $3,300.00 $3,300.00 3 SILT FENCE, MACHINE SLICED LF 300 $3.15 $945.00 $2.50 $750.00 $2.25 $675.00 $315 $945.00 4 INLET PROTECTION EXPOSED SUBGRADE EA 12 $200.00 $2,400.00 $75.00 $900.00 $100.00 $1,200.00 $165.00 $1,980.00 5 INLET PROTECTION POST BITUMINOUS BASE EA 10 $200.00 $2,000.00 $350.00 $3,500.00 $250.00 $2,500.00 $110.00 $1,100.00 6 REMOVE BITUMINOUS DRIVEWAY PAVEMENT SY 150 $2.20 $330.00 $3.00 $450.00 $2.50 $375.00 $2.85 $427.50 7 REMOVE BITUMINOUS TRAIL SY 660 $2.20 $1,452.00 $3.00 $1,980.00 $2.50 $1,650.00 $2.30 $1,518.00 8 REMOVE CONCRETE CURB AND GUTTER LF 2050 $2.00 $4,100.00 $2.00 $4,100.00 $2.00 $4,100.00 $3.10 $6,355.00 9 REMOVE CONCRETE DRIVEWAY PAVEMENT SY 133 $4.00 $532.00 $8.00 $1,064,00 $3.50 $465.50 $7.35 $977.55 10 REMOVE CONCRETE SIDEWALK SF 584 $0.35 $204.40 $1.00 $584.00 $1.25 $730.00 $0.77 $449.68 11 REMOVE SANITARY SEWER PIPE LF 657 $3.50 $2,299.50 $5.00 $3,285.00 $1.75 $1,149.75 $6.55 $4,303.35 12 REMOVE SANITARY SEWER SERVICE PIPE LF 375 $3.00 $1,125.00 $5.00 $1,875.00 $2.00 $750.00 $6.55 $2,456.25 13 REMOVE WATER MAIN LF 452 $5.00 $2,260.00 $5.00 $2,260.00 $2.25 $1,017.00 $7.60 $3,435.20 14 REMOVE HYDRANT EA 1 $150.00 $150.00 $450.00 $450.00 $400.00 $400.00 $155.00 $155.00 15 REMOVE CASTING EA 3 $75.00 $225.00 $150.00 $450.00 $150.00 $450.00 $75.00 $225,00 16 REMOVE MANHOLE OR CATCH BASIN EA 6 $350.00 $2,100.00 $650.00 $3,900.00 $350.00 $2,100.00 $315.00 $1,890.00 17 REMOVE PEDESTRIAN BRIDGE AND ABUTMENTS LS 1 $2,700.00 $2,700.00 $2,500.00 $2,500.00 $500.00 $500.00 $2,000:00 $2,000.00 18 SAWING BITUMINOUS PAVEMENT LF 200 $2.50 $500.00 $2.50 $500.00 $120 $640.00 $3.80 $760.00 19 CLEARING TREE 1 $300.00 $300.00 $600.00 $600.00 $375.00 $375.00 $395.00 $395.00 20 GRUB TREE 1 $300.00 $300,00 $250.00 $250.00 $350.00 $350.00 $395.00 $395.00 21 ADJUST VALVE BOX EA 2 $220.00 $440.00 $150.00 $300.00 $150.00 $300.00 $165.00 $330.00 22 ADJUST HYDRANT EA 2 $300.00 $600.00 $550.00 $1,100.00 $500.00 $1,000.00 $655.00 $1,310.00 23 ADJUST MANHOLE CASTING EA 1 $350.00 $350.00 $450.00 $450.00 $300.00 $300.00 $540.00 $540.00 24 SELECT GRANULAR BORROW (MODIFIED) TN 3823 $9.91 $37,885.93 $10.00 $38,230.00 $15.00 $57,345.00 $13.05 $49,890.15 25 SELECT TOP SOIL BORROW (LV) CY 320 $17.50 $5,600.00 $10.00 $3,200.00 $20.00 $6,400.00 $21.85 $6,992.00 26 COMMON EXCAVATION (EV) - OFFSITE CY 3925 $7.76 $30,458.00 $10.00 $39,250.00 $13.00 $51,025.00 $11.95 $46,903.75 27 COMMON EXCAVATION (EV) - ON SITE CY 146 $8.65 $1,262.90 $6.00 $876.00 $5.00 $730.00 $15.85 $2,314.10 28 GEOTEXTILE FABRIC, TYPE IV SY 5516 $1.25 $6,895.00 $1.50 $8,274.00 $1.50 $8,274.00 $1.40 $7,722.40 29 CONNECT TO EXISTING WATER MAIN EA 2 $500.00 $1,000.00 $550.00 $1,100.00 $600.00 $1,200.00 $590.00 $1,180.00 30 DUCTILE IRON FITTINGS LB 589 $1.34 $789.26 $5.00 $2,945.00 $3.15 $1,855.35 $2.95 $1,737.55 31 INSTALL HYDRANT AND VALVE EA 2 $3,044.00 $6,088.00 $3,200.00 $6,400.00 $3,250.00 $6,500.00 $3,600.00 $7,200.00 32 INSULATION, 2" THICK SY 20 $17.00 $340.00 $25.00 $500.00 $40.00 $800.00 $18.25 $365.00 33 8" DIP WATER MAIN, CLASS 52 LF 427 $25.28 $10,794.56 $35.00 $14,945.00 $32.00 $13,664,00 $32.90 $14,048.30 34 6" DIP WATER MAIN, CLASS 52 LF 54 $25.62 $1,383.48 $35.00 $1,890.00 $26.00 $1,404.00 $28.05 $1,514.70 35 TEMPORARY WATER SERVICE LS 1 $1,000.00 $1,000.00 $3,500.00 $3,500.00 $2,750,00 $2,750.00 $3,300.00 $3,300.00 36 8" GATE VALVE AND BOX EA 2 $617.00 $1,234.00 $950.00 $1,900.00 $1,325.00 $2,650.00 $750.00 $1,500.00 37 REMOVE EX. AND INSTALL 4" GATE VALVE AND EA 1 $958.00 $958.00 $2,500.00 $2,500.00 $1,650.00 $1,650.00 $2,100.00 $2,100.00 BOX 000034051750BT.xis BT -1 BID TABULATION Bidder No.1 Northwest Asphalt, Inc. Bidder No. 2 Bidder No. 3 Dave Perkins Contracting, Inc. C & L Excavating, Inc. Bidder No. 4 Midwest Asphalt Corporation Item Num Item Units Qty Unit Price Total Unit Price Total Unit Price Total Unit Price Total 38 CONNECT TO EXISTING WATER SERVICE EA 8 $225.00 $1,800.00 $250.00 $2,000.00 $200.00 $1,600.00 $160.00 $1,280.00 39 1" CORPORATION STOP EA 10 $76.10 $761.00 $175.00 $1,750.00 $100.00 $1,000.00 $130.00 $1,300.00 40 1" CURB STOP AND BOX " EA 10 $259.00 $2,590.00 $250.00 $2,500.00 $240.00 $2,400.00 $310.00 $3,100,00 41 1 TYPE "K" COPPER WATER SERVICE LF 375 $13.27 $4,976.25 $18.00 $6,750.00 $21.00 $7,875.00 $19.30 $7,237.50 42 CONNECT EXISTING PIPE TO SANITARY STRUCTURE EA 2 $1,000.00 $2,000.00 $1,200.00 $2,400.00 $600.00 $1,200,00 $500.00 $1,000.00 43 4' DIAMETER SANITARY MANHOLES EA 5 $1,527.00 $7,635.00 $2,400.00 $12,000.00 $2,100.00 $10,500.00 $2,450.00 $12,250.00 44 8" PVC SANITARY SEWER, SDR 35 LF 663 $20.25 $13,425.75 $21.00 $13,923.00 $21.00 $13,92100 $22.70 $15,050.10 45 CONNECT TO EXISTING SANITARY SEWER SERVICE EA 10 $200.00 $2,000.00 $250.00 $2,500.00 $100.00 $1,000.00 $135.00 $1,350.00 46 6" PVC, SDR 26 SERVICE PIPE LF 425 $13.61 $5,784.25 $21.00 $8,925.00 $17.00 $7,225.00 $17.40 $7,395.00 47 CUT 6" SERVICE WYE INTO 9" VCP EA 2 $668.00 $1,336.00 $1,500.00 $3,000.00 $1,500.00 $3,000.00 $650.00 $1,300.00 48 8" X 6" PVC WYE EA 8 $134,00 $1,072.00 $175.00 $1,400.00 $150.00 $1,200.00 $110.00 $880.00 49 INSTALL CASTING EA 3 $200.00 $600.00 $550.00 $1,650.00 $300.00 $900.00 $410.00 $1,230.00 50 CONNECT EXISTING PIPE TO STORM STRUCTURE EA 2 $500.00 $1,000.00 $550.00 $1,100,00 $800.00 $1,600.00 $425.00 $850.00 51 12" RCP STORM SEWER, CLASS 3 LF 101 $27.90 $2,817.90 $30.00 $3,030.00 $32.75 $3,307.75 $25.60 $2,585.60 52 27" RCP STORM SEWER, CLASS 4 LF 467 $45.84 $21,407.28 $53.00 $24,751.00 $60.00 $28,020.00 $48.60 $22,696.20 53 2'X 3' CATCH BASIN EA 3 $1,163.00 $3,489.00 $1,800.00 $5,400.00 $1,475.00 $4,425.00 $1,815.00 $5,445.00 54 4' DIAMETER STORM CBMH EA 2 $1,891.00 $3,782.00 $2,400.00 $4,800.00 $2,550.00 $5,100.00 $2,615.00 $5,230.00 55 5' DIAMETER STORM CBMH EA 1 $2,853.00 $2,853.00 $3,800.00 $3,800.00 $3,800.00 $3,800.00 $3,740.00 $3,740.00 56 6.5' DIAMETER STORM CBMH EA 1 $4,616.00 $4,616.00 $4,800.00 $4,800.00 $5,600.00 $5,600.00 $6,480.00 $6,480.00 57 CONSTRUCT 4' DIAMETER CBMH OVER EXISTING EA 2 $2,391.00 $4,782.00 $3,600.00 $7,200.00 $2,600.00 $5,200.00 $2,700.00 $5,400.00 PIPE 58 4' DIAMETER STRUCTURE OVERDEPTH LF 9.5 $107.00 $1,016.50 $100.00 $950.00 $80.00 $760.00 $100.00 $950.00 59 5' DIAMETER STRUCTURE OVERDEPTH LF 6 $169.00 $1,014.00 $250.00 $1,500.00 $165,00 $990.00 $170,00 $1,020.00 60 6.5' DIAMETER STRUCTURE OVERDEPTH LF 4 $318.00 $1,272.00 $450.00 $1,800.00 $320.00 $1,280.00 $315.00 $1,260.00 61 CONNECT DRAIN TILE TO STRUCTURE EA 2 $200.00 $400.00 $350.00 $700.00 $175.00 $350.00 $135.00 $270.00 62 4" PERFORATED POLYETHYLENE PIPE LF 515 $10.22 $5,263.30 $12.00 $6,180.00 $6.00 $3,090.00 $12.35 $6,360,25 63 AGGREGATE BASE, CLASS 5 TN 3184 $12.65 $40,277.60 $14.00 $44,576.00 $19.00 $60,496.00 $13.90 $44,257.60 64 STREET SWEEPER (WITH PICKUP BROOM) HOUR 30 $100.00 $3,000.00 $150.00 $4,500.00 $90.00 $2,700.00 $125.00 $3,750.00 65 66 WATER BITUMINOUS MATERIAL FOR TACK COAT MG GAL 200 260 $0.01 $1.75 $2.00 $455.00 $20.00 $3.00 $4,000.00 $780.00 $4.00 $3.00 $800.00 $33.30 $6,660.00 67 TYPE LV 3 NON WEARING COURSE MIXTURE (B) TN 623 $51.00 $31,773.00 $50.00 $31,150.00 $51.00 $780.00 $31,773.00 $2.30 $50.80 $598.00 $31,648.40 68 TYPE LV 4 WEARING COURSE MIXTURE (B) TN 468 $57.50 $26,910.00 $52.00 $24,336.00 $55.75 $26,091.00 $59.45 $27,822.60 69 TYPE LV4WEARING COURSE MIXTURE (B), FOR TN 10 $100.85 $1,008.50 $300.00 $3,000.00 $217.50 $2,175.00 $200.00 $2,000,00 DRIVEWAYS 70 TYPE LV 4 WEAR COURSE MIXTURE (B), FOR TRAIL TN 185 $61.25 $11,331.25 $65.00 $12,025.00 $77.00 $14,245.00 $62.05 $11,479.25 71 RECONSTRUCT WOOD RETAINING WALL SY 3 $225.00 $675.00 $300.00 $900.00 $100.00 $300.00 $175.00 $525.00 72 8618 CONCRETE CURB AND GUTTER LF 2748 $8.75 $24,045.00 $9.00 $24,732.00 $8.90 $24,457.20 $9,40 $25,831.20 73 6" CONCRETE DRIVEWAY PAVEMENT SF 2860 $4.10 $11,726.00 $4.00 $11,440.00 $4.00 $11,440.00 $5.40 $15,444.00 74 PEDESTRIAN CURB RAMP WITH TRUNCATED DOME EA 3 $450.00 $1,350.00 $550.00 $1,650.00 $450.00 $1,350.00 $370.00 $1,110.00 75 4" CONCRETE SIDEWALK SF 3141 $3.40 $10,679.40 $4.00 $12,564.00 $2.90 $9,108.90 $3.00 $9,423.00 76 RECLAIM BITUMINOUS PAVEMENT SY 4310 $1.76 $7,585.60 $1.00 $4,310.00 $1.10 $4,741.00 $1.00 $4,310.00 77 TEMPORARY MAIL BOXES LS 1 $300.00 $300.00 $200.00 $200.00 $750.00 $750.00 $315.00 $315.00 78 SODDING, LAWN TYPE SY 2755 $2.25 $6,198.75 $4.00 $11,020.00 $2.25 $6,198.75 $3.80 $10,469.00 79 SEEDING AC 0.1 $9,450.00 $945.00 $4,500.00 $450.00 $9,000.00 $900.00 $12,500.00 $1,250.00 80 EROSION CONTROL BLANKETS, CATEGORY 4 SY 325 $1.45 $471.25 $3.00 $975.00 $1.50 $487.50 $1.50 $487.50 81 PREFABRICATED STEEL BRIDGE, DELIVERED LS 1 $17,300.00 $17,300.00 $17,500.00 $17,500.00 $16,750.00 $16,750.00 $20,000.00 $20,000.00 82 PREFABRICATED STEEL BRIDGE, INSTALLED LS 1 $3,500.00 $3,500.00 $4,000.00 $4,000.00 $4,000.00 $4,000.00 $5,000.00 $5,000.00 83 CONCRETE ABUTMENT EA 2 $13,500.00 $27,000.00 $14,000.00 $28,000.00 $18,600.00 $37,200.00 $15,000.00 $30,000.00 84 ABUTMENT EXCAVATION AND BACKFILL LS 1 $5,000.00 $5,000.00 $5,000.00 $5,000.00 $6,000.00 $6,000.00 $4,400.00 $4,400.00 00003405175OBT.xls BT -2 Bidder No. 1 Bidder No. 2 Bidder No. 3 Bidder No. 4 BID TABULATION Northwest Asphalt, Inc. Dave Perkins Contracting, Inc. C & L Excavating, Inc. Midwest Asphalt Corporation Item Num Item Units Q Unit Price Total Unit Price Total Unit Price Total Unit Price Total 85 CLASS III RANDOM RIPRAP CY 30 $100.00 $3,000.00 $100.00 $3,000.00 $70.00 $2,100.00 $100.00 $3,000.00 TOTAL BASE BID: $484,122.61 $542,675.00 $560,363.70 $577,455.68 Contractor Name and Address: Northwest Asphalt, Inc. Dave Perkins Contracting, Inc. C & L Excavating, Inc. Midwest Asphalt Corporation 1451 Stagecoach Rd 7060 143th Ave NW -Suite 100 7939 Ridgewood Road 5929 Baker Rd - Ste 420 Shakopee, MN 55379 Anoka, MN 55303 St Joseph, MN 56374 Minnetonka, MN 55345 Phone: 952- 445 -1003 763- 427 -0109 320- 363 -1221 952- 937 -8033 Fax 952 -445 -1056 763 - 427 -3806 320- 363 -8386 952 - 937 -6910 Signed By: Grant E. E. Boisner Dave Perkins Kevin Cox Timothy J, Douglas Title: Estimator President President CFO/Treasurer Bid Security: Bid Bond Bid Bond Bid Bond Bid Bond Addenda Acknowledged: One One One One 00003405175OBT.xls BT -3 BID TABULATION Bidder No. 5 Bidder No. 6 Bidder No. 7 Bidder No. 8 Northdale Construction Burschville Construction, Inc. Three Rivers Construction, Meyer Contracting, Inc. Company, Inc. Inc. Item Num Item Units Q Unit Price Total Unit Price Total Unit Price Total Unit Price Total BASE BID: 1 MOBILIZATION LS 1 $14,288.00 $14,288.00 $15,000.00 $15,000.00 $10,000.00 $10,000.00 $137,000.00 $137,000.00 2 TRAFFIC CONTROL LS 1 $3,500.00 $3,500.00 $5,000.00 $5,000.00 $3,050.00 $3,050.00 $2,930.00 $2,930.00 3 SILT FENCE, MACHINE SLICED LF 300 $3.50 $1,050.00 $2.00 $600.00 $5.00 $1,500.00 $2.65 $795.00 4 INLET PROTECTION EXPOSED SUBGRADE EA 12 $85.00 $1,020.00 $100.00 $1,200.00 $186.00 $2,232.00 $173.00 $2,076.00 5 INLET PROTECTION POST BITUMINOUS BASE EA 10 $423.20 $4,232.00 $350.00 $3,500.00 $370.00 $3,700.00 $231.00 $2,310.00 6 REMOVE BITUMINOUS DRIVEWAY PAVEMENT SY 150 $185 $427.50 $3.50 $525.00 $2.50 $375.00 $3.85 $577.50 7 REMOVE BITUMINOUS TRAIL SY 660 $2.85 $1,881.00 $3.50 $2,310.00 $2.50 $1,650.00 $3.20 $2,112.00 8 REMOVE CONCRETE CURB AND GUTTER LF 2050 $235 $4,817.50 $4.00 $8,200.00 $3.00 $6,150.00 $1.75 $3,587.50 9 REMOVE CONCRETE DRIVEWAY PAVEMENT SY 133 $8.50 $1,130.50 $5.00 $665.00 $2.50 $332.50 $4.70 $625.10 10 REMOVE CONCRETE SIDEWALK SF 584 $0.95 $554.80 $1.50 $876.00 $2.00 $1,168.00 $0.50 $292.00 11 REMOVE SANITARY SEWER PIPE LF 657 $2.75 $1,806.75 $15.00 $9,855.00 $2.00 $1,314.00 $3.05 $2,003.85 12 REMOVE SANITARY SEWER SERVICE PIPE LF 375 $3.00 $1,125.00 $15.00 $5,625.00 $2.00 $750.00 $3.05 $1,143,75 13 REMOVE WATER MAIN LF 452 $5.25 $2,373,00 $15.00 $6,780.00 $2.00 $904.00 $5.40 $2,440.80 14 REMOVE HYDRANT EA 1 $275.00 $275.00 $1,000.00 $1,000.00 $700.00 $700.00 $280.00 $280.00 15 REMOVE CASTING EA 3 $125.00 $375.00 $300.00 $900.00 $100.00 $300.00 $148.00 $444.00 16 REMOVE MANHOLE OR CATCH BASIN EA 6 $475.00 $2,850.00 $400.00 $2,400.00 $300.00 $1,800.00 $243.00 $1,458.00 17 REMOVE PEDESTRIAN BRIDGE AND ABUTMENTS LS 1 $3,500.00 $3,500.00 $20,000.00 $20,000.00 $11,200.00 $11,200.00 $6,000.00 $6,000.00 18 SAWING BITUMINOUS PAVEMENT LF 200 $3.85 $770.00 $4.00 $800.00 $3.00 $600.00 $2.55 $510.00 19 CLEARING TREE 1 $275.00 $275.00 $400.00 $400.00 $525.00 $525.00 $532.00 $532.00 20 GRUB TREE 1 $175.00 $175.00 $300.00 $300.00 $265.00 $265.00 $532.00 $532.00 21 ADJUST VALVE BOX EA 2 $175.00 $350.00 $350.00 $700.00 $175.00 $350.00 $217.00 $434.00 22 ADJUST HYDRANT EA 2 $57181 $1,147.62 $400.00 $800.00 $600.00 $1,200.00 $735.00 $1,470.00 23 ADJUST MANHOLE CASTING EA 1 $275.00 $275,00 $500.00 $500.00 $250.00 $250.00 $356.00 $356.00 24 SELECT GRANULAR BORROW (MODIFIED) TN 3823 $22.50 $86,017.50 $11.00 $42,053.00 $24.00 $91,752.00 $16.30 $62,314.90 25 SELECT TOP SOIL BORROW (LV) CY 320 $15.95 $5,104.00 $17.00 $5,440.00 $4.00 $1,280.00 $17.20 $5,504.00 26 COMMON EXCAVATION(EV) - OFFSITE CY 3925 $11.50 $45,137.50 $12.00 $47,100.00 $11.00 $43,175.00 $8.40 $32,970.00 27 COMMON EXCAVATION (EV) - ON SITE CY 146 $6.75 $985.50 $8.00 $1,168.00 $7.50 $1,095.00 $2.95 $430.70 28 GEOTEXTILE FABRIC, TYPE IV SY 5516 $1.50 $8,274.00 $1.75 $9,653.00 $1.00 $5,516.00 $1.45 $7,998.20 29 CONNECT TO EXISTING WATER MAIN EA 2 $1,360.23 $2,720.46 $900.00 $1,800.00 $700.00 $1,400.00 $1,040.00 $2,080.00 30 DUCTILE IRON FITTINGS LB 589 $1.79 $1,054.31 $2.25 $1,325.25 $2.00 $1,178.00 $3.90 $2,297.10 31 INSTALL HYDRANT AND VALVE EA 2 $3,238.55 $6,477.10 $2,950,00 $5,900.00 $3,300.00 $6,600.00 $3,870.00 $7,740.00 32 INSULATION, 2" THICK SY 20 $13.89 $277.80 $16.00 $320.00 $10.00 $200.00 $17.30 $346.00 33 8" DIP WATER MAIN, CLASS 52 LF 427 $27.14 $11,588.78 $33.00 $14,091.00 $40.00 $17,080.00 $31.60 $13,493.20 34 6" DIP WATER MAIN, CLASS 52 LF 54 $24.88 $1,343.52 $29.00 $1,566.00 $35.00 $1,890.00 $31.40 $1,695.60 35 TEMPORARY WATER SERVICE LS 1 $2,350.00 $2,350.00 $10,000.00 $10,000.00 $5,000.00 $5,000.00 $6,350.00 $6,350.00 36 8" GATE VALVE AND BOX EA 2 $676.22 $1,352.44 $1,100.00 $2,200.00 $650.00 $1,300,00 $1,270.00 $2,540.00 37 REMOVE EX, AND INSTALL 4" GATE VALVE AND EA 1 $2,067.17 $2,067.17 $1,500.00 $1,500.00 $1,200.00 $1,200.00 $1,010.00 $1,010.00 BOX 00003405175OBT.xls BT -4 BID TABULATION Bidder No. 5 Northdale Construction Comrianv, Inc. Bidder No. 6 Bidder No. 7 Bidder No. 8 Burschville Construction, Inc. Three Rivers Construction, Meyer Contracting, Inc. Inc Item Num Item Units Qly Unit Price Total Unit Price Total Unit Price Total Unit Price Total 38 CONNECT TO EXISTING WATER SERVICE EA 8 $303.23 $2,425.84 $750.00 $6,000.00 $300.00 $2,400.00 $404.00 $3,232.00 39 1" CORPORATION STOP EA 10 $96.10 $961.00 $125.00 $1,250.00 $50.00 $500.00 $114.00 $1,140.00 40 1" CURB STOP AND BOX EA 10 $298.78 $2,987.80 $125.00 $1,250.00 $225.00 $2,250.00 $323.00 $3,230.00 41 1" TYPE "K" COPPER WATER SERVICE LF 375 $21.94 $8,227.50 $20.00 $7,500.00 $25.00 $9,375.00 $23.40 $8,775.00 42 CONNECT EXISTING PIPE TO SANITARY STRUCTURE EA 2 $1,500.00 $3,000.00 $1,000.00 $2,000.00 $400.00 $800.00 $441.00 $882.00 43 4' DIAMETER SANITARY MANHOLES EA 5 $1,641.82 $8,209.10 $1,950.00 $9,750.00 $2,000.00 $10,000.00 $1,910.00 $9,550.00 44 8" PVC SANITARY SEWER, SDR 35 LF 663 $22.22 $14,731.86 $29.00 $19,227.00 $25.00 $16,575.00 $26.30 $17,436.90 45 CONNECT TO EXISTING SANITARY SEWER SERVICE EA 10 $319.70 $3,197.00 $750.00 $7,500.00 $350.00 $3,500.00 $172.00 $1,720.00 46 6" PVC, SDR 26 SERVICE PIPE LF 425 $19.28 $8,194.00 $20.00 $8,500.00 $20.00 $8,500.00 $21.90 $9,307.50 47 CUT 6" SERVICE WYE INTO 9" VCP EA 2 $1,116.60 $2,233.20 $1,000.00 $2,000.00 $1,000.00 $2,000.00 $431.00 $862.00 48 8 "X6 "PVC WYE EA 8 $206.52 $1,652.16 $125.00 $1,000.00 $150.00 $1,200.00 $115.00 $920.00 49 INSTALL CASTING EA 3 $275.00 $825.00 $400.00 $1,200.00 $500.00 $1,500.00 $185.00 $555.00 50 CONNECT EXISTING PIPE TO STORM STRUCTURE EA 2 $1,000.00 $2,000.00 $750.00 $1,500.00 $700.00 $1,400.00 $829.00 $1,658.00 51 12" RCP STORM SEWER, CLASS 3 LF 101 $29.38 $2,967.38 $28.00 $2,828.00 $30.00 $3,030.00 $27.90 $2,817.90 52 27" RCP STORM SEWER, CLASS 4 LF 467 $51.47 $24,036.49 $77.00 $35,959.00 $55.00 $25,685.00 $50.20 $23,443.40 53 2'X 3' CATCH BASIN EA 3 $1,183.00 $3,549.00 $1,200.00 $3,600.00 $1,300.00 $3,900.00 $1,270.00 $3,810.00 54 4' DIAMETER STORM CBMH EA 2 $1,598.50 $3,197.00 $1,950.00 $3,900.00 $1,900.00 $3,800.00 $1,930.00 $3,860.00 55 5' DIAMETER STORM CBMH EA 1 $2,350.00 $2,350.00 $3,450.00 $3,450.00 $2,600.00 $2,600.00 $2,860.00 $2,860.00 56 6.5' DIAMETER STORM CBMH EA 1 $4,350.00 $4,350.00 $5,950.00 $5,950.00 $4,200.00 $4,200,00 $3,680.00 $3,680.00 57 CONSTRUCT 4' DIAMETER CBMH OVER EXISTING EA 2 $2,295.00 $4,590.00 $3,000.00 $6,000.00 $2,200.00 $4,400.00 $2,440.00 $4,880.00 PIPE 58 4' DIAMETER STRUCTURE OVERDEPTH LF 9.5 $114.76 $1,090.22 $100.00 $950.00 $100.00 $950.00 $196.00 $1,862.00 59 5' DIAMETER STRUCTURE OVERDEPTH LF 6 $179.02 $1,074.12 $225.00 $1,350.00 $175.00 $1,050.00 $257.00 $1,542.00 60 6.5' DIAMETER STRUCTURE OVERDEPTH LF 4 $364.11 $1,456.44 $420.00 $1,680.00 $300.00 $1,200.00 $323.00 $1,292.00 61 CONNECT DRAIN TILE TO STRUCTURE EA 2 $275.00 $550.00 $100.00 $200.00 $750.00 $1,500.00 $231.00 $462.00 62 4" PERFORATED POLYETHYLENE PIPE LF 515 $12.95 $6,669.25 $9.00 $4,635.00 $15.00 $7,725.00 $9.95 $5,124.25 63 AGGREGATE BASE, CLASS 5 TN 3184 $12.50 $39,800.00 $14.00 $44,576.00 $13.00 $41,392.00 $10.00 $31,840.00 64 STREET SWEEPER (WITH PICKUP BROOM) HOUR 30 $0.01 $0.30 $100.00 $3,000.00 $150.00 $4,500.00 $112.00 $3,360.00 65 WATER MG 200 $23.00 $4,600.00 $25.00 $5,000.00 $40.00 $8,000.00 $20.00 $4,000.00 66 BITUMINOUS MATERIAL FOR TACK COAT GAL 260 $2.99 $777.40 $3.00 $780.00 $3.00 $780.00 $3.10 $806.00 67 TYPE LV 3 NON WEARING COURSE MIXTURE (B) TN 623 $51.92 $32,346.16 $49.60 $30,900.80 $51.00 $31,773.00 $51.80 $32,271.40 68 TYPE LV 4 WEARING COURSE MIXTURE (B) TN 468 $60.23 $28,187.64 $52.20 $24,429.60 $54.00 $25,272.00 $54.50 $25,506.00 69 TYPE LV 4 WEARING COURSE MIXTURE (B), FOR TN 10 $204.75 $2,047.50 $225.00 $2,250.00 $68.00 $680.00 $213.00 $2,130.00 DRIVEWAYS 70 TYPE LV 4 WEAR COURSE MIXTURE (B), FOR TRAIL TN 185 $68.78 $12,724.30 $68.60 $12,691.00 $210.00 $38,850.00 $68.80 $12,728,00 71 RECONSTRUCT WOOD RETAINING WALL SY 3 $275.00 $825.00 $200.00 $600.00 $100.00 $300.00 $208.00 $624.00 72 B618 CONCRETE CURB AND GUTTER LF 2748 $8.98 $24,677.04 $9.55 $26,243.40 $10.00 $27,480.00 $10.10 $27,754.80 73 6" CONCRETE DRIVEWAY PAVEMENT SF 2860 $4.04 $11,554.40 $4.35 $12,441,00 $4.00 $11,440.00 $4.20 $12,012.00 74 PEDESTRIAN CURB RAMP WITH TRUNCATED DOME EA 3 $577.50 $1,732.50 $600.00 $1,800.00 $415.00 $1,245.00 $525.00 $1,575.00 75 4" CONCRETE SIDEWALK SF 3141 $3.36 $10,55176 $3.90 $12,249.90 $4.00 $12,564.00 $160 $8,166.60 76 RECLAIM BITUMINOUS PAVEMENT SY 4310 $2.35 $10,128.50 $1.50 $6,465.00 $3.00 $12,930.00 $0.80 $3,448.00 77 TEMPORARY MAIL BOXES LS 1 $400.00 $400.00 $500.00 $500.00 $375.00 $375.00 $320.00 $320.00 78 SODDING, LAWN TYPE SY 2755 $2.26 $6,226.30 $2.65 $7,300.75 $6.00 $16,530.00 $4.05 $11,157.75 79 SEEDING AC 0.1 $9,450.00 $945.00 $9,000.00 $900.00 $10,500.00 $1,050.00 $12,800.00 $1,280.00 80 EROSION CONTROL BLANKETS, CATEGORY 4 SY 325 $1.47 $47735 $1.50 $487.50 $2.00 $650.00 $2.35 $76175 81 PREFABRICATED STEEL BRIDGE, DELIVERED LS 1 $19,587.50 $19,587.50 $18,000.00 $18,000.00 $16,500.00 $16,500.00 $18,400.00 $18,400.00 82 PREFABRICATED STEEL BRIDGE, INSTALLED LS 1 $5,700.00 $5,700.00 $4,000.00 $4,000.00 $15,000.00 $15,000.00 $3,730.00 $3,730.00 83 CONCRETE ABUTMENT EA 2 $21,030.00 $42,060.00 $15,000.00 $30,000.00 $22,500.00 $45,000.00 $14,400.00 $28,800.00 84 ABUTMENT EXCAVATION AND BACKFILL LS 1 $7,800.00 $7,800.001 $6,500.00 $6,500.00 $5,600.00 $5,600.00 $6,350.00 $6,350.00 000034051750BT.xls BT -5 BID TABULATION Bidder No. 5 Northdale Construction Company, Inc. Bidder No. 6 Bidder No, 7 Bidder No. 8 Burschville Construction, Inc. Three Rivers Construction, Meyer Contracting, Inc. Inc- Item Num Item Units Q Unit Price Tot Unit Price Total Unit Price Total Unit Price Total 85 CLASS III RANDOM RIPRAP CY 30 $90.00 $2,700.00 $100.00 $3,000.00 $75.00 $2,250.00 $66.80 $2,004.00 TOTAL BASE BID: $603,324.16 $625,346.20 $669,182.50 $670,608.45 Contractor Name and Address: Northdale Construction Co„ Inc. Burschville Construction, Inc. Three Rivers Construction, Inc. Meyer Contracting, Inc. 14450 Northdale Blvd 11440 8th Street NEo 15001 Hudson Road 2812 Anthony Lane S NE - Roger, MN 55308 P.O. Box 65 P.O. Box 206 Suite 310 Hanover, MN 55341 Lakeland, MN 55043 Minneapolis, MN 55418 Phone: 763 - 428 -4868 (763) 497 -4242 (651) 998 -0695 612- 781 -1444 Fax 763 - 428 -4997 (763) 497 -4266 (651) 998 -0714 612 -781 -1445 Signed By: Thomas A. Wilebski James E. Schendel Reuben Mausolf Paul Meyer Title: President President President VP Bid Security: Bid Bond Bid Bond Bid Bond Bid Bond Addenda Acknowledged: One One One One 000034051750BT.xls BT -6 2335 Highway 36 W St. Paul, MN 55113 Tel 651 - 636 -4600 Fax 651 - 636 -1311 www.bonestroo.com May 30, 2007 Mr. Grant Boisner Northwest Asphalt, Inc. 1451 Stagecoach Road Shakopee, MN 55379 Re: City of New Hope, Minnesota 2007 Infrastructure Improvements Project City Project No. 816 Project No. 000034- 05175 -0 Contract Documents Enclosed are four Contract Documents between you and the City of New Hope covering the above - referenced Project, Please complete Specification Document 00520 Agreement Form, Document 00610 Performance Bond, and Document 00615 Payment Bond. The insurance and indemnity requirements shall be provided. After the bonding company has completed the Contract Documents, forward them to the attorney listed below who will review them for the City of New Hope: Steven Sondrall Jensen & Sondrall PA 8525 Edinbrook Xing #201 Brooklyn Park, MN 55443 -1968 After the necessary officials have signed the Contracts, they will be distributed as follows: 2 copies Northwest Asphalt, Inc. (1 - your file, 1 - your bond company) 1 copy City of New Hope, Attention: Valerie Leone 1 copy Bonestroo, Attention: Jason Quisberg Upon receipt of a signed Contract and a filed Certificate of Insurance, approved by the City of New Hope's attorney, a pre- construction conference will be scheduled with you and the City of New Hope to review the Project. Sincerely, I:1901*11;l�Ii7 Jason P. Quisberg, P.E. Enclosures: Four Contract Documents cc: Valerie Leone, City of New ;Hope Steven Sondrall, City Attorney St. Paul St. Cloud Rochester Milwaukee Chicago June 25, 2007 Mr. Grant Boisner Northwest Asphalt, Inc. 1451 Stagecoach Road Shakopee, MN 55379 SUBJECT: 2007 INFRASTRUCTURE IMPROVEMENTS (IMPROVEMENT PROJECT NO. 816) Enclosed is return of your bid bond and two fully executed contract documents for New Hope Project No. 816. One contract set is for your records and the second set should be transmitted to your bonding company. This contract was awarded by the New Hope City Council on May 29, 2007, for $484,122.61. Also enclosed is a "Withholding Affidavit for Contractors" (IC -134 form). We cannot make final payment to contractors until this is approved by the Minnesota Department of Revenue and submitted to our office (Minnesota Statute 290.97). The form contains instructions for completion. Should you have any questions regarding the project, please contact Vince VanderTop, City Engineer, at 651 -636 -4790. Sincerely, Valerie Leone City Clerk, CMC Enclosures — Bid bond, Contract, IC -134 cc: Steve Sondrall, City Attorney (File No. 99.10030) Vince VanderTop, Assistant City Engineer (File No. 34- 05175 -0) Guy Johnson, Director of Public Works 4401 Xylon Avenue North 4 New Hope, Minnesota 55428-4898 www. 6new- hope.mmus w r nn /6a ?x Poll 4?f i't C1F`lk�it£-k f: 76J,)- L% � 0 i'r X711 t' �'V ! J! 1. / )? � i E !�?.. 5J r5 .7; T t.{,;3 i t! 1 a : A ; ali 0 r .� � i MMI a , a • DOCUMENT 00005 PROFESSIONAL CERTIFICATIONS Responsible for Division 1 and Division 2, except Section 02850 I hereby certify that this report, drawing, or specification was prepared by me or under my direct supervision and that I am a duly Licensed Engineer under the laws of the State of Minnesota. Jason P. Quisberg, P. . Date: April 20, 2007 Reg. No. 44315 Responsible for Section 02850 and Division 3 I hereby certify that this report, drawing, or specification was prepared by me or under my direct supervision and that I am a duly Licensed Engineer under the laws of thtState of Minnesota. D. Pertzsch, P ate: May 1, 2007 Reg. No. 17383 END OF DOCUMENT 000034 - 05175 -0 © 2007 Bonestroo PROFESSIONALCERTIF[CKHONS � • 1 111 1 TABLE OF CONTENTS 2007 INFRASTRUCTURE IMPROVEMENTS CITY PROJECT NO. 816 PROJECT NO. 000034-05175-0 NEW HOPE, MINNESOTA 2007 Introductory Information 00005 Professional Certifications 00010 Table of Contents Bidding Requirements 00100 Advertisement for Bids 00200 Instructions to Bidders 00300 Information Available to Bidders 00410 Bid Form Contracting Requirements 00520 Agreement Form 00610 Performance Bond 00615 Payment Bond 00700 EJCDC C -700 Standard General Conditions of the Construction Contract (Bound in back of Project Manual) 00800 Supplementary Conditions Specifications Division 1— General Requirements 01100 Summary 01200 Price and Payment Procedures 01310 Project Management and Coordination 01330 Submittal Procedures 01400 Quality Requirements 01500 Temporary Facilities and Controls 01570 Temporary Erosion and Sediment Control 01700 Execution Requirements 000034- 05175 -0 00010 -1 © 2007 Bonestroo TABLE OF CONTENTS Specifications Continued... Division 2 — Site Construction 02225 Removals 02230 Site Clearing 02280 Adjust Miscellaneous Structures 02315 Excavation and Fill 02318 Subgrade Preparation 02320 Trench Excavation and Backfill 02341 Geotextile Soil Stabilization 02510 Water Main 02515 Water Services 02530 Sanitary Sewer Pipe 02532 Sanitary Sewer Structures 02533 Sanitary Sewer Testing and Inspecting 02535 Sanitary Sewer Services 02630 Storm Drainage 02635 Subsurface Drainage 02720 Aggregate Base Course 02740 Plant Mixed Asphalt Pavement Bonestroo Modified MnDOT Spec. 2360/2350 Combined 02770 Concrete Curb and Gutter 02775 Concrete Walks and Driveways 02850 Prefabricated Steel Bridge 02920 Lawns and Grasses 02965 Full Depth Reclamation Division 3 — Concrete 03301 Cast -In -Place Concrete END OF DOCUMENT 000034 - 05175 -0 00010 -2 © 2007 Bonestroo TABLE OF CONTENTS DOCUMENT 00100 ADVERTISEMENT FOR BIDS Sealed Bids will be received by the City of New Hope, Minnesota, in the City Hall at 4401 Xylon Avenue North, until 11 A.M., C.D.S.T., Monday, May 21, 2007, at which time they will be publicly opened and read aloud for the furnishing of all labor, materials, and all else necessary for the following: 2007 Infrastructure Improvements, City Project No. 816 In general, work consists of the following approximate quantities: 1,400 LF Residential Street Reconstruction, Including concrete curb and gutter, concrete sidewalk, bituminous pavement, aggregate base, driveway aprons, etc. 470 LF DIP Water Main Replacement, Including hydrants, fittings, valves, services, etc. 660 LF PVC Sanitary Sewer Replacement, Including manholes, wyes, services, etc. 560 LF 12 Inch to 27 Inch RCP Storm Sewer, Including structures, drain tile, etc. 950 SY Bituminous Trail Reconstruction, Including concrete ped ramps 1 EA Pedestrian Bridge and Abutments The estimated construction cost for this Project is $700,000. Bidders desiring a copy of the Bidding Documents may obtain them from the Issuing Office of Bonestroo, 2335 Highway 36 West, St. Paul, MN 55113, (651) 636 -4600 upon payment of a non - refundable fee of $50.00. Bidding Documents may be seen at the office of the City of New Hope and at the Issuing Office. Bidding Documents can also be purchased with a credit card over the internet at www.bonestroo.com. Direct inquiries to Engineer's Project Manager, Jason Quisberg at (651) 604 -4938. Bid Security in the amount of 5 percent of the amount of the Bid must accompany each Bid in accordance with the Instructions to Bidders. The Owner reserves the right to retain the deposits of the 3 lowest Bidders for a period not to exceed 60 days after the date and time set for the Opening of Bids. No Bids may be withdrawn for a period of 60 days after the date and time set for the Opening of Bids. The Owner reserves the right to reject any and all Bids, to waive irregularities and informalities therein, and further reserves the right to award the Contract to the best interests of the Owner. Daniel Donahue, City Manager City of New Hope, Minnesota 000034- 05175 -0 © 2007 Bonestroo ADVERTISEMENT FOR BIDS DOCUMENT 00200 INSTRUCTIONS TO BIDDERS . ' 0191 .aid __ OX1141 1.01 Terms used in these Instructions to Bidders have the meanings indicated in the General Conditions and Supplementary Conditions. Additional terms used in these Instructions to Bidders have the meanings indicated below: A. Issuing Office: The office from which the Bidding Documents are to be issued and where the Bidding procedures are to be administered. F.3tw, K� ' I YiT�: 1 �7 I�t�I II�Z�l�lU l 1►111T.`1 2.01 Complete sets of the Bidding Documents in the number and for the non - refundable sum stated in the Advertisement for Bids may be obtained from the Issuing Office. 2.02 Complete sets of Bidding Documents shall be used in preparing Bids; neither Owner nor Engineer assumes any responsibility for errors or misinterpretations resulting from the use of incomplete sets of Bidding Documents. 2.03 Owner and Engineer in making copies of Bidding Documents available on the above terms, do so only for the purpose of obtaining Bids for the Work and do not confer a license or grant for any other use. ARTICLE 3 - QUALIFICATIONS OF BIDDERS 3.01 To demonstrate Bidder's qualifications to perform the Work within 5 days of Owner's request, Bidder shall submit written evidence, such as financial data, previous experience, present commitments, and such other data, as may be called for below: A. Evidence of Bidder's qualification to do business in the state where the Project is located or covenant to obtain such qualification prior to award of Contract. B. Evidence of genuineness of Bid and lack of collusion in conjunction therewith. 000034 - 05175 -0 00200 -1 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS ARTICLE 4 - EXAMINATION OF BIDDING DOCUMENTS, OTHER RELATED DATA, AND SITE 4.01 Subsurface and Physical Conditions A. The Supplementary Conditions Identify: 1. Those reports of explorations and tests of subsurface conditions at or contiguous to the Site that Engineer has used in preparing the Bidding Documents. 2. Those drawings of physical conditions in or relating to existing surface and subsurface structures at or contiguous to the Site (except Underground Facilities) that Engineer has used in preparing the Bidding Documents. B. Copies of reports and drawings referenced in Paragraph 4.01.A will be made available by Owner to any' Bidder on request. Those reports and drawings are not part of the Contract Documents, but the "technical data" contained therein upon which Bidder is entitled to rely as provided in Paragraph 4.02 of the General Conditions has been identified and established in Paragraph 4.02 of the Supplementary Conditions. Bidder is responsible for any interpretation or conclusion Bidder draws from any "technical data" or any other data, interpretations, opinions, or information contained in such reports, or shown or indicated in such drawings. 4.02 Underground Facilities A. Information and data shown or indicated in the Bidding Documents with respect to existing Underground Facilities at or contiguous to the Site is based upon information and data furnished to Owner and Engineer by owners of such Underground Facilities, including Owner or others. 4.03 Hazardous Environmental Condition A. The Supplementary Conditions identify those reports and drawings relating to a Hazardous Environmental Condition identified at the Site, if any, that Engineer has used in preparing the Bidding Documents. 000034 - 05175 -0 00200 -2 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS B. Copies of reports and drawings referenced in Paragraph 4.03.A will be made available by Owner to any Bidder on request. Those reports and drawings are not part of the Contract Documents, but the "technical data" contained therein upon which Bidder is entitled to rely as provided in Paragraph 4.06 of the General Conditions has been identified and established in Paragraph 4.06 of the Supplementary Conditions. Bidder is responsible for any interpretation or conclusion Bidder draws from any "technical data" or any other data, interpretations, opinions, or information contained in such reports or shown or indicated in such drawings. 4.04 Provisions concerning responsibilities for the adequacy of data furnished to prospective Bidders with respect to subsurface conditions, other physical conditions, Underground Facilities, and possible changes in the Bidding Documents due to differing or unanticipated conditions appear in Paragraphs 4.02, 4.03, and 4.04 of the General Conditions. Provisions concerning responsibilities for the adequacy of data furnished to prospective Bidders with respect to a Hazardous Environmental Condition at the Site, if any, and possible changes in the Contract Documents due to any Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in the Drawings or Specifications, or identified in the Contract Documents to be within the scope of the work appear in Paragraph 4.06 of the General Conditions. 4.05 On request, Owner will provide Bidder access to the Site to conduct such examinations, investigations, explorations, tests, and studies as Bidder deems necessary for submission of a Bid. Bidder shall fill all holes, and clean up and restore the Site to its former condition upon completion of such explorations, investigations, tests, and studies. Bidder shall comply with all applicable Laws and Regulations relative to excavation and utility locates. 4.06 Reference is made to Article 7 of the Supplementary Conditions for the identification of the general nature of other work that is to be performed at the Site by Owner or others (such as utilities and other prime contractors) that relates to the Work contemplated by these Bidding Documents. On request, Owner will provide to each Bidder for examination access to or copies of contract documents (other than portions thereof related to price) for such other work. 4.07 It is the responsibility of each Bidder before submitting a Bid to: A. examine and carefully study the Bidding Documents, the other related data identified in the Bidding Documents, and any Addenda; B. visit the Site and become familiar with and satisfy Bidder as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work; C. become familiar with and satisfy Bidder as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the Work; 000034 - 05175 -0 00200 -3 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS D. carefully study all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) which have been identified in the Supplementary Conditions as provided in Paragraph 4.02 of the General Conditions, and (2) reports and drawings of Hazardous Environmental Conditions at the Site which have been identified in the Supplementary Conditions as provided in Paragraph 4.06 of the General Conditions; E. obtain and carefully study (or accept consequences of not doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at or contiguous to the Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including applying any specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents, safety precautions, and programs incident thereto; F. agree at the time of submitting its Bid that no further examinations, investigations, explorations, tests, studies, or data are necessary for the determination of its Bid for performance of the Work at the Price(s) Bid and within the times and in accordance with the other terms and conditions of the Bidding Documents; G. become aware of the general nature of the work to be performed by Owner and others at the Site that relates to the Work as indicated in the Bidding Documents; H. correlate the information known to Bidder, information and observations obtained from visits to the Site, reports and drawings identified in the Bidding Documents, all additional examinations, investigations, explorations, tests, studies, and data with the Bidding Documents; I. promptly give Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder discovers in the Bidding Documents and confirm that the written resolution thereof by Engineer is acceptable to Bidder; and J. determine that the Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for the performance of the Work. 000034 - 05175 -0 00200 -4 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS 4.08 The submission of a Bid will constitute an incontrovertible representation by Bidder that Bidder has complied with every requirement of this Article 4, that without exception the Bid is premised upon performing and furnishing the Work required by the Bidding Documents, and applying any specific means, methods, techniques, sequences, and procedures of construction that may be shown or indicated or expressly required by the Bidding Documents, that Bidder has given Engineer written notice of all conflicts, errors, ambiguities, and discrepancies that Bidder has discovered in the Bidding Documents and the written resolutions thereof by Engineer are acceptable to Bidder, and that the Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performing and furnishing the Work. ARTICLE 5 - PRE -BID CONFERENCE 5.01 There will be no pre -Bid conference. ARTICLE 6 — SITE AND OTHER AREAS 6.01 The Site is identified in the Bidding Documents. Easements for permanent structures or permanent changes in existing facilities are to be obtained and paid for by Owner, unless otherwise provided in the Bidding Documents. All additional lands and access thereto required for temporary construction facilities, construction equipment, or storage of materials and equipment to be incorporated in the Work are to be obtained and paid for by Contractor. ON 7.01 All questions about the meaning or intent of the Bidding Documents are to be submitted to Engineer in writing. Interpretations or clarifications considered necessary by Engineer in response to such questions will be issued by Addenda mailed or delivered to all parties recorded by Engineer as having received the Bidding Documents. Questions received less than 10 days prior to the date for Opening of Bids may not be answered. Only questions answered by Addenda will be binding. Oral and other interpretations or clarifications will be without legal effect. 7.02 Addenda may be issued to clarify, correct, or change the Bidding Documents as deemed advisable by Owner or Engineer. ARTICLE 8 - BID SECURITY 8.01 A Bid must be accompanied by Bid Security made payable to Owner in an amount of 5 percent of Bidder's maximum Bid Price and in the form of a certified check or bank money order, or a Bid Bond issued by a surety meeting the requirements of Paragraphs 5.01 and 5.02 of the General Conditions. 000034 - 05175 -0 00200 -5 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS 8.02 The Bid Security of the successful Bidder will be retained until such Bidder has executed the Contract Documents, furnished the required Contract Security, and met the other conditions of the Notice of Award, whereupon the Bid Security will be returned. If the successful Bidder fails to execute and deliver the Contract Documents and furnish the required Contract Security within 15 days after the Notice of Award, Owner may annul the Notice of Award and the Bid Security of that Bidder will be forfeited. The Bid Security of other Bidders whom Owner believes to have a reasonable chance of receiving the award may be retained by Owner until the earlier of 7 days after the Effective Date of the Agreement or 61 days after the Bid Opening, whereupon Bid Security furnished by such Bidders will be returned. 8.03 Bid Security of other Bidders whom Owner believes do not have a reasonable chance of receiving the award will be returned within 7 days after the Bid Opening. ARTICLE 9 - CONTRACT TIMES 9.01 The number of days within which or the dates by which Milestones are to be achieved and the work is to be Substantially Completed and ready for Final Payment are set forth in the Agreement. ARTICLE 10 - LIQUIDATED DAMAGES 10.01 Provisions for liquidated damages, if any, are set forth in the Agreement. ARTICLE 11 - SUBSTITUTE AND "OR- EQUAL" ITEMS 11.01 The Contract, if awarded, will be on the basis of materials and equipment specified or described in the Bidding Documents without consideration of possible substitute or "or- equal" items. Whenever it is specified or described in the Bidding Documents that a substitute or "or- equal" item of material or equipment may be furnished or used by Contractor if acceptable to Engineer, application for such acceptance will not be considered by Engineer until after the Effective Date of the Agreement. 000034 - 05175 -0 00200 -6 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS ARTICLE 12 - SUBCONTRACTORS, SUPPLIERS, AND OTHERS 12.01 If the Supplementary Conditions require the identity of certain subcontractors, suppliers, individuals, or entities to be submitted to Owner in advance of a specified date prior to the Effective Date of the Agreement, the apparent successful Bidder and any other Bidder so requested shall within 5 days after Bid Opening, submit to Owner a list of all such subcontractors, suppliers, individuals, or entities proposed for those portions of the Work for which such identification is required. Such list shall be accompanied by an experience statement with pertinent information regarding similar projects and other evidence of qualification for each such subcontractor, supplier, individual, or entity if requested by Owner. If Owner or Engineer after due investigation has reasonable objection to any proposed subcontractor, supplier, individual, or entity, Owner may before the Notice of Award is given request apparent successful Bidder to submit a substitute in which case apparent successful Bidder shall submit an acceptable substitute, Bidder's Bid Price will be increased (or decreased) by the difference in cost occasioned by such substitution and Owner may consider such price adjustment in evaluating Bids and making the Contract award. 12.02 If apparent successful Bidder declines to make any such substitution, Owner may award the Contract to the next lowest Bidder that proposes to use acceptable subcontractors, suppliers, individuals, or entities. Declining to make requested substitutions will not constitute grounds for forfeiture of the Bid Security of any Bidder. Any subcontractor, supplier, individual, or entity so listed and against which Owner or Engineer makes no written objection prior to the giving of the Notice of Award, will be deemed acceptable to Owner and Engineer subject to revocation of such acceptance after the Effective Date of the Agreement as provided in Paragraph 6.06 of the General Conditions. 12.03 Contractor shall not be required to employ any subcontractor, supplier, individual, or entity against whom Contractor has reasonable objection. ARTICLE 13 - PREPARATION OF BID 13.01 The Bid Form is included with the Bidding Documents. Additional copies may be obtained from Engineer. 13.02 All blanks on the Bid Form shall be completed by printing in ink or by typewriter and the Bid signed in ink. Erasures or alterations shall be initialed in ink by the person signing the Bid Form. A Bid Unit Price shall be indicated for each Bid Item listed therein. 13.03 A Bid by a corporation shall be executed in the corporate name by the president or a vice - president or other corporate officer accompanied by evidence of authority to sign. The corporate seal shall be affixed and attested by the secretary or an assistant secretary. The corporate address and state of incorporation shall be shown below the signature. 000034- 05175 -0 00200 -7 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS 13.04 A Bid by a partnership shall be executed in the partnership name and signed by a partner (whose title must appear under the signature), accompanied by evidence of authority to sign. The official address of the partnership shall be shown below the signature. 13.05 A Bid by a limited liability company shall be executed in the name of the firm by a member and accompanied by evidence of authority to sign. The state of formation of the firm and the official address of the firm shall be shown below the signature. 13.06 A Bid by an individual shall show the Bidder's name and official address. 13.07 A Bid by a joint venture shall be executed by each joint venturer in the manner indicated on the Bid Form. The official address of the joint venture shall be shown below the signature. 13.08 All names shall be typed or printed in ink below the signatures. 13.09 The Bid shall contain an acknowledgment of receipt of all Addenda, the numbers of which shall be filled in on the Bid Form. 13.10 The address and telephone number for communications regarding the Bid shall be shown. 13.11 The Bid shall contain evidence of Bidder's authority and qualification to do business in the state where the Project is located or covenant to obtain such qualification prior to award of the Contract. Bidder's State Contractor License Number, if any, shall also be shown on the Bid Form. 13.12 Bidders shall indicate the Total Add or Deduct to the Total Base Bid for each Alternate provided on the Bid Form. 13.13 Bidders may list proposed Substitute Items on the spaces provided on the Bid Form. Bidders shall clearly indicate the item name, Specification Section Number, and the Total Deduct to the Total Base Bid for each Substitute Item proposed. 13.14 Bidders shall circle the name of the Base Bid Manufacturer they will provide if awarded the Contract. Bidders shall circle only 1 name for each item. If the Bidder fails to circle an item, the first item listed shall be provided. 13.15 Bidders shall identify the name of the company or subcontractor that will perform the listed portion of the work if the Bidder is awarded the Contract. • :• • :It • ••' • • : 1•W 14.01 Bid Unit Price A. Bidders shall submit a Bid on a Bid Unit Price Basis for each Bid Item of work listed in the Bid Form. 000034 - 05175 -0 00200 -8 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS B. The total of all estimated prices will be the sum of the products of the estimated quantity of each Bid Item and the corresponding Bid Unit Price. The final quantities and Contract Price will be determined in accordance with Paragraph 11.03 of the General Conditions. C. Discrepancies between the multiplication of units of work and Bid Unit Prices will be resolved in favor of the Bid Unit Prices. Discrepancies between the indicated sum of any column of figures and the correct sum thereof will be resolved in favor of the correct sum. Discrepancies between words and figures will be resolved in favor of the words. D. Bids will be compared on the basis of the "Total Base Bid" and this amount will be the basis for determining the lowest Bidder. 14.02 The Bid Price shall include such amounts as the Bidder deems proper for overhead and profit on account of cash allowances, if any, named in the Contract Documents as provided in Paragraph 11.02 of the General Conditions. 15.01 With each copy of the Bidding Documents, a Bidder is furnished 1 separate unbound copy of the Bid Form, and, if required, the Bid Bond Form. The unbound copy of the Bid Form is to be completed and submitted with the Bid Security. 15.02 A Bid shall be submitted no later than the date and time prescribed and at the place indicated in the Advertisement for Bids and shall be enclosed in an opaque sealed envelope plainly marked with the Project Title (and, if applicable, the designated portion of the Project for which the Bid is submitted), the name and address of Bidder, and shall be accompanied by the Bid Security and other required documents. If a Bid is sent by mail or other delivery system, the sealed envelope containing the Bid shall be enclosed in a separate envelope plainly marked on the outside with the notation "BID ENCLOSED." A mailed Bid shall be addressed to Owner's office. ARTICLE 16 - MODIFICATION AND WITHDRAWAL OF BID 16.01 A Bid may be modified or withdrawn by an appropriate document duly executed in the manner that a Bid must be executed and delivered to the place where Bids are to be submitted prior to the date and time for the Opening of Bids. 16.02 Bids may be withdrawn after Bid Opening only in accordance with the law. 000034 - 05175 -0 00200 -9 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS 17.01 Bids will be opened at the time and place indicated in the Advertisement for Bids and, unless obviously non - responsive, read aloud publicly. A Bid Tabulation of the amounts of the Base Bids and major Alternates, if any, will be made available to Bidders after the Opening of Bids. ARTICLE 18 - BIDS TO REMAIN SUBJECT TO ACCEPTANCE 18.01 All Bids will remain subject to acceptance for the period of time stated in the Bid Form, but Owner may, in its sole discretion, release any Bid and return the Bid Security prior to the end of this period. ARTICLE 19 — EVALUATION OF BIDS AND AWARD OF CONTRACT 19.01 If the Contract is awarded, award will be made on the basis of the lowest responsive, responsible, qualified Bidder determined by the Total Base Bid. 19.02 Owner reserves the right to reject any or all Bids, including without limitation nonconforming, nonresponsive, unbalanced, or conditional Bids. Owner further reserves the right to reject the Bid of any Bidder whom it finds after reasonable inquiry and evaluation to not be responsible. Owner may also reject the Bid of any Bidder if Owner believes that it would not be in the best interest of the Project to make an award to that Bidder. Owner also reserves the right to waive all informalities not involving price, time, or changes in the work and to negotiate Contract terms with the successful Bidder. 19.03 More than 1 Bid for the same work from an individual or entity under the same or different names will not be considered. Reasonable grounds for believing that any Bidder has an interest in more than 1 Bid for the work may be cause for disqualification of that Bidder and the rejection of all Bids in which that Bidder has an interest. 19.04 In evaluating Bids, Owner will consider whether or not the Bids comply with the prescribed requirements and such Alternates, Bid Unit Prices, and other data as may be requested in the Bid Form or prior to the Notice of Award. 19.05 In evaluating Bidders, Owner will consider the qualifications of Bidders and may consider the qualifications and experience of subcontractors, suppliers, other individuals, or entities proposed for those portions of the work for which the identity of subcontractors, suppliers, other individuals, or entities must be submitted as provided in the Supplementary Conditions. 000034 - 05175 -0 00200 -10 © 2007 Bonestroo INSTRUCTIONS TO BIDDERS 19.06 Owner may conduct such investigations as Owner deems necessary to establish the responsibility, qualifications, and financial ability of Bidders, proposed subcontractors, suppliers, individuals, or entities to perform the work in accordance with the Contract Documents. As a condition of its Bid, Bidder is required to waive any and all claims of whatever nature against Owner, Engineer, and their employees and agents which arise out of or relate to such investigations and statements made as a result thereof, except for statements that can be shown by clear and convincing evidence to be intentionally false and made with actual malice. This waiver is not intended to restrict Bidder's rights to challenge a Contract award pursuant to law. 19.07 If the Contract is to be awarded, Owner will award the Contract to the Bidder whose Bid is in the best interests of the Project. ARTICLE 20 - CONTRACT SECURITY AND INSURANCE 20.01 Article 5 of the General Conditions, as may be modified by the Supplementary Conditions, sets forth Owner's requirements as to Performance and Payment Bonds and Insurance. When the successful Bidder delivers the executed Agreement to Owner, it shall be accompanied by such bonds. ARTICLE 21 - SIGNING OF AGREEMENT 21.01 When Owner gives a Notice of Award to the successful Bidder, it shall be accompanied by the required number of unsigned counterparts of the Agreement with the other Contract Documents which are identified in the Agreement as attached thereto. Within 15 days thereafter, successful Bidder shall sign and deliver the required number of counterparts of the Agreement and attached documents to Owner. Within 10 days thereafter, Owner shall deliver 2 fully signed counterparts to successful Bidder with a complete set of the Drawings with appropriate identification. 000034 - 05175 -0 00200 -11 OO 2007 Bonestroo INSTRUCTIONS TO BIDDERS DOCUMENT 00300 Portions of reports and drawings used by the Engineer in the preparation of the Bidding Documents are attached to this document. The Technical Data is identified in the Supplementary Conditions. Bidders are responsible for their own interpretation, verification, and use of the Technical Data contained in these reports and drawings consistent with the General Conditions and Supplementary Conditions. Reports, drawings, and other historical information regarding the Project may be available for Bidder's review at the Engineer's office. Schedule a viewing time with the Project Manager. � � ] � � Z � Z • 1 .1 71 � 1► i I 000034 - 05175 -0 © 2007 Bonestroo INFORMATION AVAILABLE TO BIDDERS gas THIS BID IS SUBMITTED TO: City of New Hope City Hall 4401 Xylon Avenue North New Hope, MN 55428 -4898 1.01 The undersigned Bidder proposes and agrees, if this Bid is accepted, to enter into an Agreement with Owner in the form included in the Bidding Documents to perform all work as specified or indicated in the Bidding Documents for the prices and within the times indicated in this Bid and in accordance with the other terms and conditions of the Bidding Documents, 2.01 Bidder accepts all of the terms and conditions of the Instructions to Bidders, including without limitation those dealing with the disposition of Bid Security. The Bid will remain subject to acceptance for 60 days after the Bid Opening, or for such longer period of time that Bidder may agree to in writing upon request of Owner. 3.01 In submitting this Bid, Bidder represents that: A. Bidder has examined and carefully studied the Bidding Documents, the other related data identified in the Bidding Documents, and the following Addenda, receipt of all which is hereby acknowledged: Addendum No. Addendum Date y & lt, B. Bidder has visited the Site and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. C. Bidder is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the Work. D. Bidder has carefully studied all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) which have been identified in SC -4.02, and (2) reports and drawings of Hazardous Environmental Conditions that have been identified in SC -4.06. 000034051750BIDFORM.xls 00410 -1 BID FORM / DOCUMENT 00410 BID FORM 2007 INFRASTRUCTURE IMPROVMENTS CITY PROJECT NO. 816 PROJECT NO. 000034-05175-0 NEW HOPE, MINNESOTA 2007 E. Bidder has obtained and carefully studied (or accepts the consequences for not doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at or contiguous to the Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including applying the specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents to be employed by Bidder, and safety precautions and programs incident thereto. F. Bidder does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the determination of this Bid for performance of the Work at the price(s) Bid and within the times and in accordance with the other terms and conditions of the Bidding Documents. G. Bidder is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Bidding Documents. H. Bidder has correlated the information known to Bidder, information and observations obtained from visits to the Site, reports and drawings identified in the Bidding Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Bidding Documents. I. Bidder has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder has discovered in the Bidding Documents, and the written resolution thereof by Engineer is acceptable to Bidder. The Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for the performance of the Work for which this Bid is submitted. K. Bidder will submit written evidence of its authority to do business in the state where the Project is located not later than the date of its execution of the Agreement. 4.01 Bidder further represents that: A. The prices in this Bid have been arrived at independently, without consultation, communication, or agreement as to any matters relating to such prices with any other Bidder or with any competitor for the purpose of restricting competition. B. The prices in this Bid have not or will not be knowingly disclosed to any other Bidder or competitor prior to opening of the Bids. C. No attempt has been made or will be made by the Bidder to induce any other person or firm to submit or not to submit a Bid for the purpose of restricting competition. 4.02 Bidder understands that the law may require the Owner, or Engineer at the Owner's direction, to undertake an investigation and submit an evaluation concerning Bidder's responsiveness, responsibility, and qualifications before awarding a contract. Bidder hereby waives any and all claims, of whatever nature, against Owner, Engineer, and their employees and agents, which arise out of or relate to such investigation and evaluation, and statements made as a result thereof, except for statements that can be shown by clear and convincing evidence to be intentionally false and made with actual malice. Nothing in this paragraph is intended to restrict Bidder's rights to challenge a contract pursuant to law. 000034051750BIDFORM.xls 00410 -2 BID FORM 5.01 Bidder will complete the Work in accordance with the Contract Documents for the following price(s): All specific cash allowances are included in the price(s) set forth below and have been computed in accordance with Paragraph 11.02 of the General Conditions. Unit Prices have been computed in accordance with Paragraph 11.03.13 of the General Conditions Bidder acknowledges that estimated quantities are not guaranteed, and are solely for the purpose of comparison of Bids, and final payment for all Unit Price Bid items will be based on actual quantities provided, determined as provided in the Contract Documents. No. Item Units Qty Unit Price Total Price BASE BID: 1 MOBILIZATION LS 1 $ YL1�G $ 2 TRAFFIC CONTROL LS 1 $ 47�' %y $ 3 SILT FENCE, MACHINE SLICED LF 300 $ 3. I $ 4 INLET PROTECTION EXPOSED EA 12 $ � GAP. Z -0 $ Z ro SUBGRADE 5 INLET PROTECTION POST EA 10 $ zw- t it $ i�tyL/ =tom BITUMINOUS BASE 6 REMOVE BITUMINOUS DRIVEWAY SY 150 $ $ PAVEMENT 7 REMOVE BITUMINOUS TRAIL SY 660 $ $ 8 REMOVE CONCRETE CURB AND LF 2050 $ $ GUTTER 9 REMOVE CONCRETE DRIVEWAY SY 133 $ $ 4-3 Z ey PAVEMENT 10 REMOVE CONCRETE SIDEWALK SF 584$ $ 11 REMOVE SANITARY SEWER PIPE LF 657 $ $ 12 REMOVE SANITARY SEWER SERVICE LF 375 $ Cz1 $ O/�5• e'C� PIPE 13 REMOVE WATER MAIN LF 452$ 5 $ 27-6 CQ 14 REMOVE HYDRANT EA 1 $ ZM'6 $ Z ry 15 REMOVE CASTING EA - 3 $ ,� — to $ 16 REMOVE MANHOLE OR CATCH EA 6$ .X11 $ 4q1 a PV BASIN 17 REMOVE PEDESTRIAN BRIDGE AND LS is 7E'C>, IV $ OZ C> &0 ABUTMENTS 000034051750BIDFORMals 00410 -3 BID FORM No. Item Units Qty Unit Price Total Price 18 SAWING BITUMINOUS PAVEMENT LF 200 $ �. $ f"C1 19 CLEARING TREE 1 $ 'S Ct , $ rrC 20 GRUB TREE I $ ��� eU $ ey 21 ADJUST VALVE BOX EA 2$ c . CC) $ e44-Q, 0-0 22 ADJUST HYDRANT EA 2$ c.�6t. tjC3 $ 23 ADJUST MANHOLE CASTING EA 1 $ S',Ta 1r0_ $ 24 SELECT GRANULAR BORROW IN 3823 $ $ 9� (MODIFIED) 25 SELECT TOP SOIL BORROW (LV) CY 320$ $ oG 26 COMMON EXCAVATION (EV) - CY 3925 $ 7 $� t>G OFFSITE 27 COMMON EXCAVATION (EV) - ON CY 146 $ $ SITE 28 GEOTEXTILE FABRIC, TYPE IV SY 5516$ b $ 29 CONNECT TO EXISTING WATER MAIN EA 2$ .5� 40 $ y t' 30 DUCTILE IRON FITTINGS LB 589 $ _ $ 31 INSTALL HYDRANT AND VALVE EA 2$ PC) $ 32 INSULATION, 2" THICK SY 20 $ 1 ;� to $ a r- 0 33 8" DIP WATER MAIN, CLASS 52 LF 427$ - ;- 7 6 $�". 34 6" DIP WATER MAIN, CLASS 52 LF 54 $ Z- $ !v-e 35 TEMPORARY WATER SERVICE LS 1 $ / �'�. Z $ z6f'c-z�o 36 8" GATE VALVE AND BOX EA 2 $ f Ali $ 37 REMOVE EX. AND INSTALL 4" GATE EA 1 $ VALVE AND BOX 38 CONNECT TO EXISTING WATER EA 8 $ SERVICE 39 1 " CORPORATION STOP EA 10 $ _ $ 7�/. e 40 1 " CURB STOP AND BOX EA 10$ $ 0 00034051750BIDFORM.xIs 00410 -4 BID FORM No. Item Units Qty Unit Price Total Price 41 1" TYPE "K" COPPER WATER LF 375 $ 1 1-7 $ $ SERVICE 27" RCP STORM SEWER, CLASS 4 LF 42 CONNECT EXISTING PIPE TO EA 2 $ : �eV GO $ Ztqor. -L° EA SANITARY STRUCTURE $ ✓ j IS2-I, ) 43 4' DIAMETER SANITARY MANHOLES EA C Is $ 7 Z-; 3 � 37. 44 8" PVC SANITARY SEWER, SDR 35 LF 663 $ e4 = 45 CONNECT TO EXISTING SANITARY EA 10 $ znn'y ' $ cc� 1 $ * F w _ SEWER SERVICE 57 CONSTRUCT 4' DIAMETER CBMH 46 6" PVC, SDR 26 SERVICE PIPE LF 425 $ $ 5746f. gr 47 CUT 6" SERVICE WYE INTO 9" VCP EA 2$ le $ / t� 48 8" X 6" PVC WYE EA 8 $ irr $ 49 INSTALL CASTING EA 3 $ $ 50 CONNECT EXISTING PIPE TO STORM EA 2$ $ ,!Z`rir. P 000034051750BIDFORM.xis 00410 -5 BID FORM STRUCTURE 51 12" RCP STORM SEWER, CLASS 3 LF 101 $ 4E7R $ 52 27" RCP STORM SEWER, CLASS 4 LF 467 $ J ¢ $ 53 2'X T CATCH BASIN EA 3 $ �P ro $ ✓ j 54 4' DIAMETER STORM CBMH EA 2$ e -- Z, PO $ s' 7 e 55 Y DIAMETER STORM CBMH EA 1 $ Ze53 ,trd $ ?-e53 gpz) 56 6.5' DIAMETER STORM CBMH EA 1 $ * F w _ $ 16, to 57 CONSTRUCT 4' DIAMETER CBMH EA 2$ 2 V 1 t C' $ 4VI OVER EXISTING PIPE 58 4' DIAMETER STRUCTURE LF 9.5 $ / fit $ 1P141, SV OVERDEPTH 59 5' DIAMETER STRUCTURE LF 6$ � $ OVERDEPTH 60 6.5' DIAMETER STRUCTURE LF 4$ $ OVERDEPTH 0 '/ W 61 CONNECT DRAIN TILE TO EA 2$ $ STRUCTURE 62 4" PERFORATED POLYETHYLENE LF 515 $ A $ PIPE 63 AGGREGATE BASE, CLASS 5 TN 3184$ Z - Z $ _ ° 7Z 1, G' 000034051750BIDFORM.xis 00410 -5 BID FORM No. Item Units Qty Unit Price Total Price 64 STREET SWEEPER (WITH PICKUP HOUR 30 $ Aro _ $ 5 t`t✓ 000034051750BIDFORM.xls 00410 -6 BID FORM BROOM) 65 WATER MG 200$ $ G', t 66 BITUMINOUS MATERIAL FOR TACK GAL 260$ � $ 4s:5 COAT 67 TYPE LV 3 NON WEARING COURSE TN 623$ <AP $ ,.. Z S,S O MIXTURE (B) 68 TYPE LV 4 WEARING COURSE TN 468$ 5 - 7. t;z� $ MIXTURE (B) 69 TYPE LV 4 WEARING COURSE TN 10$ pi S $ MIXTURE (B), FOR DRIVEWAYS 70 TYPE LV 4 WEAR COURSE MIXTURE TN 185$ 1�I ° "� $ (B), FOR TRAIL, 71 RECONSTRUCT WOOD RETAINING WALL SY 3 $ $ BLS. -� Aq tlI LII 72 B618 CONCRETE CURB AND GUTTER LF 2748 $ $ ,t 73 6" CONCRETE DRIVEWAY SF 2860$ _ $ PAVEMENT l tad 74 PEDESTRIAN CURB RAMP WITH EA 3 $ $ /-' TRUNCATED DOME 75 4" CONCRETE SIDEWALK SF 3141 $ $ 49 1, 76 RECLAIM BITUMINOUS PAVEMENT SY 4310$ /+ 70 $ 7 5 °n , � 0 77 TEMPORARY MAIL BOXES LS is 3' $ 3 -io y 78 SODDING, LAWN TYPE SY 2755 $ $ 17 . 2s ) 79 SEEDING AC 0.1$ : $ 80 EROSION CONTROL BLANKETS, SY 325 $ �` ��� $ 7 "s_ 7y CATEGORY 4 / 1�i a� - 02, 81 PREFABRICATED STEEL BRIDGE, LS 1$ DELIVERED b`€`t. ®� .•,_ 82 PREFABRICATED STEEL BRIDGE, LS _ 1 _ � INSTALLED 83 CONCRETE ABUTMENT EA 2$ Gn $ 84 ABUTMENT EXCAVATION AND LS 1 $"°° $ BACKFII,L /,p ®® 85 CLASS III RANDOM RIPRAP CY 30$ s $ TOTAL BASE BID $ 000034051750BIDFORM.xls 00410 -6 BID FORM 6.01 Bidder agrees that the Work will be Substantially Completed and completed and ready for Final Payment in accordance with Paragraph 14.07.B of the General Conditions on or before the dates or within the number of calendar days indicated in the Agreement. 6.02 Bidder accepts the provisions of the Agreement as to liquidated damages in the event of failure to complete the Work within the times specified above, which shall be stated in the Agreement. 7.01 The following documents are attached to and made a condition of this Bid: A. Required Bid Security in the form of 5 percent. 8.01 The terms used in this Bid with initial capital letters have the meanings stated in the Instructions to Bidders, the General Conditions, and the Supplementary Conditions. SUBMITTED on �7� 20 t If Bidder Is: An Individual Name (typed or printed): Un Doing business as: (Individual's signature) Business Street Address (No P.O. Box #'s): (SEAL) Phone No.: Fax No.: 000034051750BIDFORM.xls 00410 -7 BID FORM A Partnership Partnership Name: (SEAL) M (Signature of general partner) Name (typed or printed): Business Street Address (No P.O. Box Vs): Phone No.: A Corporation Fax No.: Corporation Name: (SEAL) State of Incorporation: T pe (General Busin s ofessional, Servi e, Limited Liability): _ BY: (Signature) Name (typed or printed): 'ff7✓l's �c_ Title: SI S SCHULTE r RY PUBLIC - MINNESOTA Attest br) EVires Jan. 31, 20 (Signature of Corporate Secretary) Business Street Address (No P.O. Box Vs): �' Phone No.: S Z ' 1-t AM Fax No.: 000034051750BIDFORM.xis 00410 -8 BID FORM A Joint Venture Joint Venture Name: (SEAL) By: Name (typed or printed): Title: Business address: (Signature of joint venture partner) Phone No.: Fax No.: Joint Venturer Name: (SEAL) IM (Signature) Name (typed or printed): Title: Business Street Address (No P.O. Box Ws): Phone No.: Fax No.: Phone and Fax Number, and Address for receipt of official communications: (Each joint venturer must sign. The manner of signing for each individual, partnership, and corporation that is a party to the joint venture should be in the manner indicated above). END OF DOCUMENT 000 03 4 051750BIDFORM.xls 00410 -9 BID FORM 9 AIA Document A310 i • • 0 KNOW ALL MEN BY THESE PRESENTS, that we Northwest Asphalt, Inc. (Here insert full name and address or legal title of Contractor) 1451 Stagecoach Road, Shakopee, MN 55379 as Principal, hereinafter called the Principal, and Western Surety Company (Here insert full name and address or legal title of Surety) P.O. Box 5077, Sioux Falls, SD 57117 -5077 a corporation duly organized under the laws of the State of South Dakota as Surety, hereinafter called the Surety, are held and firmly bound unto CITY OF NEW HOPE (Here insert full name and address or legal title of Owner) as Obligee, hereinafter called the Obligee, in the sum of FIVE PERCENT OF THE AMOUNT OF THE BID Dollars {$ 5% ), for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for (Here insert full name, address and description of project) 2007 INFRASTRUCTURE IMPROVEMENTS CITY PROJECT NO. 816 NEW HOPE NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Sig ed and sealed this 21st day of May , 2007. Wa NORTHWEST ASPHALT INC. p ' (Principal "f/ -�-- � n ) (Seat) / } ' ll✓ Sh ila Geibe (Title) Corporate Secretary _ WESTERN SURETY CONVANY . ( .5urety) (Seal) '�. (Witness) (I tue) Teresa Hammers, Attorney -in -Fact AIA DOCUMENT A310 • BID BOND •AIA ® • FEBRUARY 1970 ED . THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE., N.W., WASHINGTON, D.C. 20006 STATE OF MINNESOTA COUNTY OF SCOTT On this 21St day of May , 2007 before me personally appeared Sheila Geibe to me known, who being by me duly sworn, that he /she is the Corporate Secretary of the Northwest Asphalt, Inca the corporation described in and which executed the foregoing instrument; that he /she knows the seal of said corporation; that the seal affixed to said instrument is such corporate seal; that it was so affixed by order of the Board of Directors of said corporation; and that he /she signed his /her name thereto by like order. A (Notary Public) CAIOOLYN X WISNIEWSKI NOtAky PAC MINNESOTA a�Y Comi _Xpirgs Jan 31, 2010 STATE OF MINNESOTA COUNTY OF HENNEPIN On this 21St day of May , 2007 before me appeared Teresa Hammers to be known, who being by me duly sworn, did say that she is the aforesaid Attorney -in -Fact of the Western Surety Company a corporation; that the seal affixed to the foregoing instrument is the corporate seal of said corporation, and that said instrument was signed and sealed on behalf of said corporation by the aforesaid officer, by authority of its Board of directors; and the aforesaid officer acknowledged said instrument to be the free act and deed of said corporation. ME 4,M.'�. R,^R�\tWtN�l�fl.lVUt."9l5/IiNJb c'� T J! �� f N tar I` t F i n sc ?oi ccinrn 71 on Ex , s jan 31, [�a"�.+ •l' N4i�Pl fw^ x 'Y71IW'� +u'�+V71'!'J'v`dt+VV':� Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint William K Velin, James R Perkins, Amy M Burns, Teresa Hammers, Steven C Aronson, Nathan P Hughes, Laurent R Laventure, Stanley L Pearson, Janet D Buerg, Kathleen Sorenson, Todd A Kelsey, Gordon L Johnson, John D Moore, Individually of Bloomington, MN, its true and lawful Attomey(s) -in -Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Senior Vice President and its corporate seal to be hereto affixed on this 22nd day of March, 2007. WESTERN SURETY COMPANY g'N, pP g1t `��TN DAK Paul . Bruflat, Senior Vice President State of South Dakota County of Minnehaha ss On this 22nd'day of March, 2007, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Senior Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board 'of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires }ye, hhY'+h + +4SY +r+h4hh44 t r D. KRELL i November 30, 2012 s SEAL NOTARY PUBLIC EAR i a SOUTH DAKOTA i 1'hh4hb4'rhhS 44NhS+4hhhh4h + xaa k4-ew D. Krell, No ary Public CERTIFICATE I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this 21St day of May _'_ 2007 ; Pas WESTERN SURETY COMPANY a."'loa ox jW:4 �iZ� Form F4280 - 09 - 06 L. Nelson, Assistant Secretary Authorizing By -Law .ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. DOCUMENT 00520 AGREEMENT FORM THIS AGREEMENT is by and between the City of New Hope, Minnesota (hereinafter called Owner) and Northwest Asphalt, Inc. (hereinafter called Contractor). Owner and Contractor, in consideration of the mutual covenants hereinafter set forth, agree as follows: i J ftlkyffl R 1.01 Contractor shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: municipal utility and street reconstruction. ARTICLE 2 — THE PROJECT 2.01 The Project for which the Work under the Contract Documents may be the whole or only a part is generally described as follows: 2007 Infrastructure Improvements Project for the City of New Hope, Minnesota, City Project No. 816. ARTICLE 3 - ENGINEER 3.01 The Project has been designed by Bonestroo, 2335 Highway 36 West, St. Paul, MN 55113 (Engineer), who is to act as Owner's representative, assume all duties and responsibilities, and will have the rights and authority assigned to Engineer in the Contract Documents in connection with the completion of the Work in accordance with the Contract Documents. ARTICLE 4 - CONTRACT TIMES 4.01 Time of the Essence A. All time limits for Milestones, if any, Substantial Completion, and completion and readiness for Final Payment as stated in the Contract Documents are of the essence of the Contract. 4.02 Dates for Milestones, Substantial Completion, and Final Payment A. All street and utility work, except for wear course paving, will be completed on or before November 2, 2007. B. All wear course paving shall be completed on or before June 20, 2008. C. All of the Work of the Project shall be completed and ready for Final Payment in accordance with Paragraph 14.07 of the General Conditions on or before July 4, 2008. 000034 - 05175 -0 2007 Bonestroo 00520.1 AGREEMENT FORM 4.03 Liquidated Damages A. Contractor and Owner recognize that time is of the essence of this Agreement and that Owner will suffer financial loss if the Work is not completed within the times specified in Paragraph 4.02 above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. The parties also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as Liquidated Damages for delay (but not as a penalty), Contractor shall pay Owner $150 for each day that expires after the time specified in Paragraph 4.02 for Milestones and Substantial Completion until the Work is Substantially Complete. After Substantial Completion, if Contractor shall neglect, refuse, or fail to complete the remaining work within the Contract Time or any proper extension thereof granted by Owner, Contractor shall pay Owner $250 for each day that expires after the time specified in Paragraph 4.02 for completion and readiness for Final Payment until the Work is completed and ready for Final Payment. ARTICLE 5 - CONTRACT PRICE 5.01 Owner shall pay Contractor for completion of the work in accordance with the Contract Documents an amount in current funds as follows: For all Work at the prices stated in Contractor's Bid, attached hereto as an exhibit for an Original Contract Amount of Four Hundred Eighty -Four Thousand One Hundred Twenty -Two Dollars and Sixty -One Cents ($484,122.61) for the Total Base Bid. 6.01 Submittal and Processing of Payments A. Contractor shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Applications for Payment will be processed by Engineer as provided in the General Conditions. 6.02 Progress Payments; Retainage A. Owner shall make progress payments on account of the Contract Price on the basis of Contractor's Applications for Payment, monthly during performance of the Work as provided in Paragraphs 6.02.A1 and 6.02.A2 below. All such payments will be measured by the Schedule of Values established in Paragraph 2.07.A of the General Conditions (and in the case of Bid Unit Price work based on the number of units completed) or, in the event there is no Schedule of Values, as provided in the General Requirements: 1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below, but in each case, less the aggregate of payments previously made and less such amounts as Engineer may determine or Owner may withhold, including but not limited to liquidated damages, in accordance with Paragraph 14.02 of the General Conditions: a. 95 percent of Work completed (with the balance being retainage). b. 95 percent of cost of materials and equipment not incorporated in the Work (with the balance being retainage). 000034 - 05175 -0 2007 Bonestroo 00520 -2 AGREEMENT FORM 2. Upon Substantial Completion, Owner shall pay an amount sufficient to increase total payments to Contractor to 100 percent of the Work completed, less such amounts as Engineer shall determine in accordance with Paragraph 14.02.135 of the General Conditions and less 100 percent of Engineer's estimate of the value of work to be completed or corrected as shown on the tentative list of items to be completed or corrected attached to the certificate of Substantial Completion. 6.03 Final Payment A. Upon Final Completion and acceptance of the Work, in accordance with Paragraph 14.07 of the General Conditions, Owner shall pay the remainder of the Contract Price as recommended by Engineer as provided in said Paragraph 14.07. ARTICLE 7 - INTEREST 7.01 All moneys not paid when due, as provided in Article 14 of the General Conditions, shall bear interest at the maximum rate allowed by law at the place of the Project. 1 1M 3 t&V 9 N W1 8.01 In order to induce Owner to enter into this Agreement, Contractor makes the following representations: A. Contractor has examined and carefully studied the Contract Documents and the other related data identified in the Bidding Documents. B. Contractor has visited the Site and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. C. Contractor is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the Work. D. Contractor has carefully studied all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) which have been identified in the Supplementary Conditions as provided in Paragraph 4.02 of the General Conditions and (2) reports and drawings of a Hazardous Environmental Condition, if any, at the Site which has been identified in the Supplementary Conditions as provided in Paragraph 4.06 of the General Conditions. E. Contractor has obtained and carefully studied (or assumes responsibility for having done so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at or contiguous to the Site which may affect cost, progress, or performance of the Work, or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, including applying the specific means, methods, techniques, sequences, and procedures of construction, if any, expressly required by the Contract Documents to be employed by Contractor and safety precautions and programs incident thereto. F. Contractor does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract Documents. 000034 - 05175 -0 Q 2007 Bonestroo 00520_3 AGREEMENT FORM G. Contractor is aware of the general nature of work to be performed by Owner and others at the Site that relates to the work as indicated in the Contract Documents. H. Contractor has correlated the information known to Contractor, information and observations obtained from visits to the Site, reports and drawings identified in the Contract Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Contract Documents. I. Contractor has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Contractor has discovered in the Contract Documents, and the written resolution thereof by Engineer is acceptable to Contractor. J. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. F."I IR 9 ty �I Dia�7� ► 1 ►� 9.01 Contents A. The Contract Documents consist of the following: 1. This Agreement. 2. Performance Bond, Payment Bond, and other Bonds. 3. General Conditions. 4. Supplementary Conditions. 5. Specifications. 6. Drawings bearing the following general title: 2007 Infrastructure Improvements. 7. Addendum (Number One, inclusive). 8. Exhibits to this Agreement (enumerated as follows): a. Contractor's Bid Form. b. Documentation submitted by Contractor prior to Notice of Award. 9. The following which may be delivered or issued on or after the Effective Date of the Agreement and are not attached hereto: a. Notice to Proceed. b. Work Change Directives. C. Change Order(s). 000034- 05175 -0 2007 Bonestroo 00520 -4 AGREEMENT FORM B. The documents listed in Paragraph 9.01.A are attached to this Agreement (except as expressly noted otherwise above). C. There are no Contract Documents other than those listed above in this Article 9. D. The Contract Documents may only be amended, modified, or supplemented as provided in Paragraph 3.04 of the General Conditions. ARTICLE 10 - MISCELLANEOUS 10.01 Terms A. Terms used in this Agreement will have the meanings stated in the General Conditions and the Supplementary Conditions. 10.02 Assignment of Contract A. No assignment by a party hereto of any rights under or interests in the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 10.03 Successors and Assigns A. Owner and Contractor each binds itself, its partners, successors, assigns, and legal representatives to the other party hereto, its partners, successors, assigns, and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. 10.04 Severability A. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. 000034 - 05175 -0 Q 2007 Bonestroo 00520.5 AGREEMENT FORM IN WITNESS WHEREOF, Owner and Contractor have signed this Agreement in duplicate. One counterpart each has been delivered to Owner and Contractor. All portions of the Contract Documents have been signed or identified by Owner and Contractor or on their behalf. This Agreement will be effective on li which is the Effective Date of the Agreement). Owner: Address for giving notices: 44 Contractor: License No. °`� (Where applicable) Designated Representative: Name: /Y ) i` C �j �( ,", , CL1 its i "� ls.'�({ Title: HOPE Address: XYLON AVE • Phone: / _ ./- / Facsimile: 163- 3/- 66 Designated Representative: Name: Title: Address: 6-- a ,:� 5. Phone: Facsimile: — &5 , END OF DOCUMENT 000034- 05175 -0 4V 2007 Bonestroo 00520.6 AGREEMENT FORM V . r. ; a 11 , Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): OWNER (Name and Address): CONTRACT Date: Amount: Description (Name and Location): BOND Bond Number: Date (Not earlier than Contract Date): Amount: Modifications to this Bond Form: SURETY (Name and Address of Principal Place of Business): Surety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Performance Bond to be duly executed on its behalf by its authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL Company: Signature: _ Name and Title: (Seal) (Space is provided below for signatures of additional parties, if required.) CONTRACTOR AS PRINCIPAL Company: Signature: _ Name and Title: (Seal) SURETY Surety's Name and Corporate Seal By: Signature and Title (Attach Power of Attorney) Attest: Signature and Title J' Surety's Name and Corporate Seal By: Signature and Title (Attach Power of Attorney) Attest: Signature and Title: (Seal) (Seal) EJCDC No. C -610 (2002 Edition) Originally prepared through the joint efforts of the Surety Association of America, Engineers Joint Contract Documents Committee, the Associated General Contractors of America, and the American Institute of Architects. 00610 -1 1. Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to Owner for the performance of the Contract, which is incorporated herein by reference. 2. If Contractor performs the Contract, Surety and Contractor have no obligation under this Bond, except to participate in conferences as provided in Paragraph 3.1. 3. If there is no Owner Default, Surety's obligation under this Bond shall arise after: 3.1. Owner has notified Contractor and Surety, at the addresses described in Paragraph 10 below, that Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with Contractor and Surety to be held not later than 15 days after receipt of such notice to discuss methods of performing the Contract. If Owner, Contractor and Surety agree, Contractor shall be allowed a reasonable time to perform the Contract, but such an agreement shall not waive Owners right, if any, subsequently to declare a Contractor Default; and 3.2. Owner has declared a Contractor Default and formally terminated Contractor's right to complete the Contract. Such Contractor Default shall not be declared earlier than 20 days after Contractor and Surety have received notice as provided in Paragraph 3.1; and 3.3. Owner has agreed to pay the Balance of the Contract Price to: 1. Surety in accordance with the terms of the Contract; 2. Another contractor selected pursuant to Paragraph 4.3 to perform the Contract. 4. When Owner has satisfied the conditions of Paragraph 3, Surety shall promptly and at Surety's expense take one of the following actions: 4.1. Arrange for Contractor, with consent of Owner, to perform and complete the Contract; or 4.2. Undertake to perform and complete the Contract itself, through its agents or through independent contractors; or 4.3. Obtain bids or negotiated proposals from qualified contractors acceptable to Owner for a contract for performance and completion of the Contract, arrange for a contract to be prepared for execution by Owner and Contractor selected with Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Contract, and pay to Owner the amount of damages as described in Paragraph 6 in excess of the Balance of the Contract Price incurred by Owner resulting from Contractor Default; or 4.4. Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: 1. After investigation, determine the amount for which it may be liable to Owner and, as soon as practicable after the amount is determined, tender payment therefor to Owner; or 2. Deny liability in whole or in part and notify Owner citing reasons therefor. 5. If Surety does not proceed as provided in Paragraph 4 with reasonable promptness, Surety shall be deemed to be in default on this Bond 15 days after receipt of an additional written notice from Owner to Surety demanding that Surety perform its obligations under this Bond, and Owner shall be entitled to enforce any remedy available to Owner. If Surety proceeds as provided in Paragraph 4.4, and Owner refuses the payment tendered or Surety has denied liability, in whole or in part, without further notice Owner shall be entitled to enforce any remedy available to Owner. 6. After Owner has terminated Contractors right to complete the Contract, and if Surety elects to act under Paragraph 4.1, 4.2, or 4.3 above, then the responsibilities of Surety to Owner shall not be greater than those of Contractor under the Contract, and the responsibilities of Owner to Surety shall not be greater than those of Owner under the Contract. To a limit of the amount of this Bond, but subject to commitment by Owner of the Balance of the Contract Price to mitigation of costs and damages on the Contract, Surety is obligated without duplication for: 6.1. The responsibilities of Contractor for correction of defective Work and completion of the Contract; 6.2. Additional legal, design professional, and delay costs resulting from Contractor's Default, and resulting from the actions or failure to act of Surety under Paragraph 4; and 6.3. Liquidated damages, or if no liquidated damages are specified in the Contract, actual damages caused by delayed performance or non- performance of Contractor. 7. Surety shall not be liable to Owner or others for obligations of Contractor that are unrelated to the Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than Owner or its heirs, executors, administrators, or successors. 8. Surety hereby waives notice of any change, including changes of time, to Contract or to related subcontracts, purchase orders, and other obligations. 9. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the Work or part of the Work is located and shall be instituted within two years after Contractor Default or within two years after Contractor ceased working or within two years after Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 10. Notice to Surety, Owner, or Contractor shall be mailed or delivered to the address shown on the signature page. 11. When this Bond has been furnished to comply with a statutory requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory requirement shall be deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12. Definitions. 12.1 Balance of the Contract Price: The total amount payable by Owner to Contractor under the Contract after all proper adjustments have been made, including allowance to Contractor of any amounts received or to be received by Owner in settlement of insurance or other Claims for damages to which Contractor is entitled, reduced by all valid and proper payments made to or on behalf of Contractor under the Contract. 12.2. Contract: The agreement between Owner and Contractor identified on the signature page, including all Contract Documents and changes thereto. 12.3. Contractor Default: Failure of Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Contract. 12.4. Owner Default: Failure of Owner, which has neither been remedied nor waived, to pay Contractor as required by the Contract or to perform and complete or comply with the other terms thereof. FOR INFORMATION ONLY — Name, Address and Telephone Surety Agency or Broker Owner's Representative (engineer or other party) 00610 -2 Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): OWNER (Name and Address): CONTRACT Date: Amount: Description (Name and Location): BOND Bond Number: Date (Not earlier than Contract Date): Amount: Modifications to this Bond Form: SURETY (Name and Address of Principal Place of Business): Surety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Payment Bond to be duly executed on its behalf by its authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL Company: Signature: _ Name and Title: SURETY Surety's Name and Corporate Seal By: Signature and Title (Attach Power of Attorney) (Space is provided below for signatures of additional parties, if required.) Attest: Signature and Title CONTRACTOR AS PRINCIPAL Company: Signature: _ Name and Title: C� Surety's Name and Corporate Seal By: Signature and Title (Attach Power of Attorney) Attest: Signature and Title: (Seal) (Seal) EJCDC No. C -615 (2002 Edition) Originally prepared through the joint efforts of the Surety Association of America, Engineers Joint Contract Documents Committee, the Associated General Contractors of America, the American Institute of Architects, the American Subcontractors Association, and the Associated Specialty Contractors. (Seal) (Seal) 00615 -1 1. Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to Owner to pay for labor, materials, and equipment furnished by Claimants for use in the performance of the Contract, which is incorporated herein by reference. 2. With respect to Owner, this obligation shall be null and void if Contractor: 2.1. Promptly makes payment, directly or indirectly, for all sums due Claimants, and 2.2. Defends, indemnifies, and holds harmless Owner from all claims, demands, liens, or suits alleging non - payment by Contractor by any person or entity who furnished labor, materials, or equipment for use in the performance of the Contract, provided Owner has promptly notified Contractor and Surety (at the addresses described in Paragraph 12) of any claims, demands, liens, or suits and tendered defense of such claims, demands, liens, or suits to Contractor and Surety, and provided there is no Owner Default. 3. With respect to Claimants, this obligation shall be null and void if Contractor promptly makes payment, directly or indirectly, for all sums due. 4. Surety shall have no obligation to Claimants under this Bond until: 4.1. Claimants who are employed by or have a direct contract with Contractor have given notice to Surety (at the addresses described in Paragraph 12) and sent a copy, or notice thereof, to Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2. Claimants who do not have a direct contract with Contractor: 1. Have furnished written notice to Contractor and sent a copy, or notice thereof, to Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials or equipment were furnished or supplied, or for whom the labor was done or performed; and 2. Have either received a rejection in whole or in part from Contractor, or not received within 30 days of furnishing the above notice any communication from Contractor by which Contractor had indicated the claim will be paid directly or indirectly; and 3. Not having been paid within the above 30 days, have sent a written notice to Surety and sent a copy, or notice thereof, to Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to Contractor. 5. If a notice by a Claimant required by Paragraph 4 is provided by Owner to Contractor or to Surety, that is sufficient compliance. 6. When a Claimant has satisfied the conditions of Paragraph 4, the Surety shall promptly and at Surety's expense take the following actions: 6.1. Send an answer to that Claimant, with a copy to Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed. 6.2. Pay or arrange for payment of any undisputed amounts. 7. Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by Surety. 8. Amounts owed by Owner to Contractor under the Contract shall be used for the performance of the Contract and to satisfy claims, if any, under any performance bond. By Contractor furnishing and Owner accepting this Bond, they agree that all funds earned by Contractor in the performance of the Contract are dedicated to satisfy obligations of Contractor and Surety under this Bond, subject to Owner's priority to use the funds for the completion of the Work. 9. Surety shall not be liable to Owner, Claimants, or others for obligations of Contractor that are unrelated to the Contract. Owner shall not be liable for payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligations to make payments to, give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 10. Surety hereby waives notice of any change, including changes of time, to the Contract or to related Subcontracts, purchase orders and other obligations. 11. No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the location in which the Work or part of the Work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by Paragraph 4.1 or Paragraph 4.2.3, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12. Notice to Surety, Owner, or Contractor shall be mailed or delivered to the addresses shown on the signature page. Actual receipt of notice by Surety, Owner, or Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13. When this Bond has been furnished to comply with a statutory requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory requirement shall be deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory Bond and not as a common law bond. 14. Upon request of any person or entity appearing to be a potential beneficiary of this Bond, Contractor shall promptly furnish a copy of this Bond or shall permit a copy to be made. 15. DEFINITIONS 15.1. Claimant: An individual or entity having a direct contract with Contractor, or with a first -tier subcontractor of Contractor, to furnish labor, materials, or equipment for use in the performance of the Contract. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service, or rental equipment used in the Contract, architectural and engineering services required for performance of the Work of Contractor and Contractor's Subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials, or equipment were furnished. 15.2. Contract: The agreement between Owner and Contractor identified on the signature page, including all Contract Documents and changes thereto. 15.3. Owner Default: Failure of Owner, which has neither been remedied nor waived, to pay Contractor as required by the Contract or to perform and complete or comply with the other terms thereof. FOR INFORMATION ONLY — Name, Address and Telephone Surety Agency or Broker: Owner's Representative (engineer or other party): 00615 -2 SECTION 01100 PART 1 GENERAL 1.01 SECTION INCLUDES A. Basic description of the Project and Work restrictions. 1.02 SUMMARY OF WORK A. Project Name: 2007 Infrastructure Improvements for the City of New Hope, Minnesota, City Project No. 816. B. Description of Work: Street and utility reconstruction and park improvements. 1.03 COMPLETION DATES A. Substantial Completion: Set forth in the Agreement. B. Final Completion: Set forth in the Agreement. 1.04 LIQUIDATED DAMAGES A. Provisions for liquidated damages, if any, are set forth in the Agreement. 1.05 WORK RESTRICTIONS A. Use of Site: 1. Location of construction facilities, staging areas, product stockpiles, material storage, and temporary construction are shown on the Drawings and shall be removed upon completion of Work. 2. Contractor responsible for snow removal and disposal from the Owner's property if necessary to maintain access and working space during construction. 3. Keep existing driveways and entrances clear and available to the public and to the Owner. 4. If additional space is needed, obtain and pay for such space off Site. 000034 - 05175 -0 © 2007 Bonestroo 01100-1 SUMMARY B. Access to Site: 1. Access to the project area shall be limited to 42nd Avenue. 2. No construction traffic will be allowed to use the following street sections: a. Nevada Avenue, north of 45th Avenue. b. 45th Avenue, east of Nevada Avenue. C. 43rd Avenue, east of the Project limits. C. Construction parking will not be allowed in the apartment complex parking lot located off 43rd Avenue, east of Nevada Avenue. PART 2 PRODUCTS Not Used. PART 3 EXECUTION 3.01 MEASUREMENT AND PAYMENT A. All Work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 000034 - 05175 -0 0 2007 Bonestroo 01100 -2 SUMMARY SECTION 01200 PRICE AND PAYMENT PROCEDURES PART 1 GENERAL 1.01 SECTION INCLUDES A. Administrative and procedural requirements for pricing of Work and request for payment procedures. 1.02 BID UNIT PRICES A. Provide access and assist Engineer in determining actual quantities of Bid Unit Price Work. B. Provide documentation to substantiate Bid Unit Price Work. C. If the Contractor delivers and places more of any material that is paid for on a Bid Unit Price basis than is required to perform the Work and thereby causes the materials to be wasted, the quantity wasted will be deducted from the final measurement for that Bid Item. 1.03 PAYMENT PROCEDURES A. Submit one preliminary copy of progress payment application for review, consistent with Article 14 of the General Conditions. Submit 4 signed copies of Application for Payment to Engineer prior to the dates identified at the Preconstruction Conference. B. Attach the following supporting documentation, in addition to the requirements of General Conditions Article 14: 1. Documentation to substantiate Bid Unit Price Work. 2. Updated construction schedule consistent with Section 01330. Not Used. 000034 - 05175 -0 © 2007 Bonestroo 01200 -1 PRICE AND PAYMENT PROCEDURES PART 3 EXECUTION 3.01 MEASUREMENT AND PAYMENT A. All Work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 000034 - 05175 -0 © 2007 Bonestroo 01200 -2 PRICE AND PAYMENT PROCEDURES SECTION 01310 PROJECT MANAGEMENT AND COORDINATION f7_y711i�e • -� 1.01 SECTION INCLUDES A. General requirements for overall Project coordination. 1.02 UTILITIES A. Notify Gopher State One Call before starting construction in a given area requesting utility locates in the Site. B. Project Utility Sources: Coordinate Work with the following utility owners. The following utilities are known to be on the Site and are shown on the Drawings in a general way: 1. Water: Owner. 2. Sanitary Sewer: Owner. 3. Storm Sewer: Owner. 4. Electric: Xcel Energy, Greg Plumedahl; 763 - 493 -1670, fax: 763 - 493 -1501. 5. Gas: CenterPoint Energy, Alla Denisova; 612 -321 -5077, fax: 612 -321 -5480. 6. Telephone: Qwest, Steve Hotvedt; 612- 381 -5031, fax: 612 -381 -5571. 7. Cable TV: Comeast, Doug Zahn; 651- 493 -5316, fax: 651 -493 -5116. 8. Fiber Optics: Sprint C. Owner requires 48 hour notice for all utility interruptions. D. Private utility information obtained from utility owners /operators is shown on the Drawings in a general way. The location of utilities is not guaranteed. The locating of utilities and coordination during construction is the responsibility of the Contractor. Final locations of all utilities, per the Gopher One System, will be the responsibility of the Contractor. All costs associated with private utility coordination shall be incidental to the total Work of the Project. 000034 - 05175 -0 PROJECT MANAGEMENT AND 0 2007 Bonestroo 01310 -1 COORDINATION Information provided is of Quality Level D (QLD) as defined by ASCE Standards. Utility locations shown on the Drawings are based on this QLD information and have not been verified with a field survey. 1.03 PERMITS A. Comply with the stipulations of the following permits, which have been applied for and will be furnished by the Owner: 1. MPCA Stormwater Discharges Associated With Construction Activities NPDES General Permit. B. Apply for, obtain, and comply with the provisions of the following permits, which the Owner will waive the permit application fee: 1. City Building Permit. C. Apply for, obtain, and comply with other permits, licenses, and approvals which may be required for the Project. 1.04 SURVEYING AND CONSTRUCTION OBSERVATION A. Provide Engineer a minimum of 48 hours notice in advance of the need for establishing lines, grades, measurements, grade checks, and observation of Work. B. Engineer will furnish a Resident Project Representative consistent with Paragraph 9.03 of the Supplementary Conditions. 1.05 PROJECT MEETINGS A. Administrative Requirements: 1. Project Superintendent or persons designated by the Contractor to attend and participate in the Project meetings shall have all required authority to commit the Contractor to solutions agreed upon in the Project meetings. 2. Engineer will set the time, sites, and prepare the agenda for the meetings. 3. The attendance and cooperation of subcontractors and suppliers may be required. B. Preconstruction Conference: 1. Provisions for the Preconstruction Conference are set forth in the General Conditions. 000034 - 05175 -0 PROJECT MANAGEMENT AND 0 2007 Bonestroo 01310 -2 COORDINATION 2. Requirements for preconstruction submittals are set forth in the General Conditions. Submittal procedures shall be consistent with Section 01330. C. Progress Meeting Procedures: 1. Engineer may schedule construction progress meetings throughout the duration of the Project to assess the progress of the Work, identify and discuss Project related issues, and discuss near -term construction activities. 1.06 CONSTRUCTION SCHEDULING A. Sequencing and Scheduling: 1. The Owner is very sensitive to the inconvenience each property owner will experience to construct this Project. The most frequent complaint received during this type of Project is the length of time for which streets, driveways, and boulevards are disturbed. Therefore, scheduling of the Work, maintenance of local traffic, and timely repair of each driveway and yard are critical to the success of the Project. 2. Resident notification of Work directly affecting their property is required for all situations. The Project Inspector may assist with notifying residents. However, it is the responsibility of the Contractor to ensure residents are aware of issues, such as access restrictions or disrupted water supply. 3. Given the underlying soil type conditions resulting from precipitation can be devastating to residents. Construction should be coordinated such that disturbed areas are minimized at any given time. Work completed in the street reconstruction area may be facilitated if phasing is scheduled for the included streets. 4. Streets that are completely reconstructed shall be reclaimed. The aggregate material generated by the reclamation process can be used to ramp driveways and better maintain access for the residents within the Project area. 1.07 SUBMITTALS A. Submit a minimum of 4 copies of shop drawings, plus the quantity of copies the Contractor wants returned. Not Used. 000034- 05175 -0 PROJECT MANAGEMENT AND © 2007 Bonestroo 01310 -3 COORDINATION PART 3 EXECUTION 3.01 MEASUREMENT AND PAYMENT A. All Work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 000034 - 05175 -0 PROJECT MANAGEMENT AND 0 2007 sonestroo 01310 -4 COORDINATION SECTION 01330 SUBMITTAL PROCEDURES PART 1 GENERAL 1.01 SECTION INCLUDES A. General procedures and requirements for submittals during the course of construction. 1.02 SEQUENCING AND SCHEDULING A. Schedule submittals consistent with the Contractor's schedule of shop drawings. PART 2 PRODUCTS Not Used. PART 3 EXECUTION 3.01 CONSTRUCTION SCHEDULE A. Submit preliminary schedule and progress schedule consistent with the General Conditions. B. Prepare schedules on 11 inch by 17 inch sheets showing overall sequence of construction. Organize the schedule by work activity. Identify separate stages of each work activity: 1. List work items in chronological sequence. Show beginning and completion dates of each activity. Include all activities with an estimated duration of 3 days or longer. 2. Format schedule as a horizontal bar chart. Provide separate bars for each activity or trade. 3. Provide space for revisions and notations. 4. Identify interrelations between activities. 5. Include estimated times for preparation of submittals by Contractor, processing and review of submittals by Engineer, fabrication, delivery, installation, testing, start-up, instruction of Owner, and clean-up. 000034 - 05175 -0 0 2007 Bonestroo 01330 -1 SUBMITTAL PROCEDURES C. As Work progresses, revise, update, and resubmit schedule as requested by Engineer. At a minimum, update schedule with each Application for Payment. Show all activities started or finished since previous schedule was submitted and show percentage of completion for each activity. 3.02 EMERGENCY CONTACT LIST A. Before any Work at the Site is started, submit a typed list on 8 -1/2 inch by 11 inch paper outlining 24 hour on -call contacts for the Project. This list shall include the Contractor's safety representative, key representatives from the Contractor, subcontractors, and suppliers. Include the following information for each contact: 1. Company name. 2. Contact person(s). 3. Local and mobile phone numbers. 4. Fax number. 3.03 SHOP DRAWINGS AND MANUFACTURERS' INFORMATION A. Conform to the requirements of Paragraph 6.17 of the General Conditions, except as modified herein. B. The minimum sheet size shall be 8 -1/2 inch by 11 inch. Non - legible copies will not be reviewed. C. Submit a minimum of three copies of shop drawings, plus the quantity of copies the Contractor wants returned. Each copy shall contain the following information: 1. Date of submission and date of any previous submittals. 2. Project Title. 3. Names Of: Contractor, subcontractor, supplier, and manufacturer. 4. Identification of product and Specification Section number. 5. Identification of revisions from previous submittals. 6. A 4 inch by 4 inch blank space for the Engineer's stamp. D. Engineer's review will be in conformance with the requirements of Paragraph 6.17 of the General Conditions, except as modified herein. 000034 - 05175 -0 © 2007 Bonestroo 01330 -2 SUBMr17AL PROCEDURES E. Engineer will stamp shop drawings and indicate requirements for Contractor's review or resubmittal as follows: 1. "Approved" — Appears that items covered by the submittal will, after installation or incorporation into the Work, conform to the Contract Documents and appears to be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 2. "Approved as Noted" — Appears that items covered by the submittal will, after installation or incorporation into the Work, conform to the Contract Documents and appears to be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents, except as noted by Engineer. 3. "Revise and Resubmit" — Appears that items covered by the submittal will not, after installation or incorporation into the Work, conform to the Contract Documents and will not be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Work cannot proceed until the submittal is revised and resubmitted conforming to the resubmittal procedures described in Paragraph 6.17.E of the General Conditions. 4. "Rejected" — Work covered by the submittal is not complete or it appears that items covered by the submittal will not, after installation or incorporation into the Work, conform to the Contract Documents and will not be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Contractor shall conform to the resubmittal procedures described in Paragraph 6.17.E of the General Conditions. F. Engineer will return reviewed submittals to Contractor by U.S. Postal Service general delivery. If Contractor wants Engineer to expedite return delivery, Contractor shall notify Engineer in writing and reimburse Owner for delivery plus 15 percent mark- up. 3.04 TEST REPORTS A. Submit three copies of all inspections, tests, and approvals required in the Specification. 000034 - 05175 -0 © 2007 Bonestroo 01330 -3 SUBMITTAL PROCEDURES 3.05 WELDING CERTIFICATES A. Submit welding certificates for each person by name assigned to do field welding of materials installed under this Contract. Certificates shall indicate that each person has passed tests specified by AWS and shall be submitted prior to execution of any welding. 3.06 MATERIAL AND SAFETY DATA SHEETS A. Furnish Owner with current copies of Material Safety Data Sheets for all chemicals and products on Site. 3.07 MEASUREMENT AND PAYMENT I:1 All Work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 000034 - 05175 -0 © 2007 Bonestroo 01330 -4 SUBMITTAL PROCEDURES SECTION 01400 QUALITY REQUIREMENTS PART 1 GENERAL 1.01 SECTION INCLUDES A. Information required for conformance to regulatory requirements. B. Quality assurance. C. Procedures to measure and report the quality and performance of the Work. 1.02 REFERENCE STANDARDS A. Whenever reference is made to the Minnesota Department of Transportation Specifications, such reference shall mean "Standard Specifications for Construction," 2005 Edition (MnDOT Spec.) and all subsequent revisions and supplements. The word "Engineer" is understood to refer to the Engineer for the Owner. 1.03 SUBMITTALS A. Prior to start of Work, submit testing laboratory name for various specified tests for approval by Engineer. B. Laboratory test results or analysis. C. Manufacturer's certificates of quality control or performance. 1.04 WORKMANSHIP A. Comply with industry standards of the region, except where more restrictive tolerances or specified requirements indicate more rigid standards or more precise workmanship. 1.05 TESTS AND INSPECTIONS A. Conform to the requirements of Article 13 of the General Conditions, except as modified herein. B. Notify Engineer 48 hours prior to expected time for operations requiring tests and inspections. 000034 - 05175 -0 © 2007 Bonestroo 01400 -1 QUALITY REQUIREMENTS C. Provide incidental labor and facilities to obtain and handle samples at Site or source, transport samples to laboratory, facilitate tests and inspections for storing and curing of test samples. lff l r §�W _ 1 1 1 :•• us WA '•' A. After each inspection and test, submit 3 copies of Laboratory Report to Engineer. B. Include: Date issued, Project Title and number, name of inspector, date and time of sampling or inspection, identification of product and Specifications Section, location in the Project, type of inspection or test, date of test, results of tests, and conformance with Contract Documents. 1.07 LABORATORY RESPONSIBILITIES A. Test samples and perform field tests. B. Provide qualified personnel. Cooperate with Engineer and Contractor in performance of services. C. Ascertain compliance with the requirements of the Contract Documents. D. When requested by Engineer, provide interpretation of test results. A. Laboratory may not release, revoke, alter, or enlarge on requirements of Contract Documents. B. Laboratory may not approve or accept any portion of the Work. C. Laboratory may not assume any duties of Contractor. D. Laboratory has no authority to stop Work. 1.09 MANUFACTURER'S CERTIFICATES A. If requested by Engineer, submit manufacturer's certificate with shop drawings certifying that products meet or exceed specified requirements executed by responsible officer. 1.10 MANUFACTURER'S FIELD SERVICES A. Provide qualified representative to observe field conditions; conditions of surfaces and installation; quality of workmanship; start-up of equipment; and test, adjust, and balance of equipment. 000034 - 05175 -0 0 2007 Bonestroo 01400 -2 QUALITY REQUIREMENTS PART 2 PRODUCTS Not Used. PART 3 EXECUTION 3.01 MEASUREMENT AND PAYMENT A. All Work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 000034- 05175 -0 0 2007 Bonestroo 01400 -3 QUALITY REQUIREMENTS C. Temporary Water Services: 1. Maintain temporary potable water service to the structures that will have disrupted water service during the water main construction or as identified on the Drawings. 3.04 CONSTRUCTION FACILITIES A. Sanitary Facilities: 1. Comply with all governing regulations, including safety and health codes, for sanitary fixtures and facilities. 2. Provide self - contained toilet units, or water and sewer connected temporary toilet facilities consistent with governing regulations. Contractor may not use Owner's toilet facilities. 3. Provide and maintain adequate supply of toilet tissue, paper towels, paper cups, and similar disposable materials appropriate for each facility. Provide appropriate covered waste containers for used material. 3.05 TEMPORARY CONSTRUCTION A. Pumping and Dewatering: 1. Provide draining, pumping, dewatering, and cleaning operations necessary to complete the Work. 2. Provide all necessary pumping to remove all surface water and groundwater from structures as required for the Work. Provide erosion control measures for discharge of water. 3. Protect Site and adjacent property to avoid damage. 3.06 TRAFFIC CONTROL A. Provide and maintain all traffic control devices needed to guide, warn, control, and protect traffic throughout the Site. All traffic control devices and other protective measures shall conform to MMUTCD. B. Remove traffic control devices at the conclusion of the Work. 000034 - 05175 -0 TEMPORARY FACILITIES © 2007 Bonestroo 01500 -3 AND CONTROLS C. Flaggers are required to protect construction vehicles during unloading or construction materials. Conform to the requirements of the MMUTCD, the Flagging Handbook included in the Field Manual for Temporary Traffic Control Zone Layouts, and the following: while on duty flaggers shall wear hard hats and reflectorized florescent orange vests; and flaggers shall be fully clothed when on duty with shirt or blouse, slacks or trouser, and sturdy shoes. D. Field Quality Control: 1. Daily inspect and insure that all traffic control devices required by the construction are in accordance with the MMUTCD. Any discrepancy between the actual devices in use and the required devices shall be immediately rectified. 2. Furnish names, addresses, and phone numbers of at least 3 individuals responsible for the placement and maintenance of traffic control devices. At least 1 of these individuals shall be "on call' 24 hours per day, 7 days per week during the time any traffic control devices furnished and installed by the Contractor are in place. 3. Provide access for emergency vehicles and busses to all residences at all times. 4. Respond to any request from the Engineer to improve or correct the usage of traffic control devices on or related to this Project within 1 hour of the time of notification. 5. Keep all traffic control signs and devices in a legible condition. This shall include but not be limited to removing grime and dust deposited on any device by traffic, natural causes, or when requested by Engineer. A. Temporary Barriers: 1. Provide temporary covers, enclosures, markers, and barriers as necessary to protect Work. 2. Damage to the Site caused by removal of temporary fencing, including postholes, shall be promptly repaired by Contractor. During removal at no time shall the Work remain unattended if a dangerous condition exists because of incomplete removal or Site repairing. 000034- 05175 -0 TEMPORARY FACILITIES © 2007 Bonestroo 01500 -4 AND CONTROLS 3.08 MEASUREMENT AND PAYMENT A. A Bid Item has been provided for Mobilization. Measurement is Lump Sum. This will be considered payment in full for all work and costs of this Bid Item. The amount of the Lump Sum Bid shall not exceed 5 percent of the Total Base Bid: 1. Partial payment of the Lump Sum Bid Item "Mobilization" will be made using a percentage based on the following: Cumulative Percent of Mobilization Item Paid First Partial Payment 50 Percent of original contract amount earned — 25 70 Percent of original contract amount earned — 50 90 Percent of original contract amount earned —100 100 B. A Bid Item has been provided for Traffic Control. Measurement is Lump Sum. This will be considered payment in full for all work and costs of this Bid Item: 1. Partial payment of the Lump Sum Bid Item "Traffic Control" will be made using a percentage based on the following: Cumulative Percent of Traffic Control Item Paid First Partial Payment 50 Percent of original contract amount earned — 25 70 Percent of original contract amount earned — 50 90 Percent of original contract amount earned — 100 100 C. A Bid Item has been provided for Temporary Mailboxes. Measurement is Lump Sum. Payment for the Temporary Mailboxes Bit Item will be made as follows: 1. 50 percent of the Unit Bid Price will be paid upon completion of the removal of the existing mailboxes and installation of the temporary mailboxes. 2. 50 percent of the Unit Bid Price will be paid upon completion of the reinstallation of the existing mailboxes and removal of the temporary mailboxes. This will be considered payment in full for all Work and costs of this Bid Item. Full payment for this Bid Item will not be made until all mailboxes are installed properly and accepted by the Post Office and the homeowner. 000034 - 05175 -0 TEMPORARY FACIL M ES 0 2007 Bonestroo 01500 -5 AND CONTROLS D. All other Work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 000034 - 05175 -0 TEMPORARY FACIUDES © 2007 Bonestroo 01500 -6 AND CONTROLS SECTION 01570 TEMPORARY EROSION AND SEDIMENT CONTROL PART 1 GENERAL 1.01 SECTION INCLUDES A. Managing stormwater runoff and other Project related water discharges to minimize sediment pollution during construction. 1.02 RELATED SECTIONS A. Section 02315 — Excavation and Fill. B. Section 02920 — Lawns and Grasses. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2005 Edition (MnDOT Spec.). B. MPCA's NPDES General Stormwater Permit for Construction Activity. 1.04 SUBMITTALS A. Completed application form for the MPCA's NPDES General Stormwater Permit for Construction Activity (MN R100001) conforming to Section 01310: 1. NPDES permit inspection log resulting from weekly Site inspections. 2. Amendments to the Stormwater Pollution Prevention Plan (SWPPP) for the Project. 3. Completed form for MPCA's Notice of Termination. B. Contractor Prepared Schedules and Plans: 1. Erosion Control Schedule: Conforming to MnDOT Spec. 1717.213 and submitted each week that construction is active. 2. Site plans in conformance with MnDOT Spec. 1717.2E: a. Submitted when requested by the Engineer. 000034 - 05175 -0 TEMPORARY 0 2007 Bonestroo 01570 -1 EROSION AND SEDIMENT CONTROL b. Site plans prepared by Contractor will indicate Contractor operations, erosion and sediment control measures, and a schedule of starting and completion times. C. Certification and Sampling: 1. Furnish a manufacturer's certification stating that the material supplied conforms to the requirements of this Section. The certification shall include or have attached typical results of tests for the specified properties, representative of the materials supplied. 1.05 QUALITY ASSURANCE A. Erosion Control Supervisor: Provide an Erosion Control Supervisor to direct the erosion control operations and insure compliance with Federal, State, and Local ordinances and regulations. B. Certified Installers: Provide a certified installer to install or direct installation of erosion or sediment control practices. Certification shall be obtained through the University of Minnesota Erosion Control Inspector/Installer Certification program, or approved equal. 1.06 PERMITS A. Project disturbs 1 or more acres of total land area. Co- submittal with the Owner of a completed NPDES application form for the MPCA's General Stormwater Permit for Construction Activity and the appropriate fees to the MPCA is required. Submit a copy of the completed, signed, and dated application form to Owner. Permit coverage will become effective 7 days after the postmarked date of the completed application form. 1.07 SEQUENCING AND SCHEDULING A. Install sediment control measures prior to grading activities. B. Schedule and coordinate the Work so that permanent erosion and sediment control BMPs, such as basin construction, rip rap placement, and permanent seeding, are directly incorporated into the Work. Supplement permanent erosion and sediment control BMPs with temporary BMPs. Place temporary BMPs when permanent erosion control cannot be achieved. Coordinate construction operations so that erosion and sediment control measures (permanent or temporary) are installed and maintained concurrently with the rest of the Work of the Project. 000034 - 05175 -0 TEMPORARY © 2007 Bonestroo 01570 -2 EROSION AND SEDIMENT CONTROL C. Coordinate and schedule the Work of subcontractors such that erosion and sediment control measures are fully executed for each operation and in a timely manner over the duration of the Project. Develop a chain of responsibility for all subcontractors and operators on the Project to ensure that permit provisions are adhered to. D. Infiltration areas and constructed infiltration systems should not be constructed until the contributing drainage area and/or adjacent construction has been completely stabilized. When this timing of construction is not possible, the Contractor shall insure sediment from exposed soil areas of the Project does not enter into the infiltration area or system. E. Stabilization timeframes shall conform to the NPDES General Stormwater Permit for Construction Activity F. Prior to Project shutdown for the winter or other periods of a week or more, the Site shall be adequately protected from erosion and off Site damage by covering exposed soils with mulch and establishing perimeter controls. G. If the Contractor fails to install erosion or sediment measures, the Engineer may withhold payment from related work until the control measures are undertaken by the Contractor: 1. When the Contractor fails to conduct the quality control program, does not conduct the inspection required in the NPDES permit, or fails to take action ordered by the Engineer to remedy erosion or sediment control problems, the Engineer shall issue a Written Order to the Contractor. 2. The Contractor shall respond within 24 hours with sufficient personnel, equipment, materials, and conduct the required Work or be subject to a $2,000 per calendar day deduction for noncompliance. H. Establish permanent turf in accordance with Section 02920 to prevent excessive soil erosion. 17- \ Z4 Iva I 2.01 SILT FENCE: Conform to MnDOT Spec. 3886 A. Machine Sliced: 1. Posts: Steel T -post with welded plate, 1.261bs per lineal foot and 5 feet long. Post spacing shall not exceed 8 feet 24 inch embedment. 000034 - 05175 -0 TEMPORARY © 2007 Bonestroo 01570 -3 EROSION AND SEDIMENT CONTROL 2. Geotextile: Woven, either monofilament or tape, 36 inch minimum width, UV stabilized, with apparent opening size 20 -70 sieve, and 100 lbs minimum grab tensile strength. 2.02 EROSION CONTROL BLANKET A. Conform to MnDOT Spec. 3885. 2,03 STORM DRAIN INLET PROTECTION A. Inlet protection for paved streets with concrete curb and gutter: The following methods are acceptable: 1. Conform to the details on the Drawings. 2. Catch Basin Inserts: a. Road Drain by Wimco, LLC (www.roaddrain.com). b. Lange Industries (www.langeindustries.com), or approved equal. C. Filter bag insert conforming to MnDOT Spec. 3890.3 subject to Site and approved by the Engineer. B. Inlet protection for non -paved surfaces without curb or areas where vegetation will be established: The following methods are acceptable: 1. Conform to the details on the Drawings. 2. Silt fence ring, or approved equal: a. Place wire mesh cage in a circular or square confirmation to form a minimum 5 foot diameter zone of protection. b. Geotextile shall be monofilament/monofilament meeting the requirements of MnDOT Spec. Heavy Duty. C. Loose aggregate or a Rock Log(s) around perimeter of ring to anchor geotextile. 3. Sediment control inlet hat conforming to MnDOT Spec. 3891.30 a. InfraSafe Sediment Control Barrier by Royal Enterprises ( http : / /www.royalenterprises.net/). 4. Pop -up head conforming to MnDOT Spec. 3891.3E. 000034 - 05175 -0 TEMPORARY © 2007 Bonestroo 01570 -4 EROSION AND SEDIMENT CONTROL 2.04 DUST CONTROL A. Water clear and free from suspended fine sediment. B. The Owner may elect to have the Contractor apply a chloride solution for dust control: 1. Calcium Chloride: Conform to MnDOT Spec. 3911. 2. Magnesium Chloride Solution: Conform to MnDOT Spec. 3912. PART 3 EXECUTION A. Comply with all applicable laws, ordinances, regulations, permit requirements, orders and decrees pertaining to erosion/sediment control and stormwater discharge during the conduct of the Work. B. Take necessary precautions against damage to the Project by action of the elements. C. Implement the Project's NPDES Stormwater Pollution Prevention Plan (SWPPP) and take necessary actions to prevent off -site damage resulting from Work conducted on the Project or Project related stormwater runoff. D. Minimize the amount of disturbed land that is susceptible to erosion at any time. Delineate areas not to be disturbed: 1. Exclude vehicles and construction equipment from area not to be disturbed to preserve natural vegetation. 2. Maintain and preserve riparian and naturally vegetated buffer strips (10 feet minimum distance) along water courses. 3.02 INSTALLATION A. General: Install temporary stormwater management and sediment control devices in conformance with the details, typical sections, and elevations shown on the Drawings. B. The location of temporary stormwater and sediment control devices may be adjusted from that shown on the Drawings to accommodate actual field conditions and increase the effectiveness of the installation. 000034 - 05175 -0 TEMPORARY 0 2007 Bonestroo 01570 -5 EROSION AND SEDIMENT CONTROL C. Silt Fence: Conform to MnDOT Spec. 2573.3C: 1. Install in the locations shown on the Drawings using the machine sliced installation method, unless directed otherwise by the Engineer. 2. Use additional measures, such as rock aggregate, placed along the base of the silt fence where the silt fence geotextile cannot be trenched in, i.e. tree roots, frost, bedrock. 3. Use short sections of silt fence placed in J -hook patterns to: a. Supplement the perimeter silt fence at corner locations and areas where sediment deposition will occur. No more than 100 feet of silt fence shall be installed per 1/4 acre of drainage. b. Break up flow path along silt fence running across contours to be no more than 100 feet between hooks or as directed by the Engineer. 4. Silt fence longer than 600 feet shall be constructed in separate independent units with each unit having a length less than 600 feet. Avoid splices whenever possible:. If necessary, make splices at an opposing fence post and according to the manufacturer's specifications. D. Erosion Control Blanket: 1. Install immediately following seeding in accordance with MnDOT Spec. 2575.3.) and as modified below. 2. Install as shown on Drawings. 3. Raking or harrowing of soil/seed shall be done before installation of erosion control blanket. 4. Install blanket parallel to the direction of flow. 5. If permanent seeding is not available at the time of blanket installation, this material will have to be removed, re- seeded and installed again as a permanent erosion control measure. If permanent seeding is available at the time of initial installation, a one -time proper installation is acceptable. E. Storm Drain Inlet Protection: 1. Provide effective storm drain inlet protection over the life of the Project until all sources with potential for discharging to inlets have been paved or stabilized. 000034 - 05175 -0 TEMPORARY 0 2007 Bonestroo 01570 -6 EROSION AND SEDIMENT CONTROL 2. Place devices so that driving hazards or obstructions are not created. The devices must be cleaned out regularly and all devices must have an emergency overflow to reduce flooding potential. 3.03 MAINTENANCE A. Conform to MnDOT Spec. 2573.3M, NPDES permit, and as follows: 1. Inspect, maintain, and repair any washouts or accumulations of sediment that occur as a result of the grading or construction. Restoration consists of grade repair, turf re- establishment, and street sweeping of mud and debris tracked from the Site. 2. Inspection of all erosion and sediment control items will take place immediately after each runoff event and at least daily during prolonged rainfall. Any required repairs shall be made immediately. 3. The Contractor shall maintain the temporary sediment control devices until they are no longer necessary and are removed: a. Maintenance consists of keeping the devices functioning properly. b. The Contractor shall repair or replace plugged, torn, displaced, damaged, or non - functioning devices. 4. Upon final acceptance of the Project and establishment of permanent erosion control measures, the Contractor shall remove all temporary erosion control measures. B. Sediment Removal: Conform to MnDOT Spec. 2573.3N: 1. If an erosion control device has been reduced in capacity by 30 percent or more, the Contractor shall restore such features to their original condition. C. Control dust blowing and movement on Site and roads as directed by Engineer to prevent exposure of soil surfaces, to reduce on and offsite damage, to prevent health hazards, and to improve traffic safety. 3.04 MEASUREMENT AND PAYMENT A. Bid Items have been provided for temporary measures to control soil erosion and sedimentation. Payment at the Bid Unit Price will be considered compensation in full for all Work necessary to complete the Bid Item in full, including installation, maintenance, sediment removal, repairs, and removals. 000034 - 05175 -0 TEMPORARY 0 2007 Bonestroo 01570 -7 EROSION AND SEDIMENT CONTROL B. Measurement will be based upon the units as listed below for Bid Items removed, abandoned, or salvaged complete as specified. No measurement will be made of any removals that are not required. The actual quantity installed multiplied by the appropriate Bid Unit Price will be compensation in full for all Work and costs of the following Bid Items. 80 percent partial payment will be made upon installation and 20 percent payment will be made upon removal and restoration: 1. Silt Fence, Machine Sliced: Measurement will be along the base of the fence, from outside to outside of the end posts for each section of fence. 2. Inlet Protection Exposed Subgrade: Measurement will be by each. Payment will be made only once per structure. Temporary removal and reinstallation(s) of device to allow stages of Work will be considered incidental. 3. Inlet Protection Post Bituminous Base: Measurement will be by each. C. A Bid Item has been provided for Water for Dust Control. Measurement will be per 1000 gallons (MG) applied to the street. Payment will constitute compensation in full for all Work and cost to furnish and install the Water. This Bid Unit Bid Item is intended to pay for water used for dust control only and only at those times that it is requested by either the Engineer or Owner: 1. Water used for the construction of the streets will be considered incidental to the Project. D. All other Work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 000034 - 05175 -0 TEMPORARY © 2007 Bonestroo 01570 -8 EROSION AND SEDIMENT CONTROL SECTION 01700 EXECUTION REQUIREMENTS 1.01 SECTION INCLUDES A. Requirements for overall execution of the Work and closeout of the Contract for Final Payment. 1.02 SUBMITTALS A. Submit the following items consistent with the Conditions of the Contract and Division l: 1. Record Documents, Written Notification of Substantial Completion, Written Notification of Final Completion, Spare Parts, Operation and Maintenance Manuals, instructions, schedules, warranties, guarantees, Bonds, certificates, certificates of inspection, and other documents. 2. Final Application for Payment, including accompanying documentation IC -134 Form. PART 2 PRODUCTS Not Used. _ 1W X 3.01 EXAMINATION A. Acceptance of Conditions: By commencing Work, Contractor construes acceptance of the adjacent work as satisfactory to receive subsequent Work. B. Existing Conditions: Before commencing Work, inspect work completed by others that is adjacent to Work. If adjacent conditions prevent completion of Work, Contractor will not commence Work until the conditions are corrected. C. Inspect each product immediately prior to installation. Remove damaged products from Site. 000034 - 05175 -0 © 2007 Bonestroo 01700 -1 EXECUTION REQUIREMENTS 3.02 SITE MAINTENANCE A. Maintain stockpiles, excavations, access roads, and all other work areas free from dust. Employ dust abatement techniques whenever a dust nuisance or hazard occurs, or as directed by Engineer. Comply with local ordinances. B. Protect hazardous work areas and hazardous material storage areas. C. Protect trees, unless specifically indicated on Drawings. D. Clean access roads and haul routes with mechanical street sweeper. E. If Contractor fails to maintain Site, Engineer will provide Written Notice of Contractor's defective work. Contractor will be given 12 hours from the Notice to clean Site. After the 12 hour period, Owner may correct the defective work consistent with Article 13.09 of the Conditions of the Contract. 3.03 CERTIFICATE OF COMPLIANCE WITH MINNESOTA STATUTES 290.92 AND 290.97 A. Upon completion of the Project and prior to Final Payment, the Contractor and all subcontractors shall complete Minnesota Department of Revenue Revised Form IC -134. This form, Affidavit for Obtaining Final Settlement of Contract with the State of Minnesota and any of its Political or Governmental Subdivisions, is to be signed by a Department of Revenue representative and forwarded to the Owner. Copies of this form can be obtained by writing to the Minnesota Department of Revenue, Forms Section, Mail Station 1173, St. Paul, MN 55146 -1173 or by calling (651) 296 -4444. 3.04 MEASUREMENT AND PAYMENT A. A Bid Item has been provided for Street Sweeper (With Pickup Broom) Measurement will be by the units of hours for a sweeper and operator. B. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 000034 - 05175 -0 0 2007 Bonestroo 01700 -2 EXECUTION REQUIREMENTS Daily Production (Tons) Lots 200 to 1000 1 1001 to 2000 2 2001 to 3600 3 3601 to 5000 4 5001+ 6 Percent of Max Specific Gravity SP Wear All MV & LV , SP Shld (4% Void) Percent of Max Specific Gravity SP Non -Wear SP Shoulders (3% Void) Percent Payment 93.6 and above 94.6 and above 100 93.1 to 93.5 94.1 to 94.5 100 92.0 to 93.0 93.0 to 94.0 100 91.0 to 91.9 92.0 to 92.9 98 90.5 to 90.9 91.5 to 91.9 95 90.0 to 90.4 91.0 to 91.4 91 89.5 to 89.9 90.5 to 90.9 85 89.0 to 89.4 90.0 to 90.4 70 Less than 89.0 Less than 90.0 Overlay Specified PG Asphalt Binder Grade Vir in Asphalt Binder Grade to be used with RAP 5 20 Percent RAP I > 20 Percent FLAP All PG Grades No grade adjustment I No grade adjustment New Construction (1) Specified PG Asphalt Binder Grade Virgin Asphalt Binder Grade to be used with RAP 20 Percent RAP > 20 Percent RAP 52 -34 52 -34 52 -34 58 -28 58 -28 58 -28 58 -34 58 -34 Not allowed * 64 -28 64 -28 64 -28 64 -34 64 -34 Not allowed *' Other PG Grades No grade adjustment Not allowed * Traffic Traffic Traffic Traffic SMA Aggregate Blend Property Level 2& LV Level 3 & MV Level 4 Level 5 T. Level 6 20 year Design ESAL's <1 million I - 3 million 3-10 million 10 - 30 million See SMA Provisions Coarse Aggregate Angularity (ASTM D5821) 301- 551- 85180 95/90 (1 face / 2 face), Percent - Wear 30 /- 55/- 60 /'- 80/75 (I face / 2 face), Percent - NonWear Fine Aggregate Angularity (FAA) (AASHTO T304, Method A) Percent - 40 421" 44 45 Wear 40 40 40 40 Percent - Non -Wear Flat and Elongated Particles, max `; 10 10 10 - p ercent by weight, (ASTM D4791) (5:1 ratio) (5:1 ratio) t (5 :1 ratio) Clay Content "(AASHTO T176) 45 45 Total Spall in fraction retained on the 5.0 2.5 1.0 1.0 - 4.75mm [ #4] sieve Maximum Spall Content in Total 510 5.0 1,0 1.0 Sample Maximum Percent Lumps in fraction 0.5 0.5 0.5 0 5 retained on the 4.75mm [ #4 sieve Class B Carbonate Restrictions Maximumpercent - 4.75mm [44] Final Lift/All other Lifts 100/100 100 /100 8080 50/80 Maximumpercent t4.75mm [ + 94] Final Lift/All other Lifts 100/100 100 /100 501100 1 0/100 - Gyrat Max. allowable RAP percentage 30/40 30/30 30/30" 30/30" Wear / Non Wear' Marshall Max. allowable RAP percentage 30/40 30/30 Wear/ Non Wear Traffic Level Traffic Level Traffic Level Traffic Level SMA 2 3 4 5 T. Level 6 20 year Design ESAUs < I million I - 3 million 3 - 10 million 10-30 million See SMA Provisions Gyratory Mixture Requirements Gyrations for N 6 7 8 8 Gyrations for Ndni, 40 60 90 100 Gyrations for N j ,,j jjjjjjjj 60 90 140 160 PercentAir Voids at Ndfnigll, — 4.0 4,0 4,0 4.0 Wear 10 3,0 3.0 3.0 PercentAir Voids sat Ndolgo, -- Non -Wear & All Shoulder Percent G,,,,,, at Nj Il i t i a l — Wear - 5 91.5 5 90,5 590,0 Percent at N ill i tial — - < 92.5 :5 91.5 :5 91,0 Non-Wear & All Shoulder Percent G,,,,,, at Wear :5 98,0 < 98.0 :5 98,0 :5 98.0 Per - cent G,,,,, at N jjwxjrjjjjjjj — 5 99,0 :5 99 0 < 99,0 :5 99 0 NonWear & All Shoulder Tensile Strength Ratio '", min 75 75 (2) 80(3) 80(" Percent Fines/Effective Asphalt 0,6 —1.2 0.6-12 0.6-1.2 0.6-1.2 VFA, Percent -- Wear 65-78 65-78 65-76 65-76 Non-Wear & All Shoulder 70-83 70-83 70-82 70-82 Marshall Mixture Requirements LV MV Marshall Blows 50 50 - - Air Voids, percent 3.0 3.5 Tensile Strength Ratio"', 70(4) 70(4) min percent Stability, minimum N [Ib f] 5000 r11251 6000 [1350 Fines/Effective Asphalt Wear 0.6-1.30 0,6-1,30 Non-Wear 0.6-1.40 0.6-lA0 Gradation Fine Mixture percent Pass 2.36 mrn #5 VMA Minimum Coarse Mixture percent Pass 2.36 mm #$ VMA Minimum A or 4* >47 15.0 ** ::-:47 14.5 ** B or3* > 39 14.0 _ <39 13.5 C or 2* > 35 110 < 35 12.5 5* 15.0 ** - - -- E See +SMA Provisions Item Gyratory Desi Marshall Design Un -Compacted Mixture Sample' Size 8,200 g 8,200 g Number of Com acted Bri uettes 6 > 9 Compacted Briquette Air Void Content 6.5 — 7.5 percent 6.0 — 8.0 ercent Production Test Testing Rates Test Reference Section Bulk Specific Gravity I test ` er 450 metric tons 500 tons AASHTO T312,TI66 MnDOT modified 2360AE2< Maximum Specific Gravity I test ` er 450 metric tons 500 tons AASHTO T209 MnDOT modified 2360AE3 Air Voids (calculated) I test ` per 450 metric tons 500 tonsl AASHTO T269, T312 2360AE4 Asphalt Content I test' per 450 metric tons 500 tons Bit & Lab Manual 2360.4EI VMA (Calculated) 1 test'` per 450 metric tons 1500 tons Al MS 2 & SP 2 23604E5 Gradation I test per 900 metric tons 1000 tons AASHTO TI I, T27, T30MnDOT modified 2360AE6 Coarse Aggregate Angularity I test ` per 900 metric tons 1000 tons ASTM D5821 2360AE7 Fine Aggregate Angularity (FAA) I test per 900 metric tons [1000 tons] AASHTO T304, Method A 2360 4138 Production Pest Sampling/Testing Rates Test Reference Section Divide the planned production by 1000. Round the AASHTO T312, T245 T166 2360AE2 Bulk Specific Gravity number to the next higher whole number. MnDOT mod Maximum Specific AASHTO T209 MnDOT 23604E3 Gravity modified Air Voids (calculated) " AAS14TO T269, T312 2360.4134 Asphalt Content Bit & Lab Manual 2360.4131 VMA (Calculated) AI MS 2 & SP 2 2360.4135 I gradation per 1,800 metric tons [2,000 tons], or AASHTO TI 1, T27, 7-360 4136 Gradation onion thereof (minimum of one per day) T30MnDOT modified 2 tests /day for a minimum of 2 days, then I per day if ASTM D5821 Coarse Aggregate CAA is met If CAA >8pereent of requirement, 1 2360 4E7 Angularity sam le /day but test I /week. Fine Aggregate 2 tests /day far a minimum of 2 days, then I per day if AASHTO T304, Method A Angularity (FAA) FAA is met If FAA >5percentof requirement, I' 2360 4E8 sample/day but testl Aveck. I' sample at 5,000 tons or by second day of production, ASTM D4867 MnDOT 23604E9 TSR then sample at every 18,000 metric tons f 20,000 tons modified Aggregate Specific I per 9,000 metric tons [10,000 tons] AASHTO T84 & T85, 2360 41310 Gravity modified Mixture Moisture Daily unless exempted by Engineer MnDOT 5- 693.950 2360 4E I I Content sample I" load (each grade) then I per 1,000,000 liter MnDOT 5 -693 920 2360 41312 Asphalt Binder 250,000 gallon-sample size t quart. Mixture Type- - Minimum TSR LV and MV Gyratory Traffic Level 2` -3 Traffic Level 4 -5 Contractor MGT Owner Contractor MnDOT Contractor MAnGT Owner 70 percent 60 percent 75 percent 65 percent 80 per 70 percent ' LV and MV Mixtures Contractor TSR > 70 <70 '_ ©A4w� >60 NA 4 TSR <60 Contractor Contractor Gyratory Level 4 -5 Contractor TSR > 80 <80 >7D NA Owner TSR <70 Contractor Contractor - - - -- - Item - Allowable Difference Mixture Bulk Specific Gravity (0 1,) 0.030 Mixture Maximum Specific Gravity (G,,,,,,} 0.019 VMA (Calculated) ', 1 . 2 Fine Aggregate An ulari , uncom acted voids (U) per 1 Coarse A re ate An Mari percent fractured faces ()ercent 15 Aggregate Individual Bulk Specific Gravity ( +4.75mnz + #41} 0.040 Aggregate Individual Bulk S` ecific Gravity (- 4.75mm [- #4) 0.040 Aggregate combined blend Specific Gravity (G,b) 0:020 Tensile Strength Ratio (TSR) percent See Table 2360.3 -B2b Asphalt Binder Content Meter Method, percent 0.2 Spot Check Method, percent 0.2 Chemical Extraction Methods, percent 0.4 Incinerator Oven, percent 03 Chemical vs', Meter, Spot Check, or incinerator methods 0.4 Incinerator Oven vs. Spot Check 0.4 Gradation Sieve' percent passin " 25.0, 19.0, 12.5, 9.5 mm (1 inch, 3/4 inch, 1/2 inch, 3/8 inclij 6 4.75 mm ( #4 5 2.36 mm ( #8] 4 0.075 mm [#200] 2.0 Daily SP Wear and All MU SP Non�vear 4 Sp Shoulders (1)(2) 270* — 545 and LV Mixtures 41)42) 1 546-910 (601 -1,000 2 911 -1,455 Designed at Designed at 3 1,456 — 3,275 1,601— 3,6001 3percent 4percent voids 3,276 — 4,545 [3,601— 5,000 ] 5 voids [5,001+) percent Gmm 92.0 93.0 93.0 92.0 Daily Production Lots Metric (ton) (En" lish (Ton)l 270* — 545 [300* — 6001 1 546-910 (601 -1,000 2 911 -1,455 11,001 - -1,600 ] 3 1,456 — 3,275 1,601— 3,6001 4 3,276 — 4,545 [3,601— 5,000 ] 5 4,546+ [5,001+) 6 7.62 m 125 foot] feet either side of obstructions such as manholes, water supply castings, etc.* Rata s, Loops, Climbing lanes Side Streets, Side Connections Turn Lanes, Stora Lanes, Crossovers, Bypass Lanes Shoulders Intersections constructed under traffic — Begin and end the exclusion 30.5m 100 feet] from the intersection radius Sections less than 7.62 m 125 foot] in length Acceleration, Deceleration Lanes Projects less than 300m [1000 feet] in length Mainline p aving where the normally posted regulatory seed is less than orequal to 70 km/lir f45 miles per hour Begin the exclusion at the sign Single lift overlays over concrete Vehicle Axle and Wheel Spacings Front Wheels Rear Wheels Weight WB T P F L W P R L W! C* 4,000# 48" 32" 1,000# 2.0" 5.0" 1,000# 2.0" 5.0" 9" 6 66" 48" 1,500# 2.5" 6.0" 1,500# 2.5" 6.0" 12" 8,000# 102" 60" 1,600# 3.0 "! 8.0" 2,400# 3.0" 8.0" 15" 10,000# 120" 72" 2,000# 3.5 " 8.5" 3,000# 3.5" 8.5" 18„ This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the Controlling Law. GENER STANDARD , •; O FTHE C ONSTRUCTIO N Prepared by ENGINEERS JOINT CONTRACT DOCUMENTS COMMITTEE and Issued and Published Jointly By National Society of AWAMAO A C EC Pre,fesslon at Engipeers Aslexu1A,1 CMICct ur E.. w*zmuwc Cunir. ,ms ^^ PrEtk$$ie al Eftgimet$10 PWWto ft'ako J6A~R+rA* $4V41Y 97 0rxA. PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE a practice division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS AMERICAN COUNCIL OF ENGINEERING COMPANIES AMERICAN SOCIETY OF CIVIL ENGINEERS This document has been approved and endorsed by YCitt ` / Y t iN4� t ACM i y The Associated General Contractors of America Knowledge for Creating and Sustaining the Built Environment Construction Specifications Institute EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-1 GENERAL CONDITIONS ARTICLE 1 - DEFINITIONS AND TERMINOLOGY 1.01 Defined Terms A. Wherever used in the Bidding Requirements or Contract Documents and printed with initial capital letters, the terms listed below will have the meanings indicated which are applicable to both the singular and plural thereof. In addition to terms specifically defined, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Addenda -- Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the proposed Contract Documents. 2. Agreement - -The written instrument which is evidence of the agreement between Owner and Contractor covering the Work. 3. Application for Payment - -The form acceptable to Engineer which is to be used by Contractor during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 4. Asbestos - -Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 5. Bid - -The offer or proposal of a Bidder submitted on the prescribed form setting forth the prices for the Work to be performed. 6. Bidder - -The individual or entity who submits a Bid directly to Owner. 7. Bidding Documents- -The Bidding Requirements and the proposed Contract Documents (including all Addenda). 8. Bidding Requirements - -The Advertisement or Invitation to Bid, Instructions to Bidders, bid security of acceptable form, if any, and the Bid Form with any supplements. 9. Change Order - -A document recommended by Engineer which is signed by Contractor and Owner and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, issued on or after the Effective Date of the Agreement. 10. Claim - -A demand or assertion by Owner or Contractor seeking an adjustment of Contract Price or Contract Times, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. 11. Contract- -The entire and integrated written agreement between the Owner and Contractor concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral. 12. Contract Documents -- Those items so designated in the Agreement. Only printed or hard copies of the items listed in the Agreement are Contract Documents. Approved Shop Drawings, other Contractor's submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 13. Contract Price- -The moneys payable by Owner to Contractor for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of Paragraph 11.03 in the case of Unit Price Work). 14. Contract Times - -The number of days or the dates stated in the Agreement to: (i) achieve Milestones, if any, (ii) achieve Substantial Completion; and (iii) com- plete the Work so that it is ready for final payment as evidenced by Engineer's written recommendation of final payment. 15. Contractor - -The individual or entity with whom Owner has entered into the Agreement. 16. Cost of the Work - -See Paragraph 11.0 LA for definition. 17. Drawings - -That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings and other Contractor submittals are not Drawings as so defined. 18. Effective Date of the Agreement- -The date indicated in the Agreement on which it becomes effective, but if no such date is indicated, it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. 19. Engineer - -The individual or entity named as such in the Agreement. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-6 20. Field Order - - A written order issued by Engineer which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 21. General Requirements -- Sections of Division 1 of the Specifications. The General Requirements pertain to all sections of the Specifications. 22. Hazardous Environmental Condition - - The presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto in connection with the Work. 23. Hazardous Waste - - The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 24. Laws and Regulations; Laws or Regulations - -Any and all applicable laws, rules, regulations, ordinanc- es, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 25. Liens -- Charges, security interests, or encumbrances upon Project funds, real property, or personal property. 26. Milestone - - A principal event specified in the Contract Documents relating to an intermediate comple- tion date or time prior to Substantial Completion of all the Work. 27. Notice of Award - - The written notice by Owner to the Successful Bidder stating that upon timely compliance by the Successful Bidder with the conditions precedent listed therein, Owner will sign and deliver the Agreement. 28. Notice to Proceed - - A written notice given by Owner to Contractor fixing the date on which the Con- tract Times will commence to run and on which Contractor shall start to perform the Work under the Contract Documents. 29. Owner - - The individual or entity with whom Contractor has entered into the Agreement and for whom the Work is to be performed. 30. PCBs -- Polychlorinated biphenyls. 31. Petroleum -- Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non - Hazardous Waste and crude oils. 32. Progress Schedule - - A schedule, prepared and maintained by Contractor, describing the sequence and duration of the activities comprising the Contractor's plan to accomplish the Work within the Contract Times. 33. Project - - The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 34. Project Manual- -The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 35. Radioactive Material -- Source, special nucle- ar, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 36. Related Entity -- An officer, director, partner, employee, agent, consultant, or subcontractor. 37. Resident Project Representative - - The autho- rized representative of Engineer who may be assigned to the Site or any part thereof. 38. Samples -- Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 39. Schedule of Submittals - - A schedule, prepared and maintained by Contractor, of required submittals and the time requirements to support scheduled performance of related construction activities. 40. Schedule of Values - - A schedule, prepared and maintained by Contractor, allocating portions of the Contract Price to various portions of the Work and used as the basis for reviewing Contractor's Applications for Payment. 41. Shop Drawings - - All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. 42. Site - - Lands or areas indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights -of -way and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 43. Specifications- -That part of the Contract Documents consisting of written requirements for materials, equipment, systems, standards and workmanship as applied to the Work, and certain EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-7 administrative requirements and procedural matters applicable thereto. 44. Subcontractor - - An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 45. Substantial Completion- -The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. 46. Successful Bidder - - The Bidder submitting a responsive Bid to whom Owner makes an award. 47. Supplementary Conditions - - That part of the Contract Documents which amends or supplements these General Conditions. 48. Supplier - -A manufacturer, fabricator, suppli- er, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or any Subcontractor. 49. Underground Facilities - -All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 50. Unit Price Work - - Work to be paid for on the basis of unit prices. 51. Work - -The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. 52. Work Change Directive - - A written statement to Contractor issued on or after the Effective Date of the Agreement and signed by Owner and recommended by Engineer ordering an addition, deletion, or revision in the Work, or responding to differing or unforeseen subsurface or physical conditions under which the Work is to be performed or to emergencies. A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the change ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times. 1.02 Terminology A. The following words or terms are not defined but, when used in the Bidding Requirements or Contract Documents, have the following meaning. B. Intent of Certain Terms or Adjectives 1. The Contract Documents include the terms "as allowed," "as approved," "as ordered ", "as directed" or terms of like effect or import to authorize an exercise of professional judgment by Engineer. In addition, the adjectives "reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of like effect or import are used to describe an action or determination of Engineer as to the Work. It is intended that such exercise of professional judgment, action or determination will be solely to evaluate, in general, the Work for compliance with the requirements of and information in the Contract Documents and conformance with the design concept of the completed Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective is not intended to and shall not be effective to assign to Engineer any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility contrary to the provisions of Paragraph 9.09 or any other provision of the Contract Documents. C. Day 1. The word "day" means a calendar day of 24 hours measured from midnight to the next midnight. D. Defective 1. The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it: a. does not conform to the Contract Documents, or b. does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents, or c. has been damaged prior to Engineer's - recommendation of final payment (unless responsibility for the protection thereof has been assumed by Owner at Substantial Completion in accordance with Paragraph 14.04 or 14.05). EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-8 E. Furnish, Install, Perform, Provide 1. The word "furnish," when used in connection with services, materials, or equipment, shall mean to supply and deliver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install," when used in connection with services, materials, or equipment, shall mean to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3. The words "perform" or "provide," when used in connection with services, materials, or equipment, shall mean to furnish and install said services, materials, or equipment complete and ready for intended use. 4. When "furnish," "install," "perform," or "pro- vide" is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of Contractor, "provide" is implied. F. Unless stated otherwise in the Contract Docu- ments, words or phrases which have a well -known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2 - PRELIMINARY MATTERS 2.01 Delivery of Bonds and Evidence of Insurance A. When Contractor delivers the executed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner such bonds as Contractor may be required to furnish. B. Evidence of Insurance: Before any Work at the Site is started, Contractor and Owner shall each deliver to the other, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance which either of them or any additional insured may reasonably request) which Contractor and Owner respectively are required to purchase and maintain in accordance with Article 5. 2.02 Copies of Documents or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the Agreement. In no event will the Contract Times com- mence to run later than the sixtieth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date is earlier. 2.04 Starting the Work A. Contractor shall start to perform the Work on the date when the Contract Times commence to run. No Work shall be done at the Site prior to the date on which the Contract Times commence to run. 2.05 Before Starting Construction A. Preliminary Schedules: Within 10 days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), Contractor shall submit to Engineer for timely review: 1. a preliminary Progress Schedule; indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2. a preliminary Schedule of Submittals; and 3. a preliminary Schedule of Values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdi- vides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. 2.06 Preconstruction Conference A. Before any Work at the Site is started, a conference attended by Owner, Contractor, Engineer, and others as appropriate will be held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to in Paragraph 2.05.A, procedures for handling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. 2.07 Initial Acceptance of Schedules A. Owner shall furnish to Contractor up to ten A. At least 10 days before submission of the first printed or hard copies of the Drawings and Project Application for Payment a conference attended by Manual. Additional copies will be furnished upon request Contractor, Engineer, and others as appropriate will be at the cost of reproduction. held to review for acceptability to Engineer as provided below the schedules submitted in accordance with 2.03 Commencement of Contract Times; Notice to Paragraph 2.05.A. Contractor shall have an additional 10 Proceed days to make corrections and adjustments and to complete and resubmit the schedules. No progress payment shall be A. The Contract Times will commence to run on made to Contractor until acceptable schedules are the thirtieth day after the Effective Date of the Agreement submitted to Engineer. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-9 1. The Progress Schedule will be acceptable to Engineer if it provides an orderly progression of the Work to completion within the Contract Times. Such acceptance will not impose on Engineer responsibility for the Progress Schedule, for sequencing, scheduling, or progress of the Work nor interfere with or relieve Contractor from Contractor's full responsibility therefor. 2. Contractor's Schedule of Submittals will be acceptable to Engineer if it provides a workable arrangement for reviewing and processing the required submittals. 3. Contractor's Schedule of Values will be acceptable to Engineer as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.01 Intent A. The Contract Documents are complementary; what is required by one is as binding as if required by all. B. It is the intent of the Contract Documents to describe a functionally complete Project (or part thereof) to be constructed in accordance with the Contract Docu- ments. Any labor, documentation, services, materials, or equipment that may reasonably be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the intended result will be provided whether or not specifically called for at no additional cost to Owner. C. Clarifications and interpretations of the Contract Documents shall be issued by Engineer as provided in Article 9. 3.02 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations 1. Reference to standards, specifications, manuals, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Laws or Regula- tions in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. responsibilities of Owner, Contractor, or Engineer, or any of their subcontractors, consultants, agents, or employees from those set forth in the Contract Documents. No such provision or instruction shall be effective to assign to Owner, or Engineer, or any of, their Related Entities, any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake respon- sibility inconsistent with the provisions of the Contract Documents. 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies 1. Contractor's Review of Contract Documents Before Starting Work: Before undertaking each part of the Work, Contractor shall carefully study and compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error, ambiguity, or discrepancy which Contractor may discover and shall obtain a written interpretation or clarification from Engineer before proceeding with any Work affected thereby. 2. Contractor's Review of Contract Documents During Performance of Work: If, during the performance of the Work, Contractor discovers any conflict, error, ambiguity, or discrepancy within the Contract Documents or between the Contract Documents and any provision of any Law or Regulation applicable to the performance of the Work or of any standard, specification, manual or code, or of any instruction of any Supplier, Contractor shall promptly report it to Engineer in writing. Contractor shall not proceed with the Work affected thereby (except in an emergency as required by Paragraph 6.16.A) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in Paragraph 3.04. 3. Contractor shall not be liable to Owner or Engineer for failure to report any conflict, error, ambigu- ity, or discrepancy in the Contract Documents unless Contractor knew or reasonably should have known thereof. B. Resolving Discrepancies 1. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and: a. the provisions of any standard, specification, manual, code, or instruction (whether or not specifically incorporated by reference in the Contract Documents); or 2. No provision of any such standard, specification, manual or code, or any instruction of a b. the provisions of any Laws or Regulations Supplier shall be effective to change the duties or applicable to the per formance of the Work EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-10 (unless such an interpretation of the provisions of the Contract Documents would result in viola- tion of such Law or Regulation). 3.04 Amending and Supplementing Contract Documents A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof by either a Change Order or a Work Change Directive. B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may be authorized, by one or more of the following ways: 1. A Field Order; 2. Engineer's approval of a Shop Drawing or Sample; (Subject to the provisions of Paragraph 6.17.D.3); or 3. Engineer's written interpretation or clarification. sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. B. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60- day acceptance period will be corrected by the transferring party.. C. When transferring documents in electronic media format, the transferring party makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the data's creator. ARTICLE 4 - AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; HAZARDOUS ENVIRONMENTAL CONDITIONS; REFERENCE POINTS 3.05 Reuse of Documents A. Contractor and any Subcontractor or Supplier or other individual or entity performing or furnishing all of the Work under a direct or indirect contract with Contractor, shall not: 1. have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of Engineer or Engineer's consultants, including electronic media editions; or 2. reuse any of such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of Owner and Engineer and specific written verification or adaption by Engineer. B. The prohibition of this Paragraph 3.05 will survive final payment, or termination of the Contract. Nothing herein shall preclude Contractor from retaining copies of the Contract Documents for record purposes. 3.06 Electronic Data 4.01 Availability of Lands A. Owner shall furnish the Site. Owner shall notify Contractor of any encumbrances or restrictions not of general application but specifically related to use of the Site with which Contractor must comply in performing the Work. Owner will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. If Contractor and Owner are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, as a result of any delay in Owner's furnishing the Site or a part thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. B. Upon reasonable written request, Owner shall furnish Contractor with a current statement of record legal title and legal description of the lands upon which the Work is to be performed and Owner's interest therein as necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with applicable Laws and Regulations. A. Copies of data furnished by Owner or Engineer to Contractor or Contractor to Owner or Engineer that may be relied upon are limited to the printed copies (also known as hard copies). Files in electronic media format of text, data, graphics, or other types are furnished only for the convenience of the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user's C. Contractor shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-11 4.02 Subsurface and Physical Conditions A. Reports and Drawings: The Supplementary Conditions identify: 1. those reports of explorations and tests of subsurface conditions at or contiguous to the Site that Engineer has used in preparing the Contract Documents; and 2. those drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) that Engineer has used in preparing the Contract Documents. B. Limited Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their Related Entities with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions, or information. 4.03 Differing Subsurface or Physical Conditions A. Notice: If Contractor believes that any subsur- face or physical condition at or contiguous to the Site that is uncovered or revealed either: 1. is of such a nature as to establish that any "technical data" on which Contractor is entitled to rely as provided in Paragraph 4.02 is materially inaccurate; or is of such a nature as to require a change in the Contract Documents; or 3. differs materially from that shown or indicated in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then Contractor shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connec- tion therewith (except in an emergency as required by Paragraph 6.16.A), notify Owner and Engineer in writing about such condition. Contractor shall not further disturb such condition or perform any Work in connection therewith (except as aforesaid) until receipt of written order to do so. B. Engineer's Review: After receipt of written notice as required by Paragraph 4.03.A, Engineer will promptly review the pertinent condition, determine the necessity of Owner's obtaining additional exploration or tests with respect thereto, and advise Owner in writing (with a copy to Contractor) of Engineer's findings and conclusions. C. Possible Price and Times Adjustments 1. The Contract Price or the Contract Times, or both, will be equitably adjusted to the extent that the existence of such differing subsurface or physical condition causes an increase or decrease in Contractor's cost of, or time required for, performance of the Work; subject, however, to the following: a. such condition must meet any one or more of the categories described in Paragraph 4.03.A; and b. with respect to Work that is paid for on a Unit Price Basis, any adjustment in Contract Price will be subject to the provisions of Paragraphs 9.07 and 11.03. 2. Contractor shall not be entitled to any adjustment in the Contract Price or Contract Times if: a. Contractor knew of the existence of such conditions at the time Contractor made a final commitment to Owner with respect to Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract; or b. the existence of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, explo- ration, test, or study of the Site and contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for Contractor prior to Contractor's making such final commitment; or EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-12 c. Contractor failed to give the written notice as required by Paragraph 4.03.A. 3. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, a Claim may be made therefor as provided in Paragraph 10.05. However, Owner and Engineer, and any of their Related Entities shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. 4.04 Underground Facilities A. Shown or Indicated: The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the Site is based on information and data furnished to Owner or Engineer by the owners of such Underground Facilities, including Owner, or by others. Unless it is otherwise expressly provided in the Sup- plementary Conditions: 1. Owner and Engineer shall not be responsible for the accuracy or completeness of any such information or data; and 2. the cost of all of the following will be included in the Contract Price, and Contractor shall have full responsibility for: a. reviewing and checking all such information and data, b. locating all Underground Facilities shown or indicated in the Contract Documents, c. coordination of the Work with the owners of such Underground Facilities, including Owner, during construction, and d. the safety and protection of all such Under- ground Facilities and repairing any damage thereto resulting from the Work. B. Not Shown or Indicated 1. If an Underground Facility is uncovered or revealed at or contiguous to the Site which was not shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, Contractor shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), identify the owner of such Underground Facility and give written notice to that owner and to Owner and Engineer. Engineer will promptly review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to reflect and document the consequences of the existence or location of the Under- ground Facility. During such time, Contractor shall be responsible for the safety and protection of such Underground Facility. 2. If Engineer concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflect and document such consequences. An equitable adjustment shall be made in the Contract Price or Contract Times, or both, to the extent that they are attributable to the existence or location of any Underground Facility that was not shown or indicated or not shown or indicated with reasonable accuracy in the Contract Documents and that Contractor did not know of and could not reasonably have been expected to be aware of or to have anticipated. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment in Contract Price or Contract Times, Owner or Contractor may make a Claim therefor as provided in Paragraph 10.05. 4.05 Reference Points A. Owner shall provide engineering surveys to establish reference points for construction which in Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.06 Hazardous Environmental Condition at Site A. Reports and Drawings: Reference is made to the Supplementary Conditions for the identification of those reports and drawings relating to a Hazardous Environmental Condition identified at the Site, if any, that have been utilized by the Engineer in the preparation of the Contract Documents. B. Limited Reliance by Contractor on Technical Data Authorized: Contractor may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their Related Entities with respect to: EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-13 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences and procedures of construction to be employed by Contractor and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions or information. C. Contractor shall not be responsible for any Hazardous Environmental Condition uncovered or re- vealed at the Site which was not shown or indicated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work. Contractor shall be responsible for a Hazardous Environmental Condition created with any materials brought to the Site by Contractor, Subcontractors, Suppliers, or anyone else for whom Contractor is responsible. D. If Contractor encounters a Hazardous Environmental Condition or if Contractor or anyone for whom Contractor is responsible creates a Hazardous Environmental Condition, Contractor shall immediately: (i) secure or otherwise isolate such condition; (ii) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by Paragraph 6.16.A); and (iii) notify Owner and Engineer (and promptly thereafter confirm such notice in writing). Owner shall promptly consult with Engineer concerning the necessity for Owner to retain a qualified expert to evaluate such condition or take corrective action, if any. E. Contractor shall not be required to resume Work in connection with such condition or in any affected area until after Owner has obtained any required permits related thereto and delivered to Contractor written notice: (i) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work; or (ii) specifying any special conditions under which such Work may be resumed safely. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, or both, as a result of such Work stop- page or such special conditions under which Work is agreed to be resumed by Contractor, either party may make a Claim therefor as provided in Paragraph 10.05. entitlement to or on the amount or extent, if any, of an adjustment in Contract Price or Contract Times as a result of deleting such portion of the Work, then either party may make a Claim therefor as provided in Paragraph 10.05. Owner may have such deleted portion of the Work performed by Owner's own forces or others in accordance with Article 7. G. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, Subcontractors, and Engineer, and the officers, directors, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hazardous Environmental Condition: (i) was not shown or indicated in the Drawings or Specifications or identified in the Contract Documents to be included within the scope of the Work, and (ii) was not created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06. G shall obligate Owner to indemnify any individual or entity from and against the conse- quences of that individual's or entity's own negligence. H. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.11 shall obligate Contractor to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. I. The provisions of Paragraphs 4.02, 4.03, and 4.04 do not apply to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 5 - BONDS AND INSURANCE 5.01 Performance, Payment, and Other Bonds F. If after receipt of such written notice A. Contractor shall furnish performance and Contractor does not agree to resume such Work based on payment bonds, each in an amount at least equal to the a reasonable belief it is unsafe, or does not agree to Contract Price as security for the faithful performance and resume such Work under such special conditions, then payment of all of Contractor's obligations under the Owner may order the portion of the Work that is in the Contract Documents. These bonds shall remain in effect area affected by such condition to be deleted from the until one year after the date when final payment becomes Work. If Owner and Contractor cannot agree as to due or until completion of the correction period specified EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-14 in Paragraph 13.07, whichever is later, except as provided otherwise by Laws or Regulations or by the Contract Documents. Contractor shall also furnish such other bonds as are required by the Contract Documents. B. All bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the current list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Compa- nies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All bonds signed by an agent must be accompanied by a certified copy of the agent's authority to act. C. If the surety on any bond furnished by Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in any state where any part of the Project is located or it ceases to meet the requirements of Paragraph 5.01.13, Contractor shall promptly notify Owner and Engineer and shall, within 20 days after the event giving rise to such notification, provide another bond and surety, both of which shall comply with the requirements of Paragraphs 5.01.13 and 5.02. 5.02 Licensed Sureties and Insurers A. All bonds and insurance required by the Contract Documents to be purchased and maintained by Owner or Contractor shall be obtained from surety or insurance companies that are duly licensed or authorized in the jurisdiction in which the Project is located to issue bonds or insurance policies for the limits and coverages so required. Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided in the Supplementary Conditions. 5.03 Certificates of Insurance A. Contractor shall deliver to Owner, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Owner or any other additional insured) which Contractor is required to purchase and maintain. B. Owner shall deliver to Contractor, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Contractor or any other additional insured) which Owner is required to purchase and maintain. 5.04 Contractor's Liability Insurance A. Contractor shall purchase and maintain such liability and other insurance as is appropriate for the Work being performed and as will provide protection from claims set forth below which may arise out of or result from Contractor's performance of the Work and Contractor's other obligations under the Contract Documents, whether it is to be performed by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers' compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of Contractor's employees; 3. claims for damages because of bodily injury, sickness or disease, or death of any person other than Contractor's employees; 4. claims for damages insured by reasonably available personal injury liability coverage which are sus- tained: a. by any person as a result of an offense directly or indirectly related to the employment of such person by Contractor, or b. by any other person for any other reason; 5. claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 6. claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle. B. The policies of insurance required by this Paragraph 5.04 shall: 1. with respect to insurance required by Paragraphs 5.04.A.3 through 5.04.A.6 inclusive, include as additional insured (subject to any customary exclusion regarding professional liability) Owner and Engineer, and any other individuals or entities identified in the Supple- mentary Conditions, all of whom shall be listed as addi- tional insureds, and include coverage for the respective officers, directors, partners, employees, agents, consultants and subcontractors of each and any of all such additional insureds, and the insurance afforded to these additional insureds shall provide primary coverage for all claims covered thereby; 2. include at least the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or required by Laws or Regulations, whichever is greater; EJCDC 0.700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-15 3. include completed operations insurance; 4. include contractual liability insurance covering Contractor's indemnity obligations under Paragraphs 6.11 and 6.20; 5. contain a provision or endorsement that the coverage afforded will not be canceled, materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance has been issued (and the certificates of insurance furnished by the Contractor pursuant to Paragraph 5.03 will so provide); 6. remain in effect at least until final payment and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work in accordance with Paragraph 13.07; and 7. with respect to completed operations insur- ance, and any insurance coverage written on a claims - made basis, remain in effect for at least two years after final payment. a. Contractor shall furnish Owner and each other additional insured identified in the Supple- mentary Conditions, to whom a certificate of insurance has been issued, evidence satisfactory to Owner and any such additional insured of continuation of such insurance at final payment and one year thereafter. 5.05 Owner's Liability Insurance A. In addition to the insurance required to be provided by Contractor under Paragraph 5.04, Owner, at Owner's option, may purchase and maintain at Owner's expense Owner's own liability insurance as will protect Owner against claims which may arise from operations under the Contract Documents. 5.06 Property Insurance A. Unless otherwise provided in the Supple- mentary Conditions, Owner shall purchase and maintain property insurance upon the Work at the Site in the amount of the full replacement cost thereof (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). This insurance shall: 1. include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as an insured or additional insured; 2. be written on a Builder's Risk "all- risk" or open peril or special causes of loss policy form that shall at least include insurance for physical loss or damage to the Work, temporary buildings, false work, and materials and equipment in transit, and shall insure against at least the following perils or causes of loss: fire, lightning, extended coverage, theft, vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, water damage, (other than caused by flood) and such other perils or causes of loss as may be specifi- cally required by the Supplementary Conditions; 3. include expenses incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers and architects); 4. cover materials and equipment stored at the Site or at another location that was agreed to in writing by Owner prior to being incorporated in the Work, provided that such materials and equipment have been included in an Application for Payment recommended by Engineer; Owner; 5. allow for partial utilization of the Work by 6. include testing and startup; and 7. be maintained in effect until final payment is made unless otherwise agreed to in writing by Owner, Contractor, and Engineer with 30 days written notice to each other additional insured to whom a certificate of insurance has been issued. B. Owner shall purchase and maintain such boiler and machinery insurance or additional property insurance as may be required by the Supplementary Conditions or Laws and Regulations which will include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them, each of whom is deemed to have an insurable interest and shall be listed as an insured or additional insured. C. All the policies of insurance (and the certifi- cates or other evidence thereof) required to be purchased and maintained in accordance with Paragraph 5.06 will contain a provision or endorsement that the coverage afforded will not be canceled or materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other additional insured to whom a certificate of insurance has been issued and will contain waiver provisions in accor- dance with Paragraph 5.07. D. Owner shall not be responsible for purchasing and maintaining any property insurance specified in this Paragraph 5.06 to protect the interests of Contractor, Subcontractors, or others in the Work to the extent of any EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-16 deductible amounts that are identified in the Supple- mentary Conditions. The risk of loss within such identified deductible amount will be borne by Contractor, Subcontractors, or others suffering any such loss, and if any of them wishes property insurance coverage within the limits of such amounts, each may purchase and maintain it at the purchaser's own expense. E. If Contractor requests in writing that other special insurance be included in the property insurance policies provided under Paragraph 5.06, Owner shall, if possible, include such insurance, and the cost thereof will be charged to Contractor by appropriate Change Order. Prior to commencement of the Work at the Site, Owner shall in writing advise Contractor whether or not such other insurance has been procured by Owner. 5.07 Waiver of Rights A. Owner and Contractor intend that all policies purchased in accordance with Paragraph 5.06 will protect Owner, Contractor, Subcontractors, and Engineer, and all other individuals or entities identified in the Supple- mentary Conditions to be listed as insureds or additional insureds (and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them) in such policies and will provide primary coverage for all losses and damages caused by the perils or causes of loss covered thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any of the insureds or additional insureds thereunder. Owner and Contractor waive all rights against each other and their respective officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them for all losses and damages caused by, arising out of or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive all such rights against Subcontractors, and Engineer, and all other individuals or entities identified in the Supplementary Conditions to be listed as insured or additional insured (and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them) under such policies for losses and damages so caused. None of the above waivers shall extend to the rights that any party making such waiver may have to the proceeds of insurance held by Owner as trustee or otherwise payable under any policy so issued. B. Owner waives all rights against Contractor, Subcontractors, and Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them for: 1. loss due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to Owner's property or the Work caused by, arising out of, or resulting from fire or other perils whether or not insured by Owner; and 2. loss or damage to the completed Project or part thereof caused by, arising out of, or resulting from fire or other insured peril or cause of loss covered by any property insurance maintained on the completed Project or part thereof by Owner during partial utilization pursuant to Paragraph 14.05, after Substantial Completion pursuant to Paragraph 14.04, or after final payment pursuant to Paragraph 14.07. C. Any insurance policy maintained by Owner covering any loss, damage or consequential loss referred to in Paragraph 5.07.13 shall contain provisions to the effect that in the event of payment of any such loss, damage, or consequential loss, the insurers will have no rights of recovery against Contractor, Subcontractors, or Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them. 5.08 Receipt and Application of Insurance Proceeds A. Any insured loss under the policies of insurance required by Paragraph 5.06 will be adjusted with Owner and made payable to Owner as fiduciary for the insureds, as their interests may appear, subject to the requirements of any applicable mortgage clause and of Paragraph 5.08.13. Owner shall deposit in a separate account any money so received and shall distribute it in accordance with such agreement as the parties in interest may reach. If no other special agreement is reached, the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof, and the Work and the cost thereof covered by an appropriate Change Order. B. Owner as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within 15 days after the occurrence of loss to Owner's exercise of this power. If such objection be made, Owner as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach. If no such agreement among the parties in interest is reached, Owner as fiduciary shall adjust and settle the loss with the insurers and, if required in writing by any party in interest, Owner as fiduciary shall give bond for the proper performance of such duties. 5.09 Acceptance of Bonds and Insurance; Option to Replace A. If either Owner or Contractor has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and maintained by the other party in accordance with Article 5 on the basis of non - conformance with the Contract EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-17 Documents, the objecting party shall so notify the other party in writing within 10 days after receipt of the certificates (or other evidence requested) required by Paragraph 2.01.13. Owner and Contractor shall each provide to the other such additional information in respect of insurance provided as the other may reasonably request. If either party does not purchase or maintain all of the bonds and insurance required of such party by the Contract Documents, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. Without prejudice to any other right or remedy, the other party may elect to obtain equivalent bonds or insurance to protect such other party's interests at the expense of the party who was required to provide such coverage, and a Change Order shall be issued to adjust the Contract Price accordingly. 5.10 Partial Utilization, Acknowledgment of Property Insurer A. If Owner finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in Paragraph 14.05, no such use or occupancy shall commence before the insurers providing the property insurance pursuant to Paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES 6.01 Supervision and Superintendence A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. Contractor shall not be responsible for the negligence of Owner or Engineer in the design or specification of a specific means, method, technique, sequence, or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. B. At all times during the progress of the Work, Contractor shall assign a competent resident superin- tendent who shall not be replaced without written notice to Owner and Engineer except under extraordinary circumstances. The superintendent will be Contractor's representative at the Site and shall have authority to act on behalf of Contractor. All communications given to or received from the superintendent shall be binding on Contractor. 6.02 Labor; Working Hours A. Contractor shall provide competent, suitably qualified personnel to survey and lay out the Work and perform construction as required by the Contract Docu- ments. Contractor shall at all times maintain good disci- pline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during regular working hours. Contractor will not permit the performance of Work on a Saturday, Sunday, or any legal holiday without Owner's written consent (which will not be unreasonably withheld) given after prior written notice to Engineer. 6.03 Services, Materials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start -up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit of Owner. If required by Engineer, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. C. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 6.04 Progress Schedule A. Contractor shall adhere to the Progress Schedule established in accordance with Paragraph 2.07 as it may be adjusted from time to time as provided below. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-18 1. Contractor shall submit to Engineer for acceptance (to the extent indicated in Paragraph 2.07) proposed adjustments in the Progress Schedule that will not result in changing the Contract Times. Such adjust- ments will comply with any provisions of the General Re- quirements applicable thereto. 2. Proposed adjustments in the Progress Schedule that will change the Contract Times shall be submitted in accordance with the requirements of Article 12. Adjustments in Contract Times may only be made by a Change Order. 6.05 Substitutes and "Or- Equals" A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or-equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be submitted to Engineer for review under the circumstances described below. 1. "Or- Equal" Items: If in Engineer's sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by Engineer as an "or- equal" item, in which case review and approval of the proposed item may, in Engineer's sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this Paragraph 6.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if: a. in the exercise of reasonable judgment Engineer determines that: 1) it is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; 2) it will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole, 3) it has a proven record of performance and availability of responsive service; and b. Contractor certifies that, if approved and incorporated into the Work: 1) there will be no increase in cost to the Owner or increase in Contract Times, and 2) it will conform substantially to the detailed requirements of the item named in the Contract Documents. 2. Substitute Items a. If in Engineer's sole discretion an item of material or equipment proposed by Contractor does not qualify as an "or- equal" item under Paragraph 6.05.A.1, it will be considered a proposed substitute item. b. Contractor shall submit sufficient information as provided below to allow Engineer to determine that the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by Engineer from anyone other than Contractor. c. The requirements for review by Engineer will be as set forth in Paragraph 6.05.A.2.d, as supplemented in the General Requirements and as Engineer may decide is appropriate under the circumstances. d. Contractor shall make written application to Engineer for review of a proposed substitute item of material or equipment that Contractor seeks to furnish or use. The application: 1) shall certify that the proposed substi- tute item will: a) perform adequately the functions and achieve the results called for by the general design, b) be similar in substance to that specified, and c) be suited to the same use as that specified; 2) will state: a) the extent, if any, to which the use of the proposed substitute item will preju- dice Contractor's achievement of Substantial Completion on time; b) whether or not use of the proposed substitute item in the Work will require a change in any of the Contract Docu- ments (or in the provisions of any other direct contract with Owner for other work on the Project) to adapt the design to the proposed substitute item; and EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright 0 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-19 c) whether or not incorporation or use of the proposed substitute item in con- nection with the Work is subject to payment of any license fee or royalty; 3) will identify: a) all variations of the proposed substitute item from that specified , and b) available engineering, sales, maintenance, repair, and replacement services; 4) and shall contain an itemized esti- mate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and claims of other contractors affected by any resulting change, B. Substitute Construction Methods or Proce- dures: If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by Engineer. Contractor shall submit sufficient information to allow Engineer, in Engineer's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The requirements for review by Engineer will be similar to those provided in Paragraph 6.05.A.2. C. Engineer's Evaluation: Engineer will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs 6.05.A and 6.05.B. Engineer may require Contractor to furnish additional data about the proposed substitute item. Engineer will be the sole judge of acceptability. No "or equal" or substitute will be ordered, installed or utilized until Engineer's review is complete, which will be evidenced by either a Change Order for a substitute or an approved Shop Drawing for an "or equal." Engineer will advise Contractor in writing of any negative determination. D. Special Guarantee: Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute. E. Engineer's Cost Reimbursement: Engineer will record Engineer's costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs 6.05.A.2 and 6.05.13 Whether or not Engineer approves a substitute item so proposed or submitted by Contractor, Contractor shall reimburse Owner for the charges of Engineer for evaluating each such proposed substitute. Contractor shall also reimburse Owner for the charg of Engineer for making changes in the Contract Documents (or in the provisions of any other direct contract with Owner) resulting from the acceptance of each proposed substitute. 1 LVlG6t ClcLVf J 1,itlGftJG. oi141 provide all data in support of any proposed substitute or "or-equal" at Contractor's expense. 6.06 Concerning Subcontractors, Suppliers, and Others A. Contractor shall not employ any Subcon- tractor, Supplier, or other individual or entity (including those acceptable to Owner as indicated in Paragraph 6.06.13), whether initially or as a replacement, against whom Owner may have reasonable objection. Contractor shall not be required to employ any Subcontractor, Supplier, or other individual or entity to furnish or perform any of the Work against whom Contractor has reasonable objection. B. If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers, or other individuals or entities to be submitted to Owner in advance for acceptance by Owner by a specified date prior to the Effective Date of the Agreement, and if Contractor has submitted a list thereof in accordance with the Supplementary Conditions, Owner's acceptance (either in writing or by failing to make written objection thereto by the date indicated for acceptance or objection in the Bidding Documents or the Contract Documents) of any such Subcontractor, Supplier, or other individual or entity so identified may be revoked on the basis of reason- able objection after due investigation. Contractor shall submit an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity, and the Contract Price will be adjusted by the difference in the cost occasioned by such replacement, and an appropriate Change Order will be issued. No acceptance by Owner of any such Subcontractor, Supplier, or other individual or entity, whether initially or as a replacement, shall consti- tute a waiver of any right of Owner or Engineer to reject defective Work. C. Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor's own acts and omissions. Nothing in the Contract Documents: 1. shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between Owner or Engineer and any such Subcontractor, Supplier or other individual or entity, nor 2. shall anything in the Contract Documents create any obligation on the part of Owner or Engineer to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or ot individual EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-20 or entity except as may otherwise be required by Laws and Regulations. D. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. E. Contractor shall require all Subcontractors, Suppliers, and such other individuals or entities per- forming or furnishing any of the Work to communicate with Engineer through Contractor. F. The divisions and sections of the Specifica- tions and the identifications of any Drawings shall not control Contractor in dividing the Work among Subcon- tractors or Suppliers or delineating the Work to be performed by any specific trade. G. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appro- priate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of Owner and Engineer. Whenever any such agreement is with a Subcontractor or Supplier who is listed as an additional insured on the property insurance provided in Paragraph 5.06, the agreement between the Contractor and the Subcontractor or Supplier will contain provisions whereby the Subcontractor or Supplier waives all rights against Owner, Contractor, and Engineer„ and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or additional insureds (and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them) for all losses and damages caused by, arising out of, relating to, or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work. If the insurers on any such policies require separate waiver forms to be signed by any Subcontractor or Supplier, Contractor will obtain the same. 6.07 Patent Fees and Royalties A. Contractor shall pay all license fees and royalties and assume" all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if to the actual knowledge of Owner or Engineer its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by Owner in the Contract Documents. B. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. 6.08 Permits A. Unless otherwise provided in the Supple- mentary Conditions, Contractor shall obtain and pay for all construction permits and licenses. Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. Owner shall pay all charges of utility owners for connections for providing permanent service to the Work. 6.04 Laws and Regulations A. Contractor shall give all notices required by and shall comply with all Laws and Regulations applica- ble to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither Owner nor Engineer shall be responsible for monitoring Contractor's compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor's primary responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor's obligations under Paragraph 3.03. C. Changes in Laws or Regulations not known at the time of opening of Bids (or, on the Effective Date of the Agreement if there were no Bids) having an effect on the cost or time of performance of the Work shall be the subject of an adjustment in Contract Price or Contract Times. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-21 6.10 Taxes A. Contractor shall pay all sales, consumer, use, and other similar taxes required to be paid by Contractor in accordance with the Laws and Regulations of the place of the Project which are applicable during the performance of the Work. 6.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas 1. Contractor shall confine construction equip- ment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. Should any claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against Owner, Engineer, or any other party indemnified hereunder to the extent caused by or based upon Contractor's performance of the Work. B. Removal of Debris During Performance of the Work: During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to applicable Laws and Regulations. C. Cleaning: Prior to Substantial Completion of the Work Contractor shall clean the Site and the Work and make it ready for utilization by Owner. At the com- pletion of the Work Contractor shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D. Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 6.12 Record Documents A. Contractor shall maintain in a safe place at the Site one record copy of all Drawings, Specifications, Addenda, Change Orders, Work Change Directives, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved Samples and a counterpart of all approved Shop Drawings will be available to Engineer for reference. Upon completion of the Work, these record documents, Samples, and Shop Drawings will be delivered to Engi- neer for Owner. 6.13 Safety and Protection A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precau- tions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. C. All damage, injury, or loss to any property referred to in Paragraph 6.13.A.2 or 6.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor (except damage or loss attributable to the fault of Draw- EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-22 ings or Specifications or to the acts or omissions of Owner or Engineer or , or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of Contractor or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them). D. Contractor's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and Engineer has issued a notice to Owner and Contractor in accordance with Paragraph 14.07.13 that the Work is acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.14 Safety Representative A. Contractor shall designate a qualified and experienced safety representative at the Site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. 6.15 Hazard Communication Programs A. Contractor shall be responsible for coordi- nating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations. 6.16 Emergencies A. In emergencies affecting the safety or protec- tion of persons or the Work or property at the Site or adjacent thereto, Contractor is obligated to act to prevent threatened damage, injury, or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby or are required as a result thereof. If Engineer determines that a change in the Contract Documents is required because of the action taken by Contractor in response to such an emergency, a Work Change Directive or Change Order will be issued. 6.17 Shop Drawings and Samples A. Contractor shall submit Shop Drawings and Samples to Engineer for review and approval in accor- dance with the acceptable Schedule of Submittals (as required by Paragraph 2.07). Each submittal will be identified as Engineer may require. I. Shop Drawings a. Submit number of copies specified in the General Requirements. b. Data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Engineer the services, materials, and equipment Contractor proposes to provide and to enable Engineer to review the information for the limited purposes required by Paragraph 6.17.D. 2. Samples: Contractor shall also submit Samples to Engineer for review and approval in accor- dance with the acceptable schedule of Shop Drawings and Sample submittals. a. Submit number of Samples specified in the Specifications. b. Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as Engineer may require to enable Engineer to review the submittal for the limited purposes required by Paragraph 6.17.D. B. Where a Shop Drawing or Sample is required by the Contract Documents or the Schedule of Submittals , any related Work performed prior to Engineer's review and approval of the pertinent submittal will be at the sole expense and responsibility of Contractor. C. Submittal Procedures 1. Before submitting each Shop Drawing or Sample, Contractor shall have determined and verified: a. all field measurements, quantities, dimensions, specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; b. the suitability of all materials with respect to intended use, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; c. all information relative to Contractor's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto; and d. shall also have reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents. 2. Each submittal shall bear a stamp or specific written certification that Contractor has satisfied Contractor's obligations under the Contract Documents EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-23 with respect to Contractor's review and approval of that submittal. 3. With each submittal, Contractor shall give Engineer specific written notice of any variations, that the Shop Drawing or Sample may have from the requirements of the Contract Documents. This notice shall be both a written communication separate from the Shop Drawing's or Sample Submittal; and, in addition, by a specific notation made on each Shop Drawing or Sample submit- ted to Engineer for review and approval of each such variation. D. Engineer's Review 1. Engineer will provide timely review of Shop Drawings and Samples in accordance with the Schedule of Submittals acceptable to Engineer. Engineer's review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Docu- ments. 2. Engineer's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of con- struction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3. Engineer's review and approval shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Paragraph 6.17.C.3 and Engineer has given written approval of each such variation by specific written notation thereof incorporated it or accompanying the Shop Drawing or Sample. Engine s review and approval shall not relieve Contractor frk responsibility for complying with the requirements of raragraph 6.17.C.1. E. Resubmittal Procedures 1. Contractor shall make corrections required by Engineer and shall return the required number of cor- rected copies of Shop Drawings and submit, as required, new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous submittals. 6.18 Continuing the Work A. Contractor shall carry on the Work and adhere to the Progress Schedule during all disputes or disagreements with Owner. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by Paragraph 15.04 or as Owner and Contractor may otherwise agree in writing. 6.19 Contractor's General Warranty and Guarantee A. Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Engineer and its Related Entities shall be entitled to rely on representation of Contractor's warranty and guarantee. B. Contractor's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, modification, or improper maintenance or operation by persons other than Contractor, Sub- contractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2. normal wear and tear under normal usage. C. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor's obligation to perform the Work in accordance with the Contract Documents: 1. observations by Engineer; 2. recommendation by Engineer or payment by Owner of any progress or final payment; 3. the issuance of a certificate of Substantial Completion by Engineer or any payment related thereto by Owner; 4. use or occupancy of the Work or any part thereof by Owner; 5. any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of acceptabil- ity by Engineer; 6. any inspection, test, or approval by others; or 7. any correction of defective Work by Owner. 6.20 Indemnification A. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-24 arbitration or other dispute resolution costs) arising out of or relating to the performance of the Work, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom but only to the extent caused by any negligent act or omission of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work or anyone for whose acts any of them may be liable . B. In any and all claims against Owner or Engineer or any of their respective consultants, agents, officers, directors, partners, or employees by any employ- ee (or the survivor or personal representative of such employee) of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under Paragraph 6.20.A shall not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for Contractor or any such Subcontractor, Supplier, or other individual or entity under workers' compensation acts, disability benefit acts, or other employee benefit acts. C. The indemnification obligations of Contractor under Paragraph 6.20.A shall not extend to the liability of Engineer and Engineer's officers, directors, partners, employees, agents, consultants and subcontractors arising out of: 1. the preparation or approval of, or the failure to prepare or approve, maps, Drawings, opinions, reports, surveys, Change Orders, designs, or Specifications; or 2. giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage. 6.21 Delegation of Professional Design Services A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to carry out Contractor's responsibilities for construction means, methods, techniques, sequences and procedures. Contractor shall not be required to provide professional services in violation of applicable law. B. If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of Contractor by the Contract Documents, Owner and Engineer will specify all performance and design criteria that such services must satisfy. Contractor shall cause such services or certifications to be provided by a properly licensed professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, Shop Drawings and other submittals prepared by such professional. Shop Drawings and other submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional's written approval when submitted to Engineer. C. Owner and Engineer shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided Owner and Engineer have specified to Contractor all performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 6.21, Engineer's review and approval of design calculations and design drawings will be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. Engineer's review and approval of Shop Drawings and other submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 6.17.D.1. E. Contractor shall not be responsible for the adequacy of the performance or design criteria required by the Contract Documents. ARTICLE 7 - OTHER WORK AT THE SITE 7.01 Related Work at Site A. Owner may perform other work related to the Project at the Site with Owner's employees, or via other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Con- tract Documents, then: 1. written notice thereof will be given to Contractor prior to starting any such other work; and 2. if Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim may be made therefor as provided in Paragraph 10.05. B. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner and Owner, if Owner is performing other work with Owner's employees, proper and safe access to the Site, a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work, and shall properly coordinate the Work with theirs. Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-25 properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering their work and will only cut or alter their work with the written consent of Engineer and the others whose work will be affected. The duties and responsibilities of Contractor under this Paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. C. If the proper execution or results of any part of Contractor's Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly report to Engineer in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects and deficiencies in such other work. 7.02 Coordination A. If Owner intends to contract with others for the performance of other work on the Project at the Site, the following will be set forth in Supplementary Condi- tions: 1. the individual or entity who will have authority and responsibility for coordination of the activities among the various contractors will be identified; 2. the specific matters to be covered by such authority and responsibility will be itemized; and 3. the extent of such authority and responsibili- ties will be provided. B. Unless otherwise provided in the Supplementary Conditions, Owner shall have sole authority and responsibility for such coordination. 7.03 Legal Relationships A. Paragraphs 7.01.A and 7.02 are not applicable for utilities not under the control of Owner. B. Each other direct contract of Owner under Paragraph 7.01.A shall provide that the other contractor is liable to Owner and Contractor for the reasonable direct delay and disruption costs incurred by Contractor as a result of the other contractor's actions or inactions. C. Contractor shall be liable to Owner and any other contractor for the reasonable direct delay and disruption costs incurred by such other contractor as a result of Contractor's action or inactions. ARTICLE 8 - OWNER'S RESPONSIBILITIES 8.01 Communications to Contractor A. Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer. 8.02 Replacement of Engineer A. In case of termination of the employment of Engineer, Owner shall appoint an engineer to whom Contractor makes no reasonable objection, whose status under the Contract Documents shall be that of the former Engineer. 8.03 Furnish Data A. Owner shall promptly furnish the data required of Owner under the Contract Documents. 8.04 Pay When Due A. Owner shall make payments to Contractor when they are due as provided in Paragraphs 14.02.0 and 14.07.C. 8.05 Lands and Easements; Reports and Tests A. Owner's duties in respect of providing lands and easements and providing engineering surveys to establish reference points are set forth in Paragraphs 4.01 and 4.05. Paragraph 4.02 refers to Owner's identifying and making available to Contractor copies of reports of explorations and tests of subsurface conditions and drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site that have been utilized by Engineer in preparing the Contract Documents. 8.06 Insurance A. Owner's responsibilities, if any, in respect to purchasing and maintaining liability and property insur- ance are set forth in Article 5. 8.07 Change Orders A. Owner is obligated to execute Change Orders as indicated in Paragraph 10.03. 8.08 Inspections, Tests, and Approvals A. Owner's responsibility in respect to certain inspections, tests, and approvals is set forth in Paragraph 13.03.B. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-26 8.09 Limitations on Owner's Responsibilities A. The Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. 8.10 Undisclosed Hazardous Environmental Condition A. Owner's responsibility in respect to an undis- closed Hazardous Environmental Condition is set forth in Paragraph 4.06. 8.11 Evidence of Financial Arrangements A. If and to the extent Owner has agreed to furnish Contractor reasonable evidence that financial arrangements have been made to satisfy Owner's obligations under the Contract Documents, Owner's responsibility in respect thereof will be as set forth in the Supplementary Conditions. ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION 9.01 Owner's Representative A. Engineer will be Owner's representative during the construction period. The duties and responsi- bilities and the limitations of authority of Engineer as Owner's representative during construction are set forth in the Contract Documents and will not be changed without written consent of Owner and Engineer. 9.02 Visits to Site A. Engineer will make visits to the Site at inter- vals appropriate to the various stages of construction as Engineer deems necessary in order to observe as an experienced and qualified design professional the progress that has been made and the quality of the various aspects of Contractor's executed Work. Based on information obtained during such visits and observations, Engineer, for the benefit of Owner, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. Engineer will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. Engineer's efforts will be directed toward providing for Owner a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, Engineer will keep Owner informed of the progress of the Work and will endeavor to guard Owner against defective Work. B. Engineer's visits and observations are subject to all the limitations on Engineer's authority and responsibility set forth in Paragraph 9.09. Particularly, but without limitation, during or as a result of Engineer's visits or observations of Contractor's Work Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. 9.03 Project Representative A. If Owner and Engineer agree, Engineer will furnish a Resident Project Representative to assist Engineer in providing more extensive observation of the Work. The authority and responsibilities of any such Resident Project Representative and assistants will be as provided in the Supplementary Conditions, and limitations on the responsibilities thereof will be as provided in Paragraph 9.09. If Owner designates another representative or agent to represent Owner at the Site who is not Engineer's consultant, agent or employee, the responsibilities and authority and limitations thereon of such other individual or entity will be as provided in the Supplementary Conditions. 9.04 Authorized Variations in Work A. Engineer may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Docu- ments. These may be accomplished by a Field Order and will be binding on Owner and also on Contractor, who shall perform the Work involved promptly. If Owner or Contractor believes that a Field Order justifies an adjustment in the Contract Price or Contract Times, or both, and the parties are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment , a Claim may be made therefor as provided in Paragraph 10.05. 9.05 Rejecting Defective Work A. Engineer will have authority to reject Work which Engineer believes to be defective, or that Engineer believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Engineer will also have authority to require special inspection or testing of the Work as provided in Paragraph 13.04, whether or not the Work is fabricated, installed, or completed. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. An rights reserved. 00700-27 9.06 Shop Drawings, Change Orders and Payments A. In connection with Engineer's authority, and limitations thereof, as to Shop Drawings and Samples, see Paragraph 6.17. B. In connection with Engineer's authority, and limitations thereof, as to design calculations and design drawings submitted in response to a delegation of professional design services, if any, see Paragraph 6.21. C. In connection with Engineer's authority as to Change Orders, see Articles 10, 11, and 12. D. In connection with Engineer's authority as to Applications for Payment, see Article 14. 9.07 Determinations for Unit Price Work A. Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor. Engineer will review with Contractor the Engineer's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). Engineer's written decision thereon will be final and binding (except as modified by Engineer to reflect changed factual conditions or more accurate data) upon Owner and Contractor, subject to the provisions of Paragraph 10.05. 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work A. Engineer will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. All matters in question and other matters between Owner and Contractor arising prior to the date final payment is due relating to the acceptability of the Work, and the interpretation of the requirements of the Contract Documents pertaining to the performance of the Work, will be referred initially to Engineer in writing within 30 days of the event giving rise to the question B. Engineer will, with reasonable promptness, render a written decision on the issue referred. If Owner or Contractor believe that any such decision entitles them to an adjustment in the Contract Price or Contract Times or both, a Claim may be made under Paragraph 10.05. The date of Engineer's decision shall be the date of the event giving rise to the issues referenced for the purposes of Paragraph 10.05.13. partiality to Owner or Contractor and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. 9.09 Limitations on Engineer's Authority and Responsibilities A. Neither Engineer's authority or responsibility under this Article 9 or under any other provision of the Contract Documents nor any decision made by Engineer in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by Engineer shall create, impose, or give rise to any duty in contract, tort, or otherwise owed by Engineer to Contractor, any Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them. B. Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Engineer will not be respon- sible for Contractor's failure to perform the Work in accordance with the Contract Documents. C. Engineer will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work. D. Engineer's review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by Paragraph 14.07.A will only be to determine generally that their content complies with the require- ments of, and in the case of certificates of inspections, tests, and approvals that the results certified indicate compliance with the Contract Documents. E. The limitations upon authority and responsi- bility set forth in this Paragraph 9.09 shall also apply to, the Resident Project Representative, if any, and assistants, if any. ARTICLE 10 - CHANGES IN THE WORK; CLAIMS 10.01 Authorized Changes in the Work C. Engineer's written decision on the issue referred will be final and binding on Owner and A. Without invalidating the Contract and without Contractor, subject to the provisions of Paragraph 10.05. notice to any surety, Owner may, at any time or from time to time, order additions, deletions, or revisions in the D. When functioning as interpreter and judge Work by a Change Order, or a Work Change Directive. under this Paragraph 9.08, Engineer will not show Upon receipt of any such document, Contractor shall EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-28 promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). B. If Owner and Contractor are unable to agree on entitlement to, or on the amount or extent, if any, of an adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Work Change Directive, a Claim may be made therefor as provided in Paragraph 10.05. 10.02 Unauthorized Changes in the Work A.Contractor shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented as provided in Paragraph 3.04, except in the case of an emergency as provided in Paragraph 6.16 or in the case of uncovering Work as provided in Paragraph 13.04.13. 10.03 Execution of Change Orders A. Owner and Contractor shall execute appropri- ate Change Orders recommended by Engineer covering: 1. changes in the Work which are: (i) ordered by Owner pursuant to Paragraph 10.01.A, (ii) required because of acceptance of defective Work under Paragraph 13.08.A or Owner's correction of defective Work under Paragraph 13.09, or (iii) agreed to by the parties; 2. changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive; and 3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by Engineer pursuant to Paragraph 10.05; provided that, in lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal, Contractor shall carry on the Work and adhere to the Progress Schedule as provided in Paragraph 6.18.A. 10.04 Notification to Surety A. If notice of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times) is required by the provisions of any bond to be given to a surety, the giving of any such notice will be Contractor's responsibility. The amount of each applicable bond will be adjusted to reflect the effect of any such change. 10.05 Claims A. Engineer's Decision Required: All Claims, except those waived pursuant to Paragraph 14.09, shall be referred to the Engineer for decision. A decision by Engineer shall be required as a condition precedent to any exercise by Owner or Contractor of any rights or remedies either may otherwise have under the Contract Documents or by Laws and Regulations in respect of such Claims. B. Notice: Written notice stating the general nature of each Claim, shall be delivered by the claimant to Engineer and the other party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto. The responsibility to substantiate a Claim shall rest with the party making the Claim. Notice of the amount or extent of the Claim, with supporting data shall be delivered to the Engineer and the other party to the Contract within 60 days after the start of such event (unless Engineer allows additional time for claimant to submit additional or more accurate data in support of such Claim). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of Paragraph 12.01.13. A Claim for an adjustment in Contract Time shall be prepared in accordance with the provisions of Paragraph 12.02.13. Each Claim shall be accompanied by claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The opposing party shall submit any response to Engineer and the claimant within 30 days after receipt of the claimant's last submittal (unless Engineer allows additional time). C. Engineer's Action: Engineer will review each Claim and, within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any, take one of the following actions in writing: 1. deny the Claim in whole or in part, 2. approve the Claim, or 3. notify the parties that the Engineer is unable to resolve the Claim if, in the Engineer's sole discretion, it would be inappropriate for the Engineer to do so. For purposes of further resolution of the Claim, such notice shall be deemed a denial. D. In the event that Engineer does not take action on a Claim within said 30 days, the Claim shall be deemed denied. E. Engineer's written action under Paragraph 10.05.0 or denial pursuant to Paragraphs 10.05.C.3 or 10.05.13 will be final and binding upon Owner and Contractor, unless Owner or Contractor invoke the dispute resolution procedure set forth in Article 16 within 30 days of such action or denial. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-29 F. No Claim for an adjustment in Contract Price or Contract Times will be valid if not submitted in accordance with this Paragraph 10.05. ARTICLE 11 - COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK 11.01 Cost of the Work A. Costs Included: The term Cost of the Work means the sum of all costs, except those excluded in Paragraph 11.01.13, necessarily incurred and paid by Contractor in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to Contractor will be only those additional or incremental costs required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by Owner, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall include only the following items, and shall not include any of the costs itemized in Paragraph 11.0I.B. 1. Payroll costs for employees in the direct employ of Contractor in the performance of the Work under schedules of job classifications agreed upon by Owner and Contractor. Such employees shall include, without limitation, superintendents, foremen, and other personnel employed full time at the Site. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits, which shall include social security contributions, unemployment, excise, and payroll taxes, workers' compensation, health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on Saturday, Sunday, or legal holidays, shall be included in the above to the extent authorized by Owner. 2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts shall accrue to Contractor unless Owner deposits funds with Contractor with which to make pay- ments, in which case the cash discounts shall accrue to Owner. All trade discounts, rebates and refunds and Contractor and shall deliver such bids to Owner, who will then determine, with the advice of Engineer, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee shall be determined in the same manner as Contractor's Cost of the Work and fee as provided in this Paragraph 11.01. 4. Costs of special consultants (including but not limited to Engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed for services specifically related to the Work. 5. Supplemental costs including the following: a. The proportion of necessary transportation, travel, and subsistence expenses of Contractor's employees incurred in discharge of duties connected with the Work. b. Cost, including transportation and mainte- nance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site, and hand tools not owned by the workers, which are consumed in the perfor- mance of the Work, and cost, less market value, of such items used but not consumed which remain the property of Contractor. c. Rentals of all construction equipment and machinery, and the parts thereof whether rented from Contractor or others in accordance with rental agreements approved by Owner with the advice of Engineer, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs shall be in accordance with the terms of said rental agreements. The rental of any such equip- ment, machinery, or parts shall cease when the use thereof is no longer necessary for the Work. d. Sales, consumer, use, and other similar taxes related to the Work, and for which Contractor is liable, imposed by Laws and Regulations. e. Deposits lost for causes other than negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. returns from sale of surplus materials and equipment shall f. Losses and damages (and related expenses) accrue to Owner, and Contractor shall make provisions so caused by damage to the Work, not compensated that they may be obtained. by insurance or otherwise, sustained by Contractor in connection with the performance 3. Payments made by Contractor to of the Work (except losses and damages within Subcontractors for Work performed by Subcontractors. If the deductible amounts of property insurance required by Owner, Contractor shall obtain competitive established in accordance with Paragraph bids from subcontractors acceptable to Owner and 5.06. provided such losses and damages have EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright (D 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-30 resulted from causes other than the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of Owner. No such losses, damages, and expenses shall be included in the Cost of the Work for the purpose of determining Contractor's fee. g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, expresses, and similar petty cash items in connection with the Work. i. The costs of premiums for all bonds and insurance Contractor is required by the Contract Documents to purchase and maintain. B. Costs Excluded: The term Cost of the Work shall not include any of the following items: 1. Payroll costs and other compensation of Contractor's officers, executives, principals (of partnerships and sole proprietorships), general managers, safety managers, engineers, architects, estimators, attor- neys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by Contractor, whether at the Site or in Contractor's principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in Paragraph 11.01.A.1 or specifically covered by Paragraph 11.O1.A.4, all of which are to be considered administrative costs covered by the Contractor's fee. 2. Expenses of Contractor's principal and branch offices other than Contractor's office at the Site. 3. Any part of Contractor's capital expenses, including interest on Contractor's capital employed for the Work and charges against Contractor for delinquent payments. 4. Costs due to the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. 5. Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraphs 1 LOLA and 11.01.13. C. Contractor's Fee: When all the Work is performed on the basis of cost -plus, Contractor's fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, Contractor's fee shall be determined as set forth in Paragraph 12.01.C. D. Documentation: Whenever the Cost of the Work for any purpose is to be determined pursuant to Paragraphs I LOLA and 11.01.13, Contractor will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in a form acceptable to Engineer an itemized cost breakdown together with supporting data. 11.02 Allowances A. It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums and by such persons or entities as may be acceptable to Owner and Engineer. B. Cash Allowances 1. Contractor agrees that: a. the cash allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and b. Contractor's costs for unloading and handling on the Site, labor, installation , overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment on account of any of the foregoing will be valid. C. Contingency Allowance 1. Contractor agrees that a contingency allowance, if any, is for the sole use of Owner to cover unanticipated costs. D. Prior to final payment, an appropriate Change Order will be issued as recommended by Engineer to reflect actual amounts due Contractor on account of Work covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.03 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-31 B. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by Contractor will be made by Engineer subject to the provisions of Paragraph 9.07. C. Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractor's overhead and profit for each separately identified item. D. Owner or Contractor may make a Claim for an adjustment in the Contract Price in accordance with Paragraph 10.05 if: 1. the quantity of any item of Unit Price Work performed by Contractor differs materially and signifi- cantly from the estimated quantity of such item indicated in the Agreement; and 2. there is no corresponding adjustment with respect any other item of Work; and 3. Contractor believes that Contractor is entitled to an increase in Contract Price as a result of having incurred additional expense or Owner believes that Owner is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. ARTICLE 12 - CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES 12.01 Change of Contract Price A. The Contract Price may only be changed by a Change Order. Any Claim for an adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be determined as follows: 1. where the Work involved is covered by unit prices contained in the Contract Documents, by applica- tion of such unit prices to the quantities of the items involved (subject to the provisions of Paragraph 11.03); or 2. where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with Paragraph 12.0l.C.2);or 3. where the Work involved is not covered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under Paragraph 12.01.13.2, on the basis of the Cost of the Work (determined as provided in Paragraph 11.01) plus a Contractor's fee for overhead and profit (determined as provided in Paragraph 12.0 LQ. C. Contractor's Fee: The Contractor's fee for overhead and profit shall be determined as follows: 1. a mutually acceptable fixed fee; or 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: a. for costs incurred under Paragraphs 11.01.A.I and 11.01.A.2, the Contractor's fee shall be 15 percent; b. for costs incurred under Paragraph 11.0 LA. 3, the Contractor's fee shall be five percent; c. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of Paragraph 12.01.C.2.a is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under Paragraphs 11.0 LA. 1 and 11.0LA.2 and that any higher tier Subcontractor and Contractor will each be paid a fee of five percent of the amount paid to the next lower tier Subcontractor; d. no fee shall be payable on the basis of costs itemized under Paragraphs 11.0l.A.4, I1.01.A.5, and 11.01.13; e. the amount of credit to be allowed by Contractor to Owner for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a deduction in Contractor's fee by an amount equal to five percent of such net decrease; and f. when both additions and credits are involved in any one change, the adjustment in Contractor's fee shall be computed on the basis of the net change in accordance with Paragraphs 12.01.C.2.a through 12.01.C.2.e, inclusive. 12.02 Change of Contract Times A. The Contract Times may only be changed by a Change Order. Any Claim for an adjustment in the Contract Times shall be based on written notice submitted EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-32 by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. Any adjustment of the Contract Times covered by a Change Order or any Claim for an adjustment in the Contract Times will be determined in accordance with the provisions of this Article 12. 12.03 Delays A. Where Contractor is prevented from completing any part of the Work within the Contract Times due to delay beyond the control of Contractor, the Contract Times will be extended in an amount equal to the time lost due to such delay if a Claim is made therefor as provided in Paragraph 12.02.A. Delays beyond the control of Contractor shall include, but not be limited to, acts or neglect by Owner, acts or neglect of utility owners or other contractors performing other work as contemplat- ed by Article 7, fires, floods, epidemics, abnormal weather conditions, or acts of God. B. If Owner, Engineer, or other contractors or utility owners performing other work for Owner as contemplated by Article 7, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Price or the Contract Times , or both. Contractor's entitlement to an adjustment of the Contract Times is conditioned on such adjustment being essential to Contractor's ability to complete the Work within the Contract Times. C If Contractor is delayed in the performance or progress of the Work by fire, flood, epidemic, abnormal weather conditions, acts of God, acts or failures to act of utility owners not under the control of Owner, or other causes not the fault of and beyond control of Owner and Contractor, then Contractor shall be entitled to an equitable adjustment in Contract Times, if such adjustment is essential to Contractor's ability to complete the Work within the Contract Times. Such an adjustment shall be Contractor's sole and exclusive remedy for the delays described in this Paragraph 12.03.C. D. Owner, Engineer and the Related Entities of each of them shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of Engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. ARTICLE 13 - TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.01 Notice of Defects A. Prompt notice of all defective Work of which Owner or Engineer has actual knowledge will be given to Contractor. All defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.02 Access to Work A. Owner, Engineer, their consultants and other representatives and personnel of Owner, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspecting, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor's Site safety procedures and programs so that they may comply therewith as applicable. 13.03 Tests and Inspections A. Contractor shall give Engineer timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. Owner shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents except: 1. for inspections, tests, or approvals covered by Paragraphs 13.03.0 and 13.03.13 below; 2. that costs incurred in connection with tests or inspections conducted pursuant to Paragraph 13.04.13 shall be paid as provided in said Paragraph 13.04.C; and 3. as otherwise specifically provided in the Con- tract Documents. C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Engineer the required certificates of inspection or approval. E. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delays D. Contractor shall be responsible for arranging within the control of Contractor. Delays attributable to and obtaining and shall pay all costs in connection with and within the control of a Subcontractor or Supplier shall any inspections, tests, or approvals required for Owner's be deemed to be delays within the control of Contractor. and Engineer's acceptance of materials or equipment to EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-33 be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to Owner and Engineer. E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of Engineer, it must, if requested by Engineer, be uncovered for observation. F. Uncovering Work as provided in Paragraph 13.03.E shall be at Contractor's expense unless Contractor has given Engineer timely notice of Contractor's intention to cover the same and Engineer has not acted with reasonable promptness in response to such notice. 13.04 uncovering Work A. If any Work is covered contrary to the written request of Engineer, it must, if requested by Engineer, be uncovered for Engineer's observation and replaced at Contractor's expense. B. If Engineer considers it necessary or advisable that covered Work be observed by Engineer or inspected or tested by others, Contractor, at Engineer's request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as Engineer may require, that portion of the Work in question, furnishing all necessary labor, material, and equipment. C. If it is found that the uncovered Work is defective, Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. D. If, the uncovered Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Times, or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. 13.05 Owner May Stop the Work A. If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, Owner may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of Owner to stop the Work shall not give rise to any duty on the part of Owner to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 13.06 Correction or Removal of Defective Work A. Promptly after receipt of notice, Contractor shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by Engineer, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). B. When correcting defective Work under the terms of this Paragraph 13.06 or Paragraph 13.07, Contractor shall take no action that would void or otherwise impair Owner's special warranty and guarantee, if any, on said Work. 13.07 Correction Period A. If within one year after the date of Substantial Completion (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract Documents) or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made available for Contractor's use by Owner or permitted by Laws and Regulations as contemplated in Paragraph 6.11.A is found to be defective, Contractor shall promptly, without cost to Owner and in accordance with Owner's written instructions: 1. repair such defective land or areas; or 2. correct such defective Work; or 3. if the defective Work has been rejected by Owner, remove it from the Project and replace it with Work that is not defective, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright C 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-34 B. If Contractor does not promptly comply with the terms of Owner's written instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or repaired or may have the rejected Work re- moved and replaced. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. C. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications . D. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this Paragraph 13.07, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. E. Contractor's obligations under this Paragraph 13.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 13.07 shall not be construed as a substitute for or a waiver of the provisions of any applicable statute of limitation or repose. 13.08 Acceptance of Defective Work A. If, instead of requiring correction or removal and replacement of defective Work, Owner (and, prior to Engineer's recommendation of final payment, Engineer) prefers to accept it, Owner may do so. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to Owner's evaluation of and determination to accept such defective Work (such costs to be approved by Engineer as to reasonableness) and the diminished value of the Work to the extent not otherwise paid by Contractor pursuant to this sentence. If any such acceptance occurs prior to Engineer's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and Owner shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work so accepted. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. If the acceptance occurs after such recommendation, an appropriate amount will be paid by Contractor to Owner. 13.09 Owner May Correct Defective Work A. If Contractor fails within a reasonable time.. after written notice from Engineer to correct defective Work or to remove and replace rejected Work as required by Engineer in accordance with Paragraph 13.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, Owner may, after seven days written notice to Contractor, correct or remedy any such deficiency. B. In exercising the rights and remedies under this Paragraph 13.09, Owner shall proceed expeditiously. In connection with such corrective or remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, take posses- sion of Contractor's tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's representatives, agents and employees, Owner's other contractors, and Engineer and Engineer's consultants access to the Site to enable Owner to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount of the adjustment, Owner may make a Claim therefor as provided in Paragraph 10.05. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor's defective Work. D. Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to the exercise by Owner of Owner's rights and remedies under this Paragraph 13.09. ARTICLE 14 - PAYMENTS TO CONTRACTOR AND COMPLETION 14.01 Schedule of Values A. The Schedule of Values established as provid- ed in Paragraph 2.07.A will serve as the basis for progress EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-35 payments and will be incorporated into a form of Applica- tion for Payment acceptable to Engineer. Progress payments on account of Unit Price Work will be based on the number of units completed. 14.02 Progress Payments A. Applications for Payments 1. At least 20 days before the date established in the Agreement for each progress payment (but not more often than once a month), Contractor shall submit to Engineer for review an Application for Payment filled out and signed by Contractor covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other documentation warranting that Owner has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect Owner's interest therein, all of which must be satisfactory to Owner. 2. Beginning with the second Application for Payment, each Application shall include an affidavit of Contractor stating that all previous progress payments received on account of the Work have been applied on account to discharge Contractor's legitimate obligations associated with prior Applications for Payment. 3. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. B. Review of Applications 1. Engineer will, within 10 days after receipt of each Application for Payment, either indicate in writing a recommendation of payment and present the Application to Owner or return the Application to Contractor indicating in writing Engineer's reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the Application. 2. Engineer's recommendation of any payment requested in an Application for Payment will constitute a representation by Engineer to Owner, based on Engineer's observations on the Site of the executed Work as an experienced and qualified design professional and on Engineer's review of the Application for Payment and the accompanying data and schedules, that to the best of Engineer's knowledge, information and belief: a. the Work has progressed to the point indicat- ed; b. the quality of the Work is generally in accor- dance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the results of any subsequent tests called for in the Contract Documents, to a final determination of quantities and classifications for Unit Price Work under Paragraph 9.07, and to any other qualifications stated in the recommendation); and c. the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe the Work. 3. By recommending any such payment Engineer will not thereby be deemed to have represented that: a. inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsi- bilities specifically assigned to Engineer in the Contract Documents; or b. that there may not be other matters or issues between the parties that might entitle Contractor to be paid additionally by Owner or entitle Owner to withhold payment to Contractor. 4. Neither Engineer's review of Contractor's Work for the purposes of recommending payments nor Engineer's recommendation of any payment, including final payment, will impose responsibility on Engineer: a. to supervise, direct, or control the Work, or b. for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or c. for Contractor's failure to comply with Laws and Regulations applicable to Contractor's performance of the Work, or d. to make any examination to ascertain how or for what purposes Contractor has used the moneys paid on account of the Contract Price, or e. to determine that title to any of the Work, materials, or equipment has passed to Owner free and clear of any Liens. 5. Engineer may refuse to recommend the whole or any part of any payment if, in Engineer's opinion, it would be incorrect to make the representations to Owner stated in Paragraph 14.02.B.2. Engineer may also refuse to recommend any such payment or, because of subse- quently discovered ev idence or the results of s u bs equent EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-36 inspections or tests, revise or revoke any such payment recommendation previously made, to such extent as may be necessary in Engineer's opinion to protect Owner from loss because: a. the Work is defective, or completed Work has been damaged, requiring correction or replace- ment; b. the Contract Price has been reduced by Change Orders; c. Owner has been required to correct defective Work or complete Work in accordance with Paragraph 13.09; or d. Engineer has actual knowledge of the occurrence of any of the events enumerated in Paragraph 15.02.A. C. Payment Becomes Due 1. Ten days after presentation of the Application for Payment to Owner with Engineer's recommendation, the amount recommended will (subject to the provisions of Paragraph 14.02.1)) become due, and when due will be paid by Owner to Contractor. D. Reduction in Payment 1. Owner may refuse to make payment of the full amount recommended by Engineer because: a. claims have been made against Owner on account of Contractor's performance or furnish- ing of the Work; b. Liens have been filed in connection with the Work, except where Contractor has delivered a specific bond satisfactory to Owner to secure the satisfaction and discharge of such Liens; c. there are other items entitling Owner to set -off against the amount recommended; or d. Owner has actual knowledge of the occurrence of any of the events enumerated in Paragraphs 14.02.B.5.a through 14.02.B.5.c or Paragraph 15.02.A. 2. If Owner refuses to make payment of the full amount recommended by Engineer, Owner will give Contractor immediate written notice (with a copy to Engineer) stating the reasons for such action and promptly pay Contractor any amount remaining after deduction of the amount so withheld. Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by Owner and Contractor, when Contractor corrects to Owner's satisfaction the reasons for such action. 3. If it is subsequently determined that Owner's refusal of payment was not justified, the amount wrongfully withheld shall be treated as an amount due as determined by Paragraph 14.02.C.1. 14.03 Contractor's Warranty of Title A. Contractor warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to Owner no later than the time of payment free and clear of all Liens. 14.04 Substantial Completion A. When Contractor considers the entire Work ready for its intended use Contractor shall notify Owner and Engineer in writing that the entire Work is substantially complete (except for items specifically listed by Contractor as incomplete) and request that Engineer issue a certificate of Substantial Completion. B. Promptly after Contractor's notification, , Owner, Contractor, and Engineer shall make an inspection of the Work to determine the status of completion. If Engineer does not consider the Work substantially complete, Engineer will notify Contractor in writing giving the reasons therefor. C. If Engineer considers the Work substantially complete, Engineer will deliver to Owner a tentative certificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or corrected before final payment. Owner shall have seven days after receipt of the tentative certificate during which to make written objection to Engineer as to any provisions of the certificate or attached list. If, after considering such objections, Engineer concludes that the Work is not substantially complete, Engineer will within 14 days after submission of the tentative certificate to Owner notify Contractor in writing, stating the reasons therefor. If, after consideration of Owner's objections, Engineer considers the Work substantially complete, Engineer will within said 14 days execute and deliver to Owner and Contractor a definitive certificate of Substantial Completion (with a revised tentative list of items to be completed or correct- ed) reflecting such changes from the tentative certificate as Engineer believes justified after consideration of any objections from Owner. D. At the time of delivery of the tentative certificate of Substantial Completion, Engineer will deliver to Owner and Contractor a written recommen- dation as to division of responsibilities pending final payment between Owner and Contractor with respect to security, operation, safety, and protection of the Work, maintenance, heat, utilities, insurance, and warranties and guarantees. Unless Owner and Contractor agree otherwise in writing and so inform Engineer in writing prior to Engineer's issuing the definitive ce rtificate of S ub s tantial EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-37 Completion, Engineer's aforesaid recommendation will be binding on Owner and Contractor until final payment. E. Owner shall have the right to exclude Contractor from the Site after the date of Substantial Completion subject to allowing Contractor reasonable access to complete or correct items on the tentative list. 14.05 Partial Utilization A. Prior to Substantial Completion of all the Work, Owner may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which Owner, Engineer, and Contractor agree constitutes a separately functioning and usable part of the Work that can be used by Owner for its intended purpose without significant interference with Contractor's performance of the remainder of the Work, subject to the following condi- tions. 1. Owner at any time may request Contractor in writing to permit Owner to use or occupy any such part of the Work which Owner believes to be ready for its intended use and substantially complete. If and when Contractor agrees that such part of the Work is substantially complete, Contractor will certify to Owner and Engineer that such part of the Work is substantially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work. 2. Contractor at any time may notify Owner and Engineer in writing that Contractor considers any such part of the Work ready for its intended use and substan- tially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work. 3. Within a reasonable time after either such request, Owner, Contractor, and Engineer shall make an inspection of that part of the Work to determine its status of completion. If Engineer does not consider that part of the Work to be substantially complete, Engineer will notify Owner and Contractor in writing giving the reasons therefor. If Engineer considers that part of the Work to be substantially complete, the provisions of Paragraph 14.04 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 4. No use or occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of Paragraph 5.10 regarding property insurance. 14.06 Final Inspection A. Upon written notice from Contractor that the entire Work or an agreed portion thereof is complete, Engineer will promptly make a final inspection with Owner and Contractor and will notify Contractor in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 14.07 Final Payment A. Application for Payment 1. After Contractor has, in the opinion of Engineer, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance certificates of inspection, marked -up record documents (as provided in Paragraph 6.12), and other documents, Contractor may make application for final payment following the procedure for progress payments. 2. The final Application for Payment shall be accompanied (except as previously delivered) by: a. all documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by Paragraph 5.04.13.7; b. consent of the surety, if any, to final payment; c. a list of all Claims against Owner that Contractor believes are unsettled; and d. complete and legally effective releases or waivers (satisfactory to Owner) of all Lien rights arising out of or Liens filed in connection with the Work. 3. In lieu of the releases or waivers of Liens specified in Paragraph 14.07.A.2 and as approved by Owner, Contractor may furnish receipts or releases in full and an affidavit of Contractor that: (i) the releases and receipts include all labor, services, material, and equipment for which a Lien could be filed; and (ii) all payrolls, material and equipment bills, and other indebtedness connected with the Work for which Owner or Owner's property might in any way be responsible have been paid or otherwise satisfied. If any Subcontractor or Supplier fails to furnish such a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to Owner to indemnify Owner against any Lien. B. Engineer's Review of Application and Acceptance 1. If, on the basis of Engineer's observation of the Work during construction and final inspection, and Engineer's review of the final Application for Payment and accompanying documentation as required by the Contract Documents, Engineer is satisfied that the Work has been completed and Contract other obligat EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-38 under the Contract Documents have been fulfilled, Engineer will, within ten days after receipt of the final Application for Payment, indicate in writing Engineer's recommendation of payment and present the Application for Payment to Owner for payment. At the same time Engineer will also give written notice to Owner and Contractor that the Work is acceptable subject to the provisions of Paragraph 14.09. Otherwise, Engineer will return the Application for Payment to Contractor, indicat- ing in writing the reasons for refusing to recommend final payment, in which case Contractor shall make the necessary corrections and resubmit the Application for Payment. C. Payment Becomes Due 1. Thirty days after the presentation to Owner of the Application for Payment and accompanying docu- mentation, the amount recommended by Engineer, less any sum Owner is entitled to set off against Engineer's recommendation, including but not limited to liquidated damages, will become due and , will be paid by Owner to Contractor. 14.08 Final Completion Delayed A. If, through no fault of Contractor, final completion of the Work is significantly delayed, and if Engineer so confirms, Owner shall, upon receipt of Contractor's final Application for Payment (for Work fully completed and accepted) and recommendation of Engineer, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by Owner for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if bonds have been furnished as required in Paragraph 5.01, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by Contractor to Engineer with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. 14.09 Waiver of Claims A. The making and acceptance of final payment will constitute: 1. a waiver of all Claims by Owner against Contractor, except Claims arising from unsettled Liens, from defective Work appearing after final inspection pursuant to Paragraph 14.06, from failure to comply with the Contract Documents or the terms of any special guarantees specified therein, or from Contractor's continuing obligations under the Contract Documents; and 2. a waiver of all Claims by Contractor against Owner other than those previously made in accordance with the requirements herein and expressly acknowledged by Owner in writing as still unsettled. ARTICLE 15 - SUSPENSION OF WORK AND TERMINATION 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 90 consecutive days by notice in writing to Contractor and Engineer which will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be granted an adjust- ment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension if Contractor makes a Claim therefor as provided in Paragraph 10.05. 15.02 Owner May Terminate for Cause A. The occurrence of any one or more of the following events will justify termination for cause: 1. Contractor's persistent failure to perform the Work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the Progress Schedule established under Paragraph 2.07 as adjusted from time to time pursuant to Paragraph 6.04); 2. Contractor's disregard of Laws or Regulations of any public body having jurisdiction; 3. Contractor's disregard of the authority of Engineer; or 4. Contractor's violation in any substantial way of any provisions of the Contract Documents. B. If one or more of the events identified in Paragraph 15.02.A occur, Owner may, after giving Contractor (and surety ) seven days written notice of its intent to terminate the services of Contractor: 1. exclude Contractor from the Site, and take possession of the Work and of all Contractor's tools, appliances, construction equipment, and machinery at the Site, and use the same to the full extent they could be used by Contractor (without liability to Contractor for trespass or conversion), 2. incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere, and EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-39 expedient. complete the Work as Owner may deem C. If Owner proceeds as provided in Paragraph 15.02.11, Contractor shall not be entitled to receive any further payment until the Work is completed. If the unpaid balance of the Contract Price exceeds all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Owner arising out of or relating to completing the Work, such excess will be paid to Contractor. If such claims, costs, losses, and damages exceed such unpaid balance, Contractor shall pay the difference to Owner. Such claims, costs, losses, and damages incurred by Owner will be reviewed by Engineer as to their reasonableness and, when so approved by Engineer, incorporated in a Change Order. When exercising any rights or remedies under this Paragraph Owner shall not be required to obtain the lowest price for the Work performed. D. Notwithstanding Paragraphs 15.02.13 and 15.02.C, Contractor's services will not be terminated if Contractor begins within seven days of receipt of notice of intent to terminate to correct its failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt of said notice. E. Where Contractor's services have been so terminated by Owner, the termination will not affect any rights or remedies of Owner against Contractor then existing or which may thereafter accrue. Any retention or payment of moneys due Contractor by Owner will not release Contractor from liability. F. If and to the extent that Contractor has provided a performance bond under the provisions of Paragraph 5.01.A, the termination procedures of that bond shall supersede the provisions of Paragraphs 15.02.13, and 15.02.C. 15.03 Owner May Terminate For Convenience A. Upon seven days written notice to Contractor and Engineer, Owner may, without cause and without prejudice to any other right or remedy of Owner, terminate the Contract. In such case, Contractor shall be paid for (without duplication of any items): 1. completed and acceptable Work executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasonable sums for overhead and profit on such Work; 2. expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials, or equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; 3. all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred in settlement of terminated contracts with Subcontractors, Suppliers, and others; and 4. reasonable expenses directly attributable to termination. B. Contractor shall not be paid on account of loss of anticipated profits or revenue or other economic loss arising out of or resulting from such termination. 15.04 Contractor May Stop Work or Terminate A. If, through no act or fault of Contractor, (i) the Work is suspended for more than 90 consecutive days by Owner or under an order of court or other public authority, or (ii) Engineer fails to act on any Application for Payment within 30 days after it is submitted, or (iii) Owner fails for 30 days to pay Contractor any sum finally determined to be due, then Contractor may, upon seven days written notice to Owner and Engineer, and provided Owner or Engineer do not remedy such suspension or failure within that time, terminate the Contract and recover from Owner payment on the same terms as provided in Paragraph 15.03. B. In lieu of terminating the Contract and without prejudice to any other right or remedy, if Engineer has failed to act on an Application for Payment within 30 days after it is submitted, or Owner has failed for 30 days to pay Contractor any sum finally determined to be due, Contractor may, seven days after written notice to Owner and Engineer, stop the Work until payment is made of all such amounts due Contractor, including interest thereon. The provisions of this Paragraph 15.04 are not intended to preclude Contractor from making a Claim under Paragraph 10.05 for an adjustment in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to Contractor's stopping the Work as permitted by this Paragraph. ARTICLE 16 - DISPUTE RESOLUTION 16.01 Methods and Procedures A. Either Owner or Contractor may request mediation of any Claim submitted to Engineer for a decision under Paragraph 10.05 before such decision becomes final and binding. The mediation will be EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-40 governed by the Construction Industry Mediation Rules of the American Arbitration Association in effect as of the Effective Date of the Agreement. The request for mediation shall be submitted in writing to the American Arbitration Association and the other party to the Contract. Timely submission of the request shall stay the effect of Paragraph 10.05.E. B. Owner and Contractor shall participate in the mediation process in good faith. The process shall be concluded within 60 days of filing of the request. The date of termination of the mediation shall be determined by application of the mediation rules referenced above. C. If the Claim is not resolved by mediation, Engineer's action under Paragraph 10.05.0 or a denial pursuant to Paragraphs 10.05.C.3 or 10.05.1) shall become final and binding 30 days after termination of the mediation unless, within that time period, Owner or Contractor: 1. elects in writing to invoke any dispute resolution process provided for in the Supplementary Conditions, or 2. agrees with the other party to submit the Claim to another dispute resolution process, or 3. gives written notice to the other party of their intent to submit the Claim to a court of competent jurisdiction. ARTICLE 17 - MISCELLANEOUS 17.01 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if: 1. delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or 2. delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. 17.02 Computation of Times A. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. 17.03 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regula- tions, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 17.04 Survival of Obligations A. All representations, indemnifications, warran- ties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Docu- ments, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 17.05 Controlling Law A. This Contract is to be governed by the law of the state in which the Project is located. 17.06 Headings A. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. EJCDC C -700 Standard General Conditions of the Construction Contract. Copyright © 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700-41 Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): Northwest Asphalt, Inc. 1451 Stagecoach Road Shakopee, MN 55379 OWNER (Name and Address): City of New Hope 4401 Xylon Avenue North New Hope, MN 55428 CONTRACT Date: May 31, 2007 Amount: $484,122.61 Description (Name and Location) SURETY (Name and Address of Principal Place of Business): Western Surety Company P.O. Box 5077 Sioux Falls, SD 57117 -5077 2007 Infrastructure Improvements Project City Project No. 816 BOND Bond Number: 929 406 134 Date (Not earlier than Contract Date): May 31, 2007 Amount: $484.122.61 Modifications to this Bond Form: None Surety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side of hereof, do each cause this Performance Bond to be duly executed on its behalf by its authorized officer, agent or representative. CONTRACTOR AS PRINCIPAL Company: NORTHWESV ASPHALT, INC. Signature: L _(Seal) 1:Ve 3 Name and Title: Michael B. P e dent (Space is provided be! ow for signatures of additional parties, if required) CONTRACTGR AS PRINCIPAL Company: Name and Title: SURETY Company: WESTER SU } TY COMPAN (Seal) Surety's am attd Corporate �`e 1 Signatu and Title: Teresa Hammers, Attorney -In -Fact (Attach Power of Attorney) Attest: i (Seal) Signature and title SURETY (Seal) Surety's Name and Corporate Seal By: Signature and Title (Attach Power of Attorney) Attest: Signature and Title EJCDC No. C -610 (2002 Edition) Originally prepared through the joint efforts of the Surety Association of America, Engineers Joint Contract Documents Committee, the Associated General Contractors of America, and the American Institute of Architects. 06610 -1 1. Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Contract, which is incorporated herein by reference. 2. If Contractor performs the Contract, the Surety and Contractor have no obligation under this Bond, except to participate in conferences as provided in paragraph 3.1. 3. 1f there is no Owner Default, the Surety's obligation under this Bond shall arise after: 3.1. Owner has notified Contractor and the Surety at the addresses described in paragraph 10 below, that Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with Contractor and the Surety to be held not later than fifteen days after receipt of such notice to discuss methods of performing the Contract. If Owner, Contractor and the Surety agree, Contractor shall be allowed a reasonable time to perform the Contract, but such au agreement shall not waive Owner's right, if any, subsequently to declare a Contractor Default; and 3.2. Owner has declared a Contractor Default and formally terminated Contractor's right to complete the Contract. Such Contractor Default shall not be declared earlier than twenty days after Contractor and the Surety have received notice as provided in paragraph 3.1: and 3.3. Owner has agreed to pay the Balance ofthe Contract Price to: L Surety in accordance with the teens ofthe Contract; 2. Another contractor selected pursuant to paragraph 43 to perform the Contract 4. When Owner has satisfied the conditions of paragraph 3, the Surety shall promptly and at Surety's expense take one ofthe following actions: 4.1. Arrange for Contractor, with consent of Owner, to perform and complete the Contract, or 4.2. Undertake to perform and complete the Contract itself, through its agents or through independent contractors; or 43. Obtain bids or negotiated proposals from qualified contractors acceptable to Owner for a contract for performance and completion of the Contract, arrange far a contract to be prepared for execution by Owner and the contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the Bonds issued on the Contract, and pay to the Owner the amount of damages as described in paragraph 6 in excess of the Balance of the Contract Price incurred by the Owner resulting from the Contractor Default; or 4.4. Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances; 1. After investigation, determine the amount for which it may be liable to Owner and, as soon as practicable after the amount is determined, tender payment therefore to Owner; or 2. Deny liability in whole or in part and notify Owner citing reasons therefore. 5. If Surety does not proceed as provided in paragraph 4 with reasonable promptness, Surety shall be deemed to be in default on this Bond 15 days after receipt of an additional written notice from Owner to the Surety demanding that the Surety perform its obligations under this Bond, and Owner shall be entitled to enforce any remedy available to Owner. If Surety proceeds as provided in paragraph 4.4, and Owner refuses the payment tender or Surety has denied pliability, in whole or in part, without further notice Owner shall be entitled to enforce any remedy available to Owner. 6. After the Owner has terminated Contractor's right to complete the Contract, and if Surety elects to act under paragraph 4.1, 4.2, or 4.3 above, then the responsibilities ofthe Surety to Owner shall not be greater than those of Contractor under the Contract, and the responsibilities of Owner to Surety shall not be greater than those of Owner under the Contract. To a limit ofthe amount of this Bond, but subject to commitment by Owner of the Balance of the Contract Price to mitigation of costs and damages on the Contract, Surety is obligated without duplication for: 6.1. The responsibilities of Contractor for correction of defective Work and completion ofthe Contract; 6.2. Additional legal, design professional and delay costs resulting from Contractor's Default, and resulting from the actions or failure to act of Surety under paragraph 4; and 6.3. Liquidated damages, or if no liquidated damages are specified in the Contract, actual damages caused by delayed performance or non- performance of Contractor. 7. Surety shall not be liable to the Owner or others for obligations of Contractor that are unrelated to the Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than Owner or its heirs, executors, administrators, or successors. 8. Surety hereby waives notice of any change, including changes of time, to the Contract or to related subcontracts, purchase orders and other obligations. 9. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the Work or part of the Work is located and shall be instituted within two years after Contractor Default or within two years after Contractor ceased working or within two years after Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction ofthe suit shall be applicable. 10. Notice to Surety, Owner or Contractor shall be mailed or delivered to the address shown on the signature page. 11. When this Bond has been furnished to comply with a statutory requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12. Definitions. 12.1. Balance of the Contract Price: The total amount payable by Owner to Contractor under the Contract after all property adjustments have been made, including allowance to Contractor of any amounts received or to be received by Owner in settlement of insurance or other Claims for damages to which Contractor is entitled, reduced by all valid and proper payments made to or on behalf of Contractor under the Contract. 12.2. Contract: The agreement between Owner and Contractor identified on the signature page, including all Contract Documents and changes thereto. 12.3. Contractor Default: Failure of Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Contract. 12.4. Owner Default: Failure of Owner, which has neither been remedied nor waived, to pay Contractor as required by the Contract or to perform and complete or comply with the other terms thereof. FOR INFORMATION ONLY - Name, Address and Telephone Surety Agency or Broker Owner's representative (engineer or to the party) Wells Fargo Insurance Services 4300 MarketPointe Drive, Suite 600 Bloomington, MN 55435 952 - 830 -3000 Owner's Representative: Bonestroo 2335 Highway 36 West St. Paul, MN 55113 06610 -1 �' • • T -" STATE OF MINNESOTA COUNTY OF SCOTT On this 31 st day of May, 2007 before me personally appeared Michael B. Pfeiffer to me known, who being by me duly sworn, that he /she is the President of the Northwest Asphalt, Inc. the corporation described in and which executed the foregoing instrument; that he /she knows the seal of said corporation; that the seal affixed to said instrument is such corporate seal; that it was so affixed by order of the Board of Directors of said corporation; and that he /she signed his /her name thereto by like order. `SHEILA N. GEIBE - NO1 ARYPUBLIC- MINNES 7 My rA xnmission Expires Jan, 31, 2010 (Notary Public) ACKNOWLEDGMENT OF CORPORATE SURETY STATE OF MINNESOTA COUNTY OF HENNEPIN On this 31 st day of May, 2007 before me appeared Teresa Hammers to be known, who being by me duly sworn, did say that she is the aforesaid Attorney -in -Fact of the Western Surety Company, a corporation; that the seal affixed to the foregoing instrument is the corporate seal of said corporation, and that said instrument was signed and sealed on behalf of said corporation by the aforesaid officer, by authority of its Board of directors; and the aforesaid officer acknowledged said instrument to be the free act and deed of said corporation. (Nota Pu ac) TOD I ELS' 7 friary P€ bHc h-,n sct s x My Cornrn:ssion Expires Jail 31, r'0 -, POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint William K Velin, James R Perkins, Amy M Burns, Teresa Hammers, Steven C Aronson, Nathan P Hughes, Laurent R Laventure, Stanley L Pearson, Janet D Buerg, Kathleen Sorenson, Todd A Kelsey, Gordon L Johnson, John D Moore, Individually of Bloomington, MN, its true and lawful Attorneys) -in -Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Senior Vice President and its corporate seal to be hereto affixed on this 22nd day of March, 2007. WESTERN SURETY COMPANY WQt'v0a' ~ �N OPµ01 Paul . Bruflat, Senior Vice President State of South Dakota ss County of Minnehaha On this 22nd day of March, 2007, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Senior Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires th44444444444444444444h44 } s D. KRELL i November 30, 2012 s AE NOTARY PUBLIC Epg s s SOUTH DAKOTA s X44444444444444444444444 + D, Krell, No ary Public CERTIFICATE I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this 31 St day of May ' 2007 a r°SVaEry4yr ' , saw�40R ° °£ WESTERN SURETY COMPANY gat G� qT� =ox iz L. Nelson, Assistant Secretary Form F4280 -09 -06 Authorizing By -Law ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. I I • 1 Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): Northwest Asphalt, Inc. 1451 Stagecoach Road Shakopee, MN 55379 OWNER (Name and Address): City of New Hope 4401 Xylon Avenue North New Hope, MN 55428 CONTRACT Date: May 31, 2007 Amount: $484,122.61 Description (Name and Location) SURETY (Name and Address of Principal Place of Business): Western Surety Company P.O. Box 5077 Sioux Falls, SD 57117 -5077 2007 Infrastructure Improvements Project City Project No. 816 BOND Bond Number: 929 406 134 Date (Not earlier than Contract Date): May 31, 2007 Amount: $484,122.61 Modifications to this Bond Form: None Surety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reverse side of hereof, do each cause this Payment Bond to be duly executed on its behalf by its authorized officer, agent or representative. CONTRACTOR AS PRINCIPAL Company: NORTHWEST ASPHALT, INC. Signature: (Seal) Name and Title: Michael B. Pfeif t (Space is provided below for signatures of additional parties, if required) CONTRACTOR AS PRINCIPAL Company: Name and Title: SURETY Company: WESTER § ETY COMPANY (Seal) Surety's am' Oid Corporate al Signature and Title: Teresa Hammers, Attorney -In -Fact (Attach Power of ttorney) 4 Attest: /l (Seal) Signature a Title SURETY (Seal) Surety's Name and Corporate Seal By: Signature and Title (Attach Power of Attorney) Attest: Signature and Title EJCDC No. C -615 (2002 Edition) Originally prepared through the joint efforts of the Surety Association of America, Engineers Joint Contract Documents Committee, the Associated General Contractors of America, and the American Institute of Architects, the American Subcontractors Association, and the Associated Specialty Contractors. 06615 -1 1. Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to Owner to pay for labor, materials and equipment furnished for use in the performance of the Contract, which is incorporated herein by reference. 2. With respect to Owner, this obligation shall be null and void if Contractor:: 2.1. Promptly males payment, directly or indirectly, for all sums due Claimants, and 2.2. Defends, indemnities and holds harmless Owner from all claims, demands, liens or suits alleging non - payment by Contractor by any person or entity who furnished labor, materials, or equipment for use in the performance of the Contract, provided Owner has promptly notified Contractor and Surety (at the addresses described in Paragraph 12) of any claims, demands, liens, or suits and tender defense of such claims, demands, liens or suits to Contractor and Surety, and provided there is no Owner Default. 3. With respect to Claimants, this obligation shall be null and void if Contractor promptly makes payment, directly or indirectly, for all sums due. 4. Surety shall have no obligation to Claimants under this Bond until: 4.1. Claimants who are employed by or have a direct contract with Contractor have given notice to Surety (at the addresses described in paragraph 12) and sent a copy, or notice thereof, to Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2. Claimants who do not have a direct contract with Contractor: I-lave furnished written notice to Contractor and sent a copy, or notice thereof, to Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed; and 8. Amounts owed by Owner to Contractor under the Contract shall be used for the performance of the Contract and to satisfy claims, if any, under any Performance Bond. By Contractor furnishing and Owner accepting this Bond, they agree that all funds earned by Contractor in the performance of the Contract are dedicated to satisfy obligations of Contractor and the Surety under this Bond, subject to Owner's priority to use the funds for the completion of the Work. 9. Surety shall not be liable to Owner, Claimants or others for obligations of Contractor that are unrelated to the Contract. Owner shall not be liable for payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligations to make payments to, give notices on behalf of or otherwise have obligations to Claimants under this Bond. 10. Surety hereby waives notice of any change, including changes of time, to the Contract or to related Subcontracts, purchase orders and other obligations. 11. No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the location in which the Work or part of the Work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by paragraph 4.1 or paragraph 4.2.3 or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) of (2) first occurs. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12. Notice to the Surety, Owner or Contractor shall be mailed or delivered to the addresses shown on the signature page. Actual receipt of notice by Surety, Owner or the Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13. When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted here from and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is, that this Bond shall be construed as a statutory Bond and not as a common law bond. 2. Have either received a rejection in whole or in part from Contractor 14. Upon request of any person or entity appearing to be a potential beneficiary or not received within 30 days of furnishing the above notice any of this Bond, Contractor shall promptly furnish a copy of this Bond or shall permit communication from Contractor by which Contractor had indicated a copy to be made. the claim will be paid directly or indirectly; and 15. DEFINITIONS 3. Not having been paid within the above 30 days, have sent a written notice to the Surety and sent a copy, or notice thereof, to Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to Contractor 5. If a notice required by paragraph 4 is given by Owner to Contractor or to the Surety, that is sufficient compliance. 6. When the Claimant has satisfied the conditions of paragraph 4, the Surety shall promptly and at the Surety's expense take the following actions: 6.1. Send an answer to the Claimant, with a copy to Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed. 6.2. Pay or arrange for payment of any undisputed amounts. 15.1.Claimant: An individual or entity having a direct contract with Contractor or with a Subcontractor of Contractor to furnish labor, materials or equipment for use in the performance of the Contract. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment' that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Contract, architectural and engineering services required for performance of the Work of Contractor and Contractor's Subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. 15.2.Contract: The agreement between Owner and Contractor identified on the signature page, including all Contract Documents and changes thereto. 7. The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by the Surety 15.3.Owner Default: Failure of Owner, which has neither been remedied nor waived, to pay Contractor as required by the Contract or to perform and complete or comply with the other terms thereof. FOR INFORMATION ONLY - Name, Address and Telephone Surety Agency or Broker Owner's representative (engineer or to the parry) Wells Fargo Insurance Services 4300 MarketPointe Drive, Suite 600 Bloomington, MN 55435 952 - 830 -3000 Owner's Representative: Bonestroo 2335 Highway 36 West St. Paul, MN 55113 06615 -1 CORPORATE ACKNOWLEDGMENT STATE OF MINNESOTA COUNTY OF SCOTT On this 31 st day of May, 2007 before me personally appeared Michael B. Pfeiffer to me known, who being by me duly sworn, that he /she is the President of the Northwest Asphalt, Inc. the corporation described in and which executed the foregoing instrument; that he /she knows the seal of said corporation; that the seal affixed to said instrument is such corporate seal; that it was so affixed by order of the Board of Directors of said corporation; and that he /she signed his /her name thereto by like order. SW ILA N. GEIBE N01 rlaRY PUBLIC - MINNESOTA MY Q mission Expires Jan. 31, 2010 (Notary Public) X1 t 1ll_ 11 1 0 � l Uii 1 1 iA& STATE OF MINNESOTA COUNTY OF HENNEPIN On this 31 st day of May, 2007 before me appeared Teresa Hammers to be known, who being by me duly sworn, did say that she is the aforesaid Attorney -in -Fact of the Western Surety Company, a corporation; that the seal affixed to the foregoing instrument is the corporate seal of said corporation, and that said instrument was signed and sealed on behalf of said corporation by the aforesaid officer, by authority of its Board of directors; and the aforesaid officer acknowledged said instrument to be the free act and deed of said corporation. (Notary"PubligK ) TO DD A. KELS Notary Public- (Minnesota PAY Commission Expires Jan 31, 2 Western Surety Comp POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and sea] herein affixed hereby make, constitute and appoint William K Velin, James R Perkins, Amy M Burns, Teresa Hammers, Ste_ ven C Aronson, Nathan P Hughes, Laurent R Laventure, Stanley L Pearson, Janet D Buerg, Kathleen Sorenson, Todd A Kelsey, Gordon L Johnson, John D Moore, Individually of Bloomington, MN, its true and lawful Attorney(s) -in -Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Senior Vice President and its corporate seal to be hereto affixed on this 22nd day of March, 2007. �s�REr• WESTERN SURETY COMPANY =W�40 r� }q2 pX SLAV g�S / Paul 4rBruflat, Senior Vice President State of South Dakota ss County of Minnehaha On this 22nd day of March, 2007, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Senior Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires }hhh hhhhhhhhhhhhhhhhhhhhh } s D. KRELL s November 30, 2012 s SEAL NOTARY PUBLIC SS s s SOUTH DAKOTA s "�'hhhhhhhhhhhhhhhbhhhhhhh CERTIFICATE A'a D. Krell, No ary Public I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this 31 St day of May 2007 ��SyRE> WESTERN SURETY COMPANY ti"P� PpOgq '.3e� jr'I A�'.'•i` >H OAK L. Nelson, Assistant Secretary Form F4280 -04 -06 Authorizing By -Law ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. COR,D CERTIFICATE OF LIABILITY INSU DATE(MM/ . 107 6/20/07 PRODUCER 952 -B30 -3000 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Wells Fargo Insurance Services ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR of Minnesota, Inc. ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. 4300 MarketPointe Dr #600 COMPANIES AFFORDING COVERAGE Bloomington, MN 55435 COMPANY A General Casualty Co of WI INSURED Northwest Asphalt Inc. COMPANY B Amerisafe Insurance Group COMPANY 1451 Stagecoach Road Shakopee, MN 55379 C COMPANY D COVERAGES THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES, LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. CO LTR TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE DATE(MM/DD/YY) POLICY EXPIRATION DATE(MM/DD /YY) LIMITS A GENERAL LIABILITY CC10504038 12/01106 12/01/07 GENERAL AGGREGATE $ PRODUCTS • COMP /OP AGG _2000000 $ 2000000 X COMMERCIAL GENERAL LIABILITY CLAIMS MADE I—XI OCCUR PERSONAL& ADV INJURY $ 1000000 EACH OCCURRENCE $ 1000000 OWNER'S & CONTRACTOR'S PROT FIRE DAMAGE (Any one fire) $ 300000 X Agg per ro 'ect MED EXP (Any one person) $ 5000 A AUTOMOBILE X LIABILITY ANY AUTO CBA0504036 12101106 12/01/07 COMBINED SINGLE LIMIT $ 1000000 BODILY INJURY (Per person) _�. $ ALL OWNED AUTOS SCHEDULED AUTOS BODILY INJURY (Per accldenq $ HIRED AUTOS NON -OWNED AUTOS PROPERTY DAMAGE $ GARAGE LIABILITY AUTO ONLY - EA ACCIDENT $ OTHER THAN AUTO ONLY: _ ANY AUTO EACH ACCIDENT $ AGGREGATE $ A EXCESS LIABILITY CCU0504037 12/01/06 12/01/07 EACH OCCURRENCE $ 6000000 AGGREGATE $ 6000000 UMBRELLA FORM $ OTHER THAN UMBRELLA FORM B WORKERS COMPENSATION AND AVWCMN1551962006 12!01/06 12(01/07 X T pRy LIM T C EL EACH ACCIDENT $ 500000_ EMPLOYERS` LIABILITY EL DISEASE - POLICY LIMIT $ 500000 THE PROPRIETOR/ INCL PARTNERS /EXECUTIVE OFFICERS ARE: EXCL EL DISEASE- EA EMPLOYEE $ 500000 OTHER DESCRIPTION OF OPERATIONS /LOCATIONSIVEHICLES /SPECIAL ITEMS Re: 2007 Infrastructure Improvement Project - CP No. 816 - New Hope,MN City of New Hope and BOnestroo are additional insured with respect to General Liability for the above project. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE City of New Hope EXPIRATION DATE THEREOF, THE ISSUING COMPANY WXX1WEH{ = TO MAIL 4401 Xylon Ave North 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, New Hope, MN 55428 4W° L 1Q 9Exfim)aw 'A, Hx= xxPmux �Fx7kiTaktXtTtG�r 1' TAXXr7ri�CX�3F6�FI�Xt7�C1�� $CX�FxI�bt77C4N�9C AUTHORIZED R ENTATIVE ACORD 25 -S (1/95) 74-37 © ACORD CORPORATION 1988 Northwest Asphalt, Inc. Certificate Addendum Cancellation Clause Amendment: Should any of the above described policies be cancelled before the expiration date or not renewed in a similar policy thereafter, the issuing company will mail written notice to the certificate holder named to the left.