Loading...
IP #771 newspapers AFFIDAVIT OF PUBLICATION STATE OF MINNESOTA) ss. COUNTY OF HENNEPIN) Richard Hendrickson, being duly sworn on an oath states or affirms, that he is the Chief Fi- nancial Officer of the newspaper known as Sun-Post , and has full knowledge of the facts stated below: (A) The newspaper has complied with all of the requirements constituting qualification as a qualified newspaper, as provided by Minn. Stat. S331A.02, s331A.07, and other applic- able laws, as amended. (B) The printed public notice that is attached was published in the newspaper once each week, for ~ successive week(s); it was first published on Thursday, the ~ day of September ,2005, and was thereafter printed and published on every Thursday to and including Thursday, the _ day of , 2005; and printed below is a copy of the lower case alphabet from A to Z, both inclusive, which is hereby acknowl- edged as being the size and kind of type used in the composition and publication of the notice: abcdefghijklmnopqrstuvwxyz BY~ Subscribed and sworn to or affirmed before me on this ~ day of September, 2005. /1O-u-t a/k-~~ Notary PubTIC ( . MARY ANN CARLSON NOTARY PUBUC - MINNESOTA MY COMMISSION EXPtRES 1-31-c9 RATE INFORMATION (1) Lowest classified rate paid by commercial users for comparable space $ 2.85 per line (2) Maximum rate allowed by law $ 6.20 per line (3) Rate actually charged $ 1.30 per line COUNCIL REQUEST FOR ACTION Originating Department Approved for Agenda Public Works BY:Il2i August9,2004 Agenda Section Consent Item No. By: Guy Johnson 6.5 RESOLUTION ACCEPTING PETITION FOR PUBLIC IMPROVEMENT AND ASSESSMENT AGREEMENT AND ORDERING PROJECT (HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENT NUMBER 771) REQUESTED ACTION Staff is recommending that Council approve the resolution accepting a petition for public improvement from Allen Chazin Homes Inc., and an assessment agreement with Allen Chazin Homes Inc., and ordering the project. BACKGROUND Allen Chazin Homes has entered into an agreement with St. Joseph's Church to purchase the out lot A on the west edge of the church property. A plat plan that includes seven lots has been proposed for the development. The project consists of constructing an extension of 35th Avenue, a new cul-de-sac, and the necessary utilities in the 35th Avenue extension and the cul-de-sac. The 35th Avenue extension and the cul-de-sac will be east of Ensign Avenue and just west of St. Joseph's Church. The project would also include constructing the necessary storm water, sanitary sewer, and water infrastructure, along with the sanitary sewer and water service connections for the seven lots. The City Council authorized the preparation of plans and specifications for construction of the necessary infrastructure on June 14, 2004, and approved plans and specifications on June 28,2004. Six bids were received on July 19, 2004. The lowest responsible bid for the construction of the infrastructure was from Bolander Carl & Sons Company for $191,811.31. FUNDING The engineer's cost estimate was $202,000 for construction of the 35th Avenue extension, the cul-de-sac, and the utilities. The city of New Hope is responsible for the installation of a trunk storm water pipe serving existing neighborhoods, at an estimated construction cost of $26,150. The city is also responsible for a portion of the street construction costs associated with the reconstruction of the existing 35th Avenue, between Ensign Avenue and out lot A. The reconstruction of this portion of the street is necessary after the installation of trunk storm water pipe. The balance of the contract cost would be the responsibility of the developer through the assessment agreement. Funds for the city's portion of this project are available through the Street Infrastructure Fund and Storm Water Fund. ATTACHMENTS Attached are copies of the resolution, the petition and assessment agreement, the development agreement and the engineer's memorandums regarding the Hillside Terrace bond and water quality requirements. MOTION BY /;' /JU.~).. ) -,:.$'v-j} y- / Yi SECOND BY TO: I:RFA\Pubworks\2004\771 Acceptance of Petition & Assessment Agreement l]j lEI 1\11 Bonestroo Rosene Anderlil< & Associates Bonestroo, Rosene, Anderlik and Associates, Inc. is an Affirmative Action/Equal Opportunity Employer and Employee Owned Principals: Otto G. Bonestroo, P.E. . Marvin L Sorvala, P.E. . Glenn R. Cook, P.E. . Robert G. SChunicht, P.E. . Jerry A. Bourdon, P.E. . Mark A. Hanson, P.E. Senior Consultants: Robert W. Rosene, P.E. . Joseph C. Anderlik, P.E.. Richard E. Turner, P.E. . Susan M. Eberlin, CPA Associate Principals: Keith A. Gordon, P.E. . Robert R. Pfefferle, P.E. . Richard W. Foster, P.E. . David O. Loskota, P.E. . Michael T. Rautmann, P.E. . Ted K. Field, P.E. . Kenneth P. Anderson, P.E. . Mark R. Rolfs, P.E. . David A. Bonestroo, M.B.A.' Sidney P. Williamson, P.E., L.S.. Agnes M. Ring, M.B.A. . Allan Rick Schmidt, P.E. . Thomas W. Peterson, P.E.' James R. Maland, P.E. . Miles B. Jensen, P.E. . L Phillip Gravel III, P.E.' Daniel J. Edgerton, P.E. . Ismael Martinez, P.E. . Thomas A. Syfko, P.E. . Sheldon J. Johnson' Dale A. Grove, P.E. . Thomas A. Roushar, P.E. . Robert J. Devery, P.E. Offices: SI. Paul, SI. Cloud, Rochester and Willmar, MN . Milwaukee, WI. Chicago. IL Engineers & Architects Website: wVlVl.bonestroo.com TO: Kirk McDonald FROM: Vince Vander Top CC: Steve Sondrall, Guy Johnson DATE: July 26,2004 SUBJECT: Hillside Terrace Bond Recommendation for Site Work Our File No. 34-Gen E04-08 The developer has solicited quotes for the Hillside Terrace site grading and restoration. This work will be done privately by the developer's contractor. A bond will be required to assure the performance oft11is work. The public infrastructure will be constructed as part of the City's contract. The site work is estimated as follows: Item Quantitv Amount Site Grading LS $44,000 Soil Borrow LS $5,000 Erosion Control and Restoration LS $6.000 Construction Total $55,000 + 50% Increase $27.500 Bond Amount Recommendation $82,500 This amount can be reduced as the work is completed and recommended for approval by the City Engineer and Building Official. End of memo 2335 West Highway 36. St. Paul, MN 55113. 651-636-4600. Fax: 651-636-1311 .w - l\l1 Bonestroo Rosene Anderlik & Associates Engineers & Architects Bonestroo, Rosene, Anderlik and Associates, Inc. is an Affirmative Action/Equal Opportunity Employer and Employee Owned Principals: Otto G. Bonestroo, P.E. Marvin L. Sorvala, P.E. Glenn R. Cook, P.E. Robert G. Schunicht, P.E. Jerry A. Bourdon. P.E. Senior Consultants: Robert W. Rosene, P.E. Joseph C. Anderlik, P.E. Richard E. Tumer, P.E. Susan M. Eberlin. C.P.A. Associate Principals: Keith A. Gordon, P.E. Robert R. Pfefferle, P.E. Richard W. Foster, P.E. David O. Loskota. P.E. Mark A. Hanson, P.E. Michael T. Rautmann, P.E. Ted K. Field, P.E. Kenneth P. Anderson, P.E. Mark R. Rolfs, P.E. David A. Bonestroo, M.B.A. Sidney P. Williamson, P.E., LS. Agnes M. Ring, M.BA Allan Rick Schmidt, P.E. Thomas W. Peterson, P.E. James R. Maland, P.E. Miles B. Jensen, P.E. L. Phillip Gravel III, P.E. Daniel J. Edgerton, P.E. Ismael Martinez, P.E. Thomas A. Syfko, P.E. Sheldon J. Johnson DaleA. Grove, P.E. Thomas A. Roushar, P.E. Robert J. Devery, P.E. Offices: St. Paul, SI. Cloud. Rochester and Will mar, MN Milwaukee, WI Chicago, IL Website: wvlW.bonestroo.com To: Kirk McDonald From: Vince Vander Top Cc: Daryl Sulander, Mark Hanson, Guy Johnson Date: July 21,2004 File: 34-04-162 Re: Hillside Terrace Development Water Quality Requirements This memo outlines a recommended fee for water quality improvements for this development. The developer will contribute a cash fee toward the regional pond improvements immediately to the east of this site. The developer and City agree upon this approach which is consistent with the Surface Water Management Plan. The total fee will represents the cost that would have been incUlTed to construct a site pond and the value of the land occupied by the pond. Land value is included as the City had to acquire an equal amount ofland at the regional pond site. Site Conditions/Pond Characteristics " The development area is approximately 105,000 Square Feet. " A water quality pond for this site would inelude 1100 Cubic Yards of quality and quantity storage volume. " A pond easement area approximately 70' x 70' would be required around the pond assuming an effective depth of 5 feet, proper sideslopes, and a typical bounce to the HWL. The surface area of the pond at the NWL would be approx. 2,700 sq. ft. (52' x 52'). Pond Construction Costs Common Excavation Outlet Structure Rip Rap, Pipe, Restoration, & Landscaping Construction Cost Total Land Value (70' x 70') Total Contribution 11 00 CY @ $ lO/CY Lump Sum $11,000 $5,000 Lump Sum $2.000 $18,000 $12.250 $30,250 4,900 SF @ $2.50/SF This amount should be contributed by Hillside Development toward the regional pond improvement. 2335 West Highway 36" St. Paul, MN 55113" 651-636-4600. Fax: 651-636-1311 RESOLUTION NO. 04-~4 RESOLUTION ACCEPTING PETITION FOR PUBLIC IMPROVEMENT AND ASSESSMENT AGREEMENT AND ORDERING PROJECT (Hillside Terrace Infrastructure Improvement No. 771) BE IT RESOLVED by the City Council of the City of New Hope as follows: WHEREAS, the Church of St. Joseph's, a Minnesota corporation and Alan Chazin Homes, Inc. (hereafter collectively Owners) have submitted to the City a signedPetitioii For Public Improvement and Assessment Agreement, attached as Exhibit B for construction of infrastructure improvements within the Hillside Terrace development to be platted as Lots 1-7, Block I Hillside Terrace per New Hope Planning Case 04-03 and currently legally described on the attached Exhibit A, and WHEREAS, the City Attorney has received and reviewed title evidence from the Owners establishing that the Church of St. Joseph's is the 100% fee owner of the property described on Exhibit A subject to a purchase agreement to sell in fee all ofthe described property to Alan Chazin Homes, Inc. and has so advised this Council of said fact, and WHEREAS, this Council has reviewed the plans and specifications for the Hillside Terrace Infrastructure Improvement No. 771 (hereafter.Project) prepared by the City Engineer and hereby determines the property described on Exhibit A is all of the property which will abut on the street extension/cul-de-sac of 35th Avenue North to be constructed as part of the Project, and WHEREAS, in light of the fact Owners are or will be the fee owner of all the property abutting the 3 5th Avenue North street extension/cul-de-sac to be constructed as part of the Project this Council further determines a public hearing is not necessary to consider and order the Project as authorized by Minn. Stat. 9429.031 subd. 3., and WHEREAS, after reviewing the preliminary report for the Project submitted by the City Engineer, which includes a reasonable estimate of the total cost to be assessed, this Council also determines the Project is necessary, cost-effective and feasible and should be constructed as proposed, and WHEREAS, this Council determines the Project should be ordered subject to Owners agreement to pay the assessments as set out in their Petition For Public Improvement and Assessment Agreement and also subject to Owners entering into a Hillside Terrace Site Development Agreement required by the City's approval of Owners' preliminary and final plat ofthe subject property as requested in new Hope Planning Case 04-03. -1- NOW, THEREFORE, BE IT RESOL YED by the City Council ofthe City of New Hope as follows: 1. The Petition For Public Improvement and Assessment Agreement attached hereto as Exhibit B is accepted. 2. The Hillside Terrace Infrastructure Improvement No. 771 is hereby ordered pursuant to the Petition For Public Improvement and Assessment Agreement and as authorized by Minn. Stat. S429.031 subd. 3, but subject to Owners entering into a Hillside Terrace Site Improvement Agreement as required by the plat approval ofthe subject property identified in New Hope Planning Case 04-03 and as approved by the New Hope City Attorney. 3. The Mayor and City Manager are hereby authorized and directed to SIgn all documents and take all actions necessary to implement the directives of this resolution Dated the 9th day of August, 2004. /:/ X:;. ). . .. ~ Attest: 1. LLtLU.' ~0TL Valerie Leone, City Clerk P:'.~-\ ITOR.....;E)~'S:\S\l CLlENT FILES",,2 em' OF NeW HOPE\99~67ill(HIllSIDE TERR:\CEhR.ESOLUTION ACCEP'TIN PETITION FOR L\iPROVE!'>1El'iT AND ORDERING PROJ.DOC -2- Exhibit A Legal Description Outlot A, Parish Community of St Joseph, Hennepin County, Minnesota -3- HILLSIDE TERRACE PETITION FOR PUBLIC IM:PROVEMENT AND ASSESSMENT AGREEMENT 1. Parties - The parties to this Agreement are the City of New Hope, a Minnesota municipal corporation (hereafter City) and The Church of St. Joseph, a Minnesota corporation (hereafter Fee Owner) and Alan Chazin Homes, Inc., a Minnesota corporation (hereafter Developer), 2. Purpose - The Owner and Developer, hereby request and petition the City to construct a public street/cul-de-sac and all necessary infrastructure improvements therein, including sanitary sewer, storm sewer and water main with all bituminous pavement, concrete curb and gutter, pipe, valves, fittings, residential water services, sod, topsoil restoration and all other appurtenant works and services reasonably required to complete the street/cul-de- sac and infrastructure improvements. These public improvements and project is identified as Hillside Terrace Infrastructure Improvement Project 771 (the Project) and will extend 35th Avenue North just east of Ensign Avenue North to serve property being platted by Developer with Owner' consent into seven (7) new residential lots to be known as Lots 1-7, Block 1, Hillside Terrace located in the City of New Hope, County of Hennepin, and State of Minnesota, (hereafter Property) and is now legally described as follows: (see Edlibit A attached) The purpose of this Agreement is to set out the respective cost sharing agreement between the City and Developer relating to the Project. The Project is more fully described in the Memorandum from the Bonestroo, Rosene, Anderlik & Associates, engineers for the City, dated June 23, 2004 with Engineer's Estimate attached as Edlibit B. All work shall be done in conjunction with the Project. The Church of St. Joseph hereby warrants and represents it owns in fee 100% of the property legally described on Exhibit A. Alan Chazin Homes, Inc. hereby warrants and represents it has entered into a purchase agreement with The Church of St. Joseph to buy in fee all of the property legally described on Exhibit A and that it has submitted an application to the City to plat the property as Lots 1-7, Block 1 Hillside Terrace. Developer further acknowledges and agrees the property legally described on Exhibit A will be specially benefited from the Project and also submits this petition for the purposes set out in Minn~ Stat. 8429.031 subd. 3. 3. Description of Work - The public improvements described above shall be constructed according to plans and specifications prepared by the City engineers for the Project as referenced in his June 23,2004 Memorandum attached as E",hibit B. 4, Costs - The City has received bids from several contractors to construct the described public improvements per its advertisement for bids published in the Construction Bulletin on July 2 and 9, 2004 and in the New Hope-Golden Valley Sun Post on July 8, 1 2004. The City opened bids on July 19, 2004 and intends to award a contract to the lowest responsible bidder Carl Bolander & Sons Co. in an amount of $191,811,31. Added to the actual construction cost is an additional amount of $47,952.83 for engineering, legal and administrative costs resulting in a total public improvement cost of $239,764.14. Developer agrees to this total cost of the Project. The City agrees it is responsible for and will pay $57,014.16 of said total cost that relates to the installation of a trunk storm water line serving the existing neighborhood. The Developer agrees that $182,750.08 of said total cost shall be assessed against the Property and is the amount of the Project attributable to installing the street/cul-de-sac, sanitary sewer, storm sewer, residential water service and all other appurtenant works and services to complete the Project specially benefiting the Property referenced above (hereafter the Assessed Amount). This Assessed Amount is based on construction costs and engineering, legal and administrative cost for the entire Project. The Developer and the City understand and agree that change orders can affect the cost of the Project, including change orders based upon per unit costs, Change orders are generally the result of unforeseen construction circumstances or project design changes, Developer acknowledges and agrees to pay on a pro rata basis, as determined by the New Hope City Engineer, all change order costs which increase total Project costs and the Assessed Amount under this Agreement. Developers acknowledge and agree to pay the unit costs of the project based upon the actual units used for construction of the project which may increase the actual construction costs and the Assessed Amount referenced above. 5, Special Assessment - The Developer acknowledges and agrees that the proposed construction of the Project specially benefits the Property legally described on Exhibit A. In consideration for the City's action to cause the construction of the Project at the Owners' and Developers' request, the Developer agrees that the fair market value of the Property will increase in an amount equal to or greater than $182,750.08 and that it will pay the Assessed Amount by a special assessment levied against the Property pursuant to Minn.. Stat.. Chapter 429 over a period of ten (10) years at an interest rate of seven (7) per cent per annum, The first installment is anticipated to be payable with real estate taxes due in 2005. The Developer expressly waives all objections to any irregularity with regard to the special assessment for the Project and any claim that the Assessed Amount of $182,750.08 to be levied against the Property is excessive. The Developer further waives any and all rights to appeal the special assessment in District Court under Minll. Stat.. Chapter 429 and more specifically Minn. Stat.. 9429.081 or any other federal, state, or local law, rule, or regulation, Provided, however, the Developer shall retain the right to object to any arbitrary, unreasonable or capricious actions of the City in connection with the Project, other than the propriety ofthis project, the Developers' share in the cost thereof as set out above, or the City's right to levy an assessment therefore against the Property . 6, Indemnification - The Alan Chazin Homes, Inc, agrees to indemnify, reimburse and hold the City harmless for all costs to make the improvements described above in the event the special assessment against the Property is held invalid and unenforceable for any reason, due to the improvements or special assessments being challenged by the 2 Owner or the owners of individual lots in the Hillside Terrace plat, or anyone claiming through the Owners or the individual lot owners. This indemnification shall include reasonable attorney's fees and costs to collect and enforce the special assessment and this Agreement. 7, Owner's Special Assessment Liability. - The City agrees not to start construction of the improvements described in paragraph 2 herein until the City receives a copy of the signed deed by Owner conveying to Developer title in fee to the Property. Further, the City and Developer acknowledge and agree the Owner shall not be responsible to the City or Developer for any of the Project Costs described in paragraph 2 herein, nor shall the Property be specially assessed for any Project Costs until and unless Owner conveys to Developer title in fee to the Property. It is anticipated by the parties hereto this conveyance will occur on or before September 1,2004. Dated: 1hc / ,2004 Alan Chazin Homes, Inc. By: Its e i h f 11/{ {V'l if i~j{>v / J B~;S ~4<f!!:r The Church of St. Joseph By: Q--<~: (~~~~u'" Its' ----.--:'AO ,< / c' ~ , , c-'-' ,'-<-<'/>/A--L^----- By: Its: STATE OF MINNESOTA ) ) ss. 3 Jensen & Sondrall, P.A. 8525 Edinbrook Crossing, Suite 201 Brooklyn Park,:tvfN 55443 (763) 424-8811 petition for improvemenl-assessment agr<:<:n1enl D43.doc Exhibit A Lellal Description 5 COUNTY OF1hv ) was acknowledged before me this "--'~O ~ day of 2004 by ~u~U~=i:A./ . and , the if/? i?.u tiL4't-l and respectively, of Alan Chazin Homes, Inc., a Minnesota corporation, on behalf of said corporation, The foregoing n ,.., // ;J;~tLHJ ~. ,rzJ~A~ STATE OF MINNESOTA ) ~ )ss. COUNTYOF l"'---Vlt~ Tp,e foregoing was acknowledged before me this Cday of DflJ<D L~v:.C:""ti'--' Notary Public .._.~,~~,",;;..~~.~:,,~:;,"~~~:.2c.';;~~~ . :~ ~1};!'r,':) SHARON C. SANNEl ~ ~ NOTARY PUBLIC - MINNESOTA ~~ My Commission Expires Jan. 31, 2005 (~ "'.... 0-:v-J-,~'2004, by {/ and ~--f'.......\.L(;: 'I E e.. and the respectively of The Church of St. Joseph, a Minnesota corporation, on behalf of said corporation. NO'i'\~;Y PU3LiC -rAiNNESOTA D/WiD E. KOHNER EXFES 1~31-2GQS ".?:q"'fflhf~ " Notary Public STATE OF MINNESOTA ) ) ss. COUNTY OF HENNEPIN ) foregoing was uacknowledged before me this day of , 200,0, by Don Collier and Daniel J. Donahue, the Mayor and City Mana r, respectively, of the fCity of New Hope, a Minnesota municipal corporation, on behalf of said municipal corporation. Notary Public THIS INSTRUMENT DRAFTED BY: 4 VAlER1EJ,lEONE NOTARY PUBLIC-MINNESOTA My Gomm1ssicfl Expires Jan. 31, 2005 Exhibit A Legal Description Outlot A, Parish Community of St Joseph, Hennepin County, Minnesota 5 CITY OF NEW HOPE HILLSIDE TERRACE SITE DEVELOPMENT AGREEMENT THIS AGREEMENT is entered into by Alan Chazin Homes, lnc, a Minnesota corporation, (~ereinafter "Developer") and the City of New Hope (hereinafter "City"), this day of Z!- Eo " ", ..j.. J 004 1::1 4{t~3 {/~., I ~ -- . / WHEREAS, on June 14, 2004, by Resolution No. 2004-118, the City Council approved Developer's preliminary plat (hereinafter the "Plat") for certain real property to be knovm and legally described as Lots 1-7, Block 1 Hillside Terrace located in the City ofNev.i Hope, County of Hennepin, State of Minnesota, legally described cWTently as follows: (see Exhibit A attached) (hereinafter "Property") to allow for the development of seven (7) single fanlily residential building lots at the Property, and \VHEREAS, the City Council also approved Developer's site development plans for the Property as set forih in Planning Case 04-03 (hereinafter "Plans"), and WHEREAS, the approvals were granted subject to the following conditions: 1. Developer must enter into a Development Agreement with the City and provide an appropriate financial guarantee to secure the required work (amount to be detel111ined by City Engineer and Building Official). 2, Developer must comply with the City Engineer's recommendations as set forth in his May 13 and May 26, 2004 memoranda attached hereto as Exhibits Band C. 3. Developer must obtain approval of its building plans from the City's Building Official. 4. Developer must obtain approval of its building plans from the West Metro Fire DistTict 5. Developer shall pay the appropriate park dedication fee as required by the New Hope City Code upon final plat approval. 6. Developer must comply with the City Planner's recommendations as follows: a) retaining wall details shall be provided to the City Engineer for review and approval. b) drainage easements shall be sized and configured to cover all backyard drainage swales. c) Developer shall provide adequate documentation of permission for right of entry or easement to grade into adjacent 281 Independent School District property, d) Developer shall provide an inventory of vegetation to be preserved on the Property as part of the development (i.e., description of planting types and sizes), e) Developer shall provide a description of vegetation measures that \vill be implemented on site during constmction, f) All new plantings shall be located v.rithin the plat and new spmce trees shall be six to eight feet in height, and g) Developer shall provide at least one tree, two inches in diameter, per lot. 7. In lieu of constmcting an on-site stOTIn water pond, Developer shall pay a storm water ponding fee to the City upon final plat approval (amount to be determined by the City Engineer). 8. Final plat approval shall be waived by the New Hope Planning Commission. WHEREAS, the Developer has also agreed it will petition the City per Minll. Stat. 9429.031 subd. 3 to constmct a public street extension/cul-de-sac v.rith all necessary infrastructure utilities (sanitary sewer, stOTIn sewer and water main) on 35th Avenue North east of Ensign Avenue North to serve the Property's seven proposed residential lots, and will enter into an Assessment Agreement with the City for the constmction of said public street extension/cul-de-sac and infrastmcture utilities in a fom1 attached hereto as Exhibit D. NOW, THEREFORE, IT IS HEREBY AGREED as follows: 1. INCORPORATION OF RECITALS. The recitals above are incorporated herein by reference, specifically including the conditions of approvals. ') THE WORK. The Work shall consist of the site improvements described in the Plans, including the Secured Work as described below, and including any amendments to the Plans which are approved by the City Council. The Work shall be perfom1ed by the Developer to the City's satisfaction and in compliance with all applicable codes, ordinances, standards, and policies of the City. 3. THE SECURED WORK. The Secured Work includes all (m-site exterior amenities shown on the Plans that are listed below. 2 ltem Quantity a) Site (jrading b) Soil Borrow c) Erosion Control and Restoration LS LS LS $44,000.00 $5,000.00 $6,000.00 Construction Total + 50% Bond Increase Total Amount of Financial Guarantee $55,000.00 $27.000.00 $82,500.00 4. COMPLETION. The Developer agrees that the Work shall be completed in its entirety on or before the 31th day of December, 2005 (the Completion Date), except as this period of time is extended by resolution of the Council, or by the City taking no action to require completion herew1der on a timely basis. It is w1derstood and agreed that failure of the City to promptly take action to dra\v upon the bond or other security to enforce this Agreement after the expiration of the time in which the Work is to be completed hereunder will not waive, estop or release any rights of the City and the City can take action at any time thereafter to require completion of the Work, and payment for same, Furthem1ore, the term of this Agreement shall be deemed to be automatically extended until such time as the City Council declares the Developer in default thereunder, and the statute of limitations shall not be deemed to commence running until the City Council has been notified in \vriting by the Developer that the Developer has either complied with this Agreement, or that it refuses to for any reason. These provisions shall be applicable to any person who shall give a financial guarantee to the City as required below. 5. COST OF WORK. The Developer shall pay for all costs of persons doing work or furnishing skill, tools, machinery or materials, or insurance premiums or equipment or supplies and all just claims for the same, and the City shall be under no obligation to pay the Developer or any subcontractor any sum whatsoever on account thereof, whether or not the City shall have approved the subcontract or subcontractor, and the Developer and its suret)' shall hold the Cit)' harmless against any such claims, and provide the City with all necessar)' lien waivers. 6. DEF AULT. In the event of default by the Developer as to any of the Secured Work to be perfonned hereunder, the Cit)' may, at its option, perform the Secured Work and the Developer shall promptly reimburse the City for any expense incurred therein by the City, provided the Developer is first given written notice by United States Mail ofthe Secured Work in default and required to be done by the Developer, not less than 7 days being given thereby to the Developer to remove the default status, said notice being addressed to the Developer at the address set forth below. Notice given in this manner being sufficient as described, by agreement of the parties hereto. Notice to the Developer shall also constitute, without further action, notice to any contractor or subcontractor, whether they are approved and accepted by the City or not. In the event of emergency, as determined by the City Engineer, the 7 day notice requirement to the Developer shall be and hereby is waived in its entirety by the Developer, and the Developer shall reimburse the City for any expense so incurred by the City in the same manner as if mailed notice as described above had been given. It is understood by the parties, however, that the responsibility of the Developer is limited by strikes and force majeure. 7. ADMINISTRATION COSTS. Developer agrees to reimburse the City for the actual costs to the City associated with Planning Case 04-03 and this Agreement, including but not limited to. engineering and atto111ey's fees. Developer agrees that the financial guarantee shall not be released until all such costs have been paid to the City. 8. HOLD HARMLESS. The Developer agrees to indemnifY' and hold ha1111less the City and its agents, employees, and representatives against any and all claims, demands, losses, damages and expenses (including attomey fees) aIising out of or resulting from the Developer's negligent or intentional acts, or aI1Y violation of any safety law, regulation or code in the perf01111aI1Ce of this Agreement, without regard to any inspection or review made or not made by the City, its agents, employees, or representatives, or failure by the City, its agents, employees, or representatives to take any other prudent precaution. In the event aI1Y City employee, agent or representative shall come under the direct or indirect control of the Developer, or the City, upon the failure of the Developer to comply with any conditions of this Agreement, performs said conditions purSUaIlt to the financial guarantee, the Developer shall indemnifY and hold haImless the City, its employees, agents and representatives for its 0\\111 negligent or intentional acts in the perfOrmaI1Ce of the Developer's required work under this Agreement. 9. COST OF ENFORCEMENT. The Developer agrees to reimburse the City for all costs incuned by the City in the enforcement of this Agreement, or any portion thereof, including court costs aIld reasonable engineeling and atto111ey's fees. 10. FINANCIAL GUARANTEE, The Developer shall furnish the City with a financial guarantee acceptable to the City in one of the following forms: a) cash escrow; b) a perfonnance bond issued by an approved corporate surety licensed to do business in the State of Minnesota, and executed by the Developer as the principal: c) an inevocable letter of credit; d) an automatically renewing celtificate of deposit in Developer's nanle but assigned to the City; e) other financial instruments which provide equivalent assuraI1Ce to the City. Said financial guaraIltee shall be furnished to the City as security! to assure completion of the items of Secured Work as set forth above, aIld payment of the costs of administration as set forth above. The financial guaraIltee shall be in all aIll0Wlt of 150% of the cost of the Secured Work as estimated by the City Engineer. The financial guarantee provided shall continue in full force and effect until the landscaping guaranty is satisfied, the City Council approves aIld accepts all of the Secured Work undertaken, aIld releases the surety and/or the Developer from any further liability, and until all administrative costs are paid in full, including payment of the park dedication and St01111 water ponding fees. The City Council may reduce the amount of the financial guarantee upon partial completion of the Secured VI/ork, payment of all outstanding administrative costs and fees and satisfaction of the landscaping gUaI'aI1ty. 11, NOTICE. The address of Developer, for purposes of this Agreement is as follows, and any notice mailed by the City to this address shall be deemed sufficient notice under this Agreement, until notice of a change of address is given to the City in \vriting: Alan Chazin, President i\ Ian Chazin Homes. Inc. 5353 Wayzata Blvd. Suite 602 Minneapolis, MN 55416 (952)546-3385 12. SEVERABILITY. If any portion, section, subsection, paragraph, sentence, clause or phrase of this Af:,rreement is for any reason held to be invalid, such decision shall not affect the validity of the remaining pOltion of this Agreement. 13. SUCCESSION. This Agreement shall be binding upon the parties, their heirs, successors or assigns, as the case may be. 14. PARK DEDICATION FEE. The Developer specifically acknowledges that the park dedication fee required in connection with development of the Property pursuant to the Plans is in the amount of$10,500,OO and must be paid in full upon approval of the final plat for the Property. 15. STORM WATER PONDING FEE, The Developer specifically acknowledges that the storm water ponding fee required in connection with development of the Property pursuant to the Plans is in the amount of$30,250.00 and must be paid in full upon approval of the final plat for the Property. 16. LANDSCAPING GUARANTY, The Developer specifically acknowledges it will guaranty the life of all new plantings on the Property required by this agreement until June 1, 2006. Developer al:,rrees it will replace at its cost any required plantings that fail to survive until June 1, 2006. IN WITNESS \VHEREOF, we have hereunto set our hands and seals. ALAN CHAZIN HOMES. INC. CITY OF NEW HOPE By Its 5 A _ By LJani e II Lbi1(d7~L f"- Its C/ f-c; /]iZd.1i {f{i(y / j ;}' ~~ STATE OF MINNESOTA ) ) ss, COUNTY OF HENNEPIN ) _ The foregoing instrument was acknowledged before me this L day of IIi/CieL:Jl... , 2004, by Don Collier and Daniel J. Donahue, the Mayor and Manager, respectively, of the City of New Hope, a municipal corporation of the State of Minnesota, on behalf of said municipal corporation, VALERIE J. LEONE NOTARY PUBUC-lvliiJiiESOTA Notary Public COUNTY OF The foregoing instrument was acknowledged before me tins day of 2004, by (J 1.(1.1/1 Ch';;hC."';",-- and , the and U , respectively, of Alan Chazin Homes, Inc., a Minnesota corporation, on behalf of said corporation. /) i~,,\ /-4 if'; l-,c.Lb('tj) 0, Notary Public ;n~C\L-l") >-- I DRAFTED BY: Jensen & Sondrall, P.A. 8525 Edinbrook Crossing, #201 Brooklyn Park, Iv1N 55443 (763) 424-8811 BARBARA J. NELSON NOTARY PUBUC. MINNESOTA My Commission Expires Jan. 31. 2005 II\Atlomcy\SA.S\l Cli("''1'lt Filcs\2 City of Nt........ Hopc\99-677 I 1 (H.illsidc '"crracc}\Dcvd;:lpmcm DJ :!.ltl.":lU!.tc.doc () Exhibit A Legal Description Outlot A, Parish Community of St Joseph, Hennepin County, Minnesota 7 August 20, 2004 Mr. David Lenzen Parish Community of St. Joseph 870136th Avenue North New Hope, MN 55427 Mr. Alan Chazin Alan Chazin Homes Inc. 5353 Wayzata Boulevard, Suite 602 M:inneapolis, MN 55416 Subject: Hillside Terrace Dear Messrs. Lenzen and Chazin: Thank you for retuming the documents relating to Hillside Terrace. Enclosed are fully executed copies of the Petition for Public Improvement/Assessment Agreement and the Site Development Agreement. At this time the following items are necessary: 1. Two mylars of the final plat and 8 bluelines 2. Payment of the $10,500 park dedication fee 3. Financial guarantee of $82,500 Further, it is my understanding that per your discussion with the Community Development Director, payment of the storm water ponding fee of $30,250 (in lieu of on-site ponding) is due upon the issuance of the first building permit. If you have any questions regarding these items, please contact Kirk McDonald at 763-531-5119. Sincerely, U .____/~ / !1UjjJ.. CL)f-iTYv- Valerie Leone, CMC City Clerk Enc. cC': Kirk McDonald (PC 04-03) Vince VanderTop, City Engineer Guy Jolll1son, Director of Public Works Steve Sondrall, City Attomey Roger Axel, Building Official CITY.OF NEW HOPE 4401 Xylon Avenue North. New Hope, Minnesota 55428-4898 · www.ci.new-hope.mn.us City Hall: 763-531-5100. Police (non-emergency): 763-531-5170. Public Works: 763-592-6777. TOO: 763-531-5109 City Hall Fax: 763-531-5136. Police Fax: 763-531-5174. Public Works Fax: 763-592-6776 COUNCIL REQUEST FOR ACTION Originating Department Approved for Agenda Agenda Section Public Works August 9, 2004 eonsent Item No. By: Guy Johnson By: 6.6 RESOLUTION AWARDING CONTRACT FOR THE CONSTRUCTION OF HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENT NO. 771 REQUESTED ACTION Staff is recommending that Council approve the resolution approving a contract between the city of New Hope and Carl Bolander and Sons Company for the construction of a city street, cul-de-sac, and necessary infrastructure improvements in the amount of $191 ,811,31. BACKGROUND Allen Chazin Homes has entered into an agreement with St. Joseph's Church to purchase the out lot A on the west edge of the church property. A plat plan that includes seven lots has been proposed for the development. In order for the development to proceed, a street, cul-de-sac, and the associated infrastructure must be installed. The City Council authorized the preparation of plans and specifications for construction of the necessary infrastructure on June 14, 2004, and approved plans and specifications on June 28,2004. Six bids were received on July 19, 2004. The lowest responsible bid for the construction of the infrastructure was from Carl Bolander & Sons Company for $191,811.31. The engineer's construction cost estimate was $202,000 for the 35th Avenue extension, the cul-de-sac, and the utilities. The city of New Hope is responsible for the installation of a trunk storm water pipe serving existing neighborhoods, at a construction cost of $26,148.70. The city is also responsible for a portion of the street construction costs, estimated at $19,462,55, that is associated with the reconstruction of the existing 35th Avenue, between Ensign Avenue and out lot A, that will be impacted by the trunk storm water pipe installation, The balance of the contract cost would be the responsibility of the developer through an assessment agreement. FUNDING Funds for the city's portion of this project are available through the Street Infrastructure Fund and Storm Water Fund, ATTACHMENTS Copies of the resolution, engineer's memorandum, and the bid tabulation are attached. MOTION BY I /Z;' . / 4 L/. - /~JJ LA? l '. J:: n ./ /' /7/1,/7 r,/! /. ,........-<)!.---(/11 SECOND BY TO: - / <I s- I:RFA\Pubworks\2004\771 Award Contract RESOLUTION NO 04-~5 RESOLUTION AWARDING CONTRACT FOR THE CONSTRUCTION OF HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENT NO. 771 BE IT RESOLVED by the City Council of the City of New Hope as follows: 1. That bids for the construction of Hillside Terrace fufrastructure Improvement No. 771 were duly opened at the New Hope City Hall, 4401 Xylon Avenue North, at 1:30 p.m. on the 19'h day of July, 2004, as heretofore authorized by this Council. ') That advertisement for bids for the construction of said improvement was published in the New Hope-Golden Valley Sun-Post, the official newspaper ofthe City, on July 8, 2004, and in The Construction Bulletin on July 2 and July 9, 2004. 3. It is hereby found and determined by this Council that the bid of Carl Bolander & Sons Co. for the construction of said project in the amount of$191,811.31 is the lowest responsible bid submitted for the construction of said improvement; that Bonestroo, Rosene, Anderlik & Associates, Inc., Engineers for the City, have recommended to this Council the said low bid for the award of the contract for the construction to the designated lowest responsible bid. 4. The Mayor and Manager are authorized and directed to enter into an improvement contract for the construction of said improvement in the name ofthe City with the lowest responsible bidder, subject to the said contractor furnishing a public contractor's surety bond, conditioned as required by law. The award of this contract is also subject to the Church of St Joseph and Alan Chazin Homes, Inc., the owner and developer respectively of the property abutting and specially benefiting from this public improvement, entering into a Petition For Public Improvement and Assessment Agreement and developer entering a Site Development Agreement for the construction of the Hillside Terrace development. Adopted by the Council this 9" day of A'4 ~ J - Attest: la.u,U--f..~/'u:... Valerie Leone, City Clerk P:\A. TTQR...l.lEY..cNH RESOLUTIONSCNH99.67111-OOZ.RESOWTION AWARDING CONTRACTDZ.DQC -1- .w - 1\]1 Bonestroo, Rosene, Anderlik and Associates, Inc. is an Affirmative Action/Equal Opportunity Employer and Employee Owned Principals: Otto G. Bonestroo, P.E. . Marvin L. Sorvala, P.E. . Glenn R. Cook, P.E. . Robert G. Schunicht, P.E.. Jerry A. Bourdon, P.E.. Mark A. Hanson, P.E Senior Consultants: Robert W. Rosene, P.E. . Joseph C. Anderlik, P.E. . Richard E. Turner, P.E. . Susan M. Eberlin, C.P.A. Associate Principals: Keith A. Gordon, P.E. . Robert R. Pfefferle, P.E. . Richard W. Foster, P.E.. David O. Loskota, P.E... Michael T. Rautmann, P.E.. Ted K. Field, P.E.. Kenneth P. Anderson, P.E.' Mark R. Rolfs, P.E.. David A. Bonestroo, M.B.A.. Sidney P. Williamson, P.E., L.S. . Agnes M. Ring, M.B.A. . Allan Rick Schmidt, P.E. . Thomas W. Peterson, P.E. . James R. Maland, P.E. . Miles B. Jensen, P.E. . L. Phillip Gravel III, P.E. . Daniel J. Edgerton, P.E. . Ismael Martinez, P.E. . Thomas A. Syfko, P.E. . Sheldon J. Johnson. Dale A. Grove, P.E. . Thomas A. Roushar, P.E. . Robert J. Devery, P.E. Offices: St. Paul, SI. Cloud, Rochester and Willmar, MN . Milwaukee, WI. Chicago, IL Website: www.bonestroo.com Bonestroo Rosene Anderlik & Associates Engineers & Architects July 21,2004 Guy Johnson City of New Hope 5500 International Parkway New Hope, MN 55428-4843 Re: Hillside Terrace mfrastructure Improvements Project City Project No. 771 File No. 34-04-162 Recommendation of Contract Award Bids were opened for the Project stated above on Monday, July 19, 2004 at 1:30 P.M. Transmitted herewith is a copy of the Bid Tabulation for your information and file. Copies will also be distributed to each Bidder. There were a total of six (6) Bids. The following summarizes the results ofthe Bids received: Low #2 #3 #4 #5 #6 Contractor Carl Bolander & Sons Company G. L. Contracting, mc. Penn Contracting, mc. Jay Bros., mc. Northdale Construction Company, mc, Burschville Construction mc, Bid Amount $191,811.31 $207,625.40 $208,591.20 $216,027.95 $219,830.43 $220,039.45 The low Bidder on the Proj ect was Carl Bolander & Sons Company with a Base Bid of $191,811.31. This compares to the Engineer's Estimate of $200,000.00. These Bids have been reviewed and found to be in order. The total project includes all necessary work for the installation of infrastructure for the Hillside Terrace development. The project also includes trunk storm sewer work identified in the City's Surface Water Management Plan. As such, it is recommended that the construction cost of the project be divided between the Developer and City as follows. The details of the cost division are included in the attached spreadsheet. The follow costs do not includes indirect costs. Item Sanitary Sewer Water Main and Services Trunk Storm Sewer Lateral Strom Sewer Street Improvements Total Development Costs $24,240.36 $27,203.00 $19,049.90 $7,957.90 $ 67.748,90 $146,200.06 City Cost $0.00 $0.00 $26,148.70 $0.00 $19.462.55 $45,611.25 Total $24,240.36 $27,203.00 $45,198.60 $7,957.90 $ 87.211.45 $191,811.31 2335 West Highway 36. St. Paul, MN 55113. 651-636-4600. Fax: 651-636-1311 All of the above Contractors have proven they are capable of performing the work associated with this type of Project. lfthe City Council wishes to award the Project to the low Bidder, then Carl Bolander & Sons Company should be awarded the Project on the Base Bid Amount of $191,811.31. Should you have any questions, please feel free to contact me at (651) 604-4790. Yours very truly, BONESTROO, ROSENE, ANDERLIK & ASSOCIATES, INC. ~~~ Vincent T. Vander Top, P.E. Enclosures 2335 West Highway 36. St. Paul, MN 55113. 651-636-4600. Fax: 651-636-1311 i~=~ ~ ):.):.;:0 tD ~ VI ::;, ~ 0 ~gf5-~~ g: iii' ~ ro a r':l ,....;:;- 0 a ~ l?" 0 "0 ~. CD n. Z OJ 3 ~ ~ Vi c: m a;l .., .., Ql (') m 5' - .., OJ !!l .., c: (') 2' .., m 3' .., o < m 3 m :l it - ::r- CD Ci! ~ C') CD ~ ~ so ~ so c;;' c;;' <ll :::> CD >< <ll Q. Q -< "0 .Q. CD n. Z 9 -J -J ~ ::!1 CD Z 9 UJ -I>- 6 ! 0) N Ci! 'C a g. Q. o' :::> o ..... 0- ~ Ci! C') CD ~. !=l- OJ 0: o '0 CD OJ 5' (0 s;: o OJ c. OJ c... s:. ~ .CD N o o -I>- ~ ~ c;, o :-0 ~ o :iE OJ ~ g m ~$ <Qg 5a:~ Ql~ g::-i :::><:::: ~~ . ~ I\J'"' Ol:-i 'J.g C:l c:l 6 ~ c:l c:: r- ~ o z C")C")c:l o III -, 3 .., c. -co "0 c:l m III 0 .., :l - Z '< III 0 :l, ~.... .., "" en o :l lJl (j) !;! . c. r- c. , m C") .., o Z :l 0 .... . Ql N g, :so se 5' r c:l c: c. m .., Z !:l w c:l c: c. m .., Z !:l -I>- "0 m :l :l C") o a .., III g, :S' se 5' r c.. III '< c:l .., o r 5' r NN N -\,. -J. -J. -l. -J. -l.. ~ ~~ .... z;:;: CD CO-J 0) 01 .;::. w tv ~ c: m N~ 0 CD CO-J 0)01-1>- UJN~ 0 3 3 -J.-J.cn~"'C -l---O)COCOO)S;:(') 0::0"0 -lz~O~::O~~~~o~m(')::O-lS;:"O = = m =:t> OZS;:Z = = = =:t>ocm:t> O(,)"O<OZOX --0 --0 <::$0 m::OO:t> (')(')::0"0;;0 -l(')"O~GJGJOO-z(')s;:;;o -l::o m-GJ- 0 0 en::os;::t>OJ;;O CO<('i-l :t>::O::O)>)>)>=o=oZZ-lO-l :t> ::0;;0)> )>-I>-m<m<-lmo~--l ::O::On. w r-~Or-l-l:2::2: mr<1\) r-mOos;:ens;: =m(')m(')- <:!lC.... OJ"Omen. "0 <rmm (')mm. "OS;:<mm""m"O"Oen"Oen~~m(')N. ~~8~~ ?ii~~I;J;;J;~~ -l5Jg:2: :t>mm"O-l(')-l< )>)> )>en ;;o~O-lm)>m(') Z zs;:r~8~:t> -l-l"O(5rrmm 60"0)> -l "OI::Oen::O:2: ~ ~)>rZZOz "O~S;:-I>-< N =0::0<<::0::0 z:2:rrl .... =0 en-len~ )> )>z8~-lZ~ )>OS;:On . m)>mms;:s;: m~ ;;0 , m )>z)>m ::0 ::OIZ)>::O )> zzoenm :2: ~z)>)>~~ <::$:j~s: en ~ ZGJZ. ~ ~o ::00 ;;0 OenZ)>en :t> o-lZZzz en m )> 0 ~ ~en en enrZ~r ~ c;- -l-l~" -l coo. - ~-::o~ ~ c )> )>~ m mm~en en OJO::O-l m Z OJOJ(')(') ZZ Z -l Z ::0::0 :2::2: -l m 3 O"Om)> ;;0 0 OOrr GJGJS;:.. :t> 0 ~ ~UJ m m _m :2: x z::o s: )> .x.xf);f); ~en~ ::0 )> s;: s;:0l ::0 ::0 0:2: m (')~ :t> -l --enen . Z ~ -l )> I . - zm ;;0 Ien - is zz :2: en is Z en en -l::O .. m z Z "O"ORjRj )> m Z I:2: 0 0 0"0 :2: . r r -l :2:- O~ ::0::0 =0 m "0 )>)> m m "0 r I UJ UJ m ::0 m (')(') ::0 ;;0 m m 01 01 ::0 mm ::0 . . ~ 0 q q q . . . c:: mmr r mmmrrm rr r r m mr r m rrr :l )>)>~ ~ )>)>)>~~)> OJ~ ~ ~ )> )>~ ~ )> ~enen it 0 UJ 01 01 co~ UJ N ~ r< .... ()) -J 0-1>- UJ -J 01 01 -J-J0l UJ -J.-\.tv01CON 001 0 -J ~ -J0l 01 .... ())~~ ~~ c:: ~ ~ ~ $: ~~ ~...J.. -Ef) _-l. ~ ~ ~ ~ ~ ~()) N~ CO(O-J.~~~ ~ "c.n N~ ~ -J ~'(ow "0 O)~", '" NQ)~-\"-J.~ '" '" '" -I>- 0 ~N ~ CD ~NO 000) ~ OOOCDOl~ ~-J ~ :-J 0 ~o -J 9 NOO .., 00<0 c.n 0000,0,0 wo 01 0 0 0<:0 w 0 <000 (')' oOUJ 0 0000100 00 0 0 0 001 01 0 NOO m ~ ~ ~ d ~ '" N '" '" ~ '" '" N ~ '" '" '" "'~~ --'- ~ j\J _0 '" _-J...f';;FJ_N~~-EA ~~ ..t>. '" ~ ~ ~Ol '" '" N~()) ())-J~ N()) ())CDNN~()) "0"0 N -I>- a "c.n ~~ CD --oJ "o'(ow ~ N-J()) <J:>--oJ NO) ())CDN()) -I>-~ -I>- CD N 0 -JUJ 01 CD -I>-NO OON (.11-1>- OOO())-I>-N 001 0 01 CD 0 -JUJ -I>- 0 ~OO 00<0 oc.n ooo~<:oo 00 w 0 0 0 o~ N 0 woo 0001 (.110 0000100 00 O'l 0 0 0 001 01 0 0)00 c:: '" ~ '" '" $: _-J. -EA ~ ~ '" ~-I>- '" '" '" 0, o,w "0 N '" '" CD-JCD"''''O) ~ ~~ ~ 0) ~O)"" '" o)01())NN-J '" '" '" 01 0 -J~ ~ ~ '" UJ ~ .., ~-I>--I:> UJ NOCDO)-I>-O) UJ-J UJ -J UJ ~CD ()) 01 ())())O) ('). c.oo~ w <:o~~o,w:"'" ~N w <0 w wo, ~ w 0,00 m 000 0 000000 00 0 0 0 00 0 0 000 ~ '" ~ -l ~ '" N '" ~ '" ~ '" '" '" ....~ '" '" '" '" ~~~ ..-1. .(;A _,p.. O'l~ _.... ~ _-J. _01 -EA_-J. N~ co~ ~ ~ ",.01 ~ '" ~~-I>- 0 -1>--1>--1:> <.0'(0 CD-JCDN~UJ ~"o (,,"0 ~ 0, -I>- UJ a 0) Wo,w ~ ())-I>--I>- CON 0) Ol--oJ CD CD 01 ())-I>- -I:>()) 0 0 CD CD N ~ O1UJ~ UJ()).... NUJ NOCDOl-l>-N 0-1>- WCD 01 UJ CDO ()) 01 ())())O) woc.n ::"<0 <:O~::"O::"N 00 wo w w ~o c.n w <:000 000 00 000000 00 00 0 0 00 0 0 000 '" c:: ~ '" ~~ :l .N '" ~ ~ '" ~O ;::;: ~ '" '" '" Co ~ ~~"o "0 ~~~ ~-JCD~~UJ ~ ~ ~ '" '" 0) -J-I>-.... '" O-l>-NNNO ~~ ~ N 0 NN N 0 ~OO .., 001.... ~ OOO())-JO ~O ~ 0 0 O()) ()) 0 000 ('). ooc.n ~ 000000 ~o ~ 0 0 00 0 0 000 m 000 0 000000 00 0 0 0 00 0 0 000 ~ '" ~ ~ d ~~~ N ~ ~~ '" ~ N '" '" '" '" '" ~ ~~UJ .(.11 '" .N~~.o)~", ~~ .--oJ ~ '" ~ '" .-J ~ '" ~~O -""00, WCD -l.-..JCO-" tv 0> w~ ....01 ()) Co CO--oJ 01 0) "c.n~"o ~ CD~N <J:>CD O-l>--I>-O~O 0)01 en 0) -I>- 0 -1>-0 -I>- 0 ())OO 001N ""-l~ 00000)0 00 .... ~ 0 0 00 0 0 000 ooc.n ~~ 000000 00 0 0 0 0 00 0 0 000 000 00 000000 00 0 0 0 0 00 0 0 000 c:: ~ '" '" '" ~ :l ~ '" .N '" '" ~ N ~ '" ~.O) ;::;: ~~'" UJ-JCD"'~"o N '(0 ~~ ~ -J Ol()) "0 ())O.... '" OOONNO ~~ '" UJ 01 ())N .... 01 "'00 .., OO-/>- N OOOO())O UJ 0) N 0 0 O~ ()) 0 0)00 (')' 000, N ooo~oo 00 N 0 0 00 N 0 000 m 000 01 000000 00 01 0 0 00 0 0 000 ~ '" ~ '" d ~ '" N '" '" '" ~ '" '" W ~ '" ~ ~ '" _-\..f;;A _~ W .... _N~~_-\..Ef'7_f\.) .N '" .-1>- ~ 01 ~ ~.Ol .... '" '" '" .0) N-JOl 1.n w UJ-J ())CD NO -I>-()) en -J 0, '(0 Ol-J a -J CDOl()) ~ O)OCD 0.... OOOONO o -J W -I>- .... 01 O)-J 0 01 -1>-00 OOCD co.... OOON-I>-O 00 en N 0 0 001 .... 0 ())OO 000 N~ oooc.noo 00 c.n c.n 0 0 00 0 0 000 000 (.1101 000000 00 0 0 0 0 00 0 0 000 UJ -I>- o -I>- ~ 0) N OJ -l OJ ~ CD 6 ~ CD c r ~ (5 z (,,)(,,)CD o III -, 3 ... c. -co "C CD <ll III 0 ... :l - Z '< III 0 :l, g.-" ... ll<> C/) o :l (fl G') !;;! , c. r c. , <ll (") ... o Z :l 0 .... , iil N Sl 5' SO :; r "'0 CD <ll -, :l C. :l C. <ll (") ... o z :a. p ... III W Sl 5' SO :; r CD c: C. <ll ... Z P 0/>. c.. III '< CD ... o !" :; r 0/>.0/>. 0/>. -1>--1>--1>- -I>- 0/>. W ww W W W W W W W N NNNNN N z::;: c: <ll ""-JO) (]1 -I>-WN ~ 0 <0 CO""-J 0) (]1 -I>- W N ~ 0 <0 CO""-JO)(]1-1>- W 3 3 ;;oCll"'O c/)-iN-i~;;o-<O~~--'-O--'-"'O -iCll;;oz~o~~~~~m(")-iwow~W~(,,)CIl;;o;;o;;o"'O -i(")~ m)>:r> mOx;;o~m:r>m~q~m~:r> O~m(")~<(]1-o-(]1zr;;o~m~q~)>Ormmm:r> 00 = ~~;;o :E-i :r> -(");;om. .m-;:tl -i)>(") m --i_-i -0)>)> m 0 ZZ-i~~~;:tl -i~-i O--i m:r>"<CIl;;OOo~;;o~;;o~;;o-i :r>ro~~;;ogI)>IgCllCllCll~~~m~IZ~OOO-i :r>~-< <zO) ;:tlr(")I(")zo (")m(") (")01 rmz~<o)>;;oCll;;o)>mCllI)> ~m~omm<<<o/>. ro;\i mGl. "'0 ~ ~ ~ ~ )>::;@~~~ CIl~CIl CIl;'" "'OmCllmmm~z-izCll(")=Gl;;o ~ r(")zmmm, ;g Z = OJOJCIl ~x~ZO~mGlOGl-i~;;ocm ~ ~m-i(")("))>~-i ;:tl-i~ -::j-i ;:tl("))>S;:;;o- -i -i -i:r> -i~C-i~I~CIl~CIl~O~~~ 0 0 b~::;~~~ -ic;:tl -iI;;o;;oCZ 0 0 O-i -i;;o(") c~m O1OJom(")~ ;;0 ;;0 ;;Om 0/>.<(") ~ ;;o:r> )>~z;;ooz ;;0;;0 -i(") Z wmO ~_m ')> o-iZ ~ ~ ~;:tl .)>-i m CIlZ~Z )> 0 ~ ~ ~-<IZCll^ ,z~ Zz-i !;S:2 mz;2 CIl CIl CIlf? -i~z ~ -iO~O~ Y CIl CIl CIl ~;\iOJCIlbC/) C/)(")~ 00- -iZ z<' m m mC/) ~~~ ~ ~~m~~ ~ m ~ ~ ~~~~;;Od mIm::;: cC:S: m om(") ~ ~ ~-i ~ ;;O<ll CIlCll;g Z ;;0 Z (")-i;;o-im )> ~ m m z)>_r~;;o ~3 ~~O ;:tl CIl;;oCll m m mO ^ -i 0 -iGl(")Gl;;o (") 0 ;;0 ;;0 Gl(")zrCll:s: C'5 )> m-iGj?J?J?J;:tl )> )>)>< r ("). (") (") (") :s: C/) )> C OJ (") m .. CIlI Zm m -i <<m -i -i;;O ~ OJ 0 ~ (") (") -iZ m~C/) C/) m mm:s: C/) -i r r rC/) ~ 0 m ~ ~ )> Z s;: s;: Om ~m~ ;;0 ~~m d 0 ~ ~ ~m :s: z co ~ -i (") CIl CIl ;;ocll (");;om cIl mmz ;:tl .z cIl cIl cIl ::E . . co ~ r cIl cIl ~C )> ;;0 m ZZ-i :s: Z .(]1.Ul ,Ul ~ C/) ~ 0 .rcww (")cIl.. ;;0 -i-i~ m m mo)>o-' m~ < (") q co 0" ::E ;;0 m m ;;0 - 0 co 0 Z () r - - Cq , Cq m 0) ~ m m z ,. ,- Gl ;:tl = . .~OGlCl:l ,m CIlr mm mmr rmr m m (") m m rmmr C r r r r r r :l -<~ )>)> )>)>~ ~ ~ cIl)>~ ~ )> )> -< )> ~ ~ )> ~)>)>~ ~ .... (fl 0 Ul ~ ""-J Ul W W -< ""-J<O 0) N Ul ""-J N 0 Ul N ""-J 0 UlUl ~--'- ~~Ul Ul ""-J --'-~o Ul --'- W (]1 ~ W ""-J N O~~CJ1 Ul ~ ~ ~ ~ ~ c ,~~ ~~ .N~ ~ N ~ ~ ~ ~~ ~ 0-1>- W <0 ~ ~ ~ ""-JW --'- 'N Co ~ "--J ~ ~ W --'-Ul~ "'0 ~~ N<O (]1W--'- N N 0(]1~ W 0) W -I>- W -I>- Ul Ul ~.,J::..N~ ~ N-I>- (]1N NCO<O W 0 ON~ (]1 co Sl1 0 0 Ul N N Ul""-JCOO :---J ... ~~ 00 OO~ CD CD Oou, 0 0 0 0 0 W 0, 0 OU,OO 0 0' (]10 00 OOUl 0 (]1 000 0 0 0 0 0 0 0 0 0000 0 <ll -Y> ~ d ~ -Y> ~ ~ ~ o/>.~ ~ ~ ~ ~ ~ N ~ ~ -Y> ~ -~ ~ .""-J .~~ ~~..~ ~ W .01 J'v~..~ ~ N Ul ~ ~ N N ~ ..-J...EI)~~ o)N UlW U) 0-1>- W<ON Ul N -" ""-JW~ 0) N Co "0 "--J "--J Co ""-J (j)-1.CJ'1-....J 1.0~ ~ coco 01 N<O (]1WO) <0 co U) OUlUl ""-J 0) 0 0 W co <0 0 O-l>-NUl ow ~<O ""-J UlN NCO-l>- ""-J ~ co ON(]1 (]1 co Ul 0 0 Ul co -I>- o ""-J co 0 ""-JUl NU, U, 00 OON u, ~ en 000 0 0 0 0 0 CD N 0 OU,OO U,O (]10 0 00 OOUl 0 (]1 0 000 0 0 0 0 0 0 0 0 0000 010 C -Y> ~ ~ ~ ~ .~~ ~~ ~~ ~ N N ~ ~ ~~ N""-J -I>- co ~ ~ ~ Ul-l>- -I>- ~ ~ ~ en ~ ~ ""-J NO) ~ "'0 ~~ ~O O)UlN N N WO)~ 0 Ul N <0 N -I>- (]1 ~ ~CO<O~ --'- ... NW 00 NW-I>- :---J 0) <ONW !=" ~ ~ ~ !=" ""-J ~ W N""-J-I>-Ul W 0' ~W U,N NO:""'" --'- ~ U,NW ~ ~ ~ ~ ~ N ~ CD ~~Co~ 0, <ll 00 00 000 0 0 000 0 0 0 0 0 0 0 0 0000 0 -Y> ~ -Y> -i ~ -Y> ~ ~ ~ 0/>. ~ ~ ~ ~ ~ ~ N ~ ~ -" ~ ,~~ .U) .~~ ~~-~ ~ -I>- :0 -y>~.N N N ""-J N --'- W N --'- ~~~~ 0-1>- 0 ww 0) N""-J -I>-COUl 0) ~ 01 Ulo/>.Ul "0 ~ N "W en "--J Co ~ CO N 0)-1>- 1.n~ ~ co --'- 0) ~o O)UlO) ""-J <0 01 WO)-I>- -I>- Ul 0) Ul N -I>- Ul N O)CO<OO No/>. ow -" 00 NWO) ""-J ~ U) <ON~ 0 ~ Sl1 N !=" ~ Ul ""-J -I>-""-J-I>-Ul oco au, 00 U,N NOU, u, CD en U,NO u, --'- ~ u, ~ 0, ~ Co O~CoO 000 00 0 00 000 0 0 0 000 0 0 0 0 0 0 0 0 0000 00 C ~ ~ ~ ~ S: .~~ ~~ ~~ ~ .N N ~ --'- ~ ~~ 0/>.<0 NUl~ ~ ~ o)N ~ --'- "0 ~ "--J ~ ~ Ul ~N ~ "'0 -Y> ~ NW UlON N N o Ul -Y> Ul 0 0 0 N -I>- -I>- 0 -Y> Ul ""-J -Y> ~ ... N-I>- OUl OOCO <0 <0 00--'- 0 0 0 0 0 ""-J ""-J 0 WOOCO ~ 0' U,O 00 000 0 0 OO~ 0 0 0 0 0 0 0 0 U,OOO (]1 <ll 00 00 000 0 0 000 0 0 0 0 0 0 0 0 0000 0 -Y> -y> -Y> d -Y> -" ~ ~ -Y> .t ~ ~ ~ ~ ~ N ~ ~ ~ -y> -Y> _~ -y> .0 .~ -Y> .E:f) .E:FJ ..-J. ~ -I>- .E:FJ.E:FJ..-J. ~ ,N 0) N ~ W N ~ ..-J. -Ef) ~ -EA U)w -I>-W N -1>-<0 NUlCO ""-J "c.n 0) O)NW ""-J ~ "0 "c.n "--J en en "0 -J.-J.l'\,)cn w"c.n ~ wco 0 NW UlON N (]1 co OUlO Ul 0 0 0 N -I>- ""-J 0 NUl ""-J 0 WO ""-JO W OUl 000 Ul W U) 00<0 0 0 0 0 0 ~ <0 0 0000 01""-J U,O 0 00 000 0 0 0 000 0 0 0 0 0 0 0 0 0000 ou, 00 0 00 000 0 0 0 000 0 0 0 0 0 0 0 0 0000 00 C ~ ~ ~ ~ :l ~~ ~~ .--'- ~ -Y> -I>- N --" ~ ~~ ;:;: ""-J""-J ""-JUl~ ~ ~ N""-J W N Co ~ "--J ~ ~ ""-J NW ~ "'0 ~~ Ul~ Ulo)N W N o Ul -Y> Ul Ul W 0) 0 -I>- -I>- Ul ~ Ul Ul -y> N ... WW OUl OO""-J ~ <0 OON W 0 0 Ul 0 ""-J N 0 WOO-l>- 0 0' 0,0 00 00u, Ul 0 OON 0 0 0 0 0 0 0 0 0000 0 <ll (]10 00 000 0 0 OOUl 0 0 0 0 0 0 0 0 0000 0 -y> -Y> -Y> d ~ -y> ~ ~ 01 ~ ~ ~ ~ ~ ~ ~ N ~ ~ -" -Y> .N~ :0 ~~ .E:FJ~_-'-- ~ -I>- .0 .......:..~.......:.. ~ -I>- co ~ --'- W N --'- ~~~~ NO) ON U) ""-J""-J ""-JUl""-J ""-J "c.n U) N""-J""-J "--J N ~ .0) "--J en "W "c.n <oNWW en:'" ~ <0 CO 0 (]1--'- UlO)CO co Ul 0 OUlW 0) Ul <0 N 0 -I>- <0 0 O)UlUlO 010 COUl W OUl OO""-J ""-J W ""-J OON Ul 0 0 Ul 0 --'- -I>- 0 0000 U)O ~O 0 00 00u, u, 0 u, 00u, 0 0 0 0 0 0 0 0 0000 00 UlO 0 00 000 0 0 0 000 0 0 0 0 0 0 0 0 0000 00 W 0/>. o ::: 0) N OJ -i OJ -i N to i5 ~ to C r ~ o z nnto o III -. 3 .... 0. -0. "C to (l) III 0 .... :l - Z '< ~ p 16".... .... fie C/) o :l III en !p- . 0. r 0. , (l) n .... o Z :l 0 - , Dl N !l :i' se 5' p to 0: 0. (l) .... Z P c...> to 0: 0. (l) .... Z P -1>0 "tl (l) :l :l n o a. .... III C'l - 5' se 5' p c... III '< to .... o l' 5' p ---l---l---l ---l0l 0l0l Ol 0l0l 0l0l0l0ltl1tl1tl1 tl1 tl1tl1tl1tl1tl1 tl1 -1>0-1>0 z::;: C (l) WN.... OCO CO---l Ol tl1-1>o WN-'-OCOCO---l Ol tl1-1>oWN.... 0 coco 3 3 ~~roen~en~~0l00rozen0ro~~~en~~~~en~~en~0~en0enuQ~~ O~~omO-< =C-I>oOl ~O::j-<--<cmooOO--<0 -OQmO~~cmm ~~g~d8~~8~~~~~~c~~~~~ee~8~~~~2~~~~8~~~ ~r~m~m~rz~en0c~ ~r~r~~~~Oz~ro~mm~~mmm<< m"tl~~QX-<0z~O~B z<m<~~ rQm<C~0Q z~0~mm ~ en ~<-I>o~ z- O~ ZO 0~ _ zr ~~Q ~ ~~::j~~rm mO~0Zen c Om~~~ror om~o~~m 0 00 m~Im~m~~~Qo~Om en~ zu~~z~~ zen~~m~x z ~~ Z~ mO~~~ ccmc~ ~ ,~C0I ~ ,om~roz0 < ~,Ou~~-<co~z~enr ~~ ~m~IO~z ~~o-~c~ 0 ~m C/)um roen~~ ~ ~~ ~z muZror mw zenr ~ ~ ~~~~~ z<~~0m~ mQ ~~o~m~~ ~tl1~~~~~ 0 ~~::;: ~~~::jP O~ r~~~ ~0 ~~c~~au ~ 0~0roO ~ m-<~ m~::jI~ c mro en ~O z~enzo<m z 0 rOZ 0 0~ ~OIO-< en~ 0~0< r~ QOu00~ Q ~d~~~ I C< ~ u ~ 0 om ~ 0 ~~ 0 ~ en 0 ~ ~~m -~ zBc~ oen OZ<en~ 0 zenen~< ~ ro~ 0~< Xu 0 ~en ~m c m~en c ~tl1~~ en ~ ^~ ~~ ~Qenm ~~ ~ ~z~ ~ ~~~ - z~ c~ ~O mcm~ ~x en mQz en r~~a Z O~ uO mZ ~~ Q 0~ m Z Q m ~~~< z ~ ~ mm Z ^C ~ C ~ ro ~ ~ ~ ~ ~ en m m I Ien~ enr rr Q ~~ enenmm0en~ r m000m r en;: ~ ~-<Z -<~ ~~ ~ ZZ -<-<~~-<-<Z ~ ~-<-<-<~ ~ -<;::;: r III 0 N .... .... ~ -I:>- -I:>- ww .... -'- NN w.... -I:>- -I:>-0ltl1 W tl1tl1 tl1CO 0-1:>- tl1 -I:>-CO 0l0l WWtl1 -'- NCO-'- W co tl1 (J1 0 0 tl1tl1 tl10 0 CO---l OOW~-.....JWW co -I>otl100tl1 tl1 tl1 C "'" "'" ""'''''' "'" $: .... .... "'" ""'''''' "'" ""'''''' -1>0 -1>0 "'" "'" .... ""'''''' "'" ~ "tl .... .... "'" co -1:>-.... .... "'" "'" tl1-1:>- "'" "'" -I:>- -I:>- tl1 ""'-I:>- "'" tl1N....""'-I:>- "'" 0 O....N .... -'- ....tl1 N 0-1>0 ~-Jr.-.....J-JOc.oCJ1 Ol -I:>----ltl1tl1CO .... Ol .... 0 000 oi-v i-vo 0 0,<:0 :..i-voo:......~<:o Co ou,~~~ <:0 0 C:;' 0 000 0tl1 tl10 0 00 0000tl1tl1tl1 tl1 OOtl1COtl1 0 0 (l) ~ ""'~ d CD ""'''''' ""'''''' ""'''''' ""'''''' ~""'''''' ""''''''''''' "'" ........ "'" ~ ---l "'" "",_N_-I>o Ntl1 w.... "'" ---lCO ....... .-Jr. .-"- .E:fl _-'-- ...w ...-..J N ~_-:,,_o_[\.,)-EA "'" 'i-v tl1 tl1-1>oOl N-:" -:..~ .... -:"'Co ---ltl1W-I:>-CONO ~ OlOltl1OlN Ol U, [ .... tl1 tl1tl10 tl1tl1 wo 0 ---IN Q)-Jr..J::o.+::-.01~....Jr. ---l ....CONCO-l:>- 0 N .... 0 000 tl10l -'-0 0 -I:>-tl1 -I:>-N....---ltl1Oltl1 co Ol---lNNtl1 W 0 :.. 0 000 oi-v i-vo 0 oCo ooooo,~o ~ oo,o,<:o~ 0 0 UI 0 000 0tl1 tl10 0 00 0000tl1tl1tl1 0 0000tl1 0 0 c "'" ""'''''' S: "'" "'" "tl .... .... "'" ""'''''' "'" ""'''''' NN"'" "'" "'" ""''''''''''' N tl1 W"'" co -1:>-.... -'- "'" "'" tl1tl1 "'" "'" Ol Ol .... "'" tl1 .... -..IN......~c.n "'" "'" ~. ~ ........CO OlN NOl N tl10 ......-Jr.<DCOCOCJ1CJ1 .... ......NCOWW N ---lC'l co ocoi:..> ~<:o <:0 Co ~ o~ :......co~~~o,:.. -'- (o~:"i-vo Co i-v(l) 0 000 00 00 0 00 0000000 0 00000 0 0 ~ "'" ~ co ""'''''' ""'''''' ""'''''' ""'''''' ""'''''' ""'''''' "'" ""'.... ""'''''' I\J "'" "",_W_-I:>- NOl WN "'" coco ...-Jr. J'v -EA ~ ~ ...-Jr. _co -I:>- -EI7 ...<0 J" ...-J.. _-J.. "'" "'" 0 'i-v ---l OlCOCO u,N <ON -'- ~Co WOCON---lCO-l>o m NOlOlOlN co Ol [ UI Ol tl1N.... 010 0-1:>- W -I>oOl CO....OOlNW---l W CO-l:>-COWOl ---l co ---l -I:>- tl10tl1 coco -1>0-1>0 tl1 oco OlOlCOCOCO....Ol co ---l---lOlNtl1 .... -I:>- 0, 0, 000 0,0 00 0 o~ oo:......~(oo,i-v <:0 COO,OOO 0 0 0 0 000 00 00 0 00 0000000 0 00000 0 0 c "'" "'" "'" ""'''''' "'" "'" S: .... -'- .... "'" "'" "'" ""'''''' NN"'" "'" "'" N""'''''' .... "tl -I:>- -1:>-""'0 -1:>-.... .... "'" "'" tl1tl1 "'" "'" tl1 tl1 .... "'" tl1 .... 01-Jr.-Jr.-EA~ "'" "'" ~. 0 0....0 OlW W---l W tl10 .... NO 0 CO-l:>-tl1 0 OCOOlCOO W WC'l 0 000 ~~ ~o 0 :"<:0 i:..>o, 00 0 0:" 0, 00000 0 0(1) 0 000 tl1tl1 tl10 0 0tl1 0000000 0 00000 0 0 ~ "'" "'" d '" ""'''''' ""'''''' ""'''''' "'" .... ""'''''' ""'''''' "'" ~~-Jr.~ "'" .... "'" "",_N_tl1 NOl -I:>-N coo _-Jr._W~.Ef7~_...J.._CO -I:>- ~_-..J_-J.._~~ .... "'" 'Co u,m ~w "'" ~o w a - ---l ---l-l>oO .... Ol....---lN---lW-I:>- 00l0tl1---l N !!!. 0 0 0tl10 ---l0l coco tl1 co.... Wtl1tl1tl10W---l co o tl1-1>o CO 0 0 co ~ 0 000 ....CO Wo 0 CO---l COOOOWNOl co 00000 tl1 tl1 .... 0 000 i-v~ ~o 0 i-v:" ooooooi-v 0 00000 0 0 0 0 000 tl1tl1 tl10 0 0tl1 0000000 0 00000 0 0 C ""'''''' "'" $: "'" "'" "tl .... "'" .... ""'''''' "'" ""'''''' W W"'" "'" -'- "'" "'" "'" 0 co "'" 0 -1:>-.... .... "'" "'" tl1tl1 "'" "'" tl1 tl1 .... "'" tl1 "'" o -J.. -Jr..Ef) 0'1 "'" "'" ~, 0 tl1-'-tl1 N.... ....-1:>- S'-' coo W....0 OO-l:>-N co OCOOOlO Ol -I:>-C'l 0 000 0<:0 0,0 -'- 0:" 0<:00000(0 0 000<:00 0 0(1) 0 000 00 tl10 tl1 00 ONOOOOO 0 00000 0 0 ~ d CD ""'''''' ""'''''' ""'''''' ""'''''' ""''''''''''' ""'''''' "'" ""''''''''''' "'" -1>0 "'" "",_N_tl1 Ntl1 W.... "'" coco ...W ..N .....J.. ~ ~ ...-Jr. _OJ W ""'_---l_Ol_W"'" N "'" -:.. tl1 -I:>--I:>-N w~ u,w .... ~<o ---lNOWWWO w -I:>-OlCO-l:>-N a W [ .... 0 Ntl1tl1 -'-N NOl tl1 WN COCOtl1tl1---lWCO -I:>- 0tl100ltl1 .... co c...> 0 tl100 ow NO ---l NCO OWOOONW -1>0 OOOCOO 0 0 ~ 0 000 00 ~o 0, 0<:0 oi-voooo~ 0 00000 0 0 0 0 000 00 tl10 0 00 0000000 0 00000 0 0 W -I:>- o ~ Ol N ro ~ ro ~ w CD 6 ~ CD c: r ~ o z C"lC"lCD o III -. 3 ... 0. -0. "C CD III III 0 ... :l - Z '< III 0 :l. 15'-" ... l?O C/l o :l (fl G') ~ . 0. r 0. . III C"l ... o Z :l 0 ~ ~ !l S' !P S' p '"tl CD III -. :l 0. :l 0. III C"l ... o Z :l 0 - . ... III W !l S' !P S' p c.. CD III -. '< 0. CD 0. ... III o ... (fl Z ~ P S' ol>o P Z= t: III 3 3 ool~-iC/l-i-i -i-i-iCD O"OOmoo 000:1> ~;oO~~~~ ~~~~ r r rr rrr CD;'ii"O;o"O"O "0"0"08 lJ;s:~ ~~ ~~~.. mm-i -i-i -i-i-i CD~Q) (}1-l'>- wr-v-" - C/) I I I I I I Cl C/l r-i C/l~C/l -i ~;o m)>)> _ ;0 me ;O-iZ 3111 m ;oZ ::;m=i ~ )>A C"l;O)> rC/l ms:;o C/l-i C/l)>-< -i0 -C/l 0;0 Zm ;oS: ~ S:C/l m (') m;o o ~ ::!. m )> 03 ;0 a. n- o. 0 III z'" c: ::J :l a. W _ W 3 - )> III (fl n CD W 5 -. ::1 00. ~ a. ~ C/l co )> ro(1) 16 "0 a. 0 o.n-io. ~ a. ~ co ~ _. ""rI 0 CD -.. co ;:::;: =- co 11::1 en ~':';~':';~~ ~ 0~5~~~ ~~~ c: ffi~@~~~ ~~~ ~ Q,)tD1OJ-- OJC/)(JJ ;:;: ::Jo~ar-vr-v ~roO '"tl a.:J(t) NN ~....,- ..... -io.~r~~ s:~~ ~ ~ g.o~~ z'<g. III o ::JQ(O(O (}1C/l... -ru-.JCD (J'1=tQo 03 o~C/l ~ -....1-0 ..J..~ ~ ~-EA O'::J ~~ ~ -l'>- ~r-vr-v oool (fl -"--.j --.j (}1 Q)O-l'>- _ ~ (') ~N m ~ mNN III Q) 0 -"-" (}1 (0 O(O-l'>- - . ..J.. -Jr. -.l co -.J CJ'1 0 t..~ <0 en <OOt.. -"(}1 0 0 (}1(}1Q) O~"OO~~ S:~Q c: ::J0.(il~Q)Q) (1)0' :l ~co~.~~~ ~or ;:;: ::Jgg.C/lol>o-l'>- W~(') ~ a. a. ::J <: 0 --.j - = 0 (';' -i -~~~ S:o::!. III ~ ::Jr-v(O z~03 o (flW(}1 n g~l!5 ~~g ~~!P ~ o ~ ~~ ~ ~ ~~~ ool P "'lr-v (0 (0 OQ)~ 0 a.N "en u, u,m"en iii "-l(}1 Q) (}1 r-v~-l'>- - O1--.j -" (0 or-vw ~u. Co en Co~t.. 00 0 0 000 OCD"OO~~ S:-""O c: ::J~(il(1)Q)Q) ~~(1) :l (1)~(fl~WW ::Jr-v~ ~ wUJ-'~~~ (1) ~ ::Jgg.r~~ w~(') ~ o.o.::!.~--.j--.j ~(1)g ~ ~ roNN =::1- ~ :E :J(J1-.Jr. CJ1=r@ o g-l'>-ol>o i;:~n- ca (}1 -" Z ~ ~. 0l(1)__ ~~ ~ ~ ~~ (}1E::J 0(0 -" -l'>- ~r-vr-v oolo -l'>-(1)n ~~ ~ ~ ~~~ _ ~z O1~ r-v Q) WW-" III m ~o 0 ~ W(OQ) - ..J..CJ) W CD (J1-.,J-Jr. N~ 0 (:, o~o 00 0 0 000 0~0S:~~ ~"O~ c: ::Jo."W(}1(}1 ...0,< :l (1)CD.O....,~= rncoco ;:;: ~o. ?J-l'>--l'>- -0... '"tl 0.::J <-Q)Q) rxg ::::!, a. W -l'>- -l'>- W --.j. (') ~ '<~Cn ~8-- III o --.j -l'>- - ::J 00 s: P -l'>-O Z ~ ~ ~~ ~ ~ ~~~ ool o ~-l'>- (0 0 r-vW-l'>- a ~ b~ m m "enu,"en III "-l-" 0 0 OlOW - "'lW W --.j (O~Q) <o~ 0 u. ONU. 010 0 0 0(}10 W -l'>- o -l'>- -" Q) r-v CD -i CD -i 1. i~=~ ~ ):>):>::00 tl:l ~ "':J 0 ~~~~~ ~ iii' 3: (t) ~ fl) ......;::::::" 0 a~Q'l 0 -0 .Q. CD fl Z t\l 3 ~ ;; u; is: CD -I CD "'l "'l "'l III (') CD 5' ::r III en (') ~ -0 g. CD fl Z 9 -.J -..J -" OJ c: o u CD ::J S' 'R s:: o ::J 0.. t\l <- So -" _CD I\.) o o -I>- n, I\.)N I\.) ....J......J.....J.. -':"-J. ~ -" -" -" -" Z::+ CD CO-..J 0) (J1 ..(::l..WN-.:.. c: CD W 1\.)-" 0 CDCO-.JO)(J1-1>- WI\.)-" 0 3 3 -I>- 0 -I>- -:-:C/)~""O -I---O)COCOO)S::(')O;:O-C -Iz~O~;:O~~~~o~m(,);:O-lS::-c -" - -m -)> OZS::Z = = = =)>ocm)> 0) (')(');:0-0;:0 -I(')-o~G)G)OO-z(')s:::;o O(')-o<OZO:>< -,j -,j~om;:oO)> I\.) -1;:0 m-G)- 0 0 ~;:OS::)>OJ:;o OJ CO<('5-1 )>;:O;:O)>)>)>=o=oZZ-Io-l )> ;:0;:0)> )>-I>-m<m<-Imo~--I -I ;:0;:00_ w r-f20r--I-I~~ mr<N r-f2~oS::~S::~m(')m(')zo<~~-" OJ-om~' -c <r-mm (')mm. ~mm~~~~<-o~-o~G)~m('))>. ~~8~~ ~~8I~~~~ -I;og~ :;o~O-lm~m(') Z zs::r-~8~~ 0)> ':;0 -I-I-oc3r-r-mm dO-o~ -I ~I;:O~;:O~ ~ ~)>r-ZZOz OJ -o~S::-I>-< N =0;:0<<;:0;:0 z~m -" -0 ~-I~~ )> )>z(')~-Iz~ 6 )>OS::OC') . m~~~s::s:: ~~)>:;o . m )>z)>m ;:0 ;:OIO)>;:o )> ~ ZZO~m ~ ~-IZZ~~ (ji-l-ls:: ~ ~ ~G)~- ~ ~oz;:oO :;0 O~Z)>CIl )> 0 Oo_Z_Z -I~m)> )> 0 -I -I~ ~ ~r-z~r- ~ en OJ -I-I~" ~ C )> )>~ m mm~~ CIl c: OJ 0;:0-1 rri ~ OJOJ(')(') zz;:Oz ~ Z ~ ~ ~ ~ -1m m 3 r- O-om)> :;0 0 OOrr G)G)S::.. o W m m -~ ~ ~ X z;:o S )> _x.?<i7;i7; ~~~ :;0 )> s:: s::(J1 ;:0 ;:0 0 m (')~ )> -I __~~ - Z ~ ~ )> I - - zm :;0 0 I~ - <5 zz ~ CIl 0 Z ~ ~ -1;:0 .. Z m z Z -o-oRlRl )> m Z I ~ 0 0 0-0 ~ - rr -I ~- O~ ;:0;:0 =0 m -0 )>)> m m -0 r I W W m ;:0 m (')(') ;:0 :;0 m m (J1 (J1 ;:0 mm ;:0 -- -" 0 q q q , - m c: mmr r mmmrrm rr r r m mr r rrr ::l )>)>~ ~ )>)>)>~~)> OJ~ ~ ~ )> )>~ ~ )> ~~~ en Q W (]l (J1 co-" W N -" -'- co -..J 0-1>- W -..J (J1 (J1 -..J-..J(]l W ....J..-J.f\JUlCON 0(J1 0 -..J -'- -..J(J1 (]l -'- co-'--'- Vl c: C')ZOJ $: o 0 -' Vl Vl Vl Vl -'- 3::l-~ ~-J. ~ -EI) -'- -'- I\.) Vl_-'- Vl Vl W U, -C 't:l :::T CD I\.)VlVl CO-.JCDVlVlO -'- Vl Vl Vl -..J(J1 WO)-'- Vl WWWNWO Vl Vl Vl 0 -'- -..JW W 0 Vl(J10 "'l III 0.. "'l CDCDW 0 OVJN~-1.0 1\.)(J1 0 -" ~ ow ~ 0 -1>-00 0' ::l 2!.z <.n~c.n 0 Cn~(n(noo N~ 0 N -'- ~~ -'- 0 (noo CD ':.< CD 0 WN-I>- -'- -"W-I>-WCOO CD(J1 -'- 0) I\.) (J10) 0) 0 000 5'C');" (') 0 , ::l <f> Vl <f> Vl ~ "'l Vl Vl N Vl Vl -" Vl Vl N Vl Vl Vl ~ -'- -I c: ..-1. --E:R ...f::.. W ......J..-Efl_-J...~~_N --" ~ co ~ -'- ~_CD -" I\.) ~~_-.:.. 0 !l OJ 0)-1>-1\.) '".!>. CO-.....JCO......NO coco 10 -..J W -1>--'- Co U, -..J-..J(J1 PI o' -I -..JCOO) UI ~ WWO)O-l>-O WW N ~ 0 -'- CD-" I\.) 0 -" (J1 0 cJ, O)W(J1 -I>-(J1 OW (J1-1>-COO NW -I>- W co ~ (J1CD W 0 -"00 ::l ~i::o~ 000 Cn~o~Cno o~ '" w 00 -'- NO co 0 000 -'--1>-0 <ow -'-WCO(J1-1>-O 0(J1 <0 0 I\.) I\.) (J10 0 0 000 c: -OJOJ ~ ~ ~ Vl ~~ $: ::l c: -. P "'l 0.. ..-J. -Ef7 -ER -'- -'- -" 1\.)1\.) l/l 0.. ~Vl~ CDo)-..J~~tv ~ ~ "---l ~~ ~ u, ~u,o -c (') CD -..J-..J-'- ~ O(J1(J1WI\.)(J1 ~ -" ~ CD 0 (J1W I\.) 0 -"00 "'l :::T"'l (J1(J10 I\.) 0000(J10 WI\.) W co 0 00 (]l 0 (]l00 0" :::,z 000 (n 000000 00 (n 0 0 00 0 0 000 CD =0 000 0 000000 00 0 0 0 00 0 0 000 CD' C')~ 0 ::l ~ ~ <f> ~ ~ N~ ~ ~ -'- ~ ~~ N ~ ~ ~ ~ ~ ~~~ c? ~~_w <0 -'- ..-J. ~ ..-J. .."""-I i;f) ..N 1\.)-" -" -" -'- ~_co -" -'- I\.)I\.)N "'l ~ c: (J1(J1-'- U. '".!>. CDO)(J1NI\.)(J1 '".!>."---l Co -" 0) "---l WI\.) W U, wu,o ill !l NI\.)(J1 <O(J1 0(J10(J100 0-1>- co (J1 co 0 (J1(J1 -..J 0 -..Joo - 0' (J1(]l0 -..J-..J 000000 00 ~ (J1 0) 0 00 (J1 0 000 000 (n(n 000000 00 0 0 0 0 00 0 0 000 _::l 000 00 000000 00 0 0 0 0 00 0 0 000 OJ 6 ~ OJ C r" ~ (5 Z OZOJ o 0 -' 3 ~ ~ "0 ::r C'D III e.... ::l !l!..z :::: C'D 0 5'0;'" (') 0 . ::l !a. ... c: !l o' ::l 5'OJOJ (') c: -. , ... e. tile. (') C'D ::r'" :S. z =0 C'D' oen o ::l !a. ... c: !l o' .::l ,j:>.,j:>. ,j:>. ,j:>.,j:>.,j:>. ,j:>. ,j:>. W ww W W W W W W W f\J f\Jf\Jf\Jf\Jf\J f\J z::;: c: C'D "'-ICl) (J1 ,j:>.Wf\J -'- 0 <0 co "'-I Cl) (J1 ,j:>. W f\J -'- 0 <0 CO"'-lCl)(J1,j:>. W 3 3 ;OCJ)'tl CIl-lf\J-I-'-;o-<o-'--'--'-O-'-'tl -ICJ);oz~o~~~~~m(')-I~o~~~~(,)~;o;o;o'tl -1(')-'- m)>> mOx;o~m)>m~q~m~> O~m(')"lJ<~-o-(J1zr;o =m = - =)>Ormmm> e e = ~~;;o :!:-I )> '(');om' -m-;;o ~)>8;o;omo~~~oo~~~~;oo;oZZ-I~~~~ -I~-I 0--1 m>~CJ);OOO"lJ;o~;o"lJ;o-l r mo;o- -CJ) r (')m(')Iz~OOO ~~~ <zen ;;or"(')I(')ZO (')m(') (')UI r"mz~<o)>;oCJ);o)>mCJ)I)> "lJm"lJomm<<<,j:>. mGl. 'tl "lJ "lJ "lJ "lJ 'tlom >::;@-n~~ CJ)"lJCJ) CJ);'" 'tlmCJ)mmm~z-lzCJ)(,)=Gl;o "lJ r(')zmmm. > z = OJOJCIl ~x~ZO~mGloGl-l~;ocm ~ ~m-l(')(,))>"lJ-I -::j-l ;;o('))>~;o- -I -I -I> -I~C-l~I~CJ)~CJ)~O~~~ 0 0 d0::;5~~ ;;o-l~ -Ic;;o -II;O;oCZ 0 0 0-1 -1;0(') c~m UlOJom(')-- ;0 ;0 ;om ,j:>.<(') "lJ ;0)> )>~z;ooz ;0;0 -1(') Z wmO ~_m ')> o-lZ ~ ~ ~;;o ,)>-1 m CIlZ~Z )> 0 ~ ~ ~-<IZ~^ ,z"lJ zz-I >~ mzf] CJ) CJ) CJ)~ -I~z -n -IO~O~ y CIl CJ) CJ) ~~OJCJ)OCll CIl(')"lJ 00- mIm ::;: cc5: -IZ z<' m m mCJ) ~~~ ~ ~gmg~ ~ m ~ ~ ~~~~;O6 ~ ;oC'D CJ)CJ);g m om(') ~ ~ ~-I Z ;0 Z (')-I;O-lm )> ~ m m z)>_r~;;o ~3 ;;0 CJ);oCJ) m m me "lJ"lJe )> m-lGJ.?J.?J.?J;;o ^ -I 0 -IGl(')Gl;o (') (5 ;0 ;0 Gl(')zrCll5: n )> )>~< CJ) )> c OJ (') m .. CJ)I Zm m r" ('). (') (') (')5: -I -1;0 ~ OJ 0 ~ (') (') -IZ m~CJ) CIl -I <mm CIl -I r r rCJ) ~ 0 m ~ ~ )> z ~ ~ Om ~m~ m m~5: 6 0 )>)>)>m ;0 ~mm ;;0 .z ~ ~ ~~ 5: Z co ~ -I (') CJ) CJ) ;oCJ) (');Om CJ) mzz . - co -n r CJ) CJ) ~r )> ;;0 m ~-Iul 5: - (J1 (J1 (J1m CIl "lJ 0 -rcww (5CJ).. ;0 Z ... ;;0 m m mo)>o.. m~ < (') 0 co 0" ~ ;0 m m ;0 - 0 co 0 Z (5 r - - - ~ , ~ m Cl) "lJ m m Z ,- ,- Gl ;;0 = . ."lJ 0 GlGq 0 CJ)r mm mmr rmr m m (') m m rmmr C r r r r r r 2. -<-n )>)> )>)>-n -n -n CJ))>-n -n )> )> -< )> -n -n )> -n)>)>-n -n u; ;) (J1 -'- "'-I (J1 W W -< "'-1<0 Cl) f\J (J1 "'-I f\J 0 (J1 f\J "'-I 0 (J1(J1 -'- -'- -'- -'- (J1 (J1 "'-I -'--'-0 (J1 -'- W (J1 -'- W "'-I f\J O~....J.Ol (J1 C "" "" "" "" "" "" $: .-'- "" "".-'- """" "" f\J -'- -'- -'- """" wco ,j:>.f\J"" "" "" (J1,j:>. -'- -'- (0 "" (n "" "" 0 ,j:>.(J1 "" 'tl """" "-l0 "-l(J1f\J f\J f\J (J1 "'-I "" (J1 "'-I ,j:>. <0 ,j:>. ,j:>. ,j:>. 0 "" "'-I (J1 "" -'- ... W(J1 (J1<O (J1O<O 50 50 0(J10 (J1 ~ W co 9" Cl) Cl) 0 f\J(J1Cl)(J1 ,j:>. o' ~~ oeo oow -'- -'- 000 iv -'- eo (;, (J1 iv iv 0 mo~o 0 C'D (J1(J1 OOJ 00-'- -'- -'- 00-'- ,j:>. OJ <0 0 co (J1 (J1 0 (J10f\J0 (J1 -lfl -lfl "" -lfl "" ..... "" """" "" ,j:>. "" "" "" "" f\J "" "" ..... "" d .f\J <A ...... .-'- "" .f;;R~-l.~-l. "" ,j:>. .w """" "" 1'-' (J1 f\J -'- W f\J f\J "" <A "" "" O,j:>. -'-(J1 ..... WCO ,j:>.f\J<O "-l (n <0 (J1,j:>. "-l -'- Co ".1>- (n 'iv "en 0 OJ,j:>.(J1W "--l'iv [ (J1,j:>. ..... "-l0 "'-I(J10 f\J "-l "-l (J1 "'-I "" "-l "'-I W Cl) ,j:>. Cl) W 0 ,j:>."'-I(J1"'-1 .....CO Cl)Cl) !-' (J1<O (J10(J1 "-l 0 OJ 0(J1"-l Cl) ~ -'- f\J Cl) W Cl) 0 CO(J1Cl)(J1 0(J1 iviv ..... oeo 00:"" ~ iv i:Xl oo~ iv -'- eo (;, (;, ~ N 0 oo~o (oiv (J1(J1 UI OOJ 00(J1 (J1 "-l UI 000 0 co "-l 0 OJ (J1 (J1 0 00f\J0 0(J1 C "" "" <A "" "" "" $: ...... <A """" .-'- "" "" f\J f\J -'- -'- <A <A 0"'-1 (J1 <0 "" "" "" f\J(J1 ..... "--.I ".1>- <A "--.I "" "" (n ,j:>. "-l <A 'tl "" <A 0f\J 0"-lf\J f\J f\J 00 <A Cl) (J1 (J1 <0 Cl) ,j:>. ,j:>. 0 -Ef)OO~ "" ... ,j:>.,j:>. 0(J1 O(J1W "-l (J1 00f\J 0 0 0 0 0 Cl) <0 0 WOO(J1 <0 0' 00 00 000 0 0 00(;, 0 0 0 0 0 0 0 0 0000 0 C'D 00 00 000 0 0 000 0 0 0 0 0 0 0 0 0000 0 -lfl "" "" -lfl "" "" <A UI <A "" <A "" "" <A f\J "" "" <A -lfl "" d .f\J <A .<0 .-'- <A -EA.(;I';..-l. "" W _0 ..-l. ~ ..-1. <A f\J "-l f\J ..... _W f\J W <A <A "" .-'- enf\J W W N 0"'-1 (J1<O,j:>. Cl) (0 en f\J(J1<O OJ "--.I -W 'iv "--.I -'- "--.I 0 c.o~-.....J-l. 1.0"--.1 [ OOJ <0 0f\J 0"'-1<0 "'-I f\J UI 00f\J 0 (J1 (J1 (J1 Cl) W <0 0 Cl)00f\J ,j:>.,j:>. 00 UI 0(J1 0(J1(J1 (J1 (J1 ..... 00(J1 0 0 0 0 0 co W 0 000(J1 UI(J1 00 0 00 000 0 0 0 000 0 0 0 0 0 0 0 0 0000 00 00 0 00 000 0 0 0 000 0 0 0 0 0 0 0 0 0000 00 W ,j:>. o ,j:>. -'- Cl) N OJ -I OJ -I en ---J---J---J ---JCl) Cl)Cl) Cl) Cl)Cl) Cl)Cl)Cl)Cl)UlUlUl Ul UlUlUlUlUl Ul -!>--!>- Z;::;: c: ro WN-'- 0<0 CO---J Cl) Ul-!>- WN-'-O<OCO---J Cl) (J1~WI'\.)-Jr. 0 <0 CO 3 3 ~~m~~Q~~Cl)00mz~0m~~~~~~~~~~~~~0~~0~~Q~~ O~~omO-< =c-!>-Cl) ~O::j-<--<cmooOO--<0 -OQmO~~cmm ~~O~~O~~0~~~~~~c~~~m0~~~0~~I~ZQr~~o~~~ ~OmO~ mOm ~ ~~m mQrcc~Ocmm z~m~m~~OO ~~~~~~~~R~~8~~ z~~~~~~~Qz~~~~~~~o~~~~~ ~~~~~~~-!>-~B~Rz~ ~~mz~m~~~pmz~~~~~~ ~ 00 ~~~~~m~~~QO~Om ~~ ~~::j~z~~ ~~~~m~x ~ ~~ to en m ~~~ ccmc~ ~ ,~C0I ~ ,0 ~ z0 < E5 ~,o~~~-<co~z~~r ~~ ~m~IO~z ~~~z~c~ 0 ~~ ~ ~~m m~~~ ~ ~~ ~z m~-mr mw ~r ~ ~~~~~ z<~~0m~ mQ ~~6~m~~ ~Ul~~~~~ 0 ~~ it to ~~~::j0 Om r~~~ ~0 ~~c~~o~ ~ 0r0mO ~ m-< 3 c: m~::jI~ c~ mm~~ ~o z~~zB<m z omroz 0 0~ r ~OIO-< ~~ 0~0< r~ QO~00~ Q ~6~~~ I c< ~ ~ ~ ~-< 0 om ~ 0 ~~ 0 ~ ~ 0 ~ 0 ~~m x~ zBc~ O~ Oz<~~ 0 z~~~< ~ m~ 0~< ~ 0 ~~ ~ c m~ c ~Ul~~ ~ ~ Z ^~ ~~ ~Q~m ~~ ~ ~z~ ~ ~~~ - zm c~ ~O mcm~ ~x ~ mQz ~ rC~o Z o~ ~O mZ ~~ Q 0~ m z Q m ~~~< z ~ ~ mm z ^C ~ C ~ m ~ ~ ~ ~ ~ ~ m m I I~~ Q ~~ ~~mm0~~ m000m ~ c: ~r rr r r ~ ~ ~-<z -<~ ~~ ~ zz -<-<~~-<-<z ~ ~-<-<-<~ ~ -< r '" -'- -'- Q N -!>- -!>- WW -'- -'- NN W -'- -!>- -!>-Cl)Ul W UlUl UlCO O-!>- (J1 -!>-<O Cl)Cl) WWUl -'- N<O-'- W <0 Ul (Jl 0 0 UlUl UlO 0 CO---J OOW-l.-..JWW co -!>-UlOOUl Ul Ul c: 0Zto S: o 0 -. <f> <f> <f> <f> 3::l.!5: <f> <f> "tl '0 ::r ro -'- -'- <f> <f> <f> <f> <f> <f> -'- -'- <f> <f> <f> -'- <f> <f> -'- 0 (J1 <f> <0 Ul-'- -'- <f> <f> Ul-!>- <f> <f> 0 ---J -'- <f> Ul -'- NNN<f>N <f> <f> :!. III Co""' (J1 (J1-'-Cl) -'-N NCl) N -!>-<O N-'-OUl(J1Cl)-!>- W UlCl)N<OUl N Uln ::l !!!.Z 0 O:':"~ :':"en en:':" en ~N c.nenooo<oc.n c.n ooc.n~o N oro :c: ro 0 0 OUlUl Cl)W WUl <0 CO <0 O-Jr.OOO-Jr.O 0 OOOUlO Ul 0 :r C') ;", n 0 , ::l -E.'> ~ .... <f> <f> ""' 0 <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> -'- -'- <f> ~ c: .... <f> <f>.w.-!>- NCl) WN <f> CO <0 .w ..N <f> <f> <f> ..N .co Ul <f>.-'-.Ul.-!>-<f> <f> <f> !l c,., Ul ---JUlCO Co~ Co~ -'- 0"....1 ...Jr.oW-Jr.(JlWW -Cl) UlOUl<OCl) ---J -!>- 1[ (5' -!>- N ---JUlW WN Ul<O W -'- -'- UlNO---JUlOW -!>- OUlN---JN Ul ---J !" Ul (J1N---J OUl NW -!>- coo OCOOUlUl-'-CO W OOUlNUl W Ul ::l .... 0 oc.nc.n <:..vc.n ~o c.n Cn~ oenooooc.n 0 oooc.no ~ 0 Ul 0 000 OUl UlO 0 -!>-w OOOOOWO 0 00000 Ul 0 c: -toto ~ ~ ~ c: <f> <f> <f> <f> <f> -E.'> '" Co -E.'> -'- -'- <f> <f> <f> <f> -E.'> -!>- -!>- <f> <f> -Jr.~.Ef).Ef)-Jr. "tl n ro co (J1<f>-'- Ul-'- -'- <f> <f> Ul-!>- <f> <f> 0 0 N <f> Ul <f> ONN-'-O <f> -E.'> :!. ::r""' 0 0-'-0 N-!>- Cl)-!>- N N---J -'-NOOUl(J1N co O---JNOO Cl) Uln :5. Z 0 oc.no o~ 00 ~ oCo c.noooooo 0 ONOOO 0 oro =0 0 000 OUl 00 (J1 OUl 0000000 0 OUlOOO 0 0 ro' C')m 0 -E.'> ::l .... <f> <f> ~ 0 <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> <f> -'- -'- <f> <f> ~ ""' .... <f> <f>.W.Ul N---J -!>--'- <f> ---J<O _-J. _t\J _-J. -Ef7 -Ef) _...Jr. _-.....1 W <f>.-'-.Ul.Ul<f> N -E.'>O c: c,., -!>- ---JCl)Ul Co~ "cow -'- "en.-!>- COUlN-!>-<OCl)<o W .,f::l..(J'1....J......J..()1 0 :!::j[ !l m 0 (J1---J0 Cl)Ul COcl) W <ON <ONOONCl)Ul -!>- OCOCOOO -'- -!>- 0 OUlO ow 00 ---J Cl)Cl) OOOOUl(J1Cl) -!>- O-J.OOO 0 Ul (5' <0 0 000 O~ 00 c.n 0:':" 0000000 0 ONOOO 0 0 .::l Ul 0 000 OUl 00 0 OUl 0000000 0 OUlOOO 0 0 W -!>- o ~ cl) N m ~ m ~ ~ OJ i5 ~ OJ c: r ~ (5 Z z;:;: c: Cll 3 3 It 3 nzOJ o 0 -. 3::l-~ 'tl ;:r Cll III Q. '" ::l 2!. z ~ Cll 0 5'n;;' o 0 . ::l C/O - '" c: g, 0' ::l 5'OJOJ o c: -. . '" Q. C/OQ. o Cll ;:r'" :5. z =0 Cll' nen o ::l le. '" c: g, o' .::l 2 c: $: 'tl '" o' Cll {fl "" N-" "" "" """""" -"0 -" -I'>- -"1\)1\) -f <0-" -" c.u oc.uco 0 "co "en -" (0 ~-:::'(o ~ W-I'>- -" -..J -"(J11\) 0(0 ~ co 0-1'>--1'>- ~~ -" 0, "'ON W(J1 (J1 (J1 0(0(0 c: S: 'tl '" o' Cll {fl "" N-" "" "" Y> NO "" (J1 "" I\) I\) d 0-" (0 0 en (0-" '0 "en ~ "en (ou,Co ~ wo) (0 (J1 -1'>-(0 CO <0-1'>- (J1 -" (J1-..J0) :;..'" 0 0 0(;,0 Ul(J1 0 0 000 c: S: C/O -f-f-fOJ 000)> -f-f-fcn )>)>)>m rrrOJ lJlJlJ- )>)>)>S' ;:U;:U;:U -f-f-f c.utv-" , , , cn~cn m)>)> ;:U-fZ :::;m:::j (');:u)> ms:;:U en)>-< -en Zm ~ m ;:u -f:;:-fen-f-f O'tiOmOO ~;:u0~~~~ r r rr OJ<lJ;:UlJlJ )>~)> )>)> ~m~ ~~ OJ~O) (J1-1'>- i5enc'n ~.:; -i ~;:u ;:u me m ;:uZ m )>^ -f ren en-i -f0 0;:U ;:uS: s:en m ~ m ;:u (') o ~ )> ~ 0. ~ 0. 0 ro '" ::l Z 0. OJ OJ 3 )> ro oCD OJ 5' -. 'n ::J 00. :!.~ 0. ~en <0 )> ro~ ffi lJ ~ c8-S;::lo. 5 (ti ro::;:!:!:CD"::J C/O ~':<; ~ ':<; g,! ~ ~ o!P.:::;;J-::::J-::::J~~2i5- ffio.ooO)O)<o-I'>-3::l- CD ro 3 ~~ ro (J1-o ::r g;OlJOJ-I'>--I'>-CiloOJo. o.::J(tiC/Ol\)tv- Z::J!!!.. -i 0. ~. )> rp rp s: Q ::< ro < c.. -I'>--I'>-Z~-""" < ro<::<oco ::r::J" o ::J<::(OO) 0.00 ~a5'-..Jco~!!!..' ~ CJ" w ro ~ C/O -..J CD c: ^ -1'>-- 0 -. C3. g ::J c.u -I'>- o ~ (J) I\) CD -f O!p'lJ<--::::J-::::JlJ::3'CD ::Jo.(ti~0)0)0-l'>-0S; ro CD ~. ro ~ ~ CD ~ ~ OJ 0 o.C/O-I'>--I'>-O ::r 5.5.~rn~~~~ ~ -i enJ"J,,(J1en ro ~ otvtv '" (') ffi85t) * g ::J ~ rJl CL Z ~ ~ m n. o' ::J CD -f Co ~ ~ ~ Bonestroo II Rosene ~ Anderfik & 1 ~ . Associates Engineers & Architects 2335 West Highway 36 . St. Paul. MN 55113 Office: 651-636-4600 . Fax: 651-636-1311 www.bonestroo.com August 17, 2004 Richard L. O'Gara Carl Bolander & Sons Co. 251 Starkey Street St Paul, NIN 55107 Re: City of New Hope, Minnesota Hillside Terrace Infrastructure Improvements Project City Project No. 771 File No. 34-04-162 Contract Documents Enclosed are four (4) Contract Documents between you and the City of New Hope covering the above-referenced Project. Please complete Specification Section 00520 Agreement Form, Section 00610 Performance Bond, and Section 00615 Payment Bond. The insurance and indemnity requirements shall be provided. After the bonding company has completed the Contract Documents, forward them to the attorney listed below who will review them for the City of New Hope: Mr. Steven Sondrall Jensen & Sondrall P.A. 8525 Edinbrook Crossing, Suite 201 Brookly1l Park, NIN 55443-1983 After the necessary officials have signed the Contracts, please distribute as follows: 2 copies 1 copy 1 copy Carl Bolander & Sons Co. (1 - your file, 1 - your bond company) City of New Hope, Attention: Valerie Leone Bonestroo & Associates, Attention: Vince Vander Top Upon receipt of a signed Contract and a filed Certificate of Insurance, approved by the City of New Hope's Attorney, a pre-construction conference will be scheduled with you and the City of New Hope to review the Proj ect. Sincerely, BONESTROO, ROSENr:, Al'IDERLIK & ASSOCIATES, We. /C~y Vincent T, Vander Top, P,E, Enclosures: Four (4) Contract Documents cc: Steven Sondrall, City Attorney Valerie Leone, City of New Hope . St. Paul, St. Cloud, Rochester, Willmar, MN · ivlilwaukee, WI . Chicago, IL Affirmative Acrion,/Equal Opportunity Employer and Empioyee Owned DOUGLAS J. DEBNER' GORDON L. JENSEN! CLARISSA lVI, KLUG GLEN A. NORTON STEVEN A. SONDR~LL STACY A. WOODS OF COUNSEL LORENS Q. BRYNESTAD 'Real Propeny Law Speeialist Certified By The Minnesota State Bar Association 'Admitted in Iowa I JENSEN & SONDRALL, P.A. Attorneys At Law 8525 EDINBROOK CROSSING, STE. 201 BROOKLYN PARK, MINNESOTA 55443-1968 TELEPHONE (763) 424-8811 $ TELEFAX (763) 493-5193 e-mail law@jensen-sondrall.com Writer's Direct Dial No.: (763) 201-0217 e-mail djd@jensen-sondrall.com September 22, 2004 Mark R. Ryan, President Carl Bolander & Sons Co, 251 Starkey Street St. Paul, MN 55107-0216 SENT BY FACSIMILE ONLY TO: (651) 223-8197 Re: The City of New Hope 2004 Hillside Terrace Infrastructure Improvements Contract City Project No.: 771 City Engineer File No.: 34-04-162 Our File No.: 99.10030(B) Dear Mr. Ryan: I have received a proposed Certificate of Insurance and it meets with our approval with one exception. The notice cancellation provision on the proposed Certificate of Trust fails to meet the requirements of Section 5.04(B)(5) of the Contract. Therefore it is requested the following changes be made to that provision: SHOULD ANY OF THE ABOVE-DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEA \TOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT F;\IU_TRE TO M/,.IL SVCH l'~OTICE SHALL IMPOSE NO OBLIG.^~TION OR LL^J3ILITY OF .<,'-'NY KIND '[IPON THE INSURER, ITS L\GENTS OR REPRESENTATIVES. Please provide us with four originals of revised Certificate of Trust. Upon receipt we \vill forward the Contracts to the City for final execution. Please contact me with any questions or comments. Otherwise, I thank you for your attention to this matter. Very truly yours, Douglas J. Debner Assistant City Attorney City of New Hope JENSEN & SONDRALL, P.A. d j d@jensen-sondrall.com cc: Steven A. Sondrall, City Attorney, City of New Hope (via email onlyto:sas@jensen-sondrall.com) September 23, 2004 Page 2 Guy Jolmson, Director of Public Works, City of New Hope (via email only to: gjohnson@ci,new-hope.rrm.us) Dale Reed, Operations Manager, City of New Hope (via email only to: dreed@ci,new-hope,rrm,us) Manuel Jordan, City Forester/Contract Manager (via email only to: mjordan@ci.new-hope.rrm.us) Valerie Leone, City Clerk, City of New Hope (via email only to: vleone@ci.new-hope.rrm.us) Vincent T, Vander Top, New Hope Engineer (via email tovvandertop@bonestroo.com) P:\".ttomeyiDJD\2. City of New Hopci99.10030 (B) - Publie Works MatlersilO- 2004 Hillside Terrace Infrastructure Improvements ContractiCNH99.I0030(B)(IO)-002-Ryan LtLdoc DOUGLAS J. DEBNER' GORDON L. JENSENl CLARISSA M. KLUG GLEN A. NORTON STEVEN A, SONDRALL STACY A. WOODS OF COUNSEL LORENS Q. BRYNESTAD 'Real Property Law Specialist Certified By The Minnesota State Bar Association 'Admitted in Iowa JENSEN & SONDRALL, P.A. Attorneys At Law 8525 EDINBROOK CROSSING, STE. 201 BROOKLYN PARK, MINNESOTA 55443-1968 TELEPHONE (763) 424-8811 $ TELEFAX (763) 493-5193 e-mail law@jensen-sondraIl.com Writer's Direct Dial No.: (763) 20]-0217 e-mail djd@jensen-sondrall.com September 3, 2004 Mark R. Ryan, President Carl Bolander & Sons Co, 251 Starkey Street St. Paul, MN 55107-0216 SENT BY FACSIMILE ONLY TO: (651) 223-8197 Re: The City of New Hope 2004 Hillside Terrace Infrastructure Improvements Contract City Project No.: 771 City Engineer File No.: 34-04-162 Our File No.: 99.10030(B) Dear Mr. Ryan: The City Attorney's Office is responsible for verifying that the Contractor has validly signed the Contract and met the relevant terms of the Contract prior to execution by the City. To that end I have recently been provided with the four (4) original 2004 Hillside Terrace Infrastructure Improvements Contracts signed by you. Unfortunately, I cannot advise the City to proceed with the execution of the Contract at this time because a Certificate of Insurance was not submitted with the Contracts. Standard Conditions of the Construction Contract Section 5.03 requires a Certificate be provided, As I am unable to verify compliance with virtually all of the insurance related provisions of the Contract until I receive your Certificate of Insurance, it would be deeply appreciated if you would provide one as soon as possible. As it is very common for Certificates of Insurance to be revised, it would probably greatly speed the process if you would have your insurance agent fax a proposed Certificate to me before it is signed. Please contact me with any questions or comments. Otherwise, I thank you for your attention to this matter, Very truly yours, Douglas J. Debner Assistant City Attorney City of New Hope JENSEN & SONDRALL, P.A. djd@jensen-sondrall.com September 3,2004 Page 2 cc: Steven A. Sondrall, City Attorney, City of New Hope (via email onlyto:sas@jensen-sondral1.com) Guy Johnson, Director of Public Works, City of New Hope (via email only to: gjohnson@ci,new-hope.mn,us) Dale Reed, Operations Manager, City of New Hope (via email only to: dreed@ci.new-hope.mn.us) ManueI Jordan, City Forester/Contract Manager (via email only to: mjordan@ci.new-hope,mn.us) Valerie Leone, City Clerk, City of New Hope (via email only to: vleone@ci,new-hope.mn,us) Vincent T. Vander Top, New Hope Engineer (via email tovvandertop@bonestroo.com) P:I.-\ttorneyIDJDi2. City orNew Hope199.10030 (B) - Public Works MattersllO- 2004 Hillside Terrace Infrastructure Improvements ContractICNH99.10030(B)( 10).001-Ryan LtLdoc DOUGu.s J. DEBNER2 GORDON L. JENSEN I CLARISSA M. KLUG GLEN A, NORTON STEVEN A. SOl'mR~LL STACY A, WOODS OF COUNSEL LORENS Q. BR'\:N'ESTAD 'Real Property Law Specialist Certified By The M innesOla State Bar Association 'Admitted in Iowa JENSEN & SONDRALL, P.A. Attorneys At Law 8525 EDINBROOK CROSSING, STE. 201 BROOKL YN PARK, MINNESOTA 55443-1968 TELEPHONE (763) 424-8811 . TELEFAX (763) 493-5193 e-mail law@jensen-sondrall.com Writer's Direct Dial No.: (763) 201-0217 e-mail djd@jensen-sondrall.com October 1, 2004 Valerie Leone City Clerk City of New Hope 4401 Xylon Avenue North New Hope, MN 55428 Re: The City of New Hope 2004 Hillside Terrace Infrastructure Improvements Contract City Project No.: 771 City Engineer File No.: 34-04-162 Our File No.: 99.10030(B) Dear Val: Please find enclosed four (4) originals of the above referenced contract. Four originals of each bond and four originals of the Certificate of Insurance are also included with the contracts, The City may complete the execution of these contracts at this time. Please call me if you have any questions. Thank you. I ve. ry......)ul~7rJf '. ./! . ..:1 . u'/.' (dA- ;;'Ji/ be~ Assistant City Attorney, CjY of New Hope Enclosures cc: Steven A. Sondrall, City Attorney [via e-mail only] Guy Johnson, Public Works Director [via e-mail only] P:\Auomey\DJD\2. City of New Hope\99.10030 (B) - Public Works ~latters\lO~ 2004 Hillside Terrace Infrastructure Improvements Conrract\CNH99.10030{BHlO)-(XJ3-LT VaI.doc October 8,2004 Mr. Mark Ryan, President Carl Bolander & Sons Co. 251 Starkey Street St. Paul, MN 55107-0216 SUBJECT: 2004 HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENTS _ (IMPROVEMENT PROJECT NO. 771) Enclosed are two fully executed contract documents for New Hope Project No. 771. One set is for your records and the second set should be transmitted to your bonding company. This contract was awarded by the New Hope City Council on August 9, 2004, for $191 ,811.31. Enclosed is return of your bid bond. Also enclosed is a "Withholding Affidavit for Contractors" (IC-134 form). We cannot make final payment to contractors until this is approved by the Minnesota Department of Revenue and submitted to our office (Minnesota Statute 290.97). The form contains instructions for completion. Should you have any questions regarding the project, please contact Guy Johnson, Director of Public Works, at 763-592-6766. Sincerely, J- /.~" I Valerie Leone City Clerk, CMC enc. cc: Steve Sondrall, City Attorney (File No. 99,1 0030(B) Vince VanderTop, Assistant City Engineer (File No. 34-04-162) Guy Johnson, Director of Public Works CITY OF NEW HOPE 4401 Xylon Avenue North · New Hope, Minnesota 55428-4898 . W\VW, ci.ne\'\'-hope.mn.us City Hall: 763-531-5100. Police (non-emergency): 763-531-5170. Public Works: 763-592-6777. TDD: 763-531-5109 City Hall Fax: 763-531-5136. Police Fax: 763-531-5174. Public Works Fax: 763-592-6776 COUNCIL REQUEST FOR ACTION Originating Department Approved for Agenda Agenda Section Public Works April 11, 2005 Consent Item No. 6.5 B Guy Johnson RESOLUTION APPROVING CHANGE ORDER NO.1 RELATING TO CONTRACT FOR THE HILLSIDE TERRACE INFRASTRUCTURE INSTALLATION (IMPROVEMENT PROJECT NO. 771) REQUESTED ACTION Staff is recommending that the Council approve a change order to the contract with the Carl Bolander & Sons Company for the Hillside Terrace Infrastructure Improvement Project in the amount of $10,734. POLICY/PAST PRACTICE This work coincides with the city's mission of delivering quality public services to residents, property owners, and organizations within the city in a prudent and efficient manner. BACKGROUND Allen Chazin Homes entered into an agreement with St. Joseph's Church to purchase the out lot A on the west edge of the church property. A plat plan that includes seven lots was approved for the development. In order for the development to proceed, a street, cul-de-sac, and the associated infrastructure had to be installed. The City Council authorized the preparation of plans and specifications for construction of the necessary infrastructure on June 14, 2004, and approved plans and specifications on June 28, 2004. Six bids were received on juiy i9, 2004, The lowest responsible bid for construction of the infrastructure was from the Carl Bolander & Sons Company for $191,811.31. The engineer's construction cost estimate was $202,000 for the 35th Avenue extension, the cul-de-sac, and the utilities. During the project it has been necessary to adjust some of the work and correct some issues. The contractor has requested a change order to address these items. Staff is recommending payment for these items. The items are: Utility structures in the new street were raised. (New home sites and the street were raised because of sanitary sewer drainage concerns. This necessitated adjusting the utility structures in the new street to match the street's new elevation.) $1,992 Installation of a new storm water structure on Ensign Avenue was required. (The existing structure had to be removed because exterior structural defects were exposed during excavation around the structure.) $8,742 Total: $10,734 MOTION BY l /./:/-l (~; SECOND BY TO: I:RFA\Pubworks\2005\771 Hillside Terrace Infrastructure Change Order 771 Change Order April 11, 2005 Page 2 FUNDING Bolander and Sons Company's original contract for the project was $191,811.31. With this change order the contract amount will be $202,545.31. Funding for replacement of the city's existing storm water structure will be from the city's storm water fund. The cost for adjusting utility structures in the new street will be the responsibility of the developer. ATTACHMENTS Copies of the engineer's memorandum, the resolution, and the change order are attached, RESOLUTION NO. 05 - 53 CITY OF NEW HOPE RESOLUTION APPROVING CHANGE ORDER NO.1 FOR THE CONSTRUCTION OF THE HILLSIDE TERRACE INFRASTRUCTURE IMPROVEl\1ENT PROJECT NO. 771 BE IT RESOLVED by the City Council of the City of New Hope that Change Order No. 1 in the amount ofTen Thousand Seven Hundred and Thirty-four and 00/100 Dollars ($10,734.00) to the contract with Carl Bolander & Sons Company for the Hillside Terrace Infrastructure Improvement Project identified as Improvement No. 771 is hereby approved, Change Order No.1 is necessary to address additional work as described in the City Engineer's March 17, 2005 letter attached hereto as Exhibit A. The Mayor and City Manager are hereby authorized and directed to sign Change Order No.1 permitting this work to occur. Dated the 11 th day of April, 2005. " c) J2~ -...fi . ~-:) Attest: / /} i(7.L.U ,..... 7..nL.~ V a1~rie Leone, City Clerk p:\AnOR.~EY\SAS\1 CLlE?'o-r FTI..E$\2 CITY OF NEW HO?E\99-67711(HIU.SIDE TERR.-\CE)\RESou..inON A.PPR Clt.!u....GE ORDER LDOC 1 ~~ . f1, Bonestroo LJI Owner: City of New Hone, 4401 Xylon Ave. N., New Hope,:tvlN 55428 ..::::. Rosene "1\11 Anderli/< & Contractor: Carl Bolander & Sons Co., 251 Starkey Street, SL Paul,:tvlN 55107 . \J. Associates Engineers & Architects Bond Company: Date March 17, 2005 Bond No: CHAl'l'GEORDERNO. 1 HJLLSIDE TERRACE INFRASTRUCTURE Th1PROVEMENTS CLIENT PROJECT NO. 77I BRA FILE NO. 34-04-162 Description of Work Structure Chan!!es Several new structures were ordered to accomodate revised street grades. Storm Sewer Structure Replacement An existing storm sewer manhole was removed and replaced with a new structure. All work involved, including necessary connections to existing and new pipes, was completed. Contract Unit Total No. Item Unit Quantity Price Amount CHAl'lGE ORDER NO.1 Structure Changes LS $1,992.00 $1,992.00 2 Storm Sewer Structure Replacement LS $8,742.00 $8,742.00 Total CHANGE ORDER NO.1: $10,734.00 34041 62CHOI.xls II f1 ~ Bonestroo e Rosene 1i\lI Anderlik & 1 \J'1 Associates Engineers & Architects 2335 West Highway 36 . 51. Paul. MN 55113 Office: 651-636-4600 . Fax: 651-636-1311 www.bonestroo.com March 17,2005 Mr. Guy Johnson City of New Hope 5500 International Pkwy. New Hope, MN 55428 Re: Hillside Terrace Development, City Project No. 771 Change Order # 1 BRAA # 34-04-162 Dear Guy: The plans submitted by the developer of Hillside Terrace include home elevations such that there was concern about potential future sanitary sewer backups. To address this potential hazard, the elevations of the homes were raised, resulting in a raised street grade. This revision required design alterations for some of the sewer structures. The total costs associated with the new structures totaled $1,992.00. The existing storm manhole at the intersection of 35th and Ensign Avenues was to act as a connection point for the new City storm sewer. The connection allows the existing flow at this point to be intercepted and rerouted to the regional pond located on the St. Joseph's property, alleviating downstream capacity issues. After excavation around the structure was complete, it became evident that the structure would not support the proposed connection while maintaining sufficient structural integrity. The existing structure was removed in its entirety and replaced with a new structure. The contractor completed the work, including setting the new structure and making all the necessary connections to existing and new pipes. The equipment, material, and labor costs to perform the work totaled $8,742.00. It is recommended that the City Council approve the enclosed Change Order #1 in the amount of $10,734.00 for the work completed. This will increase the amount of the contract for the project from $191,811.31 to $202,545.31. Sincerely, BONESTROO ROSENE ANDERLIK & ASSOCIATES, INC. ?::- ~~ Vince Vander Top Enclosure . St. Paul, St. Cloud, Rochester, Willmar, MN . Milwaukee, WI · Chicago, IL Affirmative Action/Equal Opportunity Employer and Employee Owned April 15, 2005 Carl Bolander & Sons Co. 251 Starkey Street St. Paul, MN 55107 Subject: Change Order No. 1 - Project No. 771 (Hillside Terrace Infrastructure Improvements) Enclosed for your records are two fully executed copies for the above-referenced Change Order. Please forward one copy to your bonding company. The change order amount was a $10,734. This change order was approved by the New Hope City Council at its meeting of April 11, 2005. Sin9~rely, /~/ ,-' -.,. C //Y~CD'U!..- Valerie Leone, CMC City Clerk Ene. cc: Guy Johnson, Director of Public Works Vince Vander Top, Assistant City Engineer (BRAA #34-04-162) CITY OF NEW HOPE 4401 Xylon Avenue North · New Hope, Minnesota 55428-4898 · www.ci.new-hope.mn.us City Hall: 763-531-5100. Police (non-emergency): 763-531-5170. Public Works: 763-592-6777. TDD: 763-531-5109 City Hall Fax: 763-531-5136 · Police Fax: 763-531-5174. Public Works Fax: 763-592-6776 , t1, Bonestroo a Rosene ~ Anderlik & . \J. Associates Engineers & Architects Owner: City of New Hope, 4401 Xylon Ave. N., New Hope, MN 55428 Contractor: Carl Bolander & Sons Co., 251 Starkey Street, St. Paul, tvlN 55107 Date March 17,2005 Bond Company: Bond No: CHANGE ORDER NO. 1 HILLSIDE TERRACE INFRASTRUCTURE llvlPROVEMENTS CLIENT PROJECT NO. 77I BRA FILE NO, 34-04-I62 Description of Work Structure Chane:es . Several new structures were ordered to accomodate revised street grades. Storm Sewer Structure Replacement An existing storm sewer manhole was removed and replaced with a new structure. All work involved, including necessary connections to existing and new pipes, was completed. Contract Unit Total No. Item Unit Quantity Price Amount CHAN'GE ORDER NO.1 Structure Changes LS S 1,992.00 SI,992.00 2 Storm Sewer Structure Replacement LS S8,742.00 S8,742.00 Total CHAi'lGE ORDER NO.1: 510,734.00 3404162CHOl.xls Original Contract Amount Previous Change Orders This Change Order Revised Contract Amount (including this change order) $191,811.31 $10,734.00 $0.00 $202,545.31 Recommended for Approval by: BONESTROO, ROSENE, ANDERLIK & ASSOCIATES, INC. ~ /~/:2~ /' Date: 3/ZI/O:!;- I Approved by Contractor: CARL BOLAJ.'lDER & SONS CO. Approved by Owner: CITY OF NEW HOPE /1//, .'5 r::;j2'" l, Jf!t0L _~~~ / I /1 \) ~ '-I ' ~ /~ I~l/--Q) Date cc: Owner Contractor Bonding Company Bonestroo & Assoc. 3404162CH01.xls Project Manual For Hillside Terrace Infrastructure Improvements City Project NOe 771- ew o e, es a File No. 34-04-162 Julv 2004 " Bonestroo Rosene '1t\lI Anderlik & , ~., Associates Engineers & Architects ACORDTM I CERTIFICATE OF INSURANCE I ISSUE DATE 09/23/2004 PRODUCER This certificate is issued as a matter of information only and confers no rights MCGRIFF, SEIBELS & WILLIAMS, INC. upon the Certificate Holder. This Certificate does not amend, extend or alter the coverage afforded by the policies below. P.O. Box 10265 Birmingham, AL 35202 COMPANIES AFFORDING COVERAGE 205-252-9871 Company Liberty Surplus Insurance Company A INSURED Company U.S. Fire Insurance Company Carl Bolander & Sons Co. B 251 Starkey Street Company S1. Paul, MN 55107 C SI. Paul Surplus Company D Company E This is to certify that the policies of insurance described herein have been issued to the Insured named herein for the policy period indicated. Notwithstanding any requirement, term or condition of contract or other document with respect to which this certificate may be issued or may pertain, the insurance afforded by the policies described herein is subject to all the terms, conditions and exclusions of such policies. Limits shown may have been reduced by paid claims. CO TYPE OF INSURANCE POLICY NUMBER EFFECTIVE LIMITS OF LIABILITY LT EXPIRATION A GENERAL LIABILITY EGLB0200140013 09/30/2003 EACH OCCURRENCE $ 1,000,000 ~ Commercial General Liability 09/30/2004 FIRE DAMAGE $ 50,000 o Claims Made ~ Occurrence MEDICAL EXPENSE o Owners' and Contractors' Protection PERS. AND ADVERTISING INJURY $ 1,000,000 ~ Policy Cap $8,000,000 0 GENERAL AGGREGATE $ 2,000,000 General Aggregate Limit applies per: PRODUCTS AND COMPo OPER. AGG. 1$ 2,000,000 o Policy ~ Project o Location B AUTOMOBILE LIABILITY 1336698513 09/30/2003 COMBINED SINGLE LIMIT 1$ 1,000,000 ~ Any Automobile 09/30/2004 BODILY INJURY (Per person) o All Owned Automobiles BODILY INJURY (Per accident) o Scheduled Automobiles PROPERTY DAMAGE (Per accident) ~ Hired Automobiles ~ Non-owned Automobiles COMPREHENSIVE 0 COLLISION C WORKERS' COMPENSATION EMPLOYERS LIABILITY 10/01/2003 WC Statutory Limit I I Other I x I AND EMPLOYERS' LIABILITY ONLY 1 % 1/2004 EL EACH ACCIDENT $ 1,000,000 SW05515380 EL DISEASE (Each employee) $ 1,000,000 Subject to $25,000 Oed EL DISEASE (Policy Limit) $ 1,000,000 C EXCESS LIABILITY QZ06812029 09/30/2003 EACH OCCURRENCE $ 2,000,000 ~ Occurrence 0 Claims Made 09/30/2004 AGGREGATE 1$ 2,000,000 Retention/deductible $10000 I I I I Bolander Job No. 24-2860 Job Name: The City of New Hope 2004 Hillside Terrance Infrastructure Improvements City Project No. 771 City Engineer File No. 34-04-162 Attorney File No. 99.1 0030{B) City of New Hope and the Engineer are named as Additional Insured with respect to all Liability coverages shown except Workers' Compensation as required by written contract subject to policy terms, conditions and exclusions. General Liability, Automobile Liability and Excess Liability coverage applies on a primary and non-contributorY basis. CERTIFICATE HOLDER SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE INSURER WILL MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT. City of New Hope CIO Jensen & Sondrall, P.A Authorized Representative Attn: Mr. Douglas J. Debner, New Hope Ass1. City /! { '. ..( Attorney 8525 Edinbrook Crossings, STE. 201 Brooklyn Park, MN 55443-1968 Certificate ID: HRPXRMP3 PERFORMA.ci\iCE BOND Bond No. 104 370 252 Any singular reference to Comractor, Surety, Owner, or other pany shall be considered plura! where applicable. CON"TRACTOR (Name and Address): Carl Bolander & Sons Co. 451 Starkey Street, St. Paul, MN 55107 OWNER (Name and Address): City of New Hope 4401 Xylon Avenue N. New Hope, MN 55428 CONTRACT Date:8/31/04 Amount: $191,811.31 Description (Name and Location): Municipal Infrastructure Improvements SURETY (Name and Address of Principal Place of Business): Travelers Casualty and Surety Company of America One Tower Square, Conveyor 3 PB, Hartford, CT 06183 Utility & Street Construction, Hillside Terrace BOND Bond Number: 104 370 252 Date (Nor earlier than Contract Date): 8/31 /04 Amoum; $191,811.31 MDdifications to this Bond Form: None Surety and Contractor, intending to be legally bound hereby, subject to the terms printed on the reYerf,~ side hereof, do each cause this Performance Bond to be duly e,.;ecuted on its behalf by its authorized o file er . agem, or representati fe. (Space is provided below for signatures of additional parties, if required,) CONTRACTOR AS PRlNCIP AL Company: Signature: Name and Title: (Seal) SURETY Travelers Casualty and Surety Company of America '. (Seal) Surety's Na!~ ~d Corn rate Seal----I/ j , By: V ~ ~ 7 ~l-,,-- Signature and Title Mark W. Edwards, II ..-' (Attach Power of Attarne:<;) Attorney-In-Fact A~est: ~ i.~ Signature and Title Q Kay F. Dalton Account Manager SURETY (Seal) Surety's Name and Corporate Seal By: Signature and Title (Attach Power of Attorney) .~tt9st; Signat'.1!e md Title: 'EJCDC No, C-GlO (2002 edition) Originally prtpl1rcd through the john efforts of tnc Surety .6r.sSoci.iion of Americll, Engineers Joint Coo tract Documents I: ommif:tee, the AssocIated Gencml Contrll.ctors of Amerlca, IUld tile American Institute or Architects. 1. Contrac;lor ~nd Sur::ly. jointly and 5~verally. bind thc:mselves, their h~ir., e~cCUror5. administrarors. succesSOl"5, and assigns to Owner for me perfor.nnnce 01' the Contrl!l:t, I'Ihlch is incorp~rnted hcrein by reference. 2. [f Contractor performs tM ConlJ':lct. Surel:}l and Contractor have no obligation under tllis Bond. e:(cept 10 panidpare in con~r::nceS as providetlln Par:lgraph 3.1. J. If there is no Owner Dt:f3lllt, Surety's obligation undcr this Bond shall alist: ant:r~ J. \. Owner has notified Contractor and Surety, at tile addr~s::.s dt:licr1b~ in Paragraph LO belo"', t1m Ownt:r is cnnsidering declaring a ContracCCr Defaul! and has r::quested and attempted to arrange a conFerence wir., Contractor and Sut:::ty to be hcld not later than [5 days afll:r rt:l:l:ipt of such notice to discuss merhoos 01' performing \ht: Conuac;r., IF Owner, Contractor and Surety agree, Conm-ClOr shall be allowed a reasonablt: limt: to perform tht: Conmct. but such an agreement shall not \lIaive Owoer's right. if any. subst:quently to declare a Comr:lI:ror Default; and 3.2. Owner has cieclaret! a Contractor Defaulr and fonnally terminatet! Contractor's rigl\[ to complett: to1e Contl':lct. Such Contracmr Default shall not be dedared :arlier t.1an 20 days afll:r Conlroctor and Surety have rr;ct:ived notice as providctl in Paragr~ph 3.1; and 3,3, Owner has ::.gr=:! to pa}' thc 'Balance of the Contract Price (O~ t. Surety in accordance wirh thc terms of the Contract; 2, ,"'noth~r Corltr:lcmr selected purs\I~nr to Parograph 01.3 to perform tl1e Comract. ... \Vhen Owner haa Elltisfiet1 the conditions of Pa~n.graph 3, Surety shall promptly and at Surety's e:<;pense taKe ooe of the following actions~ 4.1. Arrange for COnL-;:lcror. with coilSenr or Owner. to perform am:! complete me ContUlCt: or <\.2. Undem.ke to perform and complere the Concract itself. through its agents or through indeptmdent contractors: or 4.3, Obtain bids or negotiated proposalS from qualifit'J contra(;l;or; acceptable to Owner for a COntract for performance and completion or the Contract, arrange for a CO(UrilCt to be prepared For el;ecution by Owner and COlHr"ctor seleciCU \Vim Owner's concurrence, to be se::uret! with performance and payment bonds e.~eGUle:l by " qualified surety equivalent to the bonds issued On tile Com.'1lct, and pay to Ourner the amount of damages as described In Paragrnph 5 in e.~cess of the Balance of rhe Cootra"-t Price incurred by Owner r-...sulting from Contr1lctor Deiault: or i1A. Waive Irs righe :0 perform and complete, arrange for completion, or obl"in a new COtltracror "nd with reilSonabk promptness under tht: circuffi>(S,nces : 1. Aft~r investigation, determine the :1,ffiOUnr for which it may be liable to O....'l1er and, as soon as prdcticable aner the amount is derermitltd, render paymem L'1erefor ro O.,.,n~r: or 2, Deny liability in whole or in pm and notii)' Owner citing reasons rher~for. 5. If Su.rety does not proceed 1.5 pro~'ir1;:'j in P>lr"graph 4 wi\h reasoo;l.bIe promptness. Sutety shall be deemed to be in default on \his Bond 15 days after receipt of an addition.1 wrirren notice Cram Owne, to Surety demand ing that Surety perform it.; obligations under titis Bond. and Q\O'rler shsll be entitled to e::tfurce any remedy aV:lilatlle ro O.....oer, If Surt:ty proceeds as provided in Paragrnph <1.01, ant1 Owner refusJ:S the payment tendered or Surety has denied li~bili['J, in whole ill' in pUrl, witl:.out furt11er notice Owner shall be entitled to :nforc~ any remedy availabie :0 Owner. 6. Aner Owner has terminated Comracror's right u: complete the COntrar;t, a~d if Surety elecG to act under Paragrapll 4.1. 4.2. or4.3 lbovt:. men rhe respoosibilitiJ:S of Surety to Owner shall not be g~arer than mose 01 ContractOr under me Conu:u:t, and tlle responsihilities 01' Owner to Surety shall not Ie grealer rhan t.'lose of Owner under the Conuact. To a limit of the amount of (llis Bond. ~ut subject to comrnicrnem by Owner of the Balance of the Colltrl at Price to mitigation of costs and damagc:s on the Contr3cl, SurelY is obligated wit' QUt duplication for: li.l. '(he r::sponsibiliti::.s of Contr3ctor for co re;tion of defeetivt: Work and completion of rht: Contr1lCI; 6.2, Additional I~gal. ocsign professional, ;i ld delay costs resulting from Cont!';lcrcr'5 Defaulc, and resulting from the llCLlOIU or failure 10 act of SurelY under Paragraph 4; and 6.3. Liquidated damages. or if no liquidate\' damagc:s ar:: specifio:!. in rht: Contracr, actual Qamages- causet! by ielayed pt:rformance or non- performance of Contractor. 7. Surery shall nOl be liable to OwtlCl' or orherS fa ~ obligations of ConmleWr rlm are unrelated to the Contract. and the Balanc~ of he Conmct P~ice slu!11 not be redueed or see off on ~coum of any su;h unr::l:at~d Obligations. N'o right pf action shall ilCcrue on this Bond [II any person or erliey Drh~r than Owner or irs heirs. i::'(ecutors, administrators. or sucr;::ssors, 8. Surety hereby waives nodcc of any changc. including chnnges of time, to Comr.lce or to related subcomr3cc;, purcnase orders. and other obligations. 9, ,,,,ny proc~et!\ng. legal or equit3ble:, under this Bond may be institllt:t:cl in any court of competent jurisdic;doo In cht: locadon in ...hicn the Work or part of Llo Work Is located and. shall bt: instituted widlill t.....o '1 ears aftt:r Contral:tor Defaul[ or 1I.1"-1.in t\IIO years after Contractor ceased \IIorlcil1g .1 r witllin t\IIO years after Surety refus::::i or fails to perform itS obli"ations under this lond, whichever occu~ ftrst. if rhe provisions of this paragraph B~ void or prohib; ed by law, tht: minimum period of limitation available to surcti::.s as a deranse in th, i juri~diction of rho suit shall be ~pplic:;able, 10. Notic~ to Surety, O\l,/ne~, or Contractor shal, be mail~d or de\ivt:rctl to the addre.3s shown on the signature page, 11. When tnis Bond na.> been furnished to compl: with a st:\tumry r::quirement in th:: location whcre the COntract was to be perfon Icd. any provision in th\3 Bond ;onflicdng with said statutory rt:quirem~nt snail t ~ det:meG deleted herefrom and provisions cooforming to such St;\tlliOry requirem~: 1t snail be deemet! incorpor';)tctl herein. The intent is mat mis Bond shall!;t: constl1l e-d as a Stlltutor)' bond and not as II common law bor,a, 12. Defmitions. 12,1 E~lancc: of the Contract Price; The Wi II amount pay~ble by Owner to Contmctor under the Contract after ai I proper adjustment!; have bet:n made, including alJowanct: to ControlCtl r of any amounts recdved or 10 b~ rec\lived by Owner ill settlement CJ! insurance or other Ciiifms For damages to wnich Contr<lctor is entitled, reduced by all v.lid ~nd proper payments made ro or on behalf of Conti ictor under the Contrilct. 12.2. Contracr: The agreemt:ltl betyle::;. 011.' le~ and Contr~ctor identified on the signature page, including all C. ntract Document; .and cnangtS th~reto. l2.,}, ComnCtOr Default: Failure ar COOl actor. ;\Ihicn has neither been remedied nor waived. to perform or OL lerwise to comply with titt: rernlS of the Contract. 12.4, Ownt:r Default: Failure of Owner. wnl::'~ has neither been remctlj".j nor waivctl, to pay Contractor as required i IY the Cootr;JCt or ro perform alld camplett: or comply with the other lem'S thereof. Avenue South, i Birmingham,1 1 ---.J \ 1 FOR INFOR..i\1ATlON ONLY - Name, Address and Telephone I Surery Agency or Broker McGriff, Seibe1s & Hi11iams, Inc., 2211 Seventh L Owner's Represen!:artve (Engineer or o[her party) AL 35233 (800 476 2211) PAYMENT BOND Bond No. 104 370 252 Any singular reference to Contractor. Surety, Owner, or ocher party shall be COllilidered plura where applicable. CONTRACTOR (Name and Address): Carl Bolander & Sons Co. 251 Starkey Street, St. Paul, MN 55107 OWNER (Name and Address): City of New Hope 4401 Xylon Avenue N., New Hope, MN 55428 COl'jlR.~CT Date:8/31/04 A!nount: $191,811.31 Description (Name and Location): Municipal Utility and Street Construction, Hillside Terrace Intrastructure Improvements SURETY (Name and Address of Principa. Place of Business): Travelers Casualty and Surety Company of America One Tower Square, Conveyor 3 PE, Hartford, CT 06183 BoND Bond Number: 104 370 252 Date (N~t earlier than Contract Date): 8/31 /04 A..-nount: $191 , 8'11.' 31 Modificatiom to this Bond Form: None Surety and Contractor, intending to be legally bound hereby, subject m the terms printed on the reveise side hereof, do each cause rhis Payment Bond to be duly executed on its behalf by its authorized officer, agent, or representative, SURETY Co. (Seal) President Travelers Casualty and Surety f America By: ,andC -:/s:fUr Signat1.ue and TitleMark \oJ. Edwards, II / (Attach Power of Attorney) Attorney-In-Fact (Seal) (Space is provided below for signatures of additional parties, if required.) Attest: 'J~ ~ f. Signanll'e and Title G 'Kay F. Dalton Account Manager ~ CONTRACTOR AS PRINCIPAL Company: SURETY Signature: Name and Title: ( Seal) Surety's Name and Corporate Seal (Seal) By: Sig.nature and Title (Attach Power of Attorney) A !:test: Siguarure and Title: E.ICDC No. C-615 (2002 Edition) OTigillllUy ~epared through the joillt efforts of the Sllt'1lty Association of A.mmca. Engineers Joint Contract Dd cume.nts ColJl4lJittee, the Associated Cener-a.1 Contracl:ot's of Amenca, the Americarl Institute of A-rcrute<:ts, the Americ:90 Su!xont.;lCtot'S Association. and ;he Associated Spedal'Y Clntractor$. L Contractor and Surt:ty, jointly and severally. bind themselvc;, their heirs, el>eo.ltors, ::.dminiStrlltors, successors, and assigns to Owner to pay for labor, materials, and equipment furnished by Claimants icl' use in tho: performance of the Contract, which is incorporated herein by r.::ference, 2. With respet:.t ro Owner, this obligation shall bc null aru:i void if Contractor: 2.1, Promptly rn.ak:s payment, directly or indirectly. for all sums due Claimants, and 2,2. Defends, indemnifies, a.1d holds hannl::ss O\\lTler ['rom all claims. demands, liens, or suitS alleging non-payment by Comraccor by any person o. entity who furnished labor, materials, or equipment for use in the performance of tlle Contract, provided Owner has prompdy notIfied Contnlctor and Surety (ar the addrcsses described in Paragraph 12) of any claims. demands, liens, or suits and ,ender~ defense of sucn claims, demands, liens, or suits to Concractor and Surety, and pro\'ided there is no Owner Default. 3. With respec: to ClaimantS, this obligation shall be null and void if Cont,,-acmr promptly r:\ak::s payme(lt, dircctly or indirectly, for all sums due, 4, Surety shall have no obligation to Claimanrs Under this "8ond until; 4.1. Claimanrs who are employed by or have a direct cont."act with Contractor ha\'e given notice to Surety (at the nddresses d~scrt"oed in Paragraph 12) and sem a coPY. or notice thereof, W Oym:,:r, stating th:It a claim is being made uncler mis Bond and, witll substantial accuracy, the amount of tht claim. 4.2, Claimants who do not have a direct contract with Concr-d.Ccor: L Have furnished "'1'inen notice [0 Conuactor and sem a copy, or notice wereof, to Owner, wit.,in 90 days after having last performed labor or last furnished materials or equipment included in the claim statltlg, wi", substantial accuracy, t.1e amount of the claim and d1e name of the parry to whom the maJ:erials or equipment were furnished or supplied, or Far whom the labor was done or puformed; and 2. Have either receive:! a rejection in whole or in par. from Comractor, or not received within 30 days of furolshing the above no tic\: any communication from Contractor by which Contractor had indicatcd the claim wUl be paid direcdy or indirectly; and 3. Not having been paid wimin the above 30 days, have sent a Wr1tten notice to Surety and sem a copy, or ilonce mereof, to Ov.-ner, stating mat a claim is be:ins made under this Bond and enclosing !! copy of the previous written nOtice Furnished to Contractor. 5. lf a no tic: by <l Claimant r=qwn:d by Paragraph 1\ is provided. by Owner [(J Contractor or to Surety, am is sufficient COITlplia!1c~. 6. When a Claimant h<.s satisned the conditions of par...graph <', the Surety shall promptly anI! at Surety's expense take the following actions: 6.1. Send an answer m that Claimant, with a wpy t() Owner, wi.,lio Lj days after receipt 0 f the claim, stating the amounts tbat are undisputed and the basis for challenglng any amounts that are dispured. 6.2. Payor arrange for payme:nr ofaoy \lndi~puted umO\lms, 7, Surety's total obligation snall nm exce~:! the amount of this Bond, and the a.-:;Joum of this BOr\d shall be credited ior any payments made in good faith by Surety , 8. Amounts owed by OWl1er [0 ConlT'il.ct"r under me Contract shall be used for m~ performance of the Contract and I ~ satisfy claims, if any, under :my performance bond. By Contractor Fuml: hing and Ov-rner accepting this Elond, they agree t.,m all funds eamed by Contractor In the performance of the Comract are d!:dicated to satisfy obUii~ ,ions of Conn-actor and Surety under this Eond, subject to Owner's prionty ';) use the funds fer the completion of the Work. 9. Surety 8hall not be liable to Owner, :::laimants, or ot.f}ers for Obligations of ComTaCtor thar are unrelated to tile Co :ltract. OWl1~r shall not be liable for payment of any costs or expenses of afi; Claimant under thls Bond, and shall have under this Bond no obligactotls I) make payments to, give ootices on behalf of, o\' otherwise have obligations ;0 Claimants under this :Sond. 10. Surety hereby waives notice of an; cha."1ge. inclUding changes of time. to th= Conrract or to related Subcanrra!::ts, Jurchase orders and arher obligations, 11. No suit or action shall be commenl,:d by a Clalmant under thIs Bond mher than in a COUlL of cornpetenr jurisdictitl ~ in the location in. which :he Work or part of the Work i.~ located or after the ~xpiratiOl1 of one year from t,!'e date (1) on which the Claimant gave t:"Ie notice 'equired by Paragraph 4.1 or Paragraph 4.:2.3, or (2) On which the last hbor i r serv ice was performed by anyone or tl1e last materiaLs or equipmen.r .... :re furnished by anyone under the Consrrur:tiOt1. Conrract, whichever of ( ) or (2) tirst occurs. if the provisions of t.'-Us palo.graph are void or prohi! ,ired by law, the minimum period of limitadon available to su.re;ics as a de ensc in the jur~diction of the suit shall be applicable. 12. Nonce to Surety, Owner, or Coni 'actor shall be mailed or delivered to the addresses shown on. the signature pan e. Actual receipt oi notice by Surety, Owner, or Conrracwr, however aceol ~plished, shall be sufflcient compliance as of the dare received at the addreSS SolOwn on we signature page. 13. When t.,i.; Bond. has been furnish,:;l to comply with a statutory requirement in t.'-1e loce.tion where the Contract Wo'; to be perFormed, any provision in t.'1is Bond eOlU'licting with said starutOr;, requirement shall be dc:emed t!eleted here from ac.d provisions conformln~, to such sUltutory requirement shall be de~med incorporated herein. The inti nt is thar this Bond shall be construed liS a stal1ltory Bond and not as a commor' law bor.d, 14. Upon request of any parser. or enrity appelring to be a potential oeneflciary of this :Sond, ContraCtOr:1 nail promptly furnish a copy of :i1is BoflCl or sho.ll permit a copy to be r:\aGe. 15. DEFINITIONS 15.1. Claimant: All individual ::r entity having a dire:cr contract wit.c'1 Contractor, or with a frrst-I er subconrractor of Contractor, toj'umish labor. mattrials, or ~qUipi oem for us~ in the perfomal1ce of the Contract. The imcnt of ..'lis Bond shall be to includ::: withOUt limitation In tlie terms "1011 lor, materials or tquipmem" that part of water, gas. power, lighr, 10El, oil, gasoline, [!;;l:phonc service, or rental equlpmei1t usee in d le Cotlcrac;t, 2l'chitecrural and ~ngincering services required for peri! lrmancc of the Work of ConJ::raCtor and Comracror's S'Jbcont"'act~ .s. and all other Items for whi;[l a mechanic's lien may be ~I ;ert:::d In the jurisdic;cian where tne labor. nl.merials, or equipmem W~ re Fumished, 1.5.2. Comract: The agreement t, :twe'lil Owner and Comractor identified on the signature page, inclUl ing all Contract Documents and changeS therem. i5.3, Owoer Default: Failure 0 O;l.'TIer. which has neither b~en r::medi-at! nor waived, to pay COOi ,actor as required by the Conetact or tc perform and complete or I: 'mply .....il:>.. Ltte otb.er terms thereof. FOR INFOfL'VIATION ONLY - Name, Addrf::SS ;md Telephone Surety Agency 01' Broker: McGriff, Seibe1s & Hi11iams, Owner's Rtpresentative (Engineer 01' other pam'): 'R i rmi ne;'hRm, AT. Inc., 2211 Seventh Avenue South, 35733 (800 476 2211) ~~ Travelers IMPORTANT DISCLOSURE NOTICE OF TERRORISM INSURANCE COVERAGE On November 26, 2002, President Bush signed into law the Terrorism Risk Insurance Act of 2002 (the "Act"). The Act establishes a short-term program under which the Federal Government will share in the payment of covered losses caused by certain acts of international terrorism. We are providing you with this notice to inform you of the key features of the Act, and to let you know what effect, if any, the Act will have on your premium, Under the Act, insurers are required to provide coverage for certain losses caused by international acts or terrorism as defined in the Act. The Act further provides that the Federal Govemment will pay a share of such losses. Specifically, the Federal Government will pay 90% of the amount of covered losses caused by certain acts of terrorism which is in excess of Travelers' statutorily established deductible for that year. The Act also caps the amount of terrorism-related losses for which the Federal Government or an insurer can be responsible at $100,000,000,000.00, provided that the insurer has met its deductible. Please note that passage of the Act does not result in any change in coverage under the attached policy or bond (or the policy or bond being quoted), Please also note that no separate additional premium charge has been made for the terrorism coverage required by the Act. The premium charge that is allocable to such coverage is inseparable from and imbedded in your overall premium, and is no more than one percent of your premium, TRAVELERS CASUALTY AND SURETY COMPM'Y OF AMERICA TRAVELERS CASUALTY Ai"ID SURETY COMPANY FARMINGTON CASUALTY COMPA1'lY Hartford, Connecticut 06183-9062 POWER OF ATTORNEY AND CERTIFICATE OF AUTHORITY OF ATTORNEY(S)-IN-FACT KNOW ALL PERSONS BY THESE PRESENTS, THAT TRAVELERS CASUALTY AND SURETY COlVlPANY OF AMERICA, TRAVELERS CASUALTY AN]) SURETY COMPANY and FARMINGTON CASUALTY COMPANY, corporations duly organized under the laws of the State of Connecticut, and having their principal offices in the City of Hartford, County of Hartford, State of Connecticut, (hereinafter the "Companies") hath made, constituted and appointed, and do by these presents make, constitute and appoint: Mark W. Edwards, II, Ronald B. Giadrosich, of Birmingham, Alabama, their true and lawfuI Attomey(s)-in-Fact, \',dth full power and authority hereby conferred to sign, execute and acknowIedge, at any pIace v.':ithin the United States, the following instrument(s): by his/her sole signature and act, any and aII bonds, recognizances, contracts of indemnity, and other \vritings obligatory in the nature of a bond, recognizance, or conditional undertaking and any and alI consents incident thereto and to bind the Companies, thereby as fully and to the same extent as if the same were signed by the duIy authorized officers of the Companies, and ail the acts of said Attomey(s)-in-Fact, pursuant to the authority herein given, are hereby ratified and confirmed, This appointment is made under and by authority of the following Standing Resolutions of said Companies, which Resolutions are now in full force and effect: VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact and Agents to act for and on behalf of the company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal \-vith the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her. VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in \-vTiting and a copy thereof is filed in the office of the Secretary. VOTED: That any bond, recogllizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary, or (b) duly executed (under seal, if required) by one or more Attorneys-in-Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority. This Po'wer of Attorney and Certificate of Authority is signed and sealed by facsimile (mechanical or printed) under and by authority of the following Standing Resolution voted by the Boards of Directors of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, which Resolution is now in full force and effect: VOTED: That the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in-Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking to which it is attached. (11-00 Standard) '" 'som; ABWJO '-cBp lSI s~ P;;lXY.J:B Ol;;ll;;lll ;;lq Ol SlB;;lS ;;llB1Od.IOJ 1pl.p pUB lU;}P!S;}.Id ;};)!A .IO!U;}S 1!;;l1p ,{q P;;lUE!S ;;lq Ol lU;;lUItu+SU! S~ P;;lSnBJ ;;lABl[ X~TVdli\IOJ XrIVnSVJ NOL~N:IWRViI puu XNVdli\IOJ XLmnS <INV XL'1VnSVJ S'H:H:TJlAVHL 'YJrn3:r~ iIO ANVdli\IOJ X.LIDInS (l~TV A.L'1VnSYJ S'H:H:'laAVR.L 'iIOmJIRM. SS3:NLIM. ~1J cruO.inrv'H dO -^.lNnOJ PloJjJUH'SS{ lflJll;:):I..~OJ dO nVlS Al\.1VdJ-\IO::> AJ,'IVIlSV::> NO.LDNIli\i.(fV.>I ANVdWO::> A.LmS CINV A.L'1VnSV::> S~r;;I'13AV1ll v::>nr,3}\N'.>IO Al\.1VdJ-\IO::> A.LmS CL.W A.L'1VIlSV::> SH:tI'13AV1ll ~~~r liS lUap!saJd a::l!^ Jo!uas UOSdWOIU 'M aEiJoaE) JO;;ll;;l1p suoflnlos;;l(f Euwmns ;;l1p l;;lPun ;;l::>YJO l;;ll[jSp-{ JO A)polpnB iq SUO!+B10drOJ ;;llll JO JJ:Bll;;lq uo lU;;lUItu+SU! PJ:Bs ;;lIp P;;llnJ;;lX;;l ;;lllSj;;lll Wlll pUB :SlB;;lS ;;llB10drO::> ll::>ns ;;llB lU;;lUIIUlSU! PJ:BS ;;lIp Ol P;;lXY.J:B SJ:BdS ;;ll{l lBIp :SUOflBlOdrOJ P!BS JO S'[B;;lS ;;llll SA'\OU~ ;;ll[Sj;;ll[ W1p :lU;;lUITIllSU! ;;lAOqB ;;l1p p;;llnJ;;lx;;l l{::>!ll^-\ pUB U! p;;lqpJS;;lp SUOflB10drO::> Gt{l 'ANVdWOJ A.L'1VnSVJ NO.L~NI1\TRViI puu X~TVdJ<\IOJ X.LrnLlS <INV X.L'1VnsvJ SH3:'lJIAVR.L 'vJrn3:J;\IV .tl:O ANVdI-\IOJ x.L':nms <INY XL'1ynSYJ SuaTJiAV8:L JO :j.U;}P!S;}.Id d;)!A .iO!U;}S S! GllSjGll lBtp :1(-8S pUB ;;lsodGp PW 'U.IDA\S Alnp dill ,{q EU!Gq 'Oll^-\ 'm.\oIDJ: GUI Ol NOSdli\IOH.L 'M. a~'HOa~ Gum::> '{IIBUOS1Gd GUI G10JGq SOOZ '.{BVUO .{Bp lSI S!lll uO ~W ~~ llneaJlal ':) apeL^J o!lqnd ^J8+0N 900G 'OS 8unr s8J!dx8 UO!SS!WWOO ^l^J vOoz' ::j.sn.6n\l JO ,{Bp ::j. S l E s~ P;;llBQ 'lnJ!+JGUUOJ JO GlBlS 'P10J1-.IBH JO ,\+1:) ;;ltp U! ''-cUBdUIOJ Glll JO ;;lJYJO ;;lUIOH Gtp lB PGJ:BGS pUB P;;lUl3!S ';;lJ10J U! A\OU GlB '.\+potpny JO GlEJY!+.IGJ ;;lIp U! lfl.IoJ ldS SB 'SlOlJG1!Q JO Sp1BOS: ;;l1p JO suo!+nlos;;l(f l3uwmns ;;ltp lBtp ';;llOUIlGlfl.It1J pUB :P;;l~OAG1 U;;l;;lq lOU SBll pUB ;;l:)1OJ lITlJ U! SUJ:BUI;;ll Al!.IOlpny JO ;;llB:)Y!+.IGJpUB A;;lU.I01N JO l;;l^-\Od P;;ll{:)BllE pUB l3U!Ol3;;llOJ ;;lllllBIp AdI,DlaJ A8ffi:Iill-I OQ 'In:)fl:);;luuOJ JO GlBlS ;;llll JO SUOflB10drO:) 2l:l0lS 'XNVdli\IOJ X.L'1VnsvJ NO.LDNIWHViI puu LL\.TVdJ<\IOJ X.LrnLlS <INV X.L'1VnsvJ SHa'1aA V1IL 'vJrnaI<\IV iIO XNVc:IWOJ XLmnS mN X.L'1VnsvJ SHa'laAVRL JO ,UUl;}.I;);}S lUUlS!SSV 'P;;lUE!SlGpUn ;;ltp 'I II YJ I.::IIl. CIaJ puo8 '^.re:+8J08S :+ue:+s!ss'V UOsUe40r .IN pO)i ~-W_~ .18 ~ Bonestroo -=- Rosene ~ Anderlik & '\J' Associates Engineers & Architects ADDENDUM NO.1 For HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENTS CITY PROJECT NO. 771 FILE NO. 34-04-162 NEW HOPE, MINNESOTA July 15, 2004 Number of Pages 12 (includes this sheet) To: All Planholders of Record From: Bonestroo, Rosene, Anderlik and Associates, Inc. 2335 West Highway 36 St. Paul, Minnesota 55113 (651) 636-4600 - General Office (651) 604-4731 - Katie Johnson, Project Engineer (651) 604-4790 - Vince Vander Top, City Engineer The following changes, additions, and deletions are hereby made a part of the Bidding Documents. Bidder shall acknowledge receipt of this Addendum on the Bid Form. Failure to do so may result in rejection of the Bid. Please acknowledge receipt of this Addendum by signing and faxing this page back to Bonestroo & Associates at Fax No. (651) 636-131 I as soon as you receive it. Company Name Date 34-04-162 Al-l ADDENDUM NO.1 DOCUMENT 00410 - BID FORM 1. Delete this document in its entirety and add the attached document. SECTION 01100 - SUMMARY 2. Page 01100-1, Paragraph 1.02, add the following new items immediately after Item B. "c. Interim bituminous curb: 1. It is the intent of this Project to install an interim bituminous curb and mat for the 2004 season from approximate station 1+65 to the end of the cul-de-sac. Station 0+00 to station 1+65 will receive permanent concrete curb and gutter in the 2004 season. Permanent concrete curb and gutter will be installed from station 1 +65 to the end of the cul-de-sac in 2005 as a part of this contract. The Bid Form has been adjusted to reflect the changes in quantities. " "D. Utility Poles to be protected by contractor and held by others." LIST OF ATTACHMENTS 1. DOCUMENT 00410 - Revised Bid Form. END OF ADDENDUM 34-04-162 Al-2 ADDENDUM NO.1 J1f Bonestroo l1:li Rosene "I\lI Anderlik & . ~. Associates Engineers & Architects BIDDER: DOCUMENT 00410 REVISED BID FORM REVISED BY ADDENDUM NO.1 HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENTS CITY PROJECT NO, 771 FILE NO. 34-04-162 1\TEW HOPE, MN 2004 THIS BID IS SUBMITTED TO: City of New Hope 4401 Xylon Ave N New Hope, MN 55428-4898 BID COpy 1.01 The undersigned Bidder proposes and agrees, if this Bid is accepted, to enter into an Agreement with O\\11er in the form included in the Bidding Documents to perform all work as specified or indicated in the Bidding Documents for the prices and within the times indicated in this Bid and in accordance with the other terms and conditions of the Bidding Documents. 2.01 Bidder accepts all of the terms and conditions of the Instructions to Bidders, including without limitation those dealing with the disposition of Bid Security. The Bid will remain subject to acceptance for 60 days after the Bid opening, or for such longer period of time that Bidder may agree to in writing upon request of O\\11er, 3,01 In submitting this Bid, Bidder represents that: A. Bidder has examined and carefully studied the Bidding Documents, the other related data identified in the Bidding Documents, and the following Addenda, receipt of all which is hereby acknowledged. Addendum No. Addendum Date B, Bidder has visited the Project Site and become familiar with and is satisfied as to the general, local and Project Site conditions that may affect cost, progress, and performance of the work. C. Bidder is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress and performance of the work. D, Bidder has carefully studied all: (1) reports of explorations and tests of subsurface conditions at, or contiguous to, the Project Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at, or contiguous to, the Project Site (except Underground Facilities) which have been identified in SC-4.02, and (2) reports and drawings of Hazardous Environmental Conditions that have been identified in SC- 4.06. 3404162BIDFORM.xLS Revised by Addendum # 1 00410-1 REVISED BID FORM E, Bidder has obtained and carefu11y studied (or accepts the consequences for not doing so) a11 additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at, or contiguous to, the Project Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including applying the specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents to be employed by Bidder, and safety precautions and programs incident thereto, F. Bidder does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the determination of this Bid for performance of the work at the price(s) Bid and within the times and in accordance with the other terms and conditions of the Bidding Documents, G. Bidder is aware of the general nature of work to be performed by Owner and others at the Project Site that relates to the work as indicated in the Bidding Documents. H. Bidder has correlated the information known to Bidder, information and observations obtained from visits to the Project Site, reports and drawings identified in the Bidding Documents, and a11 additional examinations, investigations, explorations, tests, studies, and data with the Bidding Documents. 1. Bidder has given Engineer written notice of a11 conflicts, errors, ambiguities, or discrepancies that Bidder has discovered in the Bidding Documents, and the written resolution thereof by Engineer is acceptable to Bidder. 1. The Bidding Documents are generally sufficient to indicate and convey understanding of a11 terms and conditions for the performance of the work for which this Bid is submitted, K. Bidder will submit written evidence of its authority to do business in the state where the Project is located not later than the date of its execution of the Agreement. 4.0 J Bidder further represents that: A. The prices in this Bid have been arrived at independently, without consultation, communication or agreement as to any matters relating to such prices with any other Bidder or with any competitor for the purpose of restricting competition. B. The prices in this Bid have not or wi11 not be knowingly disclosed to any other Bidder or competitor prior to opening of the Bids. C. No attempt has been made or wi11 be made by the Bidder to induce any other person or firm to submit or not to submit a Bid for the purpose of restricting competition, 4.02 Bidder understands that the law may require the Owner, or Engineer at the Owner's direction, to undertake an investigation and submit an evaluation concerning Bidder's responsiveness, responsibility and qualifications before awarding a contract. Bidder hereby waives any and a11 claims, of whatever nature, against Ov-mer, Engineer and their employees and agents, which arise out of or relate to such investigation and evaluation, and statements made as a result thereof, except for statements that can be shown by clear and convincing evidence to be intentionally false and made with actual malice, Nothing in this paragraph is intended to restrict Bidder's rights to cha11enge a contract pursuant to law, 3404162BIDFOR.\1.XLS Revised by Addendum #1 00410-2 REVISED BID FORM 5.01 Bidder will complete the work in accordance with the Contract Documents for the following price(s): All specific cash allowances are included in the price(s) set forth below and have been computed in accordance with paragraph 11.02 of the General Conditions, Unit Prices have been computed in accordance with paragraph 11.03,B of the General Conditions Bidder acknowledges that estimated quantities are not guaranteed, and are solely for the purpose of comparison of Bids, and final payment for all Unit Price Bid items will be based on actual quantities provided, determined as provided in the Contract Documents. No. Item Units Qty Unit Price Total Price PART 1- SANITARY SEWER: MOBlLlZA TION LS $ $ 2 TRAFFIC CONTROL LS $ $ 3 REMOVE SANITARY SE\VER PIPE LF 158 $ $ 4 CORE DRILL CONNECTION TO EA $ $ EXISTING MANHOLE 5 8" PVC SANITARY SE\VER, SDR 35, 0'- LF 55 $ $ 10' DEEP 6 8" PVC SANITARY SE\VER, SDR 35, 10'- LF 275 $ $ 15' DEEP 7 8" X 4" PVC VlYE, SDR 35 EA 7 $ $ 8 4' DIAMETER SANITARY MH WITH EA $ $ RINGS & CASTING 9 4' DIAMETER SANITARY MANHOLE LF 7 $ $ OVERDEPTH 10 IMPROVED PIPE FOUNDATION, PER 6" LF 330 $ $ INCREMENT TOTAL PART 1 - SANITARY SEWER $ PART 2 - WATER MAIN: 11 REMOVE DIP WATER MAIN LF 145 $ $ 12 DUCTILE IRON FITTINGS LB 800 $ $ 13 CON"NECT TO EXISTING 8" WATER EA 2 $ $ M.A.IN 3404 I 62BIDFORMXLS Re\ised by Addendum # I 00410-3 REVISED BID FORM No. Item Units Qty Unit Price Total Price 32 CLASS III RIPRAP, PLACED AT FLARED CY 25 $ $ END SECTION 33 4.5' DIA STORM SEWER CBMH, 8' DEEP, EA 3 $ $ WITH RINGS AND CSTG 34 5' DIA STORM SE\VER CBMH, 8' DEEP, EA $ $ WITH RINGS AND CSTG 35 4,5' DIAMETER STRUCTURE LF 5 $ $ OVERDEPTH 36 IMPROVED PIPE FOUNDATION, PER 6" LF 770 $ $ INCREMENT 37 RECONSTRUCT INVERT EA $ $ 38 SW ALE EXCA VA TION LS $ $ TOTAL PART 4-TRUNKSTORA1 $ SEWER PART 5 - LATERAL STORM SEWER: 39 15" RCP STORM SEVlER, CLASS 5, 0'-8' LF 157 $ $ DEEP 40 15" RCP STORM SEWER, CLASS 5, 8'-10' LF 25 $ $ DEEP 41 12" RCP STORM SE\\1ER, CLASS 5, 0'_8' LF 65 $ $ DEEP 42 YARD DRAIN, INCL. CSTG, EA $ $ 43 RECONSTRUCT INVERT EA $ S 44 15" RCP FLARED END SECTION, INCL EA S S TRASH GUARD 45 2' X 3' CATCH BASIN EA $ S TOTALPART5-LATER~LSTOlli~ $ SEWER PART 6 - STREET IMPROVEMENTS: 46 SA WING BITUMINOUS PAVEMENT LF 95 S S 47 REMOVE BITUMINOUS PAVEMENT SY 575 S S 48 REMOVED~VEWAYPAVEMENT SY 95 S S 49 REMOVE CONCRETE CURB AND LF 335 $ S GUTTER 3404162BIDFORMXLS Re,;sed by Addendum # I 00410-5 REVISED BID FORM No. Item Units Qty U nit Price Total Price 50 PROTECTION OF CATCH BASIN IN EA 5 $ $ STREET 51 COMMON EXCA V A TION (CV) CY 510 $ $ 52 SELECT GRANULAR BORROW (CV) CY 820 $ $ 53 AGGREGATE BASE, CLASS 5 (CV) CY 480 $ $ 54 CONNECT DRAIN TILE TO EA 4 $ $ STRUCTURE 55 4" PERFORATED PVC DRAIN TILE, LF 418 $ $ SCHEDULE SDR 35 56 TYPE LV NON-VlEARlNG COURSE TN 180 $ $ MIXTURE 57 SODDING, LAWN TYPE SY 333 $ $ 58 TOPSOIL BORROW (CV) CY 37 $ $ 59 ADJUST MANHOLE AND CASTING EA $ $ 60 ADJUST CATCH BASIN CASTING EA 3 $ $ 61 ADJUST VALVE BOX EA $ S 62 RECLAIM BITUMINOUS PAVEMENT SY 1780 $ S 63 SUBGR.A.DE PREP ARA TI0N SY 1610 S S 64 TYPE LV NON-\VEARlNG COURSE TN 197 $ S MIXTURE 65 TYPE LV \VEARlNG COURSE MIXTURE TN 148 S $ 66 BITUMINOUS MA TERlAL FOR TACK GAL 50 S S COAT 67 SA W AND SEAL TRANSVERSE JOINTS LF 340 $ S IN BITUMINOUS \VEAR COURSE 68 B618 CONCRETE CURB AND GUTTER LF 305 S $ 69 D418 SURMOUNTABLE CONCRETE LF 485 S S CURB AND GUTTER 70 6" CONCRETE DRIVEWAY APRON SY 55 S S 71 TYPE LV 4 BITUMINOUS MIXTURE TN 50 S S (B), FOR DRlYEW A YS 72 GEOTEXTILE F ABRlC, TYPE V SY 2450 $ S 3404162BIDFORJ\lXLS Re\;sed by Addendum # I 00410-6 REVISED BID FORM No. Item Units Qty Unit Price Total Price 73 MOTOR GRADER V/ITH OPERA TOR HR 5 $ $ 74 STREET SWEEPER WITH PICK UP HR 5 $ $ BROOM \!lITH OPERA TOR TOTAL PART 6 - STREET $ IMPROVEMENTS BASE BID: TOTAL PART 1 - SANITARY SEWER TOTAL PART 2 - \\1 A TER MAIN TOTAL PART 3 - SERVICES TOTALPART4-TRUNKSTOfu~ SE\\'ER TOTALPART5-LATE~~LSTORM SE\\'ER TOTALPART6-STREET IMPROVEMENTS TOTAL BASE BID: 3404162BIDFORM.xLS Revised by Addendum # I 00410- 7 s s $ s s s $ REVISED BID FORM 6.01 Bidder agrees that the work will be substantially completed and completed and ready for final payment in accordance with paragraph I4.07,B of the General Conditions on or before the dates or within the number of calendar days indicated in the Agreement. 6.02 Bidder accepts the provisions of the Agreement as to liquidated damages in the event offailure to complete the work within the times specified above, which shall be stated in the Agreement. 7,01 The following documents are attached to and made a condition of this Bid: A. Required Bid Security in the form of 5 percent. 8,01 The terms used in this Bid with initial capital letters have the meanings stated in the Instructions to Bidders, the General Conditions, and the Supplementary Conditions. SUBMITTED on ,20 If Bidder Is: An Individual Name (typed or printed): By: (SEAL) (Individual's signature) Doing business as: Business address: Phone No,: Fax No.: 00410-8 (R) 3404 I 62BlDFORM.xls Re;;sed by Addendum # I REVISED BID FORM A Partnership A Corporation 3404] 62BlDFORM.xls Revised by Addendum # J Partnership Name: (SEAL) By: (Signature of general partner) Name (typed or printed): Business address: Phone No,: Fax No.: Corporation Name: (SEAL) State of Incorporation: Type (General Business, Professional, Service, Limited Liability): By: (Signature) Name (typed or printed): Title: Attest (CORPORATE SEAL) (Signature of Corporate Secretary) Business address: Phone No,: Fax No.: 00410-9 (R) REVISED BID FORM A Joint Venture Joint Venture Name: (SEAL) By: (Signature of joint venture partner) Name (typed or printed): Title: Business address: Phone No.: Fax No.: Joint Venturer Name: (SEAL) By: (Signature) Name (typed or printed): Title: Business address: Phone No,: Fax No,: Phone and Fax Number, and Address for receipt of official communications: (Each joint venturer must sign. The manner of signing for each individual, partnership, and corporation that is a party to the joint venture should be in the manner indicated above), E1\1J) OF DOCUMENT 00410-10 (R) 3404162BIDFORM.xls Revised by Addendum # I REVISED BID FORM ~ Bonestroo -=- Rosene "I\lI Anderlik & '\J' Associates Engineers & Architects ADDENDUM NO.2 For HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENTS CITY PROJECT NO. 771 FILE NO. 34-04-162 NEW HOPE, MINNESOTA July 16, 2004 Number of Pages 12 (includes this sheet) To: All Planholders of Record From: Bonestroo, Rosene, Anderlik and Associates, Inc. 2335 West Highway 36 St. Paul, Minnesota 55113 (651) 636-4600 - General Office (651) 604-4731 - Katie Johnson, Project Engineer (651) 604-4790 - Vince Vander Top, City Engineer The following changes, additions, and deletions are hereby made a part of the Bidding Documents. Bidder shall acknowledge receipt of this Addendum on the Bid Form. Failure to do so may result in rejection of the Bid. Please acknowledge receipt of this Addendum by signing and faxing this page back to Bonestroo & Associates at Fax No, (651) 636-1311 as soon as you receive it. Company Name Date 34-04-162 A2-1 ADDENDUM NO.2 DOCUMENT 00410 - BID FORM 1. Delete the document which was attached to Addendum No. 1 in its entirety and add the attached REVISED BID FORM - REVISED BY ADDENDUM NO.2 document. LIST OF ATTACHMENTS 1. DOCUMENT 00410 - REVISED BID FORM - REVISED BY ADDENDUM NO. 2. END OF ADDENDUM 34-04-162 A2-2 ADDENDUr-,1 NO.2 . ~. Bonestroo R Rosene 'till Anderlik & . ~. Associates Engineers & Architects BIDDER: DOCUMENT 00410 REVISED BID FORM REVISED BY ADDENDUM NO.2 HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENTS CITY PROJECT NO, 771 FILENO. 34-04-162 BID COP V NEW HOPE, MN 2004 THIS BID IS SUBMITTED TO: City of New Hope 4401 Xylon Ave N New Hope, MN 55428-4898 1.01 The undersigned Bidder proposes and agrees, if this Bid is accepted, to enter into an Agreement \'-lith Owner in the form included in the Bidding Documents to perform all work as specified or indicated in the Bidding Documents for the prices and within the times indicated in this Bid and in accordance with the other terms and conditions of the Bidding Documents. 2,01 Bidder accepts all of the terms and conditions of the Instructions to Bidders, including without limitation those dealing with the disposition of Bid Security. The Bid will remain subject to acceptance for 60 days after the Bid opening, or for such longer period of time that Bidder may agree to in writing upon request of Owner. 3.01 In submitting this Bid, Bidder represents that: A. Bidder has examined and carefully studied the Bidding Documents, the other related data identified in the Bidding Documents, and the following Addenda, receipt of all which is hereby acknowledged. Addendum No. Addendum Date B, Bidder has visited the Project Site and become familiar with and is satisfied as to the general, local and Project Site conditions that may affect cost, progress, and performance of the work. C. Bidder is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress and performance of the work. D. Bidder has carefully studied all: (1) reports of explorations and tests of subsurface conditions at, or contiguous to, the Project Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at, or contiguous to, the Project Site (except Underground Facilities) which have been identified in SC-4.02, and (2) reports and drawings of Hazardous Environmental Conditions that have been identified in SC- 4.06. 3404162BIDFORM.xLS REVISED BY ADDENDUM NO.2 00410-1 (R) REVISED 81D FORM E. Bidder has obtained and carefully studied (or accepts the consequences for not doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at, or contiguous to, the Project Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including applying the specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents to be employed by Bidder, and safety precautions and programs incident thereto. F, Bidder does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the determination of this Bid for performance of the work at the price(s) Bid and within the times and in accordance with the other terms and conditions of the Bidding Documents. G, Bidder is aware of the general nature of work to be performed by Owner and others at the Project Site that relates to the work as indicated in the Bidding Documents. H. Bidder has correlated the information known to Bidder, information and observations obtained from visits to the Project Site, reports and drawings identified in the Bidding Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Bidding Documents, 1. Bidder has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder has discovered in the Bidding Documents, and the written resolution thereof by Engineer is acceptable to Bidder. J. The Bidding Documents are generally sufficient to indicate and convey understanding of all terms and conditions for the performance of the work for which this Bid is submitted, K, Bidder will submit written evidence of its authority to do business in the state where the Project is located not later than the date of its execution of the Agreement. 4,01 Bidder further represents that: A, The prices in this Bid have been arrived at independently, without consultation, communication or agreement as to any matters relating to such prices with any other Bidder or with any competitor for the purpose of restricting competition. B, The prices in this Bid have not or will not be knowingly disclosed to any other Bidder or competitor prior to opening of the Bids. C. No attempt has been made or will be made by the Bidder to induce any other person or firm to submit or not to submit a Bid for the purpose of restricting competition. 4.02 Bidder understands that the law may require the Owner, or Engineer at the Owner's direction, to undertake an investigation and submit an evaluation concerning Bidder's responsiveness, responsibility and qualifications before awarding a contract. Bidder hereby waives any and all claims, of whatever nature, against Owner, Engineer and their employees and agents, which arise out of or relate to such investigation and evaluation, and statements made as a result thereof, except for statements that can be sho\\n by clear and convincing evidence to be intentionally false and made with actual malice. Nothing in this paragraph is intended to restrict Bidder's rights to challenge a contract pursuant to law. 3404162BlDFORM.XLS REV1SED BY /illDENDUM NO.2 00410-2 (R) REVISED BID FORM 5.01 Bidder will complete the work in accordance with the Contract Documents for the following price(s): All specific cash allowances are included in the price(s) set forth below and have been computed in accordance with paragraph 11.02 of the General Conditions. Unit Prices have been computed in accordance with paragraph 11,03.B of the General Conditions Bidder acknowledges that estimated quantities are not guaranteed, and are solely for the purpose of comparison of Bids, and final payment for all Unit Price Bid items will be based on actual quantities provided, determined as provided in the Contract Documents. No. Item Units Qty Unit Price Total Price PART 1- SANITARY SEWER: MOBILIZATION LS $ $ 2 TRAFFIC CONTROL LS $ $ 3 REMOVE SANITARY SEViER PIPE LF 158 $ $ 4 CORE DRILL C01\'NECTION TO EA $ $ EXISTING MANHOLE 5 8" PVC SANITARY SEViER, SDR 35, 0'- LF 55 $ $ 10' DEEP 6 8" PVC SANITARY SEWER, SDR 35,10'- LF 275 $ $ 15' DEEP 7 8" X 4" PVC VlYE, SDR 35 EA 7 $ $ 8 4' DIAMETER SANITARY MH \\IITH EA S $ RINGS & CASTING 9 4' DIAMETER SANITARY MANHOLE LF 7 $ S OVERDEPTH 10 IMPROVED PIPE FOUNDATION, PER 6" LF 330 S $ INCREMENT TOT AL PART 1 - SANITARY SEWER $ PART 2 - WATER MAIN: 11 REMOVE DIP WATER MAIN LF 145 $ $ 12 DUCTILE IRON FITTINGS LB 800 $ $ 13 CON1\TECT TO EXISTING 8" WATER EA 2 $ $ MAIN 3404 I 62BlDFOR."1.XLS REVISED BY ADDENDUM NO.2 00410-3 (R) REVISED BID FORM No. Item Units Qty Unit Price Total Price 14 6" DIP WATER MAIN, CLASS 52 LF 8 $ $ 15 8" DIP WATER MAIN, CLASS 52 LF 575 $ $ 16 8" GATE VAL VB AND BOX, IN PLACE EA 2 $ $ 17 6" GATE VALVE AND BOX, IN PLACE EA $ $ 18 INSTALL HYDRANT EA $ $ 19 IMPROVED PIPE FOUNDATION, PER 6" LF 583 $ $ INCREMENT TOTAL PART 2 - WATER MAIN $ PART 3 - SERVICES: 20 4" PVC, SCH. 40 SANITARY SE\VER LF 315 $ $ SERVICE COMMON TRENCH 21 1" CORPORATION STOP EA 7 $ $ 22 1" CURB STOP AND BOX EA 7 $ $ 23 1" TYPE "K" COPPER WATER SERVICE, LF 305 $ $ COMMON TRENCH TOTAL PART 3 - SERVICES $ PART 4 - TRUNK STORM SEWER: 24 REMOVEPVCSTOR11SE~~R LF 75 $ $ 25 REMOVE AND INSTALL NEW CASTING EA $ 5> 26 REMOVE CATCH BASIN EA 5> S 27 SILT FENCE, TYPE .MACHINE SLICED LF 320 $ 5> 28 CONNECT TO EXISTING STOR11 EA 2 S 5> MAr.mOLE 29 30" RCP STORM SE~~R, CLASS 3, 8'-10' LF 57 $ S DEEP 30 30" RCP ST0R11 SE\\~R, CLASS 3, 0'-8' LF 503 $ S DEEP 31 30" FLARED END SECTION, EA 5> 5> INCLUDING TRASH GUARD 3404 I 62BIDFOR.1\1XLS REVISED BY ADDENDUM NO.2 00410-4 (R) REVISED BID FORM No. Item Units Qty Unit Price Total Price 32 CLASS III RlPRAP, PLACED AT FLARED CY 25 $ $ END SECTION 33 4,5' DIA STORM SE\VER CBMH, 8' DEEP, EA 3 $ $ V-lITH RINGS AND CSTG 34 5' DIA STORM SEViER CBMH, 8' DEEP, EA $ $ VllITH RINGS AND CSTG 35 4,5' DIAMETER STRUCTURE LF 5 $ $ OVERDEPTH 36 IMPROVED PIPE FOUNDATION, PER 6" LF 770 $ $ INCREMENT 37 RECONSTRUCT INVERT EA $ $ 38 SW ALE EXCA V A TION LS $ $ TOTAL PART 4-TRUNK STORfrl $ SEWER PART 5 - LATERAL STORM SEWER: 39 15" RCP STORM SEWER, CLASS 5, 0'-8' LF 157 $ $ DEEP 40 15" RCP STORM SEWER, CLASS 5, 8'-10' LF 25 $ $ DEEP 41 12" RCP STORM SEWER, CLASS 5, 0'-8' LF 65 $ $ DEEP 42 YARD DRAIN, INCL. CSTG. EA $ $ 43 RECONSTRUCT l]\-JvERT EA $ S 44 15" RCP FLARED END SECTION, INCL EA S $ TRASH GUARD 45 2' X 3' CATCH BASIN EA S S TOTALPART5-LATERALSTORfrI S SEWER PART 6 - STREET IMPROVEMENTS: 46 SAW1NG BITUMINOUS PAVEMENT LF 95 $ $ 47 REMOVE BITUMINOUS PAVEMENT SY 575 S $ 48 REMOVEDRlVEWAYPAVEMENT SY 95 $ $ 49 REMOVE CONCRETE CURB A1\TD LF 335 S $ GUTTER 3404162BIDFORM.XLS REVISED BY ADDENDUM NO.2 00410-5 (R) REVISED BID FORM No. Item Units Qty Unit Price Total Price 50 PROTECTION OF CATCH BASIN IN EA 5 $ $ STREET 51 COMMON EXCA V A TION (CV) CY 510 $ $ 52 SELECT GRANULAR BORROW (CV) CY 690 $ $ 53 AGGREGATE BASE, CLASS 5 (CV) CY 425 $ $ 54 COr..TNECT DRAIN TILE TO EA 4 $ $ STRUCTURE 55 4" PERFORATED PVC DRAIN TILE, LF 418 $ $ SCHEDULE SDR 35 56 TYPE LV NON-\VEARING COURSE TN 153 $ $ MIXTURE 57 SODDING, LA \VN TYPE SY 333 $ $ 58 TOPSOIL BORROW (CV) CY 37 $ $ 59 ADJUST MANHOLE AND CASTING EA $ $ 60 ADJUST CATCH BASIN CASTING EA 3 $ $ 62 RECLAIM BITUMINOUS PAVEMENT SY 1260 $ $ 63 SUBGRADE PREPARATION SY 1260 $ $ 64 TYPE LV NON-\VEARING COURSE TN 197 $ $ MIXTURE 65 TYPE LV \VEARING COURSE MIXTURE TN 148 $ $ 66 BITUMINOUS MATERlAL FOR TACK GAL 50 $ $ COAT 67 SA W AND SEAL TRANSVERSE JOINTS LF 340 $ $ IN BITUMINOUS WEAR COURSE 68 B618 CONCRETE CURB AND GUTTER LF 305 $ $ 69 D418 SURMOUNT ABLE CONCRETE LF 485 $ $ CURB AND GUTTER 70 6" CONCRETE DRlVEW A Y APRON SY 55 $ $ 71 TYPE LV 4 BITUMINOUS MIXTURE TN 50 $ $ (B), FOR DRlVEW A YS 72 GEOTEXTILE FABRlC, TYPE V SY 2450 $ $ 73 MOTOR GRADER WlTH OPERA TOR HR 5 $ $ 3404162BlDFORM.XLS REV1SED BY ADDENDUM NO.2 004] 0-6 (R) REVISED BID FORM No. Item Units Qty Unit Price Total Price 74 STREET SWEEPER WITH PICK UP HR 5 $ $ BROOM WITH OPERA TOR TOTAL PART 6-STREET $ IMPROVEMENTS BASE BID: TOTAL PART 1 - SANITARY SEVlER TOTAL PART 2 - WATER MAIN TOTAL PART 3 - SERVICES TOTALPART4-TRUNKSTO~~ SEV-,TER TOTALPART5-LATERALSTORM SEWER TOTALPART6-STREET IMPROVEMENTS TOTAL BASE BID: 3404162BIDFORM.XLS RE\lSED BY iillDENDUM NO.2 00410-7 (R) $ $ $ $ $ $ s REVISED BID FORM 6.0I Bidder agrees that the work will be substantially completed and completed and ready for final payment in accordance with paragraph 14,07,B of the General Conditions on or before the dates or within the number of calendar days indicated in the Agreement. 6.02 Bidder accepts the provisions of the Agreement as to liquidated damages in the event of failure to complete the work within the times specified above, which shall be stated in the Agreement. 7,01 The following documents are attached to and made a condition of this Bid: A. Required Bid Security in the form of 5 percent. 8.01 The terms used in this Bid with initial capital letters have the meanings stated in the Instructions to Bidders, the General Conditions, and the Supplementary Conditions, SUBMITTED on ,20_ If Bidder Is: An Individual Name (typed or printed): By: (SEAL) (Individual's signature) Doing business as: Business address: Phone No,: Fax No.: 00410-8 (R) 3404162BIDFORM.xls REVISED BY ADDENDUM NO.2 REVISED BID FORM A Partnership A Corporation Partnership Name: By: (Signature of general partner) Name (typed or printed): Business address: Phone No.: Fax No.: Corporation Name: (SEAL) State of Incorporation: Type (General Business, Professional, Service, Limited Liability): By: (Signature) Name (typed or printed): Title: Attest (CORPORATE SEAL) (Signature of Corporate Secretary) Business address: Phone No,: Fax No.: 00410-9(R) 3404I62BIDFORM.xls REVISED BY ADDEND\Jl-.-l NO.2 REVISED BID FORM A Joint Venture Joint Venture Name: (SEAL) By: (Signature of joint venture partner) Name (typed or printed): Title: Business address: Phone No,: Fax No,: Joint Venturer Name: (SEAL) By: (Signature) Name (typed or printed): Title: Business address: Phone No,: Fax No.: Phone and Fax Number, and Address for receipt of official communications: (Each joint venturer must sign. The manner of signing for each individual, partnership, and corporation that is a party to the joint venture should be in the manner indicated above). END OF DOCUMENT 00410-10(R) 3404162BlDFORM.xIs REVISED BY ADDEl--.'DUM NO.2 REVISED SID FORM DOClJ1-fENT 00005 PROFESSIONAL CER TIFIC'\ nONS I hereby certify that this report, drawing, or specification was prepared by me or under my direct supervision and that I am a duly Licensed Professional Engineer under the laws of the State of Minnesota. ~~/~ Vincent T. Vander Top, P.E, Date: Julv 2.2004 Reg, No. 25770 E1\TD OF DOCuMENT 34-04-162 (Q 2004 Bonestroo, Rosene, Anderlik & Associates Inc. PROFESSIONAL CERTIFICATIONS DOCillv1ENT 00010 TABLE OF CONTENTS HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENTS CITY PROJECT NO. 771 FILE NO. 34-04-162 NEW HOPE, MINNESOTA 2004 Introductory Information 00005, Professional Certifications 00010. Table of Contents Bidding Requirements 00100, Advertisement for Bids 00200, Instructions to Bidders 00300, Information Available to Bidders 00410. Bid Form Contracting Requirements 00520. Agreement Form 00610. Performance Bond 00615. Payment Bond 00700. EJCDC C-700 Standard General Conditions of the Construction Contract (Bound in back of Project Manual) 00800, Supplementary Conditions Specifications Division 1 - General Requirements 01100. Summary 01310. Project Management and Coordination 01400, Quality Requirements 01500. Temporary Facilities and Controls 01570, Erosion and Sediment Control 01700. Execution Requirements 34-04-162 (Q 2004 BonestToo, Rosene, Anderlik & Associates, Inc. 00010-1 TABLE OF CONTENTS Specifications Continued... Division 2 - Site Construction 02108. 02225, 02280. 02315. 023 18. 02320. 02341. 02510, 02515, 02530. 02535. 02630, 02635. 02720. 02360. 02740. 02760. 02770, 02775, 02920, Full Depth Reclamation Removals Adjust Miscellaneous Structures Excavation and Fill Subgrade Preparation Trench Excavation and Backfill Geotextile Soil Stabilization Water Main Water Services Sanitary Sewer Sanitary Sewer Services Storm Drainage Subsurface Drainage Aggregate Base Course MnDot Combined 2360/2350 Plant Mixed Asphalt Pavement Plant Mixed Asphalt Pavement Bituminous Joint Construction Concrete Curb and Gutter Concrete Walks, Medians and Driveways Lawns and Grasses END OF DOCUl\1ENT 34-04- t 62 \&\ 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. 00010-2 T,-\BLE OF CONTENTS DOC'LJ:N1ENT 00100 ADVERTISEMENT FOR BIDS Sealed Bids will be received by the City of New Hope, Minnesota, in the City Hall at 4401 Xylon Avenue North, until 1 :30 P.M., C.D.S.T., on Monday, July 19, 2004, at which time they will be publicly opened and read aloud for the furnishing of all labor, material, and all else necessary for the following: Hillside Terrace Infrastructure Improvements - City Project No. 771. File No. 34-04-162 Consisting of the following approximate quantities: 350 900 1300 750 600 575 550 200 1 TN TN TN LF LF LF LF LF LS Bituminous Pavement Class 5, Aggregate Base, 100% crushed Select Granular Borrow Concrete Curb and Gutter 8-inch Sanitary Sewer 8-inch water, fittings, and residential services 30-inch RCP Storm Sewer, including Structures 12 and IS-inch lateral Storm Sewer including structures Sod, Topsoil and restoration Bidders desiring a copy of the Drawings and Specifications may obtain them from the Issuing Office of Bonestroo, Rosene, Anderlik & Associates, Inc., Consulting Engineers, 2335 West Highway 36, St. Paul, .I\1N 55113, (651) 636-4600 upon payment of a non-refundable fee of $45.00. Drawings and Specifications may be seen at the office of the City of New Hope and at the Issuing Office, Drawings and Specifications can also be purchased w'ith a credit card over the internet from w\vw,bonestroo,com, Each Bid shall be accompanied by a Bidder's Bond naming the City of New Hope as obligee, certified check payable to the Clerk of the City of New Hope or a cash deposit equal to at least five percent of the amount of the Bid, which shall be forfeited to the City in the event that the Bidder fails to enter into a Contract. . The City Council reserves the right to retain the deposits of the 3 lowest Bidders for a period not to exceed 60 days after the date and time set for the Opening of Bids. No Bids may be withdrawn for a period of 60 days after the date and time set for the Opening of Bids. Payment for the work will be by cash or check. The City Council reserves the right to reject any and all Bids, to waive irregularities and informalities therein, and further reserves the right to award the Contract to the best interests of the City, 34-04-162 Q 2004 Bonestroo, Rosene, Allderlik & Associates, Inc. Daniel Donahue, City Manager City ofNe\v Hope, Minnesota ADVERTISEMENT FOR BIDS DOCUMENT 00200 INSTRUCTIONS TO BIDDERS ARTICLE 1 - DEFINED TERi\1S 1.01 Terms used in these Instructions to Bidders have the meanings indicated in the General Conditions and Supplementary Conditions, Additional terms used in these Instructions to Bidders have the meanings indicated below: A. Issuing Office: The office from which the Bidding Documents are to be issued and where the Bidding procedures are to be administered, ARTICLE 2 - COPIES OF BIDDING DOCillvlENTS 2.01 Complete sets of the Bidding Documents in the number and for the non-refundable sum stated in the Advertisement for Bids may be obtained from the Issuing Office. 2.02 Complete sets of Bidding Documents shall be used in preparing Bids; neither O"vner nor Engineer assumes any responsibility for errors or misinterpretations resulting from the use of incomplete sets of Bidding Documents. 2.03 Owner and Engineer in making copies of Bidding Documents available on the above terms, do so only for the purpose of obtaining Bids for the work, and do not confer a license or grant for any other use, ARTICLE 3 - QUALIFICATIONS OF BIDDERS 3,01 To demonstrate Bidder's qualifications to perform the work within 5 days of O"\TIer's request, Bidder shall submit written evidence such as financial data, previous experience, present commitments, and such other data as may be called for below: A. Evidence of Bidder's qualification to do business in the State where the Project is located or covenant to obtain such qualification prior to aw'ard of Contract. B, Evidence of genuineness of Bid and lack of collusion in conjtillction therewith. 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00200-1 fNSTRUCTIONS TO BIDDERS ARTICLE 4 - EXAi\tlINATION OF BIDDING DOCU'N1ENTS, OTHER RELATED DATA, Ai"ID PROJECT SITE 4,01 Subsurface and Physical Conditions A. The Supplementary Conditions Identify: 1. Those reports of explorations and tests of subsurface conditions at, or contiguous to, the Project Site that Engineer has used in preparing the Bidding Documents, 2. Those drawings of physical conditions in or relating to existing surface and subsurface stmctures at, or contiguous to, the Project Site (except Underground Facilities) that Engineer has used in preparing the Bidding Documents, B. Copies of reports and drawings referenced in Paragraph 4.01.A will be made available by Owner to any Bidder on request. Those reports and drawings are not part of the Contract Documents, but the "technical data" contained therein upon which Bidder is entitled to rely as provided in Paragraph 4.02 of the General Conditions has been identified and established in Paragraph 4.02 of the Supplementary Conditions. Bidder is responsible for any interpretation or conclusion Bidder draws from any "technical data" or any other data, interpretations, opinions, or information contained in such reports or shown or indicated in such drawings. 4.02 Underground Facilities A. Information and data shown or indicated in the Bidding Documents with respect to existing Underground Facilities at, or contiguous to, the Project Site is based upon information and data furnished to Owner and Engineer by owners of such Underground Facilities, including Owner or others. 34-04-162 @ 2004 BonestToo, Rosene, Anderlik & Associates, Inc. 00200-2 INSTRUCTIONS TO BIDDERS 4.03 Hazardous Environmental Condition A. The Supplementary Conditions identify those reports and drawings relating to a Hazardous Environmental Condition identified at the Project Site, if any, that Engineer has used in preparing the Bidding Documents, B. Copies of reports and drawings referenced in Paragraph 4.03,A will be made available by Owner to any Bidder on request. Those reports and dra\vings are not part of the Contract Documents, but the "technical data" contained therein upon which Bidder is entitled to rely as provided in Paragraph 4.06 of the General Conditions has been identified and established in Paragraph 4.06 of the Supplementary Conditions. Bidder is responsible for any interpretation or conclusion Bidder draws from any "technical data" or any other data, interpretations, opinions, or information contained in such reports or shown or indicated in such Drawings, 4.04 Provisions concerning responsibilities for the adequacy of data furnished to prospective Bidders with respect to subsurface conditions, other physical conditions, Underground Facilities, and possible changes in the Bidding Documents due to differing or unanticipated conditions appear in Paragraphs 4.02, 4,03, and 4.04 of the General Conditions. Provisions concerning responsibilities for the adequacy of data furnished to prospective Bidders with respect to a Hazardous Environmental Condition at the Project Site, if any, and possible changes in the Contract Documents due to any Hazardous Environmental Condition uncovered or revealed at the Project Site which was not shown or indicated in the Drawings or Specifications, or identified in the Contract Documents to be within the scope of the \vork appear in Paragraph 4.06 of the General Conditions, 4.05 On request, Owner will provide Bidder access to the Project Site to conduct such examinations, investigations, explorations, tests, and studies as Bidder deems necessary for submission of a Bid. Bidder shall fill all holes, and clean up and restore the Project Site to its former condition upon completion of such explorations, investigations, tests, and studies. Bidder shall comply with all applicable Laws and Regulations relative to excavation and utility locates. 4.06 Reference is made to Article 7 of the Supplementary Conditions for the identification of the general nature of other work that is to be performed at the Project Site by Owner or others (such as utilities and other prime contractors) that relates to the work contemplated by these Bidding Documents, On request, Owner will provide to each Bidder for examination access to or copies of Contract Documents (other than portions thereof related to price) for such other work. 34-04-162 @ 20041 Bonestroo, Rosene, A.nderlik & Associates. Inc. 00200-3 fNSTRUCTIONS TO BIDDERS 4,07 It is the responsibility of each Bidder before submitting a Bid to: A. examine and carefully study the Bidding Documents, the other related data identified in the Bidding Documents, and any Addenda; B, visit the Project Site and become familiar with and satisfy Bidder as to the general, local, and Project Site conditions that may affect cost, progress, and performance of the work; C. become familiar with and satisfy Bidder as to all federal, state, and local Lavis and Regulations that may affect cost, progress, and performance of the work; D. carefully study all: (1) reports of explorations and tests of subsurface conditions at, or contiguous to, the Project Site and all drawings of physical conditions in, or relating to, existing surface or subsurface structures at, or contiguous to, the Project Site (except Underground Facilities) which have been identified in the Supplementary Conditions as provided in Paragraph 4.02 of the General Conditions, and (2) reports and drawings of Hazardous Environmental Conditions at the Project Site which have been identified in the Supplementary Conditions as provided in Paragraph 4.06 of the General Conditions; E. obtain and carefully shtdy (or accept consequences of not doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at, or contiguous to, the Project Site which may affect cost, progress, or performance of the work, or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Bidder, including applying any specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents, safety precautions, and programs incident thereto; F. agree at the time of submitting its Bid that no fhrther examinations, investigations, explorations, tests, studies, or data are necessary for the determination of its Bid for performance of the work at the price(s) Bid and within the times and in accordance with the other terms and conditions of the Bidding Documents; G. become aware of the general nahlre of the work to be performed by Owner and others at the Project Site that relates to the work as indicated in the Bidding Documents; H, correlate the information known to Bidder, information and observations obtained from visits to the Project Site, reports and drawings identified in the Bidding Documents, all additional examinations, investigations, explorations, tests, studies, and data with the Bidding Documents; 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00200-4 INSTRUCTIONS TO B[DDERS I. promptly give Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Bidder discovers in the Bidding Documents and confIrm that the written resolution thereof by Engineer is acceptable to Bidder; and J, determine that the Bidding. Documents are generally suffIcient to indicate and convey understanding of all terms and conditions for the performance of the work. 4.08 The submission of a Bid will constitute an incontrovertible representation by Bidder that Bidder has complied with every requirement of this Article 4, that without exception the Bid is premised upon performing and furnishing the work required by the Bidding Documents and applying any specifIc means, methods, techniques, sequences, and procedures of construction that may be shown or indicated, or expressly required by the Bidding Documents, that Bidder has given Engineer written notice of all conflicts, errors, ambiguities, and discrepancies that Bidder has discovered in the Bidding Documents and the wTItten resolutions thereof by Engineer are acceptable to Bidder, and that the Bidding Documents are generally suffIcient to indicate and convey understanding of all terms and conditions for performing and furnishing the work. ARTICLE 5 - PRE-BID CONFERENCE 5,01 There will be no pre-Bid conference. ARTICLE 6 - PROJECT SITE Al'ID OTHER AREAS 6,01 The Project Site is identifIed in the Bidding Documents, Easements for permanent structures or permanent changes in existing facilities are to be obtained and paid for by Owner, unless otherwise provided in the Bidding Documents. All additional lands and access thereto required for temporary construction facilities, construction equipment, or storage of materials and equipment to be incorporated in the work are to be obtained and paid for by Contractor. ARTICLE 7 - INTERPRETATIONS AJ.'ID ADDENDA 7.01 All questions about the meaning or intent of the Bidding Documents are to be submitted to Engineer in writing. Interpretations or clarifIcations considered necessary by Engineer in response to such questions will be issued by Addenda mailed or delivered to all parties recorded by Engineer as having received the Bidding Documents. Questions received less than 10 days prior to the date for Opening of Bids may not be answered, Only questions answered by Addenda will be binding, Oral and other interpretations or clarifIcations \vill be without legal etfect. 7,02 Addenda may be issued to clarify, correct, or change the Bidding Documents as deemed advisable by O\Vner or Engineer. 34-04-162 @ 2004 Bonestroo, Rosene, A.nderlik & Associates. Inc. 00200-5 INSTRUCTIONS TO BlDDERS ARTICLE 8 - BID SECURlTY 8.01 A Bid must be accompanied by Bid Security made payable to O\vner in an amount of 5 percent of Bidder's maximum Bid price and in the form of a certified check or bank money order, or a Bid Bond issued by a surety meeting the requirements of Paragraphs 5.01 and 5.02 of the General Conditions. 8.02 The Bid Security of the successful Bidder will be retained until such Bidder has executed the Contract Documents, furnished the required Contract Security, and met the other conditions of the Notice of Award, whereupon the Bid Security will be returned. If the successful Bidder fails to execute and deliver the Contract Documents and furnish the required Contract Security within 15 days after the Notice of Award, Owner may annul the Notice of Award and the Bid Security of that Bidder will be forfeited. The Bid Security of other Bidders whom Owner believes to have a reasonable chance of receiving the award may be retained by O\vner until the earlier of 7 days after the Effective Date of the Agreement or 61 days after the Bid opening, whereupon Bid Security furnished by such Bidders \vill be returned, 8.03 Bid Security of other Bidders whom Owner believes do not have a reasonable chance of receiving the award will be rehrrned within 7 days after the Bid opening. ARTICLE 9 - CONTRACT TTh1ES 9,01 The number of days within which or the dates by \vhich, Milestones are to be achieved and the work is to be Substantially Completed and ready for Final Payment are set forth in the Agreement. ARTICLE 10 - LIQ1JIDATED DA..MAGES 10,01 Provisions for liquidated damages, if any, are set forth in the Agreement. ARTICLE 11 - SUBSTITUTE AND "OR-EQUAL" ITEMS 11.01 The Contract, if awarded, will be on the basis of materials and equipment specified or describe in the Bidding Documents without consideration of possible substitute or "or- equal" items. Whenever it is specified or described in the Bidding Documents that a substitute or "or-equal" item of material or equipment may be furnished or used by Contractor if acceptable to Engineer, application for such acceptance will not be considered by Engineer until after the Effective Date of the Agreement. 34-04-162 @ 2004 Bonestroo. Rosene, i.\nderlik & Associates, Inc. 00200-6 rNSTRUCTIONS TO BIDDERS ARTICLE 12 - SUBCONTRACTORS, SlJPPLIERS, A1'\ffi OTHERS 12,01 If the Supplementary Conditions require the identity of certain subcontractors, suppliers, individuals, or entities to be submitted to Owner in advance of a specified date prior to the Effective Date of the Agreement, the apparent successful Bidder, and any other Bidder so requested, shall within 5 days after Bid opening, submit to O\Vner a list of all such subcontractors, suppliers, individuals, or entities proposed for those portions of the work for which such identification is required. Such list shall be accompanied by an experience statement with pertinent information regarding similar projects and other evidence of qualification for each such subcontractor, supplier, individual, or entity if requested by Owner. If Owner or Engineer, after due investigation, has reasonable objection to any proposed subcontractor, supplier, individual, or entity, O\Vner may, before the Notice of Award is given, request apparent successful Bidder to submit a substitute, in w'hich case apparent successful Bidder shall submit an .acceptable substitute, Bidder's Bid price will be increased (or decreased) by the difference in cost occasioned by such substitution, and Owner may consider such price adjustment in evaluating Bids and making the Contract award. 12,02 If apparent successful Bidder declines to make any such substitution, Ow'ner may award the Contract to the next lowest Bidder that proposes to use acceptable subcontractors, suppliers, individuals, or entities. Declining to make requested substitutions will not constitute grounds for forfeihlIe of the Bid Security of any Bidder. Any subcontractor, supplier, individual, or entity so listed and against which Owner or Engineer makes no written objection prior to the giving of the Notice of A\vard, will be deemed acceptable to Owner and Engineer subject to revocation of such acceptance after the effective date of the Agreement as provided in Paragraph 6.06 of the General Conditions. 12.03 Contractor shall not be required to employ any subcontractor, supplier, individual, or entity against whom Contractor has reasonable objection. ARTICLE 13 - PREPARATION OF BID 13.01 The Bid Form is included with the Bidding Documents. Additional copies may be obtained from Engineer. 13,02 All blanks on the Bid Form shall be completed by printing in ink or by typev-ITIter and the Bid signed in ink. Erasures or alterations shall be initialed in ink by the person signing the Bid Form. A Bid price shall be indicated for each Bid Item listed therein. 13,03 A Bid by a corporation shall be executed in the corporate name by the president or a vice- president or other corporate officer accompanied by evidence of authority to sign. The corporate seal shall be affixed and attested by the secretary or an assistant secretary. The corporate address and state of incorporation shall be sho\vn below the signature. 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, L'1c. 00200-7 INSTRUCTIONS TO BIDDERS 13.04 A Bid by a partnership shall be executed in the partnership name and signed by a partner (whose title must appear under the signature), accompanied by evidence of authority to sign. The official address of the partnership shall be show'll below the signature, 13.05 A Bid by a limited liability company shall be executed in the name of the firm by a member and accompanied by evidence of authority to sign, The state of formation of the firm and the official address of the firm shall be shown below the signature. 13.06 A Bid by an individual shall show the Bidder's name and official address. 13.07 A Bid by ajoint venture shall be .executed by each joint venturer in the manner indicated on the Bid Form. The official address of the joint venture shall be shown below the signature. 13.08 All names shall be typed or printed in ink below the signatures, 13.09 The Bid shall contain an acknowledgment of receipt of all Addenda, the numbers of which shall be filled in on the Bid Form. 13.10 The address and telephone number for communications regarding the Bid shall be shown. 13.11 The Bid shall contain evidence of Bidder's authority and qualification to do business in the state where the Project is located, or covenant to obtain such qualification prior to award of the Contract. Bidder's State Contractor License Number, if any, shall also be shown on the Bid Form. 13.12 Bidders shall indicate the total add or deduct to the Total Base Bid for each Alternate provided on the Bid Form. 13.13 Bidders may list proposed substitute items on the spaces provided on the Bid Form. Bidders shall clearly indicate the item name, Specification Section Number, and the Total Deduct to the Total Base Bid for each substitute item proposed, 13.14 Bidders shall circle the name of the Base Bid Manufacturer they will provide, if awarded the Contract, Bidders shall circle only 1 name for each item. If the Bidder fails to circle an item, the first item listed shall be provided. 13.15 Bidders shall identify the name of the company or subcontractor that will perform the listed portion of the \vork if the Bidder is awarded the Contract. 34-04-162 @ 2004 Bonestroo, Rosene, .A.nderlik & Associates, Inc. 00200-8 INSTRUCTIONS TO BfDDERS ARTICLE 14 - BASIS OF BID; COMPARISON OF BIDS 14.01 Bid Unit Price With Alternates A. Bidders shall submit a Bid on a Bid Unit Price for each Bid Item of work listed in the Bid Form, and include a separate price for each Alternate described in the Bidding Documents as provided for in the Bid Form. The price for each Alternate will be the amount added to the Base Bid if Owner selects the Alternate. In the evaluation of Bids, Owner may select any combination of Alternates, or the Owner may choose not to accept any Alternate Bids. B. The total of all estimated prices will be the sum of the products of the estimated quantity of each Bid Item and the corresponding Bid Unit Price, The final quantities and Contract Price will be determined in accordance with Paragraph 11.03 of the General Conditions. C. Discrepancies between the multiplication of units of work and Bid Unit Prices will be resolved in favor of the Bid Unit Prices. Discrepancies between the indicated sum of any column of figures and the correct sum thereof will be resolved in favor of the correct sum. Discrepancies bet\veen words and figures will be resolved in favor of the words. D, Bids will be compared on the basis of the "Adjusted Total Base Bid" and this amount \vill be the basis for determining the low'est Bidder. The sum of the Total Base Bid and any combination of Alternates accepted by the Owner \vill determine the "Adjusted Total Base Bid." The Owner may choose to not accept any Alternate Bids, 14.02 The Bid price shall include such amounts as the Bidder deems proper for overhead and profit on account of cash allowances, if any, named in the Contract Documents as provided in Paragraph 11.02 of the General Conditions. ARTICLE 15 - SUBMITTAL OF BID 15.01 With each copy of the Bidding Documents, a Bidder is furnished 1 separate unbound copy of the Bid Form, and, ifrequired, the Bid Bond Form, The unbound copy of the Bid Form is to be completed and submitted with the Bid Security. 15.02 A Bid shall be submitted no later than the date and time prescribed and at the place indicated in the Advertisement for Bids, and shall be enclosed in an opaque sealed envelope plainly marked with the Project title (and, if applicable, the designated portion of the Project for which the Bid is submitted), the name and address of Bidder, and shall be accompanied by the Bid Security and other required documents, If a Bid is sent by mail or other delivery system, the sealed envelope containing the Bid shall be enclosed in a separate envelope plainly marked on the outside \vith the notation "BID ENCLOSED." A mailed Bid shall be addressed to Owner's office. 34-04-162 @ 2004 BonestToo, Rosene, Anderlik & Associates, Inc. 00200-9 INSTRLJCTIONS TO BIDDERS ARTICLE 16 - MODIFICATION AL'ID WITHDRAWAL OF BID 16.01 A Bid may be modified or withdrawn by an appropriate document duly executed in the manner that a Bid must be executed and delivered to the place where Bids are to be submitted prior to the date and time for the opening of Bids. 16.02 Bids may be withdrawn after Bid opening only in accordance with the law, ARTICLE 17 - OPENING OF BIDS 17.01 Bids will be opened at the time and place indicated in the Advertisement for Bids and, lmless obviously non-responsive, read aloud publicly. A Bid Tabulation of the amounts of the Base Bids and major Alternates, if any, will be made available to Bidders after the opening of Bids. ARTICLE 18 - BIDS TO REMAIN SUBJECT TO ACCEPTAL'\J'CE 18,01 All Bids will remain subject to acceptance for the period of time stated in the Bid Form, but Owner may, in its sole discretion, release any Bid, and return the Bid Security prior to the end of this period. ARTICLE 19 - EVALUATION OF BIDS Al"-JTI AWARD OF CONTRACT 19,01 If the Contract is awarded, award will be made on the basis of the lowest responsive, responsible, qualified Bidder determined by the Adjusted Total Base Bid, 19,02 O\vner reserves the right to reject any, or all, Bids, including without limitation, nonconforming, nomesponsive, unbalanced, or conditional Bids, Owner further reserves the right to reject the Bid of any Bidder whom it finds after reasonable inquiry and evaluation, to not be responsible, Owner may also reject the Bid of any Bidder if Owner believes that it would not be in the best interest of the Project to make an award to that Bidder. Owner also reserves the right to waive all informalities not involving price, time, or changes in the work, and to negotiate Contract terms with the successful Bidder. 19.03 More than 1 Bid for the same work from an individual or entity under the same or different names will not be considered, Reasonable grounds for believing that any Bidder has an interest in more than 1 Bid for the work may be cause for disqualification of that Bidder and the rejection of all Bids in which that Bidder has an interest. 19.04 In evaluating Bids, Owner \vill consider whether or not the Bids comply with the prescribed requirements, and such Alternates, Bid Unit Prices, and other data, as may be requested in the Bid Form or prior to the Notice of Award. 34-04-162 @ 200d Bonesrroo, Rosene, .A.nderlik & Associates, Inc. 00200-10 INSTRUCTIONS TO BIDDERS 19,05 In evaluating Bidders, Owner will consider the qualifications of Bidders and may consider the qualifications and experience of subcontractors, suppliers, other individuals, or entities proposed for those portions of the work for which the identity of subcontractors, suppliers, other individuals, or entities must be submitted as provided in the Supplementary Conditions. 19.06 Owner may conduct such investigations as Owner deems necessary to establish the responsibility, qualifications, and financial ability of Bidders, proposed subcontractors, suppliers, individuals, or entities to perform the work in accordance with the Contract Documents. As a condition of its Bid, Bidder is required to waive any and all claims, of whatever nature, against Owner, Engineer, and their employees and agents which arise out of, or relate to, such investigations and statements made as a result thereof, except for statements that can be shovvn by clear and convincing evidence to be intentionally false and made with actual malice. This waiver is not intended to restrict Bidder's rights to challenge a Contract award pursuant to law, 19.07 If the Contract is to be awarded, Owner will award the Contract to the Bidder whose Bid is in the best interests of the Project. ARTICLE 20 - CONTRACT SEClTR1TY Al'ID INSlTRA1"l'CE 20.01 Article 5 of the General Conditions, as may be modified by the Supplementary Conditions, sets forth Owner's requirements as to Performance and Payment Bonds and Insurance, 'When the successful Bidder delivers the executed Agreement to Owner, it shall be accompanied by such Bonds. ARTICLE 21 - SIGNiNG OF AGREEMENT 21.01 vYnen Owner gives a Notice of Award to the successful Bidder, it shall be accompanied by the required number of unsigned counterparts of the Agreement with the other Contract Documents which are identified in the Agreement as attached thereto. Within 15 days thereafter, successful Bidder shall sign and deliver the required number of counterparts of the Agreement and attached documents to Ovvner. Within 10 days thereafter, Owner shall deliver 2 fully signed counterparts to successful Bidder with a complete set of the Drawings with appropriate identification. END OF DOCu'NIENT 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00200-11 rNSTRUCTIONS TO BIDDERS DOCUMENT 00300 INFOR.i\1A TrON AVAILABLE TO BIDDERS Portions of reports and drawings used by the Engineer in the preparation of the Bidding Documents are attached to this document. The Technical Data is identified in the Supplementary Conditions, Bidders are responsible for their own interpretation, verification, and use of the Technical Data contained in these reports and drawings consistent with the General Conditions and Supplementary Conditions. Reports, drawings, and other historical information regarding the Project may be available for Bidder's review at the Engineer's office, Schedule a viewing time with the Project Manager. E~1) OF DOClTMENT 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. lNFOR:v[A TION A V:-\IL-\BLE TO BIDDERS 2004/07/16 10:56:57 Powered by LightningFAX Page: 3/12 J.1j Bonestroo .;. Rosene U Andcrlilc &. .~, Associates E'rglnecrs: &. Ar::hHec.t~ BIDDER: Carl Bolander & Sons Co. DOCUMENT 00410 REVISED BID FORM REVISED BY ADDENDUM NO.2 HIllSIDE TERRACE INFflA.STRUCTLR.E lMPROVEMENTS CITY PROJECT NO 771 FILE NO. 34-04-162 NEW HOPE, MN 2004 BID COpy T! liS BID IS SUBMITTED TO: City of Nc\'/ i-lope ~~40i Xvlcnt\vcN ?'h:\\' h{N 55428-4898 01 The tlnder~igned Bidder proposes and ag~ees, if thls Bid is accepted. to enter into an r\grcenlcnt \vitll O\vner in the tornl included in the Bidding Documents to perfoffil all work as specified or indicated in the Bidding Documents for the prices and '.vithin the t1l1WS llldicated in this Bid and in accordance with the other terms and conditions of the Bidding Docllmems 2.01 Bidder accepts all of the terms and conditions of the lnstrucriolls to Bidders, including without iimitation those dealing with the disposition of Bid Seemity The Bid will remain subject to <1CCeptilnCe for 60 days <:fter the Bid opening, or for such longel penod of lime that Bidder may agree to in writing Up01l1equest of Owner :; OlIn submItting this Bid, Bidder represents that: ;\. Bidder has examined and carefully studied the Bidding Documents, the other related data idenl1fied in the Bidding DOGumcnts~ and the follo\ving ,A~ddenda, receipt e,[ all \vhlch is hereby ack-no\vledged Addendum No. Addendum Date 15, 2004 #i ~~ '1 r~ L:. 2004 B Bidder has visited the Project Site and become familiar with and is satisfied as to the general, ioeai and Site cOrldltions that may affect cost, progress, and performance of the work c Bidder is farniliar \vith {,inois satisfied as to all federaL state, and local LaViS and Rcgulations that rnn}' affect cost~ plogrcss and perfornlance of the ,""vorlc D Bidder has CUl efully studied all: (J) reports of explorations and tests of subsurface conditions ai. or contlguou:; tOl the Project Site and aU dnl\vings of phYS1C:.il conditions in or relating to existing surface or subsurface structures att or contgtlOUS to, the Project Site (except Underg7oundFacilitics) \vhichhave been identified in SC~402t and (2) repDrts and dru\vingsof Iiaz.ardous Environrnental Conditlons that h:lve been identified in SC 406 :.4D~ I !:28!DFORhi XLS REvrSED BY AUtJENDIJM N02 00410-1 (R) REVISED SiD FORM l004/0ljlb 10:56:57 E F. G j.j K Powered by LightningFAX Page: 4/12 Bidder nns obtained und carefully studied (or accepts the consequences for not doing SD) a11 additional or supplementnry examinations, investigations, explorations. tests. studies. and data concerning conditions (surface, subsurface, :md Underground Facilities) at, or contiguous to, the Project Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed hy Bidder, including applying the speclilc means, methods, techniques, sequences, and pmcedures of construction expressly required by the Bidding Documellls to be employed by Bidder, and safety precautions and programs inCIdent thereto Bidder does not consider that any fulther ex"minations, investigations, eKplorations, tests, studIes, or data are necessary for the determination of this Bid for performance of the work at the price(s) Bid and withi:. the time:s and in accordance with the other terms mld conditions of the Bidding Documents Bidder is ;}\varc of the general nature of \vork to be performed by O\\l1Cr and others at the. Project Site that relates to the work as indicated in the Bidding Dm:umems Bidder has correlated the mrormation bOWD to Bidder, infOlmation and observations obtained from \'151[;; to the Project Site, repOlts and drawings identified in the Bidding Documents, and all additional examha!JDil5, investigations, explorations, tests, studies, and data with the Bidding Documents Bidder has given Engineer written notice of ali conflicts, errors, ambiguities, or discrepancies that Bidder hris discovered in the Bidding Documents, <:1nd the written n.:solutJan thereof by Engineer is acceptable LJ EiJde: The Biddll1g Documents 2re generuily sufficient \0 indicate and convey understanding of alllerms and conditions for the performance of the work for which this Bid is submmcd Bidder will submit written evidence of its nuthority to de business in the stute where the Project is lc,c<ltcc not later thni1 the date of its execution of the i\greement. 4.01 Bidder further represents that: B c The pr1ces in this Bid have been arrived at independentlYt \vithout COnSl.Jlt2tion~ comIT;unication or agrcernent as to any matters relating to such pilces \vith any other Bidder or \v1th any competitor for the pUlpOSC of restricting conlpctlticn The prices in this Bid have not or will not be knowingly disclosed to any other Bidder or competilO! pllor to opening of the Bids No atternpt 11;15 been made or \vi11 he rnade by the Bidder to induce any other person or fin1i to 5.uhmitor no! 10 submit a Bid for the purpose of restricting competition 402 Bidder under stands that the lav! rnay require the O\vner~ or Engineer at th~ Owner's dil t:ct1on~ 10 undtrtuke ilIl and submit an evabation concerning Bidder's responsiveness, responsibility and quaiifications before awarding <:1 contract Bidder hereby waives any and all claims, of whatever nature, against O\\11er, Engineer and their employees and agents, which arise ellt oi or relate to such investigation and evGluation, und slatements made as a result thereof, except for statements that can be sho\vn by clear and convincing evidence to be intentionally false and made \vith actual IT!ajice Nothing in this paragraph 15 intended to restrict Bidder!s rights to challenge a conn act pursuant to la...s. }.W41 G2BlDFOHh! XL5 F.EVISEU iiY ADDENDUM NO 2 00410-2 (R) REVISED 81D FORM LUU4/UI/lb lU:)b:57 pmvered by L i ghtni ngFAX Page: 5/12 501 Biddcr will complcte the work in accordance with the Conl1act Documents for the following price(s}: All specific cash allowances are included in the price(s) set fonn below and have been computed in accoldt:lncc with paragraph I J .02 of the Gcneml Conditions Unit Prices have been computed in accordance with paragraph II 03 B of the General Conditions Bidder ac1mowledges that estimated quantities ale not guaranteed, and are solely for the purpose uf compariSon of B:ds, 2nd final payment for all Unit Price Bid items will be based on .actual quantities pro\,idcc, detennined as provided in the Contact Documents No. Total Price Item U II its Qty Unit Price 2 4 5 () 9 10 11 12 p PART 1 . SANITARY SEWER: MOBIl. IZA TION TRAFFIC CONTROL REMOVE SANITAR'{ SEWER PIPE CORE DRIll CONNECTION TO EXISTING MANHOLE 8" PVC SANl1ARY SEWER, SDR 35, 0'- 10' DEEP 8" PVC SANITARY SEWER, SDH. 35,10'. 15' DEEP 8" X 4" PVC WYE, SDR 35 "DiNvlETER SANiTARY Ml-I WITH RINGS & CASTING 4' DlAMETER SANITARY MANHOLE OVERDEPTH IMPROVED PIPE FOUNDATION, PER 6" INCREMENT IOTAL PART I - SANITARY SEWER PART 2 - 'VA TER MAIN: REMOVE DIP WATEH MArN DUCTILE IRON FITTINGS CONNECT TO EXISTING 8" \VATER ivlAIN J.W": 162B1DFOR!-,;1 XLS REV1SED BY ADDENDU!\1 NO Z 00410-3 (R) LS S 8,300 00 :. 8,300 00 l.5 oS 1, 9 2 .9.~~g__ s ~_?~g._g 0 LF S 12.92 11 2,041..36 158 EA J, 790.00 ~ 790.00 LF s: 17.35 s 954..25 55 LF S 20.85 ':),733..75 275 $ EA S 211 1 477 7 :i EA ~ 1,500 00 s 1,500.00 u. S 147.00 ~"f029..00 , -' LF S 1.50 s 495.00 330 ;, 24,240.36 J r: -"! S 7.. 00 1,015..00 1"" "1J s LB S 1 'On 1,04C.OO 800 r, 1:/'\ S 441.. 00 882..00 2 s REViSED BID FORM LVU4!U/;~O lU:~b:57 Powered by LightningFAX Page:6/12 No. Item Units Qty Unit Price Total Price 14 6" DIP WATER MAIN, CLASS 52 LF 8 S 15.60 S 124.80 is 8" DIP WA TER MAIN, CLASS 52 LF 575 S 19.65 $ 11,298.75 16 8" GA TE VALVE ,A.ND BOX, IN PLACE EA :: S 1,140.00 S 2,280.00 t ; 6" GATE VALVE AND BOX, iN PLACE EA S 960.00 S 960.00 18 INSTALL HYDRANT fA :Ii 1,820.00 S 1,820.00 19 IMPROVED PIPE FOUNDA TION, PER 6' LF 583 ~ 1.50 1 874.50 iNCRErv1ENT ------- TOTAL PART 2 - WATER MAIN S 2 ,295.05 ---~-------_.._-- PART.3 - SERVICES: " 4" I'VC, SCH 4[\ SANl1ARY SEWER Lf .3tS S 6.93 S 2,182.95 L.\J SERVICE COMMON TRENCH 21 1" CORPORA nON STOP EA 7 S 110.00 S 770.00 --- 22 1" CURB STOP AND BOX LA ... S 260.00 -'.. 1,820.00 I 23 i" TYPE ilK;! COPPER \VA TER SERVICE, LF 305 C' 7.00 S 2,135.00 J; COMMON TRENCH TOTAL PART.3 - SERVICES S 6,907.95 -;,~ 25 26 27 28 29 30 3 i PART 4 - TRUNK STORM SEWER: REMOVE PVC STORM SEVIER LF 75 S 10 . 00 S ! 50 00 S 52 Q 00 '" 528 . 00 u . .,~ S 1 4 ! . 50 S 14 7 50 .320 S 5 . 00 S - , 600 00 2 ~ 352 . 00 $ 7 04 00 5 --. 60 --. 998 20 57 S L . 5. , , . -.-- 4 5 30 2 --. 785 90 5D3 S . S L , S 1 , i 30 . 00 S 1 , 7 30 00 REMOVE AND INSTALL NEW CAS! INO EA REl'vlOVE CA TCH BASIN EA Sil T FENCE, TYPE lvlACHIT\E SLICED LF CONNECT TO EXISTING STORM MANHOLE EA 30" RCP STORM SEVIER, CLASS 3, S'-10' DEEP LF .30" ReI' STORM SEWER, CLASS .3, O'-S' DEEP 30" FLARED END SECTION, INCL UDlNG TR.ASH GUARD LF E1\ j~041625iDFORM XLS FCVlSED OY ADDf:NDU~,,~ NO 2 00410-4 (R) REViSED 310 FORM LUV4/U/I~O ~U:~b:~1 Powered by LightningFAX Page:? 12 No. Total Price Item Units Qty Unit Price " ..1.. $ 1,000.00 33 34 35 36 ,) / 38 39 40 4] ~2 .i:L' i~4 45 (~6 '-7 .::.8 ':9 CLASS III RIPRAP, PLACED AT FLARED END SECTiON 45' D1A STORM SEWER CBMH, 8' DEEP, WlTH RINGS AND CSTG 5' DlA STORM SE\VER CBMH, 8' DEEP, Wll!-l RINGS AND CS1 G 45' DlAMETER STRUCTURE OVERDEPTH lIvfPROVED PIPE FOUNDA lION, PER 6" lNCRErvlENT RECONSTRUCT INVERT SWALE EXCA \',\TION TOTAL PART 4 - TRlJNK STORM SEWER l'/\RT 5 . LATERAL STORM SEWER: 15" RCP STORM SEWER, CLASS 5, 0'.8' DEEP i 5" Ref> STORM SEWER, CLASS -', 8'. W DEEP 12" RCP STORM SEWER, CLASS 5, 0'-8' DEEP Yf\.RD DRf\n~, [NCL CSTG R.ECONSTRUCT INVERT ]5" RCP flARED END SECTION, INCL TRASH GUARD ~, X .3' CA TCH BASIN TOTAL PART 5 - LATEI0\L STORi\I SEWER PAR 1 lJ - STREET HVlPROVEMEN I S: 51\. \VlNG BlTUMINOlJS P A VEivfENT REMOVE BiTUMINOUS PP.VEMENT REMOVE DIUVE\V.A Y P'\ VEMENI REMOVE CONCRETE CURB AND GUTTER ;.W4IGZlHDFGR!.: XLS REVISED OY :\DDE"'JDUM NO.2 G04 iO.5 (ft) CY EA EA LF LF fA LS LF Lf LF EA EA EA EA LF Sy Sy LF 575 .335 25 S 40.00 S 1,935.00 S 2,268.00 5 S 135.00 770 $ 1.50 S 352.00 S 2,700.00 157 S 20.95 25 S 23..90 65 S 19 . 45 3 938.00 $ 352.00 S $ 492..00 oS ,'); 1,025.00 S 95 s -010 :5 ') ...,~ ~. j:J 95 16.00 s s 1.80 s 5,805.00 s 2,268.00 s 675.00 s 1,155.00 s 352~OO s "c,700.00 S 45,198.60 s 3,289.15 s 597.50 s 1,264.25 ,:') 938..00 352. 492.00 1,025.00 7,957..90 s 389.50 s 1,581.25 s 1,520.00 s 603.00 REVISED 810 FORt.!, 2004/07/16 10:56:57 pmvered by L i ghtni ngFAX Page: 8/12 No. Total Price Item Units Qty U nit Price 50 s 245.75 5 i 52 53 54 55 56 :':/ 58 59 60 62 63 64 6.') 66 67 68 69 70 7J 72 73 PROTECTION OF CA TeH BASIN IN STREET COMMON EXCA V A TJON (CY) SELECT GR...\NULAR BORROW (CV) AGGREGr\TE BASE, CLASS 5 (CV) CONNECT DRAIN TILE TO STRUCTURE 4" PERFORA TED I'VC DRAIN TIL.E, SCHEDULE SDR 35 TYPE LV NON-WEARING COURSE MiXTURE SODDING, LA WN TYPE TOPSOIL BORROW (CV) ADJUST MANHOLE AND CAS1ING ADJUST CA TCH BASIN CASTING RECLAIi\1 BITUMr.\iOUS PA YEMENT SUBGRADE PREPAR.A nON TYPE LV NON-WEARING COURSE MIXTURE TYPE LV WEAIUNG COURSE MIXTURE BITUMINOUS MATERIAL FOR TACK COAT SA W AND SEAL. TRANSVERSE JOINTS IN BITUMfNOUS WEAR COURSE B6i8 CONCRETE CURB AND GUTTER D418 SURMOUNTABLE CONCRETE CURB AND GUTTER 6" CONCRETE DR1VEW A Y APRON TYPE LV 4 BITUMINOUS 1\llXTURE (8), FOR DR!VEWA YS GEOTEXTILE FABR1C, TYPE \ MOTOR GRADER WITH OPERA.. TOR 3404 :t2tHDIORM XLS H.EVtSED D Y ;\DDENDUhl NO ;. ()O.11 0-6 (R) EA CY CY CY EA LF TN Sy CY EA EA SY SY TN iN CAl LF LF LF SY TN SY HR J260 \260 2450 5 5) 49.15 510 S 5.28 690 $ 15.25 425 S 27.50 4 S 154.00 418 '" 6.65 153 S 45..85 3D S 9. 75 ,.... )f 50.15 $ S 447.00 , :. $ 447.00 S 1. 20 S 1.40 197 S 44.80 148 $ 50.50 50 S 2.00 340 S 5.00 305 S 11.25 485 S 11. 25 55 S 41. 00 50 S 92.00 ] 00 .1' 5 :; 110.00 .s 2,692.80 $ 10/522.50 S 11,687.50 S 616.00 s: 2,779.70 ~, 1,015.05 ~ 3/246..75 3: 1,855.55 s 447.00 s 1,341. 00 s 1,512.00 s 11764.00 s 8,825.60 s 7,474.00 s 100.00 $ 1,700.00 s 3,431.25 .C ...., 5,456..25 s 2,255.00 s 4,600.00 s 2,450..00 s 550.00 REVISED 810 FORlv', LUU4/UI/lb 1U:56:57 Powered by LightningFAX Page: 9/12 No. Item Units Qty Unit Price Total Price 74 STREET SWEEPER \VITI-! PICK UP HR 5 S llO.OO $ 550.00 BROOM WITH OPERA TOR TOTAL PART G. STREET S 87 I 211. 45 IMPROVEi\:1ENTS BASE BID: TOT AI. PART i - SANIT ARY SEWER S 24,240.36 TOTAL PART 2 - \VATER MAIN 5 20,295~05 TOT AL PART; - SERVICES S 6 f 907" 95 TOTAL PART - TRUNK STORM SEWER TOTAL PART 5 - LA TERAL STORM SEWER s s TOT AL PART 6 - STREET IMPROVEt"lENTS TOTAL BASE BID: $87,211.45 S 191,811.31 :qO~ t61B1DFOR.k.1 Xl.S REVISED BY t\.DDi:!~":DUM NO l 00410-7 (1'.) REVISED BID FORM 2004/07/16 10:56:57 Powered by LightningFAX Page: 10/12 6.0 1 Bidder :1l:,'Tees that the work will be substantially completed and completed and ready for final payment in accordance with paragraph 1407.B of the General Conditions on or before the dates or within the number of calendar days indicated in the Agreement 602 Bidder accepts the provisions of 01::: Agreement as w liquidated damages in the tvt:lll of failure to cump!:::lt: th::: ViOl/( within the times specified above, which shall be stated in the Agreement. "7.0 i The foliawing documents are attached 10 and made a condition of this Bid: A Required Bid Security in the form of 5 percent SOl The terms used in this Bid with inirial capital letters have the meanings stated in the Instructions to B:dders. the General Conditioils, and the Suppicmentary Conditions SlJBI\11TTED on July 19 .2004 If Bidder Is: An Individuul Name (typed or printed): By: (SEAL) (Indi vidual's signature) Doing business as: Business address: P!wnc "No.: Fax 1'10: 00410.8 (R) 34G41iJ2!31DFORM xls "EViSED BY ,\DDENDUM NO 2 REVISED BID FORM LVU4/UI/~O lU:)b:57 Powered by LightningFAX Page: 11/12 /"}J~.iHlm:[5Jli.R Par1Jlership Name: (SEAL) By: (Signatmt of general partner) Name {typed or pr inled): Business address: Phone No : l:ax No: Corporation Nmnc: Carl Bolander ~ Sons Co. State of Incorporation: I'-1innesota T }lJC Limited Liability): Service By: (Signature) Name (typcd or printed): Richard L. O'Gara Title: vice-President (COP-PORI\ TE SEAL) Tirnoth'"':/ Business addrcss: 251 Street St. Paul, L'~ll~ 55107-0216 Phone No: 651,.224.6299 Fax No: 651.223.8197 00410-9(R) }404161B!DFOrU~i );ls HEVtSED [1\' ADDENDUM NO 2 R:::VISED BID FORI,,' LUU4/UI/lb 1U:56:57 Powered by LightningFAX Page:12/12 A Joint Venture Joint Venture Nnme: (SEAL) By: (Signature of joint venture partner) Name (rY'Ped or printed): Title: Business "ddress: Phone No.: Fax No: Joint Venturer Name: fJo...f. ~_... (Sign3tUlC) Name (typed or printed): Title: Business address: Phone No: Fax No: Phone 2nd Fax Number, and Address for receipt of official communications: 'Eacb joint venturer must sign The manner of signing for each individunl, parmership, and cOIporation thnt is a party to the joint venture should be in the manner indicated above) END OF DOCUMENT 00410-10(11.) 3.10.j 1 C~8fDFore,,1 xis REVISED BY ADDI:l,DUM NO 2 REVISED BID FORM "-...../ MINuTES OF A SPECIAL Y~ETING OF THE BOARD OF DIRECTORS OF C.~~L BO~~DER & SONS CO. \..J The undersigned constituting ali'of the directors of Carl Bolander & Sons COOt a Minnesota corporation, acting pursuant to'Minnesota Statutes, hereby adopts the follOwing resolution, effective May 1, 1989. /' ~lliEP~}3 there are times 'when the President of Carl Bolander & Sons Co. is unavailable to sign bid documents; NOW THEREFORE be it RESOLVED, That any officer of the corporation. has the authority to sign~any and all bids and bind the corporation for that purpose. There being no other business to come before the Board, the mee~~ng was ajaurned. ~: /) J?~ . ()f' Kl:O! ()J1 ~,--) Bolander l /, (\4, rj~ ~'-I 1/ V-.-J F '-' ' no~otnv E Raiar,dpr u.... (j/lf;Y;JjjI t L ()./ Dominiaue E. Najjar ~. \"--,, THE AMERICAN INSTITUTE OF ARCHITECTS AlA Document A310 Bid Bond KNOW ALL MEN BY THESE PRESENTS, THAT WE Carl Bolander & Sons Co. 251 Starkey Street S1. Paul, MN 55107 as Principal, tlereinafter called the Principal, and Travelers Casualty and Surety Companv of America One Tower Square -13 CZ. Hartford, CT 06183-6014 a corporation duly organized under the laws of the State of as Surety, hereinafter called the Surety, are held and firmly bound unto 4401 Xylon Avenue North. New Hope, ~v1N 55428-4898 as Obligee, hereinafter called the Obligee, in the sum of Five Percent of Amount Bid Dollars ($ 5.00% i, for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally. firmly by these presents. VVHEREP,S. the Principal has submitted a bid for Hillside Terrace Infrastructure Improvements. City Project No. 771, NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful periormance of suct1 Contract and for the prompt payment of labor and materials furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to periorm the Work covered by said bid, then this obligation shall be null and void, ott1erwise to remain in full force and effect. Signed and sealed this 19-th day of 2004 CFO/Secretary-Treasurer Travelers Casualty and Surety Company of America I I (Su. rety) ~ (Seal) I By ~iLJv~ (}J /1--JL:;; Attorney-in-Fact Mark W. Edwards, II (Title! AlA DOCTl\lE\'T A3JO . BID BO\'D . AlA. FEBRUARY 1970 ED. . TIlE A:\lERlCA\ INSTITUTE OF ARCHITECTS. 1735 N.Y. A \'E., N.W.. WASHlNGTO\', D.C. 20006 ~~ Traveler's ~/ IMPORTANT DiSCLOSURE NOTICE OF TERRORISM INSURANCE COVERAGE On Noverllber 261 2002, President Bush signed into law the Terrorism Risk Insurance ,ll..ct of 2002 (the "Act"), The Act establishes a shari-term program under which the Federal Government will share in the payment of covered losses caused by certain acts or international terrorism. VVe are providing you with this notice to inform you of the key features of the Act, and to iet you know vvhat effect, if any, the Act will have on your premium. Under the Act, insurers are required to provide coverage for certain losses caused by international acts of terrorism as defined in the Act. The Act further provides that the Federal Government wIli pay a share of such losses. Specifically! the Federal Government will pay 90% of the amount of covered losses caused by certain acts of terrorism which is in excess of Travelers' statutorily established deductible for that year. The Act also caps the amount of terrorism-related losses for vv'hich the Federal Government or an insurer can be res.ponsible at $100,000,000,000.00, provided that the insurer has met its deductible. Please note that passage of the Act does not result in any charlge in coverage under the attached policy or bond (or Ule policy or bond being quoted). Please also note that no separate additional premium charge has been made for the terrorism coverage required by the P,ct. The premium charge that is allocable to such coverage is inseparable from and imbedded in your overall premium and is no more than one percent of your premium. TR4.. VELERS CASU.o\LTY A1'\'"D SURETY COooMPA.1\l:' OF A...M.IRICA TRAVELERS CASUALTY A....~"D SlJRETY COJ\1P A..'r..'1' FARM1NGTON CASU.A..LTY COl\'1P.tu'\l' Hartford, Connecticut 06183-9062 PO\VER OF ATTOR'i"EY :\1'\""]) CERTIFICATE OF AUTHORITY OF ATTORl...."EiYCS}-IN....FACT :K.."?\O\V ALL PERSONS BY THESE I)RE;SENTS, TH..4.T TRAooVELERS CASUALTY A..l\']) SURETY COIVIP...v--i'Y OF AYvlERICA, TR<\. "i/ELEI'~ CASUALTI.' AooJ\""1J SURETY C01\fPA..J\'!' and FA.R.1\ill"GTON CABUALTY COl\iPANY, corporations duly organized under the laws of the State of Connecticut, and having their principal offices in t..i}e City of Hartford., County of F...a.-ti'ord, State or Connecticut, (herei.naf(er the "Companies") hath made, cOils-Limted and appointed, 3:.'1G do by these presents rna.ke, constitute and appall"!!: Mark \V. Edwards, IT, Ronald B. Giadrosich, or Birmingham, Alabama, tlleir True ,.JiC lav.ful ~A.ttomey(s)-in-Fact, ,vith full power and auti10rity hereby comerred to sigIi., execute and aclmowledge, at any place '\cvit11.in the United States, the following instrument(s): by bis/her sole signature and act, any and all bonds, recognizan::es, contracts or indemnity, and other \vritings obligator:' in the D..8.ture or a bond., recogniza:.'1.ce, or conditionallL.'1denaldng a."'1d any and all conseIll5 incident thereto aud to bind the Compilllies, thereby as funy and to tl1e &'lme extent as if tile same "Vt'cre signed D): the duly allthoriz~d officers of IDe, Comp3.llics. and. all the acts of said.;l:..ttomey(s)-m-Factt pursuant to the authority herein given~ are hereby ratified aIle: cOmJrmed. Tllis appointment is made under and by authoriTY of we fol1ov.ing no"\~v in full. force d.L"1d effect: Resolutions of said Conlpanie.s~ ~'vh.i;::h F~esolutions are 'VO.TED: Tnal the ChaLlnan, the President, any ~v"iceCh!}.h-n:z.r~ any Executive \;ice ?resjden~ ~'1y Senior 'Vice ?re5ident~alY \Tice Second "\I'ice President, the Treasurer, any P..sslstaIltTreasurer, theCoipGrate or any ..k.sslStaIli. Secretfu:~ may' appoint toacl for fu"1d on behalf efllie COInpaL"1Y ELla may give such appointee such as his Dr her cerUficate of auL10nty may' aTI\' Lr,e nature of a bor:d~ or ~ODG1Uonal s se.a! bonds. contracts of indemnilY, fu"JG ouleT .;~. B..!'1d any of said officers or the Beard of Directors at any tL."TIe may remove an.:.' s'ucn to ~~d revoke the po\!/er given lurrl or her. "VOTEI): ina: tne (,p an:,' V1ce anv.:...xecuuve Vice ..... ' ..~. ,",", " '" -. -, " an~~' ~er.uO:Vlce Yre.s:Qer~t or a.ny v:ce :'[eSlce:n may aHa r iL."1Y of the fores:ollliZ to o::e or TI10re ofuce:rs or ernpjoyees aftius Company: provided that eacn sueD and. a copy thereof is DIed in the office of t~e \lC'TED: Tha! any bond, recogrili-:3riCe, contract shall be ~\~al,id and, UDOIl the or indenullty~ yvnen or \\T1tl.i."lg abErra-lorv in the nature of a h^T\t": V,.f~.""'l recogr.... ~?::<'r1Get or COnCl111cnal Senior 'V'ice President Dr ~!Y '\Tice President., any Second Vice by [1e President, any\Tice Chainna.r1..; any Executive 'Vice ~n'" Lie fu"lV P..sStSlal1t the Corporate or 211\ and seal bV a to the pov/er or P..ssisrent or (b) executed in his Dr her c.ertif1cate or lllcrr certificates of sc;::;L i:- ana attcstecand sealed \vith t~e GIle or more Corr~p~"1Y offic.ers pursu2.:lt to a \Y.r:inen delegation of This Power oflutorney and Certificate of Authority is signed and sealed by facsimile (mecharJcaJ or primeo) under and by authority of the following Standing Resolution voted by the Boards of Directors of TR}~ VlLLERS CASUALTY .A~N1) SURETY COl\IPA.ooNY OF .t\..MERICA, TR.-\.v'ELERS C4..SUliliTY lu,\1) SURETY COlYiPiu\l' and FARl\-TINGTON CASDALT1- COJ\:IPA..NY, which Resolution is no" in full force and effect: "'\Ie/TED: .lnat the 01 eacn of tlie oIuceTs: all\' t.xecutlve VIce a:.'1'\' Senior ""lee ill1:,.' \::ce a11Y l~:...ssist3.Ilt c.I1V ar:y P..s.sls:'arn and the seal 01 u'1e . -- . may' ne alID(ea ia.CS1I11l1 e tc an \' "JQVier of attorney or to &jV certiiicat.e reiatin2. thereto . '" - 0-' r~~eS1C1ent F(esident /.i..SSistaIlt Secret?~ie:s or . "- ~,~~ purposes only of executing fu"}Q . . . Donas ana. ana otner ill tIle nanrre and e.n)' such pc)\ver of a:::.orr>ey upon the Compa...'1j' a11d fu~y such po\ve:- so exe::u1.ed E:ld t..:~:: in the furore \vifn respect to fillY DODG Dr or certl!..1 cate such facslnule ,- ... . or.laCSlInHe seal Ceri.1HeQ . ,.. . " SUCh IaCS11Illle and fa:sir-uile seal shall h~ to \vlllcn it is atta:..hed. r, ~ nr" "",__...l__':'. IN \VITI';ESS \YHEREOF, TRAV'"ELERS CA5U.-\..LTY A..l'ljD SURETY Co:rVIPA....l\.ir OF AIYIERICA, TR.~y"ELERS CASUALTY AND SURETY COlYJP.-il,Y :lndFA..Rl'\1INGTON CASUALTY COMPA,Y have caused this instrument to be signed by Lf1eir Senior Vice President and their corporate seals to be hereto affixed this 1st day of May 2003. 81i'.2 OF Cot.,1]'rECTlC"\JT } SS. HarJord TRA. VELERS CASUALTY A..i,\1) S"l.JRETY COiYIP..u,y' OF Al'\ffiRlCA TRA YELERS CASUALTY ..u"1) SURETY COJ.\:1P..u'iY FARrvITNGTON CASUALTY CO.M.PAl'fY CO\..TN1~{ (IF Rt...l'""ZTFORD ff~ ~~\ CONN. l~~ -;..~~ \.~ /,.;~!l "'....~ ,,,~_,,,,,."\~'i"..'P' '~"~~:~..:~~::;I~;;F' By ~~~ George W. Thompson Senior Vice President r-\..., LJ.,U.) 1st of 1\/12\", 2003 before Ine came GEORGE \V. rnOlYIPSON to me known., \vno, being me sv/o r1"L me cepose ane sa}': tha he/she is Senior Vice President of TR.A.\!ELERS CASUALTY AN']) SURETY COlYIPA.l'\Y OF .4J\1ERlCA, 'IRA. V'ELERS CASUl'iLTY A1\:,]) SURETY COl\IPA.i~Y and FA.R:'VIINGTON CASUALTY C01\IPAJ."';-Y, the corporations described in ~"1d '\.vruch exe::uted th,e above instrument; thatrle/she L--.:.O\V5 the seals or said corporations; that the seals 21I1X:::d to tile said instmmem are such corporate seals; and that he/she executed the said il1strtl...'nent eIl behalf of tile corporations by of 111s/her office'iL'rlder the Standing Resolutions thereof ~~'\,~ c.. ..: -- ~ ...!l- ~ Public rviarie C. Tetreault remams hi f1..u1 force and has not been revoked; and furthermore, t.:.'lat the Standing Resolutions of Lhe Boards of Directors, as set forrh in tJleCerillicme Of~~IlthOrity~ are novt in force. the State of C'orillec:icilt, DOPJ:P~B'\{ CE.RTIF""{ that rIle foregoing CL."1d attached Po\ver of :l1e Assistant SecretaQ' of TRA..\"ELEI'..s CASD.AlTY Al"-iD SURETY CQIvIPANY OF AMERICA, TRAVELERS CASUALTY AND S1IRETY COI\IPA.N"l' and FA..Ri'VII.\XGTON C.-1.SU.4..LTY COMPANY, 5:001;: corporations of lliiG' '"'~ V~ a.nc Sealed at the Home Office of the COmpill"1Y, in the City ofHarrfor~ State OfC0D11ecticuL Dated Uris 19th ;n04 ': _v .~. day of ~ fa~~~~\ i.... f . \ rf"l I ~ ( H~t~...,~:?.D, 1 ::} ,\...., ~ v......t'il't. i!":) ~~~o~ ~ c:::::;:::::;:-):-;;:- r7/f.... ~~ ,/ r-r'-,;Y ,-", By \....; Kori 1\1. Johanson Assistant Secretary, Bond DOCUMENT 00520 AGREEMENT FORM THIS AGREEMENT is by and between City of New Hope, Minnesota, (Owner) and Carl Bolander & Sons Co. (Contractor). Owner and Contractor, in consideration of the mutual covenants hereinafter set forth, agree as follows: ARTICLE 1 - WORK 1.01 Contractor shall complete all work as specified or indicated in the Contract Documents. The work is generally described as follows: municipal utility and street construction for the City of New Hope, Minnesota, City Project No. 771. ARTICLE 2 - THE PROJECT 2.01 The Project for which the work under the Contract Documents may be the whole or only a part is generally described as follows: Hillside Terrace Infrastructure Improvements for the City of New Hope, Minnesota, City Project No. 771. ARTICLE 3 - ENGINEER 3.01 The Project has been designed by Bonestroo, Rosene, Anderlik & Associates, Inc., 2335 West Highway 36, St. Paul, MN 55113 (Engineer), who is to act as Owner's representative, assume all duties and responsibilities, and will have the rights and authority assigned to Engineer in the Contract Documents in connection with the completion of the work in accordance with the Contract Documents. ARTICLE 4 - CONTRACT TIMES 4.01 Time of the Essence A. All time limits for Milestones, if any, Substantial Completion, and completion and readiness for Final Payment as stated in the Contract Documents are of the essence of the Contract. 4.02 Datesfor Milestones, Substantial Completion, and Final Payment A. An early start date of September 7, 2004 is anticipated. This relies on the completion of site work and grading by others. Adjustments in the start and completion dates may be necessary pending the completion of work by others. B. All work involved in this Project, with the exception of the wear course paving, shall be substantially completed on or before October 8, 2004. C. Any remaining restoration work shall be completed on or before May 5,2005. D. All wear course paving shall be completed on or before July 31,2005. Wear course paving cannot occur in 2004. 34-04-162 @ 2004 Bonestroo, Rosene, Anderiik & Associates, Inc. 00520-1 AGREEMENT FORM E. All of the work of the Project shall be completed and ready for Final Payment in accordance with Paragraph 14.07 of the General Conditions on or before August 15,2005. 4.03 Liquidated Damages A. Contractor and Owner recognize that time is of the essence of this Agreement and that Owner will suffer financial loss if the work is not completed within the times specified in paragraph 3.02 above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. The parties also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty), Contractor shall pay Owner $250.00 for each day that expires after the time specified in paragraph 3.02 for Substantial Completion until the work is Substantially Complete. After Substantial Completion, if Contractor shall neglect, refuse, or fail to complete the remaining work within the Contract Time or any proper extension thereof granted by Owner, Contractor shall pay Owner $250.00 for each day that expires after the time specified in paragraph 3.02 for completion and readiness for Final Payment until the work is completed and ready for Final Payment. ARTICLE 5 - CONTRACT PRICE 5.01 Owner shall pay Contractor for completion of the work in accordance with the Contract Documents an amount in current funds as follows: For all work, at the prices stated in Contractor's Bid, attached hereto as an exhibit for an Original Contract Amount of One Hundred Ninety-One Thousand Eight Hundred Eleven Dollars and Thirty-One Cents ($191,811.31) for the Total Base Bid. ARTICLE 6 - PAYMENT PROCEDURES 6.01 Submittal and Processing of Payments A. Contractor shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Applications for Payment will be processed by Engineer as provided in the General Conditions. 6.02 Progress Payments; Retainage A. Owner shall make progress payments on account of the Contract Price on the basis of Contractor's Applications for Payment, monthly during performance of the work as provided in Paragraphs 6.02.A.l and 6.02.A.2 below. All such payments will be measured by the Schedule of Values established in Paragraph 2.07.A of the General Conditions (and in the case of Bid Unit Price work based on the number of units completed) or, in the event there is no Schedule of Values, as provided in the General Requirements: 1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below but, in each case, less the aggregate of payments previously made and less such amounts as Engineer may determine or Owner may withhold, including but not limited to liquidated damages, in accordance with Paragraph 14.02 of the General Conditions: a. 95 percent of work completed (with the balance being retainage). b. 95 percent of cost of materials and equipment not incorporated in the work (with the balance being retainage). 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00520-2 AGREEMENT FORM 2. Upon Substantial Completion, Owner shall pay an amount sufficient to increase total payments to Contractor to 100 percent of the work completed, less such amounts as Engineer shall determine in accordance with Paragraph 14.02.B.5 of the General Conditions and less 100 percent of Engineer's estimate of the value of work to be completed or corrected as shown on the tentative list of items to be completed or corrected attached to the certificate of Substantial Completion. 6.03 Final Payment A. Upon Final Completion and acceptance of the work, in accordance with Paragraph 14.07 of the General Conditions, Owner shall pay the remainder of the Contract Price as recommended by Engineer as provided in said Paragraph 14.07. ARTICLE 7 - INTEREST 7.01 All moneys not paid when due, as provided in Article 14 of the General Conditions, shall bear interest at the rate the maximum rate allowed by law at the place of the Project. ARTICLE 8 - CONTRACTOR'S REPRESENTATIONS 8.01 In order to induce Owner to enter into this Agreement, Contractor makes the following representations: A. Contractor has examined and carefully studied the Contract Documents and the other related data identified in the Bidding Documents. B. Contractor has visited the Project Site and become familiar with and is satisfied as to the general, local, and Project Site conditions that may affect cost, progress, and performance of the work. C. Contractor is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the work. D. Contractor has carefully studied all: (1) reports of explorations and tests of subsurface conditions at, or contiguous to, the Project Site and all drawings of physical conditions in, or relating to, existing surface or subsurface structures at, or contiguous to, the Project Site (except Underground Facilities) which have been identified in the Supplementary Conditions as provided in Paragraph 4.02 of the General Conditions and (2) reports and drawings of a Hazardous Environmental Condition, if any, at the Project Site which has been identified in the Supplementary Conditions as provided in Paragraph 4.06 of the General Conditions. E. Contractor has obtained and carefully studied (or assumes responsibility for having done so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at, or contiguous to, the Project Site which may affect cost, progress, or performance of the work, or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, including applying the specific means, methods, techniques, sequences, and procedures of construction, if any, expressly required by the Contract Documents to be employed by Contractor, and safety precautions and programs incident thereto. 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00520-3 AGREEMENT FORM F. Contractor does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract Documents. G. Contractor is aware of the general nature of work to be performed by Owner and others at the Project Site that relates to the work as indicated in the Contract Documents. H. Contractor has correlated the information known to Contractor, information and observations obtained from visits to the Project Site, reports and drawings identified in the Contract Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Contract Documents. 1. Contractor has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Contractor has discovered in the Contract Documents, and the written resolution thereof by Engineer is acceptable to Contractor. 1. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the work. ARTICLE 9 - CONTRACT DOCUMENTS 9.01 Contents A. The Contract Documents consist of the following: 1. This Agreement. 2. Performance Bond, Payment Bond, and other Bonds. 3. General Conditions. 4. Supplementary Conditions. 5. Specifications. 6. Drawings bearing the following general title: Hillside Terrace Development; 7. Addenda (Numbers One to Two, inclusive). 8. Exhibits to this Agreement (enumerated as follows): a. Contractor's Bid Form. b. Documentation submitted by Contractor prior to Notice of Award. 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00520-4 AGREEMENT FORM 9. The following which may be delivered or issued on or after the Effective Date of the Agreement, and are not attached hereto: a. Notice to Proceed b. Work Change Directives; c. Change Order(s). B. The documents listed in Paragraph 9.01.A are attached to this Agreement (except as expressly noted otherwise above). C. There are no Contract Documents other than those listed above in this Article 9. D. The Contract Documents may only be amended, modified, or supplemented as provided in Paragraph 3.04 of the General Conditions. ARTICLEIO-NllSCELLANEODS 10.01 Terms A. Terms used in this Agreement will have the meanings stated in the General Conditions and the Supplementary Conditions. 10.02 Assignment of Contract A. No assignment by a party hereto of any rights under or interests in the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 10.03 Successors and Assigns A. Owner and Contractor each binds itself, its partners, successors, assigns, and legal representatives to the other party hereto, its partners, successors, assigns, and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. 10.04 Severability A. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. 34-04- i 62 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00520-5 AGREEMENT FORM IN WITNESS WHEREOF, Owner and Contractor have signed this Agreement in duplicate. One (1) counterpart each has been delivered to Owner and Contractor. All portions of the Contract Documents have been signed or identified by Owner and Contractor or on their behalf. This Agreement will be effective on g }31 ~ . Owner: Ci Address for giving notices: ,!jLI/ / /G~I V /! I/-,-v/ <';.J i i) I"~; j /'- '- / ;:; j f .. U......,/t/"'C . \-/ J I HZ IJJL )}/7/7 ~~-5-i/ d k I / II L j i'Vt/"\"../v Designated Representative: i Name: :11, . I . iLll ,e( i c L CO FlC. Title: Address: Phone: / /,. 2. ! ({)...) ,;5j/- 5(/7 Facsimile: J / '? Ii?J J(/5!3 , 2004 (which is the Effective Date ofthe Agreement). Contractor: ..../(,/ L. t PJZ~ I De?J1" Attes~t?L ~ Address for giving notices: d-5J S~k~ cz>7. J)/414 L/ ~ b'Old'1 License No. (Where applicable) Designated Representative: Name: Title: Address: Phone: Facsimile: END OF DOCUMENT 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00520-6 AGREEMENT FORM PERFORJ.\1ANCE BOND Any singular reference to Contractor, Surety, Owner, or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Address of Principal Place of Business): OWNER (Name and Address): CONTRA.CT Date: Amount: Description (Name and Location): BOND Bond Number: Date (Not earlier than Contract Date): Amount: Modifications to this Bond Form: Sucety and Cont"ctoc, intending to be legally bound heeeby, subject to the terms pcinted on the cevme side heceof, do each cause this Performance Bond to be duly executed on its behalf by its authorized officer, agent, or representative. CONTRACTOR AS PRINCIPAL Company: Sl.TRETY Signature: Name and Title: (Seal) Surety's Name and Corporate Seal (Seal) (Space is provided belo\v for signatures of additional parties, if required.) By: Signature and Title (Attach Power of Attorney) Attest: Signature and Title CONTRA.CTOR AS PRINCIPAL Company: SlTRETY Signature: Name and Title: (Seal) Surety's Name and Corporate Seal ( Seal) By: Signature and Title (Attach Power of Attorney) EJCDC No. C-610 (2002 Edition) Originally prepared through the joint effOrts of the Suret}' Association of America, Engineers Joint Contract Documents Committee, the Associated General Contractors of America, and the American Institute of Architects. Attest: Signature and Title: ~ 00610-1 1. Contractor and Surety, jointly and severally, bind themselves. their heirs. executors. administrators. successors. and assigns to Owner for the performance of the Contract, which is incorporated herein by reference. 2. If Contractor performs the Contract. Surety and Contractor have no obligation under this Bond. except to participate in conferences as provided in Paragraph 3.1. 3. If there is no Owner Default, Surety's obligation under this Bond shall arise after: 3.1. Owner has notified Contractor and Surety, at the addresses described in Paragraph 10 below. that Owner is considering declaring a Contractor Default and has requested and arrempted to arrange a conference with Contractor and Surety to be held not later than 15 days after receipt of such notice to discuss methods of performing the Contract. If Owner. Contractor and Surety agree. Contractor shall be allowed a reasonable time to perform the Contract, but such an agreement shall not waive Owner's right. if any, subsequently to declare a Contractor Default; and , 1 ~.~. Owner has declared a Contractor Default and formally terminated Contractor's right to complete the Contract. Such Contractor Default shall not be declared earlier than 20 days after Contractor and Surety have received notice as provided in Paragraph 3. i; and 3.3. Owner has agreed to pay the Balance of the Contract Price to: I. Surety in accordance \vith the terms of the Contract; 2. Another contractor selected pursuant to Paragraph 4.3 to perform the Contract. 4. When Owner has satisfied the conditions of Paragraph 3. Surety shall promptly and at Surety's expense take one of the following actions: 4.1. Arrange for Contractor, with consent of Owner, to perform and complete the Contract; or 4.2. Undertake to perform and complete the Contract itSelf, through itS agents or through independent contractors; or 4.3. Obtain bids or negotiated proposals from qualified contractors acceptable to Owner for a contract for performance and completion of the Contract. arrange for a contract to be prepared for execution by Owner and Contractor selected with Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Contract, and pay to Owner the amount of damages as described in Paragraph 6 in excess of the Balance of the Contract Price incurred by Owner resulting from Contractor Default: or 4.4. Waive itS right to perform and complete. arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: 1. After investigation, determine the amount for which it may be liable to Owner and, as soon as practicable after the amount is determined, tender payment therefor to Owner; or 1 Deny liability in whole or in part and notify Owner citing reasons therefor. 5. If Surety does not proceed as provided in Paragraph 4 with reasonable promptness, Surety shall be deemed to be in default on this Bond 15 days after receipt of an additional written notice from Owner to Surety demanding that Surety perform itS obligations under this Bond. and Owner shall be entitled to enforce any remedy available to Owner. If Surety proceeds as provided in Paragraph 4.4. and Owner refuses the payment tendered or Surety has denied liability, in whole or in part. without further notice Owner shall be entitled to enforce any remedy available to Owner. 6. After Owner has terminated Comractor's right to complete the Contract, and if Surety electS to act under Paragraph 4.1, 4.2, or 4.3 above, then the responsibilities of Surety to Owner shall not be greater than those of Contractor under the Contract, and the responsibilities of Owner to Surety shall not be greater than those of Owner under the Contract. To a limit of the amount of this Bond, but subject to commitment by Owner of the Balance of the Contract Price to mitigation of costS and damages on the Contract, Surety is obligated without duplication for: 6.1. The responsibilities of Contractor for correction of defective Work and completion of the Contract; 6.2. Additional legal, design professional, and delay costS resulting from Contractor's Default, and resulting from the actions or failure to act of Surety under Paragraph 4; and 6.3. Liquidated damages, or if no liquidated damages are specified in the Contract, actual damages caused by delayed performance or non- performance of Contractor. 7. Surety shall not be liable to Owner or others for obligations of Contractor that are unrelated to the Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than Owner or itS heirs, executors, administrators, or successors. 8. Surety hereby waives notice of any change, including changes of time. to Contract or to related subcontractS, purchase orders, and other obligations. 9. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the Work or part of the \Vork is located and shall be instituted within two years after Contractor Default or within twO years after Contractor ceased working or within tWO years after Surety refuses or fails to perform itS obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law. the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 10. Notice to Surety, Owner, or Contractor shall be mailed or delivered to the address shown on the signature page. 11. When this Bond has been furnished to comply with a statutory requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory requirement shall be deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12. Definitions. 12.1 Balance of the Contract Price: The total amount payable by Owner to Contractor under the Contract after all proper adjustments have been made. including allowance to Contractor of any amountS received or to be received by Owner in settlement of insurance or other Claims for damages to which Contractor is entitled, reduced by all valid and proper payments made to or on behalf of Contractor under the Contract. 12.2. Contract: The agreement between Owner and Contractor identified on the signature page, including all Contract DocumentS and changes thereto. 12.3. Contractor Default: Failure of Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Contract. '1 ~l 1...."":". Owner Default: Failure of Owner. which has neither been remedied nor waived, to pay Contractor as required by the Contract or to perform and complete or comply with the other terms thereof. FOR INFORMATION ONLY - Name, Address and Telephone Surety Agency or Broker Owner's Representative (Engineer or orher party) 00610-2 PAYMENT BOND Any singuIa; reference to Cont"ctOt, SUtety, Ownet, Ot othet patty shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Address of Principal Place of Business): OWNER (Name and Address): CONTRACT Date: Amount: Description (Name and Location): BOND Bond Number: Date (Not earlier than Contract Date): Amount: ivlodifications to [his Bond Fonn: Surety and Conteactot, intending to be legally bound heteby, subject to the tenus pdnted on the reVetse side heceof, do each cause this Payment Bond to be duly eXecuted on its behalf by its authorized officer, agent, or representative. CONTRACTOR AS PRIN"CIPAL Company: S"(JRETY Signature: Name and Title: (Seal) Surety's Name and COrporate Seal (Seal) (Space is provided below for signatures of additional parties, if required.) By: Signature and Title (Attach Pow'er of Attorney) CONTRACTOR AS PRIN"CIP AL Company: Attest: Signature and Title S'(.JRETY Signature: Name and Title: (Seal) Surety's Name and COrporate Seal (Seal) Bv. J. Signature and Title (Attach Po\ver of Attorney) Attest: Signature and Title: EJCDC No. C-615 (2002 Edition) OMgin,Uy P"_d 'in-,ugh 'h, j'in' ,rr,", ,f <h, S~"y "",;";,, ,r Am",,", Eog;,~" J';n< Coo,,,,, D~tuneo" C,_,,,,, 'h, "'''M'',d "eo",t C"'Met,,, ,r Am'd", th, Am'd,," _to" ,r ""'hi'~", th, Am'd,," S'htUn""",,, ""'d,"", ,"d <h, ''''~;,''d SP""'ry Cu,,",,,",,, = 00615-1 l. Contractor and Surety, jointly and severally, bind themselves, their heirs, ~xecutors, administrators, successors, and assigns to Owner to pay for labor, materials, and equipment furnished by Claimants for use in the performance of the Contract, which is incorporated herein by reference, 2. With respect to Owner, this obligation shall be null and void if ContractOr: 2.1. Promptly makes payment, directly or indirectly, for all sums due Claimants, and 2.2. Defends, indemnifies, and holds harmless Owner from all claims, demands, liens, or suits alleging non-payment by ContractOr by any person or entity who furnished labor, materials, or equipment for use in the performance of the Contract, provided Owner has promptly notified Contractor and Surety (at the addresses described in Paragraph 12) of any claims, demands, liens, or suits and tendered defense oi such claims, demands, liens, or suits to Contractor and Surety, and provided there is no Owner Default. 3. With respect to Claimants, this obligation shall be null and void ii Contractor promptly makes payment, directly or indirectly, ior all sums due. .t. Surety shall have no obligation to Claimants under this Bond until: 4.1. Claimants who are employed by or have a direct contract with Contractor have given notice to Surety (at the addresses described in Paragraph 12) and sent a copy, or notice thereof, to Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2. Claimants who do not have a direct contract with Contractor: 1. Have furnished written notice to Contractor and sent a copy, or notice thereof. to Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials or equipment were furnished or supplied, or for whom the labor was done or performed; and 2. Have either received a rejection in whole or in pan from Contractor, or not received within 30 days of furnishing the above notice any communication from ContractOr by which ContractOr had indicated the claim will be paid directly or indirectly; and 3. Not having been paid within the above 30 days, have sent a written notice to Surety and sent a copy, or notice thereof, to Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to Contractor. 5. Ii a notice by a Claimant required by Paragraph 4 is provided by Owner to Contractor or to Surety, that is sufficient compliance. 6. When a Claimant has satisiied the conditions of Paragraph 4, the Surety shall promptly and at Surety's expense take the following actions: 6.1. Send an answer to that Claimant, \vith a copy to Owner, within 45 days after receipt of the claim, stating the amountS that are undisputed and the basis for challenging any amounts that are disputed. 6.2. Payor arrange for payment of any undisputed amounts. 7. Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited ror any payments made in good faith by Surety . 8. Amounts owed by Owner to ContractOr under the Contract shall be used for the performance of the Contract and to satisfy claims, if any, under any performance bond. By Contractor furnishing and Owner accepting this Bond, they agree that all funds earned by Contractor in the performance of the Contract are dedicated to satisfy obligations of ContractOr and Surety under this Bond, subject to Owner's priority to use the funds for the completion of the Work. 9. Surety shall not be liable to Owner, Claimants, or others for obligations of Contractor that are unrelated to the Contract. Owner shall not be liable for payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligations to make payments to, give notices on behalf of. or otherwise have obligations to Claimants under this Bond. 10. Surety hereby waives notice of any change, including changes of time, to the Contract or to related Subcontracts, purchase orders and other obligations. 11. No suit or action shall be commenced by a Claimant under this Bond other than in a coun of competent jurisdiction in the location in which the Work or pan of the Work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by Paragraph 4.1 or Paragraph 4.2.3, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (I) or (2) iirst occurs. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction oi the suit shall be applicable. 12. Notice to Surety. Owner, or Contractor shall be mailed or delivered to the addresses shown on the signature page. Actual receipt of notice by Surety, Owner, or Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13. Wnen this Bond has been furnished to comply with a statutory requirement in the location where the Contract was to be performed, any provision in this Bond conflicting with said statutory requirement shall be deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory Bond and not as a common law bond. 14. Upon request of any person or entity appearing to be a potential beneficiary of this Bond. Contractor shall promptly furnish a copy of this Bond or shall permit a copy to be made. 15. DEF1NlTlONS 15.1. Claimant: An individual or entity having a direct contract with Contractor. or with a fIrst-tier subcontractor of Contractor, to_furnish labor. materials. or equipment for use in the performance of the Contract. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that pan of water. gas, power, light, heat, oil, gasoline, telephone service, or rental equipment used in the Contract, architectural and engineering services required for performance of the Work of Contractor and Contractor's Subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials. or equipment were furnished. IS .2. Contract: The agreement between Owner and Contractor identiiied on the signature page. including all Contract Documents and changes thereto . 15.3. Owner Default: Failure or Owner, which has neither been remedied nor waived, to pay Contractor as required by the Contract or to perform and complete or comply with the other terms thereof. FOR INFOR.cvIA nON Ol'i'L Y - Name, Address and Telephone Surety Agency or Broker: Owner's Representative (Engineer or other party): 00615-2 DOCUMENT 00800 SlTPPLEMENT AR Y COr-,TDITIONS These Supplementary Conditions amend or supplement the Standard General Conditions of the Construction Contract (No. C-700, 2002 Edition) and other provisions of the Contract Documents as indicated below. All provisions, which are not so amended or supplemented, remain in full force and effect. The terms used in these Supplementary Conditions have the meanings stated in the General Conditions. Additional terms used in these Supplementary Conditions have the meanings stated below, vvhich are applicable to both the singular and plural thereof. ARTICLE 1 - DEFINITIONS A1~TI TERlvlINOLOGY SC-1.02 Add the following new paragraph immediately after Paragraph 1.02.F: G. The Specifications are written in imperative mood and streamlined form. This imperative language is directed to the Contractor, unless specifically noted otherwise. The words "shall be" are included by inference where a colon (:) is used within sentences or phrases. ARTICLE 2 - PRELllvlINARY MATTERS SC 2.02.A Amend the first sentence of Paragraph 2.02.A by striking out the word "ten" and inserting the word "five." ARTICLE 4 - AVAILABILITY OF LANTIS: StTBStTRF ACE A:NTI PHYSICAL CONTIITIONS, REFERENCE POINTS SC-4.02 Delete 4.02.A and 4.02.B in their entirety and insert the following: A. No reports of explorations or tests of subsurface conditions at, or contiguous to, the Project Site are known to the Owner or Engineer. ARTICLE 5 - BONTIS ANTI INStJRANCE SC-S.Ol Add the following nevv paragraph immediately after Paragraph S.01.C: D. Separate Performance and Payment Bonds should be submitted utilizing EJCDC Form C-61 0 and C-61S (2002 Editions), or a similar bond form if approved by Owner. 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, L'1c. 00800-1 SLJPPLEMENTAR Y CONDITIONS SC-5.03.B Delete Paragraph 5.03.B in its entirety and insert the following: B. Failure of Owner to demand such certificates or other evidence of full compliance with these insurance requirements, or failure of Owner to identify a deficiency from evidence provided, shall not be constmed as a \vaiver of Contractor's obligation to maintain such lilsurance. C. By requiring such insurance and insurance limits herein, Owner does not represent that coverage and limits will necessarily be adequate to protect Contractor and such coverage and limits shall not be deemed as a limitation on Contractor's liability under the indemnities granted to Owner in the Contract Documents. SC-5.04. Add the following new paragraph immediately after Paragraph 5.04.B: C. The limits of liability for the insurance required by Paragraph 5.04 of the General Conditions shall provide coverage for not less than the following amounts or greater where required by Laws and Regulations: 1. Worker's Compensation Insurance Coverage A - Statutory Coverage B - $500,000 S500,000 S500,000 Each Accident Disease - Policy Limit Disease - Each Employee ') Commercial General Liability Sl,OOO,OOO General Aggregate Sl,OOO,OOO Products/Completed Operations Aggregate Sl,OOO,OOO Each Occurrence $1,000,000 Personal Injury 3. Comprehensive Automobile Liability Sl,OOO,OOO Combined Single Limit - Bodily injury and property damage. All owned, non-owned, and hired vehicles. 4. Umbrella Excess Liability Sl,OOO,OOO 51,000,000 Each Occurrence Aggregate Umbrella excess liability shall be a combined single limit which shall provide excess liability insurance over Commercial General Liability, Comprehensive Automobile Liability, and Employers Liability. 34-04-162 @ 2004 Bonestroo, Rosene, Anderiik & Associates, Inc. 00800-2 SUPPLEMENTARY CONDITIONS 5. The following persons or entities shall be included as additional insured on the Commercial Liability, Comprehensive Automobile Liability, and Umbrella Excess Liability. This coverage shall be primary and noncontributory: Owner. Engineer. SC-5.06.A Amend the first sentence of Paragraph 5.06.A. to read: A. Contractor shall purchase and maintain during the entire construction period, a Builders Risk Property Insurance Policy in the amount of the full replacement cost of the entire work at the Project Site. The insurance policy shall comply with the provisions of Paragraph 5.06.A.1 through 5.06.A.7. A minimum deductible of Sl,OOO each claim shall apply to this insurance and the risk of loss of the applicable deductible shall be born by Contractor, subcontractor, or others suffering such loss. In addition, the provisions of Paragraphs 5.07, 5.09, and 5.10 shall apply with the exception that Contractor shall act as fiduciary for the insureds, as their interest may appear and adjust the loss with the insurance company. SC-5.06.A Add the following new item immediately after Item 5.06.A.7: 8. The Builder's Risk Insurance required herein shall apply to projects involving construction of structures and buildings only. The requirements of this Section shall be waived on projects involving only underground utilities, grading, street improvements, and similar construction work but any damage or loss to property shall be at the sole responsibility of Contractor until final acceptance of the work. ARTICLE 6 - CONTR.A.CTOR'S RESPONSIBILITIES SC-6.08.A. Amend the first sentence of Paragraph 6.08.A by replacing the words "the Supplementary Conditions" \vith the words "Division 1 - General Requirements." SC-6.19.A. Delete the words "representation of" in the second sentence. ARTICLE 10 - CHA.".JGES IN THE WORK; CLAD/IS SC-10.05.B. Amend the tIrst sentence of Paragraph 10.05.B by replacing the words "30 days" with the words "10 days." Amend the third sentence of Paragraph 10.05.B by replacing the words "60 days" with the words "30 days." ARTICLE 13 - TESTS Al"J"D INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTA.".JCE OF DEFECTIVE WORK SC-13.07.A. Amend the first sentence of Paragraph 13.07.A by striking out the words "one year" and inserting the \vord "two years." 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00800-3 SUPPLEMENTARY CmWlTlONS l~RTICLE 14 - PA yJ\lfENTS TO CONTR.A.CTOR Al~l) CONlPLETION SC-14.02.B.S Add the following new item immediately after Item 14.02.B.S.d: e. Contractor's failure to make acceptable submittals in accordance with the accepted schedules. ARTICLE 16 - DISPUTE RESOLUTION SC-16.01 Delete Paragraph 16.01.C in its entirety and insert the following in its place: C. If the claim is not resolved by mediation, Engineer's action under Paragraph 10.0S.C or a denial pursuant to Paragraphs 10.0S.C.3 or 10.0S.D shall become final and binding 30 days after termination of the mediation unless, within that time period, Owner or Contractor: 1. elects in writing to demand arbitration of the claim, pursuant to Paragraph SC-16.02, or 2. agrees with the other party to submit the claim to another dispute resolution process. SC-16.01.D Add the following new paragraph immediately after Paragraph SC-16.01.C: D. Notwithstanding any applicable statue of limitations, a party giving notice under Paragraph SC-16.01.C.1 shall commence an action on the claim within 1 year of giving such notice, and within the period of any applicable statute of limitation or repose. Failure to do so shall result in the claim being time-barred and Engineer's action or denial shall become final and binding. SC-16.02 Add the following ne\v paragraph immediately after Paragraph 16.01: SC-16.02 Arbitration A. All claims or counterclaims, disputes, or other matters in question between Owner and Contractor arising out of or relating to the Contract Documents or the breach thereof (except for claims which have been waived by the making or acceptance of Final Payment as provided by Paragraph 14.09), including but not limited to those not resolved under the provisions of Paragraphs SC-16.01A and l6.01.B, but not including any claim in excess of S100,000, will be decided b.y arbitration in accordance \vith the Construction Industry Dispute Resolutions Procedures of the American Arbitration Association then in effect, subject to the conditions and limitations of this Paragraph SC-16.02. This agreement to arbitrate and any other agreement or consent to arbitrate entered into will be specifically enforceable under the prevailing law of any court having jurisdiction. 34-04-! 62 :9 2004 Bonestroo. Rosene, Anderlik & Associates, Inc. 00800-4 SUPPLEMENTAR Y CONDITIONS B. The demand for arbitration will be filed in writing with the other party to the Contract and with the selected arbitrator or arbitration provider and a copy will be sent to Engineer for information. The demand for arbitration will be made within the 30 day period specified in Paragraph SC-16.01.C, and in all other cases within a reasonable time after the claim or counterclaim, dispute, or other matter in question has arisen, and in no event shall any such demand be made after the date when institution of legal or equitable proceedings based on such claim or other dispute or matter in question would be barred by the applicable statue of limitations. C. No arbitration arising out of or relating to the Contract Documents shall include by consolidation, joinder, or in any other manner any other individual or entity (including Engineer, and Engineer's consultants and the officers, directors, partners, agents, employees, or consultants of any of them) who is not a party to this Contract, unless: 1. in inclusions of such other individual or entity is necessary if complete relief is to be afforded among those who are already parties to the arbitration; and 2. such other individual or entity is substantially involved in a question of law or fact which is common to those who are already parties to the arbitration and which \vill arise in such proceedings. D. The award rendered by the arbitrator(s) shall be consistent with the agreement of the parties, in writing, and include: (i) a concise breakdown of the award; (ii) a written explanation of the award specifically citing the Contract Documents provisions deemed applicable and relied on in making the award. E. The award will be final. Judgment may be entered upon it in any court having jurisdiction thereof, and it \vill not be subject to modification or appeal, subject to provisions of the Controlling Law relating to vacating or modifying an arbitral award. F. The fees and expenses of the arbitrators and any arbitration service shall be shared equally by Owner and Contractor. ENTI OF DOClJl\ilENT 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 00800-5 SUPPLElvlENTARY CONDITIONS SECTION 01100 SUMMARY Pi\RT 1 - GENER.AL 1.01 SECTION INCUJDES A. Basic description of the Project and work restrictions. 1.02 SlJ1vlMARY OF WORK A. Project Name: Hillside Terrace Infrastucture Improvements for the City of New Hope, Minnesota, City Project No. 771. B. Description of Work: Project consists of installation of new sanitary seVier, storm sewer, and vvater main. This Project also includes the installation of interim bituminous street and final concrete curb and gutter and pavement. 1.03 COMPLETION DATES A. Set forth in the Agreement. 1.04 LIQUIDATED DA1\1AGES A. Provisions for liquidated damages, if any, are set forth in the Agreement. 1.05 WORK RESTRICTIONS A. Use of Project Site: 1. Location of construction facilities, staging areas, product stockpiles, material storage, and temporary construction should be reviewed and approved by the Owner, and shall be removed upon completion ofvvork. 2. Keep existing driveways and entrances clear and available to the public and to the Owner: a. Salvaged Class 5 from the existing street section shall be used to maintain access to resident's driveways at no additional cost to the Owner. b. Access interruptions must be noticed to the Owners representative and impacted residents. 3. If additional space is needed, obtain and pay for such space offsite. 3.1-04-162 .]J 2004 Bonestroo. Rosene, Anderiik & Associates, Inc. 01100-1 SUMMARY B. Access to Project Site: 1. Hauling access shall be limited to Ensign Avenue north of 35th Avenue to 36th Avenue to TH 169. C. Other Work at Project Site: 1. The installation and revision of electric power, telephone lines, gas lines, and cable TV by private utilities is anticipated. PART 2 - PRODUCTS Not Used PART 3 - EXECUTION 3.01 MEASUREMENT A.l'ID PAYMENT A. All work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 34-04-162 .9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01100-2 SU"Itv!ARY SECTION 01310 PROJECT MAi'JAGEMENT Ai'ID COORDINATION PART 1 - GEN~RAL 1.01 SECTION INCLUDES A. General requirements for overall Project coordination. 1.02 UTILITIES A. Notify Gopher State One Call before starting construction in a given area requesting utility locates in the Project Site. B. Project Utility Sources: Coordinate work with the following utility owners. The follo\ving utilities are known to be on the Project Site and are shown on the Drawings in a general way: 1. Water: Owner. 2. Sanitary Sewer: Owner. 3. Storm Sewer: Owner. 4. Electric: Xcel Energy, Gregory S. Plumedahl, 8701 Monticello Lane, Maple Grove, ivfN 55369; ph: 763-493-1670; fax: 763-493-1501. 5. Gas: Reliant Energy, Minnegasco, Cherie Monson, P.O. Box 1165, Minneapolis, MN 55440-1165; ph: 612-321-5435; fax: 763-321-5480. 6. Telephone: Qwest, Carrie Oster, 9700 Schmidt Lake Road, Room 155, Plymouth, MN 55442; ph: 763-381-5542; fax: 763-536-5098. 7. Cable TV: Comcast Communication, Doug Zahn, 1238 Grey Fox Road, Arden Hills, IvIN 55112-6930; ph: 651-493-5316; fax: 651-493-5116. C. Ow'ner requires 48 hour notice for all utility interruptions. D. Private utility infonnation obtained from utility owners/operators is shown on the Drawings in a general way. The location of utilities is not guaranteed. The locating of utilities and coordination during construction is the responsibility of the Contractor. Final locations of all utilities, per the Gopher One System, will be the responsibility of the Contractor. All costs associated with the private utility coordination shall be incidental to the total work of the Project. Private utility information was provided to the City per design locate Ticket Number 40363594. 34-04-162 ';9 2004 Bonestroo, Rosene, Ander!ik & Associates, Inc. o 13 1 0-1 PROJECT MANAGEMENT AND COORDLNA TION Information provided is of Quality Level D (QLD) as defined by ASCE Standards. Utility locations shown on the Drawings are based on this QLD information, and have not been verified with a field survey. 1.03 PERLYfITS A. Comply with the stipulations of the following permits which have been applied for or will be furnished by the Owner: 1. MPCA Stormwater Discharges Associated With Construction Activities NPDES General Permit. Contractor will pay the application cost of this permit. B. Apply for, obtain, and comply with other permits, licenses, and approvals which may be required for the Project. 1.04 SlJRVEYING Ml) CONSTRUCTION OBSERVATION A. Provide Engineer and Resident Proj ect Representative a minimum of 48 hours notice in advance of the need for establishing lines, grades, measurements, grade checks, and observation of work. 1.05 PROJECT MEETINGS A. Administrative Requirements: 1. Proj ect Superintendent, or persons designated by the Contractor to attend, and participate in the Project meetings shall have all required authority to commit the Contractor to solutions agreed upon in the Project meetings. 2. Engineer \-vill set the time, sites, and prepare the agenda for the meetings. 3. Engineer will prepare meeting minutes and distribute 1 copy to Contractor. Notify Engineer of inaccuracies, or discrepancies in the meeting minutes within 5 calendar days ofreceipt of the minutes. 4. The attendance and cooperation of subcontractors and suppliers may be required. 34-04-162 (Q 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01310-2 PROJECT MANAGEMENT AND COORDINATION B. Preconstruction Conference: 1. Provisions for the Preconstruction Conference are set forth in the General Conditions. 2. Requirements for preconstruction submittals are set forth in the General Conditions. C. Progress Meeting Procedures: 1. Engineer will schedule construction progress meetings throughout the duration of the Project to assess the progress ofthe work, identify and discuss Project related issues, and discuss near-term construction activities. 1.06 CONSTRUCTION SCHEDULING A. Sequencing and Scheduling: 1. Owner is very sensitive to the inconvenience each property owner will experience to construct this Project. The most frequent complaint received during this type of Project is the length of time for which streets, driveways, and boulevards are disturbed. Therefore, scheduling ofthe work, maintenance oflocal traffic, and timely repair of each driveway and yard are critical to the success of the Project. 1.07 Sl:JBMITTALS A. Submit a minimum of 4 copies of shop draw'ings, plus the quantity of copies the Contractor wants returned. PART 2 - PRODUCTS Not Used PART 3 - EXECUTION 3.01 MEASlJREMENT AL~v PAYMENT A. All work and costs of this Section shall be incidental to the Proj ect and included in the TOTAL BASE BID. E0Iv OF SECTION 34-04-\62 9 2004 Bonestroo, Rosene, Anderlik & Associates, inc. 01310-3 PROJECT ivL-\NAGEMENT AND COORDiNATION SECTION 01400 QUALITY REQUIREMENTS PART 1 - GE~'ERAL 1.01 SECTION INCLUDES A. Information required for conformance to regulatory requirements. B. Quality assurance. C. Procedures to measure and report the quality and performance of the work. 1.02 REFERENCE STA1~TIARDS A. \\'henever reference is made to the Minnesota Department of Transportation Specifications, such reference shall mean "Standard Specifications for Constmction," 2000 Edition (MnDOT Spec.) and all subsequent revisions and supplements. The word "Engineer" is understood to refer to the Engineer for the Owner. 1.03 SUbMITTALS A. Prior to start of work, submit testing laboratory name for various specified tests for approval by Engineer. B. Submit copies oflaboratory test results or analysis in consistent with Section 01310- Project Management and Coordination. C. Manufacturer's certificates of quality control or performance. 1.04 WORKL\1ANSHIP A. Comply with industry standards of the region, except where more restnctlve tolerances or specified requirements indicate more rigid standards, or more precise workmanship. 3'"--04-162 9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01400-1 QUALITY REQUIREMENTS 1.05 TESTS .L\1'ID INSPECTIONS A. Conform to the requirements of Article 13 of the General Conditions, except as modified herein. B. Notify Engineer 48 hours prior to expected time for operations requiring tests and inspections. C. Provide incidental labor and facilities to obtain and handle samples at Project Site, or source, transport samples to laboratory, facilitate tests and inspections for storing and curing of test samples. 1.06 LABORATORY REPORTS A. After each inspection and test, submit 3 copies of Laboratory Report to Engineer. B. Include: Date issued, project title and number, name of inspector, date and time of sampling or inspection, identification of product and Specifications Section, location in the Project, type of inspection or test, date of test, results of tests, and confoffi1ance \vith Contract Documents. 1.07 LABORATORY RESPONSIBILITIES A. Test samples and perform field tests. B. Provide qualified personnel. Cooperate with Engineer and Contractor in performance of services. C. Ascertain compliance with the requirements of the Contract Documents. D. vVhen requested by Engineer, provide interpretation of test results. 1.08 LIMITS ON TESTING LABORATORY AUTHORITY A. Laboratory may not release, revoke, alter, or enlarge on requirements of Contract Documents. B. Laboratory may not approve or accept any portion of the \',lork. C. Laboratory may not assume any duties of Contractor. D. Laboratory has no authority to stop work. 34-04-[62 (92004 Bonestroo, Rosene, Anderlik & Associates, lnc. 01400-2 QUALITY REQUIREMENTS 1.09 MA1~lJFACTURER'S CERTIFICATES A. If requested by Engineer, submit manufacturer's certificate with shop drawings, certifying that products meet, or exceed specified requirements executed by responsible officer. 1.10 MAN1JFACTURER'S FIELD SERVICES A. Provide qualified representative to observe field conditions; conditions of surfaces and installation; quality of workmanship; start-up of equipment; and test, adjust, and balance of equipment. PART 2 - PRODUCTS Not Used PART 3 - EXECUTION 3.01 MEASUREMENT Ai'<TI PAYMENT A. All work and costs of this Section shall be incidental to the Proj ect and included in the TOTAL BASE BID. Ei'<TI OF SECTION 34-0..!-162 'Q 2004 Bonestroo, Rosene, Anderiik & Associates, inc. 01400-3 QUALITY REQUiREMENTS SECTION 01500 TEMPORARY FACILITIES AND CONTROLS PART 1 - GENERAL 1.01 SECTION INCLUDES A. Temporary utilities and miscellaneous temporary facilities required during constmction. 1.02 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (MnDOT Spec.). B. The Minnesota Manual on Uniform Traffic Control Devices (MNfUTCD), including the Field Manual on Temporary Traffic Control Zone Layouts - Latest edition. PART 2 - PRODUCTS Not Used PART 3 - EXECUTION 3.01 MOBILIZATION A. Move personnel, equipment, materials, and all other items required to complete the work at the Project Site: 1. Multiple mobilizations will be required for the reclamation process. B. Establish Contractor offices, building, or other facilities necessary for \vork on the Proj ect. C. T emporaril y ho ld or relocate utili ties and any miscellaneous structures, such as signs, power poles, guy wires, and mailboxes disturbed. 34-04-162 .~ 2004 Bonestroo, Rosene, Anderiik & Associates, Inc. 01500-1 TEMPORA.RY FACILITIES AND CONTROLS 3.02 SIGNS, NLL\ILBOXES, ETC. REMOVAL AL~D REPLACEMENT A. Remove, store carefully, and replace all signs, posts, etc. that may be within the construction limits, as directed by Engineer. B. Remove existing mailboxes and posts, and temporarily install in locations determined by Engineer. Replace mailboxes prior to Substantial Completion. Removal, temporary reinstallation, and replacement shall occur such that mail delivery is not interrupted. Mailboxes, posts, and appurtenances damaged during construction shall be replaced with new at no charge to the Owner. 3.03 TEMPORARY UTILITIES A. Provide and maintain all temporary facilities, utilities, and controls as long as needed for the safe and proper completion of the work. Remove all temporary facilities, utilities, and controls as rapidly as progress will permit or as directed by Engineer. B. Temporary Water for Construction: 1. Use of new or existing hydrants is prohibited, except for testing and flushing of newly installed mains. 2. Obtain water for construction from locations designated by the Owner. 3.04 CONSTRUCTION F ACILITlES A. Sanitary Facilities: 1. Comply with all governing regulations, including safety and health codes for sanitary fixtures and facilities. 2. Provide self-contained toilet units, or water and sewer connected temporary toilet facilities, consistent with governing regulations. Contractor may not use Owner's toilet facilities. 3. Provide and maintain adequate supply of toilet tissue, paper towels, paper cups, and similar disposable materials appropriate for each facility. Provide appropriate covered waste containers for used material. 34-04-162 '.g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01500-2 TEMPORARY FACIliTIES AND CONTROLS 3.05 TEMPORARY CONSTRUCTION A. Pumping and Dewatering: 1. Provide draining, pumping, dewatering, and cleaning operations necessary to complete the work. 2. Provide all necessary pumping to remove all surface water and groundwater from structures as required for the work. Provide erosion control measures for discharge of water. 3.06 TRAFFIC CONTROL 3. Protect Project Site and adjacent property to avoid damage. A. Provide and maintain all traffic control devices needed to guide, warn, control, and protect traffic throughout the Project Site. All traffic control devices and other protective measures shall conform to M.iVfUTCD. B. Remove traffic control devices at the conclusion of the work. C. Flaggers are required to protect construction vehicles during unloading for construction materials. Conform to the requirements of the :fv.ITvfUTCD, the Flagging Handbook included in the Field Manual for Temporary Traffic Control Zone Layouts, and the fOllo\ving: \vhile on duty, flaggers shall wear hard hats and reflectorized florescent orange rests; and flaggers shall be fully clothed when on duty with shirt or blouse, slacks or trouser, and sturdy shoes. D. Field Quality Control: 1. Daily inspect and insure that all traffic control devices required by the construction are in accordance with the MMUTCD. Any discrepancy between the actual devices in use and the required devices shall be immediately rectified. 2. Furnish names, addresses, and phone numbers of at least 3 individuals responsible for the placement and maintenance of traffic control devices. At least 1 of these individuals shall be "on call" 24 hours per day, 7 days per \veek, during the time any traffic control devices furnished and installed by the Contractor are in place. 3. Provide access for emergency vehicles and busses to all residences at all times. 34-04. ! 62 :J::; 2004 Bonestroo, Rosene, Anderlik & Associates, inc. 01500-3 TE,'vIPOR.ARY FACU.ITIES ANTI CONTROLS 4. Respond to any request from the Engineer to improve or correct the usage of traffic control devices on or related to this Project within 1 hour of the time of notification. 5. Keep all traffic control signs and devices in a legible condition. This shall include, but not be limited to removing grime and dust deposited on any device by traffic, natural causes, or when requested by Engineer. 3.07 TEMPORARY BARRIERS Ai"\JTI ENCLOSURES A. Temporary Barriers: 1. Provide temporary covers, enclosures, markers, and barriers as necessary to protect work. 2. Damage to the Project Site caused by removal of temporary fencing, including postholes, shall be promptly repaired by Contractor. During removal, at no time, shall the work remain unattended if a dangerous condition exists because of incomplete removal or Project Site repairing. 3.08 MEASUREMENT A~1) PAYMENT A. A Bid Item has been provided for Mobilization. l'v'1easurement is Lump Sum. This will be considered payment in full for all work and costs if this Bid Item. The amount of the Lump Sum Bid: 1. Partial payment of the Lump Sum Bid Item "Mobilization" will be made using a percentage based on the following: Cumulative Percent of Mobilization Item Paid First Partial Payment Percent of original contract amount earned - 25 Percent of original contract amount earned - 50 Percent of original contract amount earned - 100 50 70 90 100 34-04-162 .~ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01500-4 TEMPORA.RY FACILITIES AND CONTROLS B. A Bid Item has been provided for Traffic Control. Measurement is Lump Sum. This will be considered payment in full for all work and costs if this Bid Item. The amount of the Lump Sum Bid: 1. Partial payment of the Lump Sum Bid Item "Traffic Control" will be made using a percentage based on the following: Cumulative Percent of Traffic Control Item Paid First Partial Payment Percent of original contract amount earned - 25 Percent of original contract amount earned - 50 Percent of original contract amount earned - 100 50 70 90 100 C. No Bid Item has been proved for Temporary Mailboxes. This "vork is considered to be incidental to the project. D. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. Ern) OF SECTION 34-04-162 '9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01500-5 TEMPORA.RY FACILITIES AND CONTROLS SECTION 01570 EROSION A1'ID SEDIMENT CONTROL PART 1 - GENERAL 1.01 SECTION INCLUDES A. Temporary measures to control soil erosion and sedimentation. 1.02 RELATED SECTIONS A. Section 02315 - Excavation and Fill. B. Section 02920 - Lawns and Grasses. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (MnDOT Spec.): 1. 1803 - Prosecution of Work. 2. 2573 - Temporary Erosion Control. 3. 3886 - Silt Fence. 4. 3891 - Inlet Protection. 5. Technical Memorandum No. 99-23-ENV-03 and Attachment. 6. Technical Memorandum No. 99-27-ENV-05. 7. Technical Memorandum No. 02-11-ENv-01. 8. Technical Memorandum No. 02-13-ENv-02. 9. Technical Memorandum No. 02-14-ENv-02. 10. Technical Memorandum No. 01-06-ENv-01. 11. Technical Memorandum No. 00-10-ENV-04. 12. Technical Memorandum No. 00-12-ENV-05. 13. Special Provisions S- 25. 34-04-162 ':9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01570-1 EROSION AND SEDIlvlENT CONTROL 14. Special Provisions S-249. 15. Special Provisions S-250. 16. Special Provisions S-252. . 17. Special Provisions S-264. 1.04 SUBMITTALS A. Erosion Control Plans: 1. Completed application form for the :tviPCA's General Storm Water Permit for Construction Activity. B. Certification and Sampling: 1. Furnish a manufacturer's certification stating that the material supplied conforms to the requirements ofthis Section. The certification shall include or have attached typical results of tests for the specified properties, representative of the materials supplied. 1.05 PERi\1ITS A. General: 1. This Project disturbs 1 or more acres of total land area, submit a completed application form for the MPCA's General Storn1 Water Permit for Construction Activity and the appropriate fees to the MPCA. Also, submit a copy of the completed, signed, and dated application form to Owner. Authorization to begin grading under the NPDES Permit is automatically granted 48 hours after the permit application has been submitted to the MPCA. 1.06 SEQlJENCING Al"lU SCHEDULING A. Conform to MnDOT Spec. 1803.5: 1. Submit for approval, the plan of operations for accomplishing temporary and permanent erosion control. 2. All temporary erosion control measures to be installed prior to any grading activities. 3. Permanent erosion control measures are to be installed when deemed appropriate during the grading process. 34-04-162 :9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01570-2 EROSION AND SEDUvIENT CONTROL 4. If the Contractor fails to install erosion or sediment measures, the Engineer may withhold payment from related work until the control measures are undertaken by the Contractor: a. \Vhen the Contractor fails to conduct the quality control program, doesn't conduct the inspection required in the N1>DES Permit, or fails to take action ordered by the Engineer to remedy erosion or sediment controi problems, the Engineer shall issue a Written Order to the Contractor. b. The Contractor shall respond within 24 hours with sufficient personnel, equipment, materials, and conduct the required work, or be subject to a $500 per calendar day deduction for noncompliance. B. Contractor is responsible for the establishment of permanent turfin accordance with Section 02920 - Lawns and Grasses to prevent excessive soil erosion. PART 2 - PRODUCTS 2.01 SILT FENCE A. Standard Silt Fence: 1. Geotextile Fabric: Woven wire fabric with the following physical properties: a. Grab Tensile Strength (ASTM D4632): 100 lb. b. Apparent Opening Size (ASTM D4751): #20 to 70 sieve. c. Width: 36 inches. d. Ultraviolet Resistance (ASTM D4355): 70 percent. e. Furnish geotextile with protective wrapping to protect the fabric from ultraviolet radiation and abrasion, due to shipping and handling. 2. Posts: 2 inch x 2 inch wood. 2.02 BALE CHECKS A. Type 1 mulch conforming to MnDOT Spec. 3882.2. B. All bales shall be either bound with wire or tied with nylon string. C. Hardwood stakes shall be 1-1/2 inch x 1-1/2 inch x 36 inches. 34-04-162 g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01570-3 EROSION AND SEDLvlENT CONTROL 2.03 STORJ.\1 DRAIN INLET PROTECTION A. Paved streets with concrete curb and gutter inlet protection: 1. Road Drain Curb and Gutter: Manufacturer: Wimco, LLC. 2. Silt Screen: Manufacturer: Alpine Stormwater Management. B. Non-paved surfaces without curb and gutter inlet protection: 1. Silt fence box. 2. Road Drain: Manufacturer: Wimco, LLC. 3. Erosion Control Shroud: Manufacturer: Royal i\nchor Systems, Inc. 4. Silt Sack: Manufacturer: ACF Environmental. 5. Verti* Pro as Manufactured by Alpine Stormwater Ivlanagement. C. Alternate Curb Inlet Protection Devices: 1. Eco Block. 2. Straw or Excelsior Wattle (8 inch minimum diameter). 3. Filter Compost Sock: Manufacturer: Filtrexx. 4. Rock Barrier: a. Clear Aggregate Only: 3/4 inch to 1-1/2 inch. b. Wire mesh and filter fabric. 5. Woven Type Sandbag Barriers conform to MnDOT Spec. 3893. 2.04 WATER FOR DUST CONTROL A. Apply water as directed by field Engineer, to prevent dust and \vind erosion. B. Confirm water source with Public Works contact Paul Coone. C. Do not use City hydrants without approval. 34-04-162 1;: 2004 Bonestroo, Rosene, Ander1ik & Associates, lnc. 01570-4 EROSION AND SEDITvIENT CONTROL PART 3 - EXECUTION 3.01 GEN'ERAL A. Conform to MnDOT Spec. 2573.3: 1. Minimize the amount of disturbed land that is susceptible to erosion. 2. Install the appropriate temporary erosion and sediment structural controls measures in accordance with approved sequence of construction. Clearing and grubbing operations shall be so scheduled and performed, so that grading operations and permanent erosion control features can follow immediately thereafter. 3. The slolrface area of erodible earth material exposed at 1 time by clearing and grubbing, by excavating, by fill, or by borrow shall not exceed 1/3 of the Project length without written approval of the Engineer. 4. Only disturb, clear, or grade areas necessary for construction. Delineate areas not to be disturbed: a. Exclude vehicles and construction equipment from these areas to preserve natural vegetation. 5. Maintain and preserve riparian and naturally vegetated buffer strips along water courses. 3.02 INSTALLATION A. Silt Fence: Conform to MnDOT Spec. 2573.3B3: 1. Silt fences shall be installed in the locations shown on the Drawings, using the machine sliced installation method. 2. If the silt fence is longer than 600 feet, it shall be constructed in separate independent units with each unit having a length less than 600 feet. All splices shall be avoided whenever possible: a. If necessary, splices vvill be made at an opposing fence post and according to the manufacturer's specifications. B. Storm Drain Inlet Protection: 1. Storm Drain Inlet Protection shall be installed at locations determined by the field engineer. 34-04- i 62 :g 2004 Bonestroo, Rosene, Anderlik & Associates. lnc. 01570-5 EROSION AND SEDl?vlENT CONTROL 2. Storm Drain Inlet Protection shall protect against sediment entering the storm sewer system until the bituminous base is paved, and areas stabilized. 3. The Contractor is responsible for cleaning any sediment, which may have entered storm sewer pipes, ponds, and adj acent properties at their expense. 3.03 MAINTENAl"'JCE A. Control dust blowing and movement on Project Site and roads, as directed by Engineer, to prevent exposure of soil surfaces, to reduce on and off Project Site damage, to prevent health hazards and to improve traffic safety. B. Acceptance of Work: Conform to MnDOT Spec. 2573.3.C. 3.04 MEASUREMENT .A..1\TD PA Yl\!IENT A. A Bid Item has been provided for Silt Fence. Measurement will be per lineal foot, along the base of the fence from outside to outside of the end posts for each section of fence. Payment will constitute compensation in full for all work and cost to furnish and install material in place, and to remove. B. A Bid Item has been provided for Storm Drain Inlet Protection. Measurement will be per each and shall include installing, cleaning, and any other maintenance of the device while in place. C. No Bid Item has been provided for Water for Dust Control. 'vVater used for the construction of the streets, dust control, or for turf establishment and maintenance will be considered incidental to the Project. D. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. E0i'D OF SECTION 34-04..162 (~ 2004 Bonestroo, Rosene, Anderlik & Associates, [nc. 01570-6 EROSION AND SEDlMENT CONTROL SECTION 01700 EXECUTION REQUIREMENTS PART 1 - GENERAL 1.01 SECTION INCLUDES A. Requirements for overall execution of the work and closeout of the Contract for Final Payment. 1.02 SlJBMITTALS A. Submit the following items consistent with the Conditions of the Contract and Division 1 - General Requirements Sections: 1. Record Documents, Written Notification of Substantial Completion, Executed Certificate of Substantial Completion, Written Notification of Final Completion, Spare Parts, Operation and Maintenance Manuals, instructions, schedules, warranties, guarantees, Bonds, certificates, certificates of inspection, and other documents. 2. Final Application for Payment, including accompanying documentation IC-134 Form. PART 2 - PRODUCTS Not Used P.;\RT 3 - EXECUTION 3.01 EXAi\1INATION A. Acceptance of Conditions: By commencing work, Contractor construes acceptance of the adjacent work as satisfactory to receive subsequent work. B. Existing Conditions: Before commencing work, inspect work completed by others that is adjacent to work. If adjacent conditions prevent completion of work, Contractor will not commence work until the conditions are corrected. C. Inspect each product immediately prior to installation. Remove damaged products from Project Site. 3.1-04-162 ..]; 2004 Bonesrroo, Rosene, Ander!ik & Associates, lnc. 01700-1 EXECUT10N REQUlREMENTS 3.02 GENERAL INSTALLATION REQUIREMENTS A. Comply with the manufacturer's instructions for installation of manufactured products to the extent that these instructions are applicable and more explicit, or more stringent than requirements indicated in the Contract Documents. B. Secure work true to line and level, within recognized industry tolerances, with anchorage devices designed and sized to withstand stresses, vibration, and rocking. Allow for expansion and movement of building. C. Install each element of work during weather conditions and Project status to ensure coordination of the work. Isolate each element of work from incompatible work, as necessary to prevent deterioration. D. Record installation details and prepare Record Documents consistent with the General Conditions. 3.03 PROJECT SITE MAINTENAl'fCE A. Maintain stockpiles, excavations, access roads, and all other vvork areas free from dust. Employ dust abatement techniques whenever a dust nuisance or hazard occurs, or as directed by Engineer. Comply with local ordinances. B. Protect hazardous work areas and hazardous material storage areas. C. Protect trees unless specifically indicated on Drawings. D. Clean access roads and haul routes with mechanical street sweeper. E. If Contractor fails to maintain Project Site, Engineer will provide Written Notice of Contractor's defective work. Contractor will be given 12 hours from the Notice to clean Project Site. After the 12 hour period, Owner may correct the defective work consistent with Article 13.09 of the Conditions of the Contract. 3.04 CLEANlNG Al"-iTI PROTECTION A. Clean and protect work in progress and adjoining vvork during handling and installation. Apply protective covering on installed \-vork, w'here it is required to ensure freedom from damage, or deterioration. B. Clean and perform maintenance as frequently as necessary throughout construction period. Adjust and lubricate operable components to ensure operability without damage effects. 34-04-162 ::g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 01700-2 EXECUTION REQUIREMENTS 3.05 CUTTING Al'ID PATCHING A. Complete all cutting, fitting, and patching as necessary to join the new work to existing conditions. B. Remove, or cut existing work only as necessary to join the new work to the existing construction, or as required by the Contract Documents. C. Patch defective and incomplete surfaces caused, or exposed by work of the Project. D. Repair any damage to existing conditions and patch to match. E. Existing construction designated by the Contract Documents to remain that is loosened, cracked, or otherwise damaged, or defaced beyond repair as a result of work by the Contractor, will be considered unsuitable for the use intended, and shall be removed and replaced by the Contractor. 3.06 CERTIFICATE OF COMPLLA1"JCE WITH MIN~tSOTA STATUTES 290.92 & 290.97 A. Upon completion of the Project, and prior to Final Payment, the Contractor and all subcontractors shall complete Minnesota Department of Revenue Revised Form IC-134. This form, Affidavit for Obtaining Final Settlement of Contract with the State of Minnesota and any of its Political or Governmental Subdivisions, is to be signed by a Department of Revenue representative and forwarded to the Owner. Copies of this form can be obtained by writing to the Minnesota Department of Revenue, Forms Section, Centennial Office Building, St. Paul, Minnesota 55145, or calling (651) 297-3737. 3.07 MEAS1.JREMENT Al'\JU PAYNfENT A. A Bid Item has been provided for Motor Grader with Operator. Measurement will be by units of hours. B. A Bid Item has been provided for Street Sweeper with Operator. Measurement will be by the units of hours. C. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. E~'D OF SECTION 34-04-162 9 2004 Bonestroo, Rosene, Anderiik & Associates, lnc. 01700-3 EXECUTION REQUIREMENTS SECTION 02108 FULL DEPTH RECLAl\1ATION PART 1 - GENERi\L 1.01 SECTION INCLUDES A. Reclamation of the existing bituminous surfacing. 1.02 RELATED SECTIONS A. Section 02318 - Subgrade Preparation. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (MnDOT Spec.): 1. 2112 - Subgrade Preparation. 1.04 SEQtJENCING AND SCHEDULING A. Compaction of the reclaimed material by rubber-tired roller IS required immediately following the reclamation process. B. Subgrade preparation and tolerancing of the reclaimed material will immediately follow the reclamation process. C. Access to all residents is to be maintained to the best ability of the Contractor during the reclamation and tolerancing process. Pi\RT 2 PRODUCTS Not Used PART 3 - EXECUTION 3.01 G ENnR..A.L A. Create an aggregate base course composed of the existing bituminous pavement, bituminous curb, and existing Class 5 gravel base. Full depth of existing bituminous pavement shall be mixed \vith 4 inches of existing Class 5 gravel base to form aggregate base. 34-04-162 <1J 2004 Bonestroo. Rosene. Anderlik & Associates, Inc. 02108-1 FULL DEPTH RECL~'vlA TiON 3.02 PREPARATION A. The Contractor is to provide a 48 hour notice prior to beginning the reclamation process. 3.03 EQUIPMENT A. Contractor to notify the Engineer of the equipment to be used at the preconstnlction conference: 1. Equipment to be hydrostatically driven. 2. Computerized operation controls. 3. Capable of cutting up to a 12 inch depth in 1 pass. 3.04 THICKl"JESS REQUIREMENTS A. Typical Reclaimed Section: 1. Consists of approximately 2 inches of eXlstmg bituminous mat and bituminous curb and 5 to 6 inches of existing Class 5 gravel base. 2. Rotating cutter drum to operate parallel to the existing road surface, providing a uniform 4 to 8 inch section across the entire roadway. 3. The reclaimed depth is anticipated to be 6 inches, however, if variations occur the depth shall be between 4 inches and 8 inches. 3.05 MEASlJREl'v'1ENT AND PAYMENT A. A Bid Item has been provided for Full Depth Reclamation. rvleasurement will be by the square yard, based on the width of the existing street: 1. Payment for leveling and compaction of the material immediately after it is reclaimed is to be included in the Bid Unit Price per square yard. 2. The Bid Unit Price is to include the motor grader and any water necessary to maintain the street until paved. B. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. E~1J) OF SECTION 34-04-162 !~ 2004 Bonestroo. Rosene. Ander!ik & Associates. Inc. 02108-2 FULL DEPTH REC LA:'v1 A TION SECTION 02225 REMOVALS. PART 1 - GEN"ERAL 1.01 SECTION INCLUDES A. Complete or partial removal and disposal, or salvage of at grade, above grade, and below grade stmctures and miscellaneous items. 1.02 RELATED SECTIONS A. Section 02315 - Excavation and Fill. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Constmction," 2000 Edition (MnDOT Spec.): 1. 2104 - Removing Pavement and Miscellaneous Stmctures. 1.04 DEFIN1TIONS A. Remove: To take away or eliminate from the Project Site by any method selected by the Contractor, including disposal of material. B. Salvage: To dismantle, disassemble, or remove carefully without damage so the item can be re~assembled, replaced, or reused in a workable condition equal to that existing before removal. C. Abandon: To fill, bulkhead, or close offpipes and stmctures so that no settlement or flow can occur. 1.05 REGULATORY REQUIREMENTS A. Conform to MnDOT Spec. 2104.3.C, with the following modifications: 1. All materials designated for removal shall be disposed of outside the Project Site at locations to be selected by the Contractor. 2. All materials designated for salvage shall be stockpiled or temporary stored on sites to be provided by the Contractor. 34-04-162 !~ 2004 Bonestroo, Rosene, Anderiik & Associates, inc. 02225-1 REMOVALS 1.06 PROJECT SITE C01\TDITIONS A. This work consists of removing the eXlstmg pavement, curb and gutter, SignS, mailboxes, and other miscellaneous items within the Project Site. 1.07 SCHEDULING A. Prior to starting \vork, submit for review by the Engineer and approval by the Owner, a schedule showing the commencement, order, and completion dates of the various parts of this work. B. Fill holes or depressions resulting from removal or salvage immediately. C. Provide temporary surface restoration for traffic continuity where removal or salvage operations are completed within streets, driveways, or parking lots. PART 2 PRODUCTS Not Used PART 3 - EXECUTION 3.01 GENERAL A. Dispose of all items removed, except for those items identified to be salvaged or recycled. Said disposal shall be in accordance with all laws, regulations, statutes, etc. B. Perform removal work w'ithout damage to adjacent retained work. vVhere such work is damaged, the Contractor shall patch, repair, or otherwise restore same to its original condition at no expense to the Owner. C. Remove debris from the work area as often as necessary, but not less than at least once at the end of each \vorkday. Debris shall be placed in approved containers to prevent the spread of dust and dirt. D. Execute the work in a careful and orderly manner with the least possible disturbance to the public and occupants of buildings. E. Fill holes resulting from removals consistent \vith Section 02315 - Excavation and Fill. 34-04-162 9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02225-2 REMO\'ALS 3.02 EXAL\1INATION A. Meet with owners of signs to determine requirements for salvage, storage, and replacement. B. Develop plan acceptable to Engineer and postal service for maintaining mail service. Temporary relocations of mailboxes will be necessary. 3.03 PROTECTION A. Take all necessary precautions to adequately protect personnel and public and private property in the areas of work. All Project Site fencing shall be in place prior to the start of any removal work. B. All street signs, traffic control signs, guy wires, mailboxes, posts, wood fence, etc. which may interfere with construction shall be removed, stored safely, and replaced. C. Approved barriers or warning signs shall be provided as necessary. D. Provide and maintain temporary protection of existing structures designated to remain where removal \vork is being done, connections made, materials handled, or equipment moved. E. Do not close or obstruct walkways or roadways. Do not store or place materials in passageways or other means of egress. Conduct operations with minimum traffic interference. F. Take reasonable precautions to limit damage to existing turf. G. Holes or depressions created by removals shall not be left open for more than 1 day. Any hole within 10 feet of sidewalks shall be filled, suitably marked, or covered immediately. H. Avoid disturbance to any material beyond the limits required for new construction. 3.04 SAvVINGPAVEMENT A. Concrete Pavement: Saw' along the removal line to a depth of 1/3 of the thickness of the concrete prior to breaking off the pavement. B. Bituminous Pavement: Saw along the removal line to a minimum depth of3 inches prior to breaking off the pavement. 34-04-162 :Q 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02225-3 REMOVALS 3.05 REMOVE CONCRETE PAVEMENT A. Remove in accordance with MnDOT Spec. 2104.3.B, except as modified below. B. Sawcut concrete pavement and concrete base prior to mechanical pavement removal equipment. Remove concrete in such a manner that the remaining pavement is not damaged. C. Prior to restoring trench areas, the edges of the trench shall be trimmed back to a vertical face on a straight line \vhich is parallel with the centerline of the trench. 3.06 REMOVE BITillvlINOUS PAVEMENT, PATH, DRIVEWAY A. Remove in accordance with MnDOT Spec. 2104.3.B, except as modified below. B. Savvcut bituminous pavement at the removal limits prior to that removal, unless otherwise approved by the Engineer. C. Prior to restoring trench areas, the edges of the trench shall be trimmed back to a vertical face on a straight line which is parallel with the centerline of the trench. 3.07 REMOVE CURB AND GUTTER A. Sawcut at removal limits. B. Concrete Curb and Concrete Curb and Gutter: Do not disturb any material beyond the limits required to form for new construction (assumed 12 inches maximum from the back of new \vork and 6 inches beyond the edge of new driveways). 3.08 PAVEMENT MILLING A. Bituminous: 1. Sawcut at removal limits prior to milling process. 2. Mill bituminous surface to the depth specified as shown on the Drawings, or as directed by the Engineer. 3. Edge mill bituminous surface 6 to 8 feet wide as specified on the Dra\vings, or as directed by the Engineer. 3.l-04-162 '&: 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. 02225-4 REMOVALS 3.09 REMOVE CONCRETE SURFACING A Work includes sidewalks, pedestrian ramps, medians, and driveways. B. Sawcut concrete surfacing prior to removal. C. Remove concrete in such a manner that the remaining surfacing is not damaged. D. vVhen removing existing sidewalks, the Contractor shall not disturb any material beyond the limits required for new construction (assumed as 6 inches maximum beyond and 8 inches maximum below existing grade). E. When removing existing driveways, the Contractor shall not disturb any material beyond the limits required to form for new construction (assumed 12 inches maximum from the back of new work and 6 inches beyond the edge of new driveways). F. Prior to restoring trench areas, the edges of the trench shall be trimmed back to a vertical face on a straight line which is parallel with the centerline of the trench. 3.10 REMOVE BITlTMINOUS SlJRFACING A Work includes pathvvays and drivevvays. B. Sawcut bituminous surfacing to full depth at the limits of partial removal prior to that removal, unless otherwise approved by the Engineer. C. Remove bituminous in such a manner that the remaining surfacing is not damaged. D. Prior to restoring trench areas, the edges of the trench shall be trimmed back to a vertical face on a straight line which is parallel with the centerline of the trench. E. When removing existing pathvvays and driveways, the Contractor shall not disturb any material beyond the limits required to form for new construction (assumed 12 inches maximum from the back of new work and 6 inches beyond the edge of new driveways). 3.11 REMOVE MAl'\,T}{OLES Al"TI CATCHBASINS A. Remove all sections of the structure, including the base slab. 34-04-\62 :Q 2004 Bonestroo, Rosene, Anderlik & Associates, inc. 02225-5 REMOVALS 3.12 REMOVE SECTIONS OF EXISTING PIPE A. Pipes to be abandoned shall be bulkheaded with brick, non-shrink concrete grout 8 inches thick at the upstream and downstream ends. B. Pipe to be abandoned shall be filled with suitable material as directed by the Engineer. C. Pipe to be abandoned shall be removed if the top of pipe is within 3 feet of final surface elevation. 3.13 SALVAGE Al'ID REINSTALL A. Signs: 1. In no case shall a traffic sign or street sign be removed or disturbed by Contractor without prior notification being given to Engineer, and then only after satisfactory arrangements have been made for a temporary installation or its disposition: a. Street identification signage shall be maintained at all times due to its importance to the 911 Emergency Response System. 2. Remove and salvage all posts, A-frame angle brackets, stringers, as well as the nuts, bolts, and washers. 3. Exercise reasonable care against damage to in-place signs during storage and installation. 4. Remove signs damaged during construction and replace \vith new signs. B. Mailboxes: 1. Remove and salvage existing mailboxes that interfere with the work or whose access is restricted by the construction activities. 2. Place at temporary locations as directed by Engineer, or as shown on Dra-vvings. 3. Removal, temporary re-installation, and replacement shall occur such that mail delivery is not intemlpted. 4. Reinstall in locations as shown on Drawings or as directed by Engineer. 5. Mailboxes, posts, and appurtenances damaged during construction shall be replaced with new at no charge to Owner. 34-04-162 9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02225-6 REMOVALS C. Fences: 1. Salvage and store fence and post material where they are in conflict with the. work. 2. After completion of work, reinstall fence to the condition existing prior to removal. 3. Install temporary snow fence or similar barrier at the end ofthe working day while the permanent fence is removed. 3.14 FIELD QUALITY CONTROL A. Salvaged items to be reinstalled shall be of the same shape, dimension, location, and quality of the original item prior to construction. B. Items damaged during removal, or salvaging operations shall be replaced vvith new material of equal type and quality of the damaged item when it was new. 3.15 DISPOSING OF MATERIAL A. Dispose of all materials outside of the Project Site at disposal site selected by Contractor, in compliance with state and local regulations. Burying of material and debris is not allowed within the Project Site. 3.16 MEASUREMENT Al"Jl) PAYMENT A. Bid Items have been provided for Removal Items. Payment at the Bid Unit Price will be considered compensation in full for all \vork necessary to complete the Bid Item in full, including removal, salvage, storage, disposal, and reinstallation. B. Measurement will be based upon the units as listed below for items removed, abandoned, or salvaged complete as specified. No measurement will be made of any removals that are not required. The actual quantity removed multiplied by the appropriate Bid Unit Price will be compensation in full for all work and costs of the following Bid Items: 1. Saw Bituminous Pavement: Per lineal foot along the saw cut line as staked. Sawing Bituminous Driveway Pavement is incidental and shall be included in the Remove Bituminous Driveway Pavement Bid Item. 2. Remove Bituminous Pavement: Per square yard of bituminous pavement removed, regardless of thickness. 34-04-162 ':9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02225-7 REMOVALS 3. Remove Bituminous Driveway Pavement: Per square yard, without regard to thickness, including integral bituminous curb. 4. Remove Concrete Driveway Pavement: Per square yard, without regard to thickness. 5. Remove Concrete Curb and Gutter: Per lineal foot of the type specified. 7. Remove Storm Structure: Per each. 8. Remove Storm Sewer Pipe: Per lineal foot, regardless of size or type, measured from center of junction fittings, catch basins, or manholes, and will include the length of any aprons. 9. Remove Water Main: Per lineal foot, regardless oftype or size. 10. Remove Fence: Per lineal foot of the type specified. 11. Remove Bituminous Pavement: per square yard. C. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. E:N'D OF SECTION 3J.-04-162 ~ 200J. Bonestroo, Rosene. Anderlik & Associates. Inc. 02225-8 REMOVALS SECTION 02280 ADJUST MISCELLA1'ffiOUS STRUCTURES PART 1 - GENERAL 1.01 SECTION INCLUDES A. Adjustment of utility structures. 1.02 RELATED SECTIONS A. Section 02510 - Water Main. B. . Section 02630 - Storm Drainage. C. Section 02740 Plant Mixed Asphalt Pavement. 1.03 REFERENCES A. American Society of Testing and Materials (ASTM): 1. A48 - Specification for Gray Iron Casting. 2. A240 - Specification for Heat - Resisting Chromium - Nickel Stainless Steel Plate Sheet and Strip for Pressure Vessels. 3. C6 - Specification for Normal Finishing Hydrating Lime (Mortar). 4. C141 - Specification for Hydraulic Hydrated Lime for Structural Purposes (Mortar). 5. C 150 - Specification for Portland Cement (Concrete Rings!JVlortar). 6. C923 - Specification for Resilient Connectors Bet\veen Reinforced Concrete Manhole Structures, Pipes, and Materials. 7. F593 - Specification for Stainless Steel Bolts, Hex Cap Screw's, and Studs. 8. F594 - Specification for Stainless Steel Nuts. 34-04-162 :9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02280-1 ADJUST MISCELLANEOUS STRUCTURES B. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (rvlnDOT Spec.): 1. 2506 - Manholes and Catch Basins. 2. 3733 - Geotextiles. 1.04 DEFINITIONS A. Remove and Replace Casting: The process of removing the existing casting from an existing structure and placing a new casting on manholes and catch basins. B. Adjust Frame and Ring Casting: A change in rim elevation accomplished for manholes or catch basins through the addition or removal of adjustment rings only. Adjustment does not include the addition or removal of sections from the structure. C. Adjust Valve Box: A change in elevation of the top of the valve box accomplished through the raising or lowering of the existing top section of the valve box only. Adjustment does not include the addition orremoval of sections from the valve box. D. Remove and Replace Adjustment Rings: The process of removing the existing concrete adjustment rings from an existing structure and placing new rings on manholes and catch basins. 1.05 SEQlJENCING AND SCHED1JLING A. Contractor, Engineer, and Owner shall inspect all existing structures pnor to beginning construction. B. Owner will remove any foreign material found in the existing structures prior to construction. Contractor is responsible for removing any foreign material that enters the structures during construction. PART 2 - PRODUCTS 2.01 ADJUSTING RING A. Concrete: 1. Size to match cone or opening in top slab. 2. Concrete Compressive Strength: Minimum 3000 psi. 3. Reinforcing: Single hoop 8 gauge steel wire. 4. Thickness: Minimum 2 inches, maximum 4 inches. 34-04-162 (9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02280-2 ADJUST (I,!lSCELLANEOUS STRUCTURES 2.02 ADHESION MATERIALS A. Ram-Nek material, or approved equal. B. Mortar: 1. Standard Portland Cement: Type I, ASTM C1S0. 2. Normal Finishing Hydrated Lime: ASTM C6. 3. Hydraulic Hydrated Lime for Structural Purposes: ASTM C141. 4. Mix Proportions: 1 part cement to 3 parts mortar sand; lime may be added to mixture: maximum amount 15 percent by volume. 2.03 HYDRA1'\JT EXTENSIONS A. Sections: Match existing hydrant manufacturer and model. 2.04 CASTINGS A. Manhole, Catch Basin Frames, and Covers: 1. Requirement: ASTM A48. 2. Material: Class 35 cast iron. Best grade. Free from injurious defects and flaws. 3. Finish: Coal tar pitch varnish. 4. Finish Preparation: Sandblast. 5. Machine cover and frame contact surface for non-rocking protection. 6. Type and Style: l\'EENAH R1642, Type "B" Lid, or approved equal, for sanitary and storm seVier manholes, and :NeENAH R3067, TYVe "V" Grate, or approved equal, for storm sewer catch basin manholes and catch basins. Covers without grate openings stamped with "SANITARY SEWER," or "STORivI SEWER" as appropriate. Use 2 inch letters. 34-04-l62 "9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02280-3 ADJUST MISCELL\NEOUS STRUCTURES PART 3 - EXECUTION 3.01 GENERAL A. The necessary vertical alignment will be determined by the Engineer and generally as indicated on the schedule of adjustments. B. "Nhere existing frame is within 0.10 feet of grade, no adjustment is to be made, unless the structure is in the street. C. The frame shall be raised or lowered to match the street or gutter. D. Protect existing structures from damage. E. Prevent sand, concrete, or any other debris from entering the structures. 3.02 PREPARATION A. Call utility owners to field mark their utility locations. B. Contractor to verify exact location of existing utilities. 3.03 ADJUST FRA.lvIE Al~1) RING CASTING A. Remove all dirt, debris, dust, and other deleterious material from surface prior to placement of first adjusting ring. B. Concrete Adjusting Ring: 1. Mortar on top and bottom surfaces of all concrete adjusting rings; betvveen surface of top slab or cone and bottom ring; betvveen surface of top ring and casting; on entire surface of area of ring with no gaps: a. Mortar Thickness: 1/4 to 1/2 inch. 2. No shims of any material allowed. .., :Y. Required cross slope of casting to be achieved by varying thickness of mortar. 4. Do not plaster the inside surface of rings. 5. Wipe clean all excess mortar from the joints inside all rings and frame. 6. Remove all mortar spills from the structure. 7 I. Minimum of2, maximum of 5 adjusting rings allo\ved. 34-04-162 ,~ 2004 Bonestroo, Rosene, Anderlik & Associates, inc. 02280-4 ADJUST MISCELL\NEOUS STRUCTURES 8. Use a 6 inch ring where applicable. 3.04 REMOVE Al"JD REPLACE CASTING A. Remove and dispose of frame and casting as indicated on the Drawings. B. Place new adjustment rings conforming to Paragraph 3.03 - Adjust Frame and Ring Casting. C. Install new frame and casting. D. Patch road to match existing pavement section. E. Dispose of removed material off the Project Site. 3.05 FIELD QUALITY CONTROL A. For adjustments made within bituminous surfaced areas, any settlements of the bituminous surface greater than 3/8 inch below the rim of the adjustment stmcture will require removal and replacement ofthe bituminous surfacing at the Contractor's expense. B. Secure manholes and stmctures inm1ediately after completion or before suspension of operations at the end of working day with castings or suitable alternative device, C. Adjust Manholes and Catch Basin Frames 1/8 inch to 3/8 inch below grade prior to placing the final wear course. Thorough tamping ofthe material around manhole and catch basin frames is required. INhere existing frame is within 0.10 feet of grade no adjustment is to be made, unless the frame is in the street. In such cases the crown or gutter shall be either lo\vered or raised, as the case may be, to put the street and frame - at the same grade. D. Adjusted frame upward with standard concrete adjustment rings of the same size as the cone or slab opening. Place each adjustment ring and frame in a full mortar bed. Adjusting rings needed to raise the casting to grade shall be incidental to the adjustment pay item. E. Adjust frame dow'nward by removing the necessary number of adjustment rings from the structure and resetting the frame in a full mortar bed to grade. 34-04-162 9 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. 02280-5 ADJUST MISCELLANEOUS STRUCTURES F. Regardless of the direction of adjustment, no shims of any material will be allowed. The minimum thickness of all mortar joints shall be at least 1/4 inch with a maximum allowable thickness of 1/2 inch. All excess mortar from the joint shall be wiped clean from the inside of all rings and frame. All manhole castings must be replaced prior to the placing of the final wear course. G. Adjust valve boxes to 1/8 inch to 3/8 inch below grade prior to placing the final wear course. Thorough tamping of the material around the valve box is required. All valve boxes are the sectional screw-threaded adjustable type. 3.06 METHOD OF MEASlJREMENT Ai~"D PAThIENT A. Bid Items have been provided for various adjustments. Payment at the Bid Unit Price for all items is considered compensation in full for all materials and \vork required to furnish and install the Bid Item in place. B. Remove and Install New Casting (For Each Type Specified): Measurement will be by each type of frame removed and replaced. C. Adjust Frame Ring and Casting: Measurement will be by each. D. All other \'lork and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. EN"D OF SECTION 34-04-162 '9 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. 02280-6 ADJUST MISCELLANEOUS STRUCTURES SECTION 02315 EXCA V A TION A..i'ID FILL PART 1 - GENERi\L 1.01 SECTION INCLUDES A. Excavation and fill for roadways and other areas. 1.02 RELATED SECTIONS A. Section 02225 - Removals. B. Section 02318 - Subgrade Preparation. C. Section 02320 - Trench Excavation and Backfill. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction,;' 2000 Edition (MnDOT Spec.): 1. 2105 - Excavation and Embankment. 2. 3149 - Granular Material. 1.04 SD13MITTALS A. Submit the Following Items: 1. Gradation tests for borrow materials. 1.05 DEFINITIONS A. The definitions of the different classifications of excavation and borrow material shall conform to MnDOT Spec. 2105.2, or as moditled herein: 1. Grading Grade: Bottom of the aggregate base as shown on the Drawings. ') Common Excavation: Will include all excavation below the grading grade. Other excavations directed by the Engineer, such as subgrade excavation, shall be included as common excavation. 34-04-162 rQ 2004 Bonestroo, Rosene. Anderlik & Associates. Inc. 02315-1 EXCAVATION AND FILL 1.06 QUALITY ASSURAl"TCE A. Assist testing laboratory by excavating for density tests. Assist testing laboratory with obtaining material samples. 1.07 SEQUENCING AJ.'ID SCHEDULING A. Perform excavation as soon as possible after water construction. B. Complete subgrade for streets, driveways, walks, and parking lots immediately after trench backfill and compaction. PART 2 - PRODUCTS 2.01 MATERIALS A. Select Granular Borrow: 1. Conform to MnDOT Spec. 3149.2.B2. B. Salvaged Aggregate: 1. Conform to MnDOT Spec. 3149.2.C. PART 3 - EXECUTION 3.01 GENERl\L A. Conform to MnDOT Spec. 2105.3A, or modified herein: 1. Establish traffic control prior to excavations. 2. Establish the specified erosion control devices according to Section 01570 - Erosion and Sediment Control prior to all excavations. 3. Notify utility companies of progress schedule so they can accomplish relocations, removals, and holding of lines. 4. Perform removals consistent with Section 02225 - Removals. 34-04-162 '9 2004 Bonestroo, Rosene. Anderlik & Associates, Inc. 02315-2 EXCA VA nON AND FILL 3.02 PREPARATION OF EMBl\l~1Z.L\tlENT A. Conform to MnDOT Spec. 2105.3B, or as modified herein: 1. Engineer's approval is required of all areas where preparation work has been performed prior to the placement of the embankment or fill material. 2. \-Vhere embankment is to be constructed over swamp, marsh, or other locations where the foundation material is unstable, the foundation shall be excavated to remove all or part of the unstable material. 3.03 EXCAVATION OPERATIONS A. Conform to MnDOT Spec. 2105.3C, or as modified herein: 1. Perform excavations to the alignment, cross section, and grade as shown on the Drawings and staked by the Engineer. 2. Excavation of unstable material below grade shall be done under the direction of the Engineer as the subsurface conditions are disclosed. 3. Remove muck excavation material by utilizing a backhoe, so as to minimize disruption to the bottom of the excavation. 4. No solid rock vvill be allowed within 12 inches of the subgrade. 5. Cut, fill, and grade Project Site to elevations and contours shown on the Drawings with allowances for pavements, topsoil, and structures. 6. Grading temporary swale for drainage shall consist of excavating material to specified elevation by engineer. All soils generated from excavation shall be stored on regional pond site. 3.04 DISPOSITION OF EXCAVATED MATERIAL A. Conform to ~!lnDOT Spec. 2105 .3D, or as modified herein: 1. Strip topsoil consistent with Section 02230 - Site Clearing. 2. No disposition of bituminous millings will be permitted, unless thoroughly mixed with other Project Site materials. 3.05 PLACING EMBA:0.TK:.\;IENTS A. Conform to MnDOT Spec. 2105.3E, or as modified herein: 1. Topsoil placement shall conform to Section 02920 - Lawns and Grasses. 34-04-162 :j;; 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. 02315-3 EXCAVATION AND FILL 3.06 COMPACTING EMBANKl\;lENTS A. Conform to MnDOT Spec. 2105 .3F, or as modified herein: 1. Compaction required for embankment materials shall conform to the Specified Density Method with the testing location and rates being determined by the Engineer. 3.07 FINISH OPERATIONS A. Conform to MnDOT Spec. 2105 .3G, or as modified herein: 1. Finish grading of sub grade prior to placement of an aggregate base course shall conform to the following tolerances: a. Not vary by more than 0.05 feet above or below the prescribed elevation at any point where a measurement is made. 2. Finish grading of select granular borrow for sub grade prior to placement of an aggregate base course shall conform to the follo\ving tolerances: a. Not vary by more than 0.1 0 feet above or below the prescribed elevation at any point where a measurement is made. b. Sub grade to be completed and approved by the Engineer prior to installation of select granular borro\v. 3. Grading of the soils beneath the proposed topsoil shall be revie\ved and approved by the Engineer prior to the start of the topsoil placement. 3.08 MEAS1JREMENT Af-,1) PAYNIENT A. Bid Items have been provided for Various Excavation Materials, Borrow Materials, and Salvage Materials. Measurement and payment shall be at the Bid Unit Price, consistent with MnDOT Spec. 2105.4 and 5, except as modified in the following. B. Payment for Common Excavation (P) at the Bid Unit Price shall be compensation in full for removal of material, hauling, disposal, placement in an embankment, compaction, disking, harrowing, blading, grading, shaping, preparation of sub grade, and all miscellaneous items associated \'lith the work. The basis of payment for Common Excavation items shall be by planned quantity of material to constmct the street section in accordance \vith the plan. 34-0.1-162 ~ 2004 BonestToo, Rosene, Al1derlik & Associates, Inc. 02315-4 EXCA VA TION AND FILL C. A Bid Item has been provided for Select Granular Borrow (CV). Select Granular Borrow shall be paid for by the number of c.y. compacted in place and calculated from design widths, depths, and lengths. If the material is furnished by the Contractor, it must meet all material requirements, and payment shall include furnishing, placing, compacting, and shaping the material and all miscellaneous items associated with the work. D. A Bid Item has been provided for Swale Excavation. Measurement shall be by lump sum. Payment shall be considered compensation in full for all time and materials required for this work. D. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. EN'D OF SECTION 34-04-162 :id 2004 Bonestroo. Rosene, Anderlik & Associates. lnc. 02315-5 EXCA VA TION AND FILL SECTION 02318 SlJBGRADE PREPARATION PART 1 - GENERAL 1.01 SECTION INCLUDES A. Grading, shaping, and compacting sub grade prior to placing a base or surface course. 1.02 RELATED SECTIONS A. Section 02315 - Excavation and Fill. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition, (MnDOT Spec.): 1. 2105 - Excavation and Embankment. 2. 2111 - Test Rolling. 3. 2112 - Subgrade Preparation. 1.04 SEQUENCING Al'ID SCHEDULING A. Subgrade preparation shall be performed prior to placement of the select granular barrow or aggregate base material. PART 2 - PRODUCTS Not Used PART 3 - EXECUTION 3.01 GEN'ERAL A. Sub grade preparations shall be performed to produce the required density, grade, and cross-section. B. There will be approximately 6-7 inches of existing Class 5 under the interim bituminous mat in the prior to final paving. The reclaimed material is expected to produce approximately 2 inches of additional gravel base. The final section shall include 8 inch of Class 5. Removal of excess or addition of Class 5 aggregate may be required to meet Section requirements. 34-04-162 ':9 2004 BonestToo, Rosene, Anderlik & Associates, Inc. 02318-1 SUBGRADE PREPARA TIOM 3.02 PREPARATION A. Inspection of subgrade by test rolling conforming to MnDOT Spec. 2111, or as modified herein: 1. The equipment used for test rolling shall be a Tandom Truck with a gross weight of 45,000 pounds. 2. The road bed will be considered unstable if yielding and rutting is greater than 1-1/2 inch. 3.03 COMPACTION A. Conform to MnDOT Spec. 2105.3Fl, or as modified herein: 1. For the Specified Density Method, the Engineer will sample and test the soils to determine the Maximum Density and Optimum Moisture. 2. Density and moisture tests will be taken on the compacted subgrade at the location and testing rates designated by the Engineer. Nuclear density testing shall be considered an approved method. 3.04 FINISH OPERATIONS A. Subgrade tolerance shall conform to MnDOT Spec. 2105.3G, or as modified below: 1. Not vary by more than 0.05 feet above or below the prescribed elevation at any 1 point where a measurement is made. 3.05 MEASlJRErv'1ENT A.l\1) PAYMENT A. A Bid Item has been provided for Subgrade Preparation. Measurement shall be by the units of square yards and shall be based on a width between the front edge of the curb and gutter: 1. Payment at the Bid Unit Price shall include all costs related to performing the work in accordance with these Specifications, including shaping, grading, compacting, tolerancing, and test rolling. 2. Payment will be made once per square yard for the entire Project duration. 3. Payment at the Bid Unit Price shall include all costs related to moving any excess material around the Project Site, to be used on the Project. 34-04-162 :g 2004 8onestToo, Rosene, :\nder!ik & Associates, Inc. 02318-2 SlTBGRADE PREPAR.A. TION B. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. EJ\TD OF SECTION 34-04-162 '~ 2004 Bonestroo, Rosene, A.nderlik & Associates, Inc. 02318-3 SlTBG~"..DE PREPA~'\ TION SECTION 02320 TRENCH EXCA V A nON AL'ID BACKFILL PART 1- GENERAL 1.01 SECTION INCLUDES A. Trenching requirements for underground pIpmg and appurtenances, including requirements for excavation, backfill, and compaction. 1.02 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (MnDOT Spec.): 1. 2105 - Excavation and Embankment. 2. 3149 - Granular Material. B. American Society of Testing Materials (ASTM): 1. D2321 - Recommended Practice for Underground 1'1stallation of Flexible Thermoplastic Sewer Pipe. 2. D698 - Test Method for Laboratory Compaction Characteristics for Soil Using Standard Effort (12,400 ft-Ibflft). C. American Water Association (A WW A): 1. C 150 - Thickness Design of Ductile Iron Pipe. 2. C151 - Ductile Iron Pipe, Centrifugally Cast in Metal Molds or Sand- Lined Molds for Water and Other Liquids. 1.03 SUBMITTALS A. Provide the Following Submittals: 1. Product Data: a. Each Borrow Material: 1) Name and location of source. 2) Results of gradation tests. 34-04-162 .~ 2004 Bonestroo, Rosene, Anderiik & Associates, lnc. 02320-1 TRENCH EXCAVATION AND BACKFILL 1.04 DEFINITIONS A. Bedding: The soil material adjacent to the pipe which makes contact with the pipe foundation, walls of the trench, and upper level of backfill. The purpose of bedding is to secure the pipe to true line and grade, and to provide structural support to the pipe barrel. B. Foundation: Soil material beneath the pipe bedding. C. Improved Pipe Foundation: Foundation provided by importing material from sources outside the Project Site. Required when foundation is soft, or unstable. D. Course Filter Aggregate: Free draining mineral product used around draintile pIpe. E. Rock Excavation: Includes such rocks as are not decomposed, weathered, or shattered, and which \vill require blasting, barring, wedging, or use of air tools for removal. Also included are any boulders, concrete, or masonry structure (except concrete pavement, curb and gutter, and sidewalk) exceeding 1 cubic yard. F. Pipe Zone: That part of the trench belovl a distance of 1 foot above the top of the pIpe. G. Sand Cushion: Aggregate bedding material used around pipe in areas \vhere rock excavation is encountered, where pipe insulation is used, and when crossing existing utilities. 1.05 SEQUENCING Al~1) SCHEDULING A. Known existing underground utilities are shown on the Draw'ings in a general way. Owner does not guarantee the locations as show'n on the Drawings. Contractor shall anticipate variations in both the vertical and horizontal locations of underground utility lines from those shown on the Drawings. B. Uncover utilities and verify both horizontal and vertical alignments sufficiently in advance of construction to permit adjustments in the work. Determine location of existing utilities and identify conflicts before excavating trench for pipe installation. C. Notify Gopher State One Call before starting construction 111 a gIven area, requesting utility locations in the field. D. Provide continuance of flow of existing sewer and other facilities. E. Backfill and compact all trench excavations promptly after the pipe is laid. 34-04-162 (9 2004 Bonestroo. Rosene, Anderlik & ASSOCiates, Inc. 02320-2 TRENCH EXCA VA TION AND BACKFILL 1.06 W ARRAi"JTY A. Trench settlements that occur during the correction period and are greater than 1 inch as measured by a 10 foot straight edge will be repaired in a manner acceptable to the Owner at the Contractor's expense. P ART 2 - PRODUCTS 2.01 PIPE BEDDING MATERIAL A. Polyvinyl Chloride (PVC) Pipe and High Density Polyethylene (HDPE) Pipe: 1. Comply with MnDOT Spec. 3149.2.B 1 for granular borrow: a. No Project Site granular material encountered during constmction may be used. b. Aggregate Size: 1 inch maximum. B. Ductile Iron Pipe (DIP) and Reinforced Concrete Pipe (RCP): 1. Class C-1 Bedding: a. Undisturbed soil. 2.02 ITv1PROVED PIPE FO~'DATION MATERIAL A. Comply with MnDOT Spec. 3149.2H Modified: 1. Cmshing Requirements: At least 50 percent of the material, by weight, retained on the No.4 sieve shall have 1 or more cmshed faces. 2.03 COARSE FILTER AGGREGATE MATERIAL A. Comply with MnDOT Spec. 3149.2H. 2.04 SA1"-il) CUSHION MATERIAL A. Comply with MnDOT Spec. 3l49.2.B1 for Granular Borrovv: 1. No Project Site granular material encountered during constmction may be used. ) Aggregate Size: 1 inch maximum. 34-04-162 ,~ 2004 Bonestroo, Rosene, Anderlik & Associates, inc. 02320-3 TRENCH EXCA VA TION AND BACKFILL 2.05 BACKFILL MATERiAL A. Suitable materials selected from the excavated materials to the extent available and practical. B. Suitable materials are mineral soils free of rubbish, trees, stumps, branches, debris, frozen soil, oversize stone, concrete and bituminous chunks, and other similar unsuitable material. PART 3 - EXECUTION 3.01 EXAlvIINATION A. Prior to construction, inspect existing utility structures and surface features, and document condition. B. Re-inspect foundation soils if rain fall or snow has occurred after initial inspection, but prior to placing pipe and bedding. 3.02 PREPARATION A. Notify Utility Owners to field mark their utility locations. B. Protect as necessary surface features such as utility poles, trees, structures, pavement, etc. that are not designated on the Drawings to be removed. C. Notify utility companies of progress schedule so they can accomplish any necessary relocations and removals that they have agreed to relocate, remove, or support. D. Implement traffic control. E. Complete temporary removal or relocation of surface features, such as fences, shrubs, signs, and mailboxes. F. Strip off existing topsoil from within the trench excavation limits and stockpile. Separate vegetative strippings from salvageable topsoil and dispose of appropriately. G. Crossing Under Existing Utility Lines: 1. Use extreme care when excavating in the vicinity of underground utility lines to avoid damage to protective coatings, or surfaces. 2. Where possible and as authorized by the utility, temporarily remove the utility line, install the new pipe, and reinstall the utility line. 34-04-162 .~ 2004 Bonestroo, Rosene. Anderlik & Associates, Inc. 02320-4 TRENCH EXCA VA TION AND BACKFILL 3. "Nhere existing line cannot be removed or is not feasible to remove, securely support, excavate under, backfill under and around the utility line to 100 Percent Standard Proctor Density. 4. Report and repair damaged lines prior to backfilling trench. 3.03 CONSTRUCTION A. Trench Excavation: 1. Excavate trench to alignment and grade shO\,vn on the Drawings. 2. The trench width at the surface may vary and depends on the depth of trench and nature of the excavated material encountered. However, it shall be of ample width to permit the pipe to be laid and jointed properly and the backfill to be placed and compacted properly. 3. Correct any part of the trench that is inadvertently excavated below grade with approved material compacted to 100 Percent Standard Proctor Density. 4. Brace, shore, or sheet trench and provide drainage. Comply with applicable State Regulations relating to industrial safety to a safe angle of repose. Angle of repose may be no less than that required by the Accident Prevention Division of the State Industrial Commission or the requirements of the Occupational Safety and Health Act (OSHA), whichever is most restrictive. 5. Pile all excavated material in a manner that will not endanger the work, or obstruct sidewalks, driveways, gutters, etc. 6. Segregate soils in the excavated material that are not suitable for trench backfill and dispose of in a manner that is consistent \vith the requirements specified herein under "Backfill Above Pipe Zone." 7. Dispose of excess excavated materials off of right-of-'vvays and easements in a suitable site selected by the Contractor. 8. Haul materials, other than natural soil materials that are suitable as backfill material, to an approved landfill as directed by the Engineer. 3.:.\-04-162 '9 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. 02320-5 TRENCH EXCAVATION AND BACKFILL B. Water Control: 1. Dewater the ground as necessary to excavate the trench and install the pipe. All pipe and structures shall be laid in a dry condition prior to backfill. Maintain groundwater level a minimum of 1 foot below' the pipe invert. Measure the rate of flo\v from dewatering pumps at the beginning of the de\vatering operation(s) and once per week there after. Keep a daily log of hours pumped. C. Trench Bottom: 1. Excavate to a sufficient depth to insure adequate foundation when the bottom of the trench is soft, or where in the opinion of the Engineer unsatisfactory foundation conditions exist. Bring excavation up to pipe grade with thoroughly compacted granular materials meeting the requirements of Improved Pipe Foundation Material. 2. Provide temporary support, remove, relocate, or reconstruct eXlstll1g utilities located within the trench excavation. Utility shall designate method employed. Use particular care and provide compacted fill, or other stable support for utility crossings to prevent detrimental displacement, rupture, or failure. 3. Excavate to expose existing utilities that cross in close proximity to the planned pipe line to determine the utilities' exact location sufficiently ahead of pipe installation to plan for the avoidance of grade conflict. Measure to determine the utilities' location relative to the planned pipe line location. A deviation from the alignment, grade, and location to avoid conflict may be ordered by the Engineer. 4. In locations where rock affects the pipe foundation, excavate the trench 6 to 12 inches below the pipe, and place sand cushion material up to the proposed invert elevation. The remainder of the trench up to the top of rock elevation shall be backfilled with granular backfill material meeting the requirements of Paragraph 2.0S.B of this Section: a. Sand Cushion: The removal and disposal of the unsuitable material within the trench and below the invert elevation, and the replacement up to invert elevation with the appropriate bedding material. b. Granular Backfill: The removal and disposal of unsuitable material \vithin the trench, above the invert elevation, and replacement up to the surface \vith appropriate backfill material. No additional compensation will be allowed for wider or deeper trenches in rock excavations. 34-04-\62 ~ 2004 Bonestroo, Rosene. Anderlik & Associates, Inc. 02320-6 TRENCH EXCAVATION AND BACKFILL c. For PVC and HDPE Pipe, the sand cushion shall be placed to 1 foot above the pipe, and shall be paid as pipe bedding. The remainder of the trench up to the top of the rock shall be backfilled with granular backfill material. 5. Improved Pipe Foundation: When unsatisfactory foundation conditions exist, excavate to a depth consisting of solid materials. Fill to pipe grade with thoroughly compacted granular materials meeting the requirements of Improved Pipe Foundation Material. 3.04 PIPE BEDDING A. Polyvinyl Chloride Sewer Pipe: Bed pipe in accordance with ASTM D2321. B. Reinforced Concrete Pipe: Bed pipe in accordance with Class C-1 Bedding. C. Ductile Iron Pipe: Bed pipe in accordance with A WW A Standard C 150 and C151. D. High Density Polyethylene (HDPE) Profile vVall Pipe: Bed pipe in accordance with ASTM D2321. E. Use only selected materials free from rock, boulders, debris, or other high void content substances to a level 1 foot above the top of pipe. Remove ledge rock, boulders, and large stones to provide at least 6 inch clearance from pipe. F. Dig bell holes of ample dimension at each joint such that the pipe barrel rests continuously on the bedding. 3.05 BACKFILL vVITHIN PIPE A. Backfill immediately after pipe is laid. Restrain pipe, as necessary to prevent their movement during backfill operations. B. Place material completely under pipe haunches in uniform layers not exceeding 4 inches in depth. 3.06 BACKFILL ABOVE PIPE ZO:Nt: A. Use suitable materials meeting the requirements of Backfill Material. B. Place in uniform depth layers not to exceed 12 inches before compaction. Complete the compaction of each layer before placing material for the succeeding layer. ]J.-04-l62 ,~ 2004 3onestTQo, Rosene. Anderiik & Associates, Inc. 02320-7 TRENCH EXCA VA TION AND BACKFILL C. Compact each layer by mechanical means until it meets the requirements of MnDOT Spec. 2105.3Fl "Specified Density Method." Trenches shall be compacted to a minimum of 95 percent, except to 100 percent in the upper 3 feet. If the moisture content of the backfill materials is greater than 3 percent above the optimum moisture, compact the materials to a minimum density of 3 pounds/cubic foot less than the Standard Proctor Curve at that moisture content, except that minimum compaction shall be 85 Percent of Standard Proctor Density. D. The method and means of placement and type of compaction equipment used is at the discretion of the Contractor. Ho\vever, all portions of the trench backfill must meet minimum specified compaction requirements. E. Any deficiency in quantity of backfill material (caused by shrinkage, or settlement) shall be supplied at no additional cost to the Owner. F. Excavated material not suitable or required for backfill shall be disposed of outside of the Project Site. 3.07 RESTRICTED TRENCH WIDTH A. Restrict width of trench to confoffi1 to constmction limits indicated on the Drawings and where directed by the Engineer to prevent damage to specimen trees or adj acent structures. 3.08 FIELD QUALITY CONTROL A. Density Tests: To be performed by an approved soils testing firm at various locations and depths throughout the Project Site as directed by the Engineer. The Contractor shall cooperate fully and provide assistance as necessary to complete these tests. B. Failed density test areas shall be excavated and re-compacted until the density requirements are met. 3.09 MEASUREMENT Al'-i'D PAYMENT A. Trench Excavation: Excavation and backfilling of trench and associated pipe bedding shall be included in the price of pipe provided. B. Pipe Bedding: Considered incidental and shall be included in the price of pipe furnished and installed. 34-04w 162 ~ 2004 BonestToo, Rosene, Anderiik & Associates, Inc. 02320-8 TRENCH EXCA VA T10N AND B.'\CKFILL C. Improved Pipe Foundation: At the Bid Unit Price per lineal foot for each 6 inch layer placed below pipe bedding: 1. For example, if 2 feet of foundation material is required under a pipe installed with C-2 bedding; 6 inches of material is required for Class C-2 bedding and payment will be made for 3 lineal feet of pipe foundation material, 6 inches deep, per foot of pipe installed. 2. No payment vvill be made without the knowledge, or consent of the Engineer. 3. No payment will be made for subgrade rock installed for de-watering purposes only, unless specified. D. Temporary Bracing and Sheeting: Considered part of the excavation costs with no additional compensation to Contractor, unless provided for otherwise. E. Density Tests: 1. Passing Tests: All costs paid by Owner. 2. Failing Tests: All costs charged to and paid by the Contractor. F. Dewatering: No explicit, direct payment is made for this work. Include the costs in the Bid Unit Prices for the pipe, or structure installed. G. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. El\TD OF SECTION 34-04-162 :9 2004 Bonestroo, Rosene. Anderlik & Associates, Inc. 02320-9 TRENCH EXCAVATION AND BACKFILL SECTION 02341 GEOTEXTILE SOIL STABILIZATION PART 1- GENERi\L 1.01 SECTION INCLlTDES A. Geotextile fabric used for street construction. 1.02 RELATED SECTIONS A. Section 02315 - Excavation and Fill. B. Section 02318 - Subgrade Preparation. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (MnDOT Spec.): 1. 3733 - Geotextiles. 1.04 SUBMITTALS A. Manufacturer's Certificate of Compliance which shall include the follo\ving information: 1. Full product name by trademark and style number. 2. Geotextile polymer type(s). 3. Geotextile physical properties. B. Samples of the geotextile: 1. The geotextile machine direction shall be marked on each sample submitted for testing. 34-04~ 162 ..:1:J 2004 Bonestroo, Rosene. Anderlik & Associates. Inc. 02341-1 GEOTEXTILE SOIL STABILIZATION PART 2 - PRODUCTS 2.01 GEOTEXTILE FABRIC A. Conform to the requirements of1\tlnDOT Spec. 3733, Type Y, except as modified below: 1. Minimum Fabric 'Weight: Type Y 4.5 oz/sy. PART 3 -EXECUTION 3.01 PREPARATION A. Excavation: Conform to Section 02315 - Excavation and Fill. B. Subgrade Preparation: Conform to the requirements of Section 02318 - Sub grade Preparation: 1. Subgrade shall be toleranced and approved before geotextile placement. 3.02 INSTALLATION A. The geotextile shall be placed immediately ahead of the covering operation: 1. No geotextiles shall be left exposed to sunlight during installation for a total of more than 7 calendar days. 2. The geotextile shall be laid smooth without excessive wrinkles. 3. The geotextile shall not be dragged through mud or over sharp objects which could damage the geotextile. B. All adjoining sections of the geotextile shall be overlapped a mllllmum of 18 inches or sewn using mechanical machine. C. Secure fabric in place by means of stone weights to prevent displacement. D. If geotextile is tom or punctured, the damaged area shall be repaired or replaced: 1. The patch shall overlap the existing geotextile a minimum of 3 feet from the edge of any part of the damaged area. E. Use fabric type (woven or non-woven) as specified that corresponds to typical section shown in the Drawings. 34-04-162 9 2004 Bonestroo, Rosene, i\Jlderlik & Associates, Inc. 02341-2 GEOTEXTILE SOIL STABILIZATION 3.03 FILL PLACEMENT A. Only granular spreading methods that will not tear the fabric shall be used. B. Granular borrow shall not be dropped on the fabric from a height greater than 3 feet: 1. Minimum of 8 inches of granular borrow, must be placed on the geotextile prior to the movement of construction equipment: a. Turning movement must be carefully monitored. 2. Tracked or wheeled equipment shall not be permitted to drive directly on the fabric. 3. iilly ruts occurring during constnlction shall be filled with additional granular borro\v and compacted to the specified density. C. Compaction of first lift above the geotextile shall be limited to routing of placement and spreading equipment only. No vibratory compaction will be allo\ved on the first lift. 3.04 MEASUREMENT AND PAYNfENT A. Bid Items have been provided for Geotextile Fabric, Type V, both \voven and non-woven. Measurement will be based upon units of square yards of actual surface area covered by geotextile fabric. Payment at the Bid Unit Price shall include all materials, installation, and protection of installed geotextile fabric as specified. The required overlap joint or joint sewing shall be incidental to this fabric item, with no direct payment being made. B. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. ENTI OF SECTION 34-04-162 Q 2004 Bonestroo, Rosene, Ander!ik & Associates, lnc. 02341-3 GEOTEXTILE SOlL STABILIZATION SECTION 02510 WATER MAIN PART 1- GENERAL 1.01 SECTION INCLUDES A. vVater main pipe, hydrants, valves, fittings, and miscellaneous appurtenances. 1.02 RELATED SECTIONS A. Section 02280 - Adjust Miscellaneous Structures. B. Section 02315 - Excavation and Fill. C. Section 02320 Trench Excavation and Backfill. 1.03 REFERENCES A. American Water Works Association (A vVWA): 1. CI04 - American National Standard for Cement Mortar Lining for Ductile-Iron Pipe and Fittings for Water. 2. C 1 05 - American National Standard for Polyethylene Encasement for Ductile-Iron Pipe Systems. 3. Clll - American National Standard for Rubber Gasket Joints for Ductile Iron Pressure Pipe and Fittings. 4. C151 - American National Standard for Ductile-Iron Pipe, Centrifugally Cast, for Water. 5. C153 - American National Standard for Ductile-Iron Compact Fittings, 3 Inch Through 24 Inch, and 54 Inch Through 64 Inch, for Water Service. 6. C504 - A WW A Standard for Rubber-Seated Butterfly Valves. 7. C509 - A\VVVA Standard for Resilient-Seated Gate Valves for vVater Supply Service. 8. C600 - A V/vVA Standard for Installation of Ductile-Iron Water Main and Their Appurtenances. 9. C651 - A WW A Standard for Disinfecting Water Mains. 34.04.162 'ld 2004 Bonestroo, Rosene, Anderiik & Associates. Inc. 02510-1 WATER MAIN B. American Society of Testing and Materials (ASTM): 1. A48 - Gray Iron Castings. 2. A126 - Gray Iron Castings for Valves, Flanges, and Pipe Fittings. 3. A674 - Standard Practice for Polyethylene Encasement for Ductile Iron Pipe for Water or Other Liquids. 4. D2842 - Standard Test Method for Water Absorption of Rigid Cellular Plastics. C. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (MnDOT Spec.): 1. 3760 - Insulation Board (PolystYTene). D. National Electrical Ivlanufacturers Association (NEMA): 1. WC 70 - Non-Shielded Po\ver Cables Rated 2000 Volt or Less for the Distribution of Electrical Energy. 1.04 SEQlJENCING A.'ND SCHEDULING A. Notify the Owner a minimum of 48 hours prior to performing work. At this time, the Contractor is responsible to notify the City Fire Department of the intended shutdown. B. Notify all customers connected to water system to be shut down 48 hours m advance of shut down. C. The O\vner must open and close the existing valves for this part of the operation. The Owner is responsible for flushing the mains after the connection is completed; however, the Contractor shall assist the Owner as necessary. D. Successfully complete required test and inspections before restoration of surface. 34-04- t 62 :g 2004 Bonestroo, Rosene, Anderlik & Associates, [nc. 02510-2 \VA TER MArN PART 2 - PRODUCTS 2.01 DUCTILE IRON PIPE Ai'ID FITTINGS (DIP) A. General Requirement: AWWA C151/A21.51. B. Cement-mortar lining conforming to A WW A C 104/A21.4. C. Class 52 for diameters less than 20 inches. D. Class 51 for 20 inch diameter, or greater. E. Fittings: AWWA C153/A21.53, Ductile Iron, 250 psi working pressure, AWWA C111/ A21.11 latest revision, mechanical joint, or push-on. F. Spray exterior fitting nuts, bolts, and megalugs using a bituminous coal tar as supplied by the manufacturer. G. Wrap all pipe and fittings according to pipe encasement requirements. H. Cor-Blue T -Bolts shall be required on all mechanical joint fittings. 2.02 H'rlJRA.l"-TT A. General Requirements: A WWA Standard C-502. B. Specified Hydrant: WB-67-250, or approved equal. C. Approved Manufacturer: Waterous Pacer, or approved equal. D. Two (2) - 2-1/2 inch hose connections. E. One (1) - 4-1/2 inch steamer. F. National standard operating nut. G. 5 inch valve opening. H. 6 inch mechanical joint pipe connection. 1. Break-off flange with breakable rod coupling. J. 8 feet - 0 inch cover. 34-04-162 :g 2004 BonestToo, Rosene, Anderlik & Associates. lne. 02510-3 WA TER MAIN K. 16 inches high traffic section. L. Nozzle caps attached to hydrant with metal chains. M. Stainless steel hardware. N. Fiberglass Flag: Hydrafinder Hydrant Marker, or approved equal: 1. White fiberglass rod with 4 red reflective bands without a bulb end. 2. 54 inches long, 3/8 inch diameter. O. Hydrants placed where the ground \vater table is less than 8 feet below the ground surface shall have the drain holes plugged and shall be equipped \vith a tag stating the need for pumping after use. P. Color: Painted Waterous Enamel #V18l4-R at the place of manufacture. Q. After installation and testing is complete, the "field coat" of paint shall be app lied with a bmsh. 2.03 GATE VALVE fu~1) BOX A. General Requirement: A W'vV A C509. B. Bronze mounted, iron body valves. C. O-ring seals. D. Non-rising stem, opening by tuming counter clockwise, 2 inch square operating nut. E. Mechanical joint ends conforming to A WW A Clll/ A2l.ll. F. Stainless steel hardware. G. Spray exterior nuts and bolts and megalugs usmg a bituminous coal tar, as supplied by the manufacturer. H. Wrap gate valves according to Paragraph 2.07 - Pipe Encasement. 34-04-162 ..~ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 025 10-4 WATER MAIN 1. Valve Boxes: 1. 3 piece, cast iron, screw-type. 2. Adjustable for 7-1/2 foot depth of cover. 3. Valve and box considered as integral units. 4. 5-1/4 inch diameter shafts. 5. "Stay put" type drop covers, "YVATER" on top with extended skirts. 2.04 BUTTERFLY VAL VE A~rn BOX A. General Requirement: A YVV/ A C504. B. Mechanical joint valve ends conforming to A WWA C 111/ A21.11. C. A WW A C504 Class 150B valve shaft diameter. D. Valve Body: High strength cast iron conforming to ASTM A126, Class B. E. Valve Vane: High-strength cast iron conforming to ASTM A48, Class 40, mbber seat mechanically secured with an integral 18-8 stainless steel clamp ring and 18-8 stainless steel self-locked screws. F. a-Ring seal. G. Stainless steel hard\vare. H. Spray exterior nuts and bolts and megalugs usmg a bituminous coal tar as supplied by the manufacturer. 1. Wrap butterfly valve according to Paragraph 2.07 - Pipe Encasement. J. Operator: 1. Traveling nut type sealed, gasketed, and lubricated for underground servIce. 2. Open counter clockwise. 3. 2 inch square operating nut. 34-04-162 '9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02510-5 WATER MAIN K. Valve Box: 1. 3 piece, cast iron, screw-type. 2. Valves and boxes to be considered integral units. 3. 5-1/4 inch diameter shafts. 4. Round or oval bases. 5. "Stay put" type drop covers, bearing the word "WATER" on top with extended skirts. 2.05 CONDUCTIVITY STRA..P A. As specified by the pipe manufacturer. 2.06 JOINT RESTRA.INT A. Mechanical Joint Restraint: 1. Ductile iron. 2. Working Pressure: Minimum 250 psi. 3. EBAA Iron, Inc., rv'fega-lug, or approved equal. Mega-lug and retainer glands are not allowed on existing cast iron pipe. 4. Spray exterior ductile iron nuts and bolts using a bituminous coal tar as supplied by the manufacturer and wrap according to Paragraph 2.07 - Pipe Encasement. B. Tie Rods: Steel rods with "Star" brand tie bolts. 2.07 PIPE ENCASEMENT A. Polyethylene: Conform to A'vVYVA CI05/A21.5, Class C (Black), tube fom1. Material shall confoml to ASTM A674. 2.08 INSULATION A. Conform to MnDOT Spec. 3760. 2.09 CORPORATION COCK A. See Section 02515 - 'vVater Services. 34-04-162 ,~ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02510-6 WATER MAIN 2.10 COPPER SERVICE PIPE A. See Section 02515 - Water Services. PART 3 -EXECUTION 3.01 PREPARATION A. Conform to Section 02320 - Trench Excavation and Backfill. 3.02 INSTALLATION OF PIPE A. Install pipe and fittings in accordance with the manufacturer's instmctions and with the details shown on the Drawings. B. Permanently support, remove, relocate, or reconstmct existing utility pipes, cables, stmctures, or other appurtenances when they obstmct the line, grade, or location of the pipe, or appurtenance. C. Remove foreign matter or dirt from the inside of pipe. D. All jointing of mechanical joint pipe and push-on joint pipe In accordance to AWWA C600. E. Outside of the spigot and the inside of the bell, wire bmsh, wipe clean and dry. Keep pipe ends clean until joints are made. F. Lay and maintain pipe and appurtenances to the alignment, grade, and location shown on the Drawings. No deviation from the Drawing alignment, grade, or location is allowed, unless approved by the Engineer. No pipe shall be laid in water or when the trench conditions are unsuitable for such work. G. Provide conductivity throughout the water system by use of conductivity strap, except for HDPE and pve water main pipe. H. Precautions are to be taken to prevent debris, or groundwater from entering the pipe being laid. 1. Installing Fittings: 1. General Requirements: A WWA C600. 2. Set and jointing to existing pipe and fittings as specified for cleaning, laying, and joining pipe. J. Backfilling: Conform to Section 02320 - Trench Excavation and Backfill. 34-04-l62 ~ 2004 Bonestroo. Rosene. Anderlik & Associates, Inc. 02510-7 WATER MAIN 3.03 INSTALLATION OF HYDRAJ.'JT A. Location determined by Engineer. A grade stake and location stake will be provided by the Engineer before the hydrant may be set. B. Set on 8 inch concrete block, or approved equal concrete base. C. Brace according to Draw'ings. D. After each hydrant has been set, place around the base of the hydrant not less than 1 cubic yard of Class A round washed rock with a minimum diameter of 3/4 inch. Carefully place 2 layers of polyethylene, minimum 4 mm thickness each, over the rock to prevent backfill material from entering voids in the drain rock. E. Maintain hydrants in a plumb position during the backfilling operation. F. Attach a fiberglass marker to the hydrant using an existing flange bolt located at the back of the hydrant. 3.04 INSTALLATION OF VALVE A. Set and joint valves to new pipe in the manner as specified for cleaning, laying, and jointing pipe. Location to be determined by the Engineer. B. Valves and boxes shall be supported on an 8 inch concrete block as shown on the Drawings. C. Maintain valve box centered and plumb over the operating nut of the valve. D. Set top of valve box flush with the existing surface to provide 12 inches of upward adjustment. 34-04-162 ,1::) 2004 Bonestroo, Rosene, Anderiik & Associates, Inc. 02510-8 WATER MAiN 3.05 AJ."TCHORA GE A. Brace fittings and hydrants securely against undisturbed soil using precast concrete block. Mega-lug or rod all joints from main line tee to hydrant gate valve, then from gate valve to hydrant. B. Where lines terminate with plugs, restrain the plug and next 2 joints with 3/4 inch tie rods in conjunction with the blocking, as directed by the Engineer. The number of rods required is as follows: Pipe Size 6 Inch 8 Inch 12 Inch 16 Inch 18 Inch 20 Inch 24 Inch No. of 3/4 Inch Rods 2 2 4 6 6 8 10 3.06 INSULATION A. Review Insulation Installation with Engineer: 1. Place insulation between water pipe and sanitary pipe \vhen water main, or service is within 1 foot above, or below the sanitary pipe. 2. Place insulation between storn1 se\ver pipe and water mam, or water service when pipes are separated by less than 2 feet. 3.07 TEMPORARY WATER SERVICE A. During water main constmction, install and maintain temporary water service to all homes, apartments, and/or businesses as shown on the Drawings: 1. The temporary service will allow efficient removal of the existing water main and services, and installation of the new. 2. The temporary service shall provide adequate pressure and volume to properties. 3. Coordinate all work with the Owner and the Engineer. 4. Coordinate cOI1..nections and service interruptions with the property o\vners. 5. Provide rampmg and/or shallow trenching at street and driveway crossmgs. 34-04-162 :&;; 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02510-9 \VA TER MAlN 6. Provide emergency contact numbers for evenings and weekends. 7. Temporary system will be provided in stages throughout the Project if necessary. Submit a plan for temporary service for approval by the Owner. 8. Use a minimum of 4 inch diameter main line. B. Contractor is to super chlorinate the temporary ""vater service lines. The lines are to be filled with water, let stand for 48 hours and then flush the entire system. After the temporary water services lines have been flushed, let them sit for 24 hours and perform a bacteria test. When the bacteria tests result have past, the residents may then be hooked up. 3.08 PIPE CON"FLICTS A. Shall apply to any crossings under existing cast iron pipe and any pipe conflicts where a minimum clear separation of 1 foot is not possible. B. Cut the water main beyond the proposed sewer trench wall. C. Remove the abandoned water main and install offset as show'n on the Drawings, or as encountered during construction. D. All offset piping shall be DIP. E. Megalug type restraints shall not be allowed on cast iron pipe. 3.09 PROTECTION A. Existing valves and hydrants shall be operated by the Public Works Department, unless under emergency situations. B. Securely plug all water main openings promptly before suspension of work at any time to prevent earth, or other substances from entering the water main. C. Mark valve boxes and structures susceptible to being hit by construction, or vehicular traffic. 34-04-162 .1d 2004 Bonestroo, Rosene, Anderlik & Associates, inc. 02510-10 WA TER :v!ArN 3.10 FIELD QUALITY CONTROL A. Scope: 1. Perform hydrostatic pressure, disinfection, and conductivity tests. 2. The Engineer will observe and verify all tests and visually inspect final work for compliance. B. Required Tests and Inspection: 1. Hydrostatic Pressure Test: a. Minimum Test Pressure: 150 psi. b. Test Duration: 2 hours. c. Criteria: No drop in pressure allowed. d. Testing gauge shall be liquid filled, 4-112 inch diameter, labeled in 1 psi increments, such as Ashcroft Modell 082, or approved equal. e. All lines, including hydrant leads, water services, and stubs, shall be tested. Services will be testes to the new curb stops. 2. Disinfection: a. General Requirement: A WWA C651 - Disinfecting Water Mains (Tablet Method). b. Place hypochlorite tablets In each section of pIpe and all appurtenances: 1) Attach tablets to top of pipe with a food grade adhesive such as denture grip. 3.1-04-162 --g 2004 Bonestroo, Rosene, Anderlik & Associates, [nc. 02510-11 \VA TER MAIN 2) The number of tablets required per 20 foot length of pipe based on 3-1/4 grain available chlorine per tablet is as follows: Diameter 4 Inch 6 Inch 8 Inch 10 Inch 12 Inch 16 Inch 18 Inch 20 Inch 24 Inch No. of Tablets 1 2 .., .) 4 5 9 12 14 20 c. Fill main with water at a velocity of less than 1 foot per second if tablet method is used and let sit for 48 hours. d. Flushing, by Contractor, may begin after the chlorinated water has been allowed to disinfect the new pipe for 24 hours. e. 1 bacteria test is required for every 2,000 feet of \vater main installed, with a minimum of 2 sample tests per Project. Bacteria test shall be done by Contractor. 3. Conductivity: 34-04-162 C1d 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. a. Conductivity shall be provided throughout the water system by use of copper straps or approved conductive gaskets with copper inserts, except when PVC or HDPE pipe is used. b. Current - 350 amps at approximately 30 volts for 4 minutes, then 400 amps for 1 minute without fluctuation. c. Lines must be filled with water prior to test. d. All lines, including hydrant leads, water services, and stubs, shall be tested. 02510-12 WATER MAfN 3.11 MEAS1JREMENT Al"-il) P A YNIENT A. Bid Items have been provided for Water Main. Measurement and payment will be based upon the units listed below: 1. Water Main Pipe: Measurement will be based upon units of lineal feet for each size and type of pipe installed, as measured along the axis of pipe, without regard to intervening valves or fittings. 'vVater main over depth shall not be measured. Payment at the Bid Unit Price shall include furnishing and installing pipe complete in place as specified. 2. Valve and Box: Measurement will be based on valve and box installed. Payment at the Bid Unit Price shall include furnishing and installing the valve and box complete in place as specified. 3. Hydrant: Measurement will be based on units of each hydrant installed. Payment at the Bid Unit Price shall include furnishing and installing the hydrant, including fiberglass flag. 4. DIP Fittings: Measurement shall be based on the fitting weight installed in pounds. The fitting weight shall be construed to mean equivalent cast iron \V'eight. Payment at the Bid Unit Price shall include DIP fitting, poly encasement, bituminous coal tar spray, and hardware. 5. Connect to Existing Water Main: Measurement shall be based on each connection made, including the removal of existing plugs, and all work necessary to make the connection. Payment at the Bid Unit Price shall include all items required to complete the \vork. B. No Bid Items have been provided for Steel Rodding. Steel Rodding shall be considered incidental to water main installation with no direct payment made. C. No Bid Items have been provided for Testing. Testing shall be considered incidental to water main installation with no direct payment made. D. Should 4 Inch Ductile Iron Pipe or 4 Inch Gate Valves be required, these items will be paid under the Bid Unit price for 6 Inch Ductile Iron Pipe and 6 Inch Gate Valve. E. Note that no direct payment will be made for removal of existing gate valves. Removal and disposal will be incidental to the removal of the existing V-later main plpe. F. If offsets are required, payment will be made using the Bid Prices for the actual pipe length used and the fittings used. No additional compensation will be made. 34-04-162 [;) 2004 Bonestroo, Rosene, ."v1derlik & Associates, L'1c. 02510-13 \VATER MAIN G. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 34-04-162 .:1:) 2004 Bonestroo, Rosene, Anderlik & Associates, [nc. 02510-14 ,VA TER MAlN SECTION 02515 W ATER SERVICES PART 1- GENERAL 1.01 SECTION INCLUDES A. Constmction of water service pipe, corporation stops, curb stops and boxes, and all appurtenances. 1.02 RELATED SECTIONS A. Section 02320 - Trench Excavation and Backfill. B. Section 02510 - Water Main. 1.03 REFERENCES A. American Society of Testing and Materials (ASTM): 1. B88 - Class K Copper Water Service Pipe. 2. A674 - Standard Practice for Polyethylene Encasement for Ductile Iron Pipe for Water or Other Liquids. B. i\merican Water Works Association (A WWA): 1. C 1 05 - American National Standard for Polyethylene Encasement for Ductile Iron Pipe Systems. 2. C900 - A WvVA Standard for Polyvinyl Chloride (PVC) Pressure Pipe and Fabricated Fittings, 4 Inch Through 12 Inch, for Water Distribution. 3. C906 - A WW A Standard for Polyethylene (PE) Pressure Pipe and Fittings, 4 Inch Through 63 Inch, for Water Distribution. 1.04 SEQUENCING ANTI SCHEDULING A. Install sanitary sewer, water main, and all pipe deeper than the services prior to the installation of the services. B. Install water service in same trench as the sanitary sewer service. C. Perform testing of new water main prior to recoll..'1ecting existing services. 34-04-\62 C9 2004 Bonestroo, Rosene, Anderlik & Associates, [nc. 02515-1 WATER SERVICES P ART 2 - PRODUCTS 2.01 SERVICE PIPE A. Copper Water Tube: 3/4 inch through 2 inch, for buried service shall be seamless, Type K water tube conforming to ASTM B88. Service tubing larger than 1 inch shall be rigid Type K and joined using soldered joints: 1. Fittings shall be designed for working pressures up to 150 psig. Fittings used in service lines shall be designed for connection to the service line by threads, brazing, compression, and/or flaring. B. Ductile Iron Pipe (DIP): Conform to Section 02510 - Water Main. 2.02 CORPORATION STOP A. Approved Manufacturers: 1. Mueller, Minneapolis Pattern H-15000. 2. Ford Type F600. 3. Hayes No. 5200. 4. McDonald No. 4701. B. Threaded for use with copper service pipe. C. Threaded on inlet end with standard corporation cock thread. D. Mueller 110 compression connections are approved. 2.03 CURB STOP A. Approved Manufacturers: 1. Curb Stops 1 Inch and Smaller: a. Mueller .0v'lark II Oriseal Pattern H -15154. b. McDonald No. 4717. 2. Curb Stops Larger Than 1 Inch: a. Mueller Mark II Oriseal Pattern H-15154 b. McDonald No. 6104 ball valves. 34-04-\62 -&; 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02515-2 WATER SERVICES B. Proper connection type for inlet and outlet. C. Full opening through the valve body with no smaller restriction allowed. 2.04 CURB BOX A. Approved Manufacturers: 1. Mueller: Conforming to 2.03.A.l (or 2) a-b. 2. McDonald: Conforming to Paragraph 2.03.A.l (or 2) a-d. B. Adjustable in height from 78 inches to 90 inches. C. No Stationary rods. D. 2 inch upper section. E. Mueller improved extension typed with arch pattern base. 2.05 SERVICE SADDLES A. Approved ManufaCturers: 1. Smith-Blaair 372. 2. Ford FS303. 3. Cascade CS22. 2.06 TRANSITION FITTINGS A. Polycam steel transition fittings shall conform to A WW A C90 land C906 for connections to SDR 11 IPS PE Service Pipe. PART 3 - EXECUTION 3.01 INSTALLATION A. Governing Code: Minnesota Plumbing Code and any local ordinances that may apply. B. Preparation: Conform to Section 02320 - Trench Excavation and Backfill. 34-04-\62 ;:g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02515-3 WATER SERVICES C. New services shall be connected at the locations shown on the Drawings, or if not shown as directed by the Engineer. D. Water Service Line: 1. Parallel and upstream of the se\ver service line in the same trench. 2. Terminate water service as sho\vn on Drawings or as directed by the Engineer. E. Corporation Stop: 1. Tap into main only when water main is under pressure. F. Curb Box: 1. Support on full size pre-cast segmental manhole block. 2. Place in a vertical position. 3. Install to finished grade. 4. Grade stakes will be furnished to establish elevations. G. Reconnect Existing Service: 1. Disconnect existing service from existing water main. 2. Remove existing curb stop and box and excess existing service pipe. 3. Reconnect existing service from house to ne\v curb box. H. All trenches shall be backfilled and compacted in accordance to Section 02320 - Trench Excavation and Backfill. 3.02 FIELD QUALITY CONTROL A. Do not backfill trench until the service has been inspected and approved by the Engineer. B. All water services will be pressure tested in conjunction with the water main, conforming to Section 02510 Water Main. 34-04-\62 9 2004 Bonesttoo, Rosene, Anderlik & Associates, Inc. 02515-4 WA TER SERVICES 3.03 PROTECTION A. Mark Each Curb Box: 1. Solid 4 inch x 4 inch x 8 feet wood post extending 4 feet above grade. 2. Metal fence post extending 4 feet above grade. B. Mark the End of the Utility Services: 1. Solid 4 inch x 4 inch x 8 feet wood post extending 4 feet above grade. 2. Metal fence post extending 4 feet above grade. 3.04 MEASlJREMENT Ai~TI P A'r''MENT A. Type "K" Copper Water Service: Measurement by linear foot, from centerline of the water main to termination as shown on the Drawings with no regard to intervening fittings. Payment at the Bid Unit Price per foot shall include cost of all pipe, fittings, laying, excavation, backfilling, and testing: 1. Placement and compaction of the aggregate material around the corporation stop and gooseneck is incidental to the service line. 2. Supplying and installing wooden markers or fence a post is incidental to the service line. B. Corp (Corporation Stop) and Corporation Stop with 12Inch Saddle: By physical count of each type installed. C. Curb Stop and Box: By physical count of each type installed. D. Material, placement, compaction, and removal of excess trench material to be included in the Bid Unit Price for water service line. E. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. ENTI OF SECTION 34-04-162 :g 2004 Bonestroo. Rosene. Anderlik & Associates, Inc. 02515-5 \VA TER SERVICES SECTION 02530 SAN1TARY SEINER PART 1 - GENERAL 1.01 SECTION INCLUDES A. Sanitary se\ver gravity pipe, forcemain, pressure sewer, manholes, fittings and miscellaneous appurtenances. 1.02 RELATED SECTIONS A. Section 02280 - Adjust Miscellaneous Structures. B. Section 02320 - Trench Excavation and Backfill. 1.03 REFERENCES A. American Society of Testing and Materials (ASTM): 1. A48 - Specification for Gray Iron Castings. 2. A615 - Specification for Deformed and Plain Billet-Steel Bars for Concrete Reinforcement. 3. C76 - Specification for Reinforced Concrete Culvert, Drain and Sewer Pipe. 4. C 139 - Specification for Concrete Masomy Units for Construction of Catch Basins and Manholes. 5. C 150 - Specification for Portland Cement. 6. C206 - Specification for Finishing Hydrated Lime. 7. C361 - Specification for Reinforced Concrete Low Head Pressure Pipe. 8. C478 - Specification for Precast Reinforced Concrete Manhole Sections. 9. D16 - Terminology Relating for Paint, Varnish, Lacquer, and Related Products. 10. D698 - Test Method for Laboratory Compaction Characteristics of Soil Using Standard Effort. 34-04-! 62 :g 2003 Bonestroo, Rosene, Anderlik & Associates, Inc. 02530-1 SANITARY SE\VER 11. D1784 - Specification for Rigid Poly (Vinyl Chloride) (PVC) Compounds and Chlorinated Poly (Vinyl Chloride) (PVC) Compounds. 12. Dl785 - Specification for PVC Plastic Pipe, Sch. 40, 80, and 120. 13. D2321 - Practice for Underground Installation of Thermoplastic Pipe for Sewers and Other Gravity - Flo\v Applications. 14. D3034 - Specification for Type PSM Poly (Vinyl Chloride) (PVC) Sewer Pipe and Fittings. 15. D3212 - Specifications for Joints for Drain and Sewer Plastic Pipes Using Flexible Elastomeric Seals. 16. F477 - Specifications for Elastomeric Seals (Gaskets) for Joining Plastic Pipe. 17. F794 - Specification for Poly (Vinyl Chloride) (PVC) Profile Gravity Sewer Pipe and Fittings Based on Controlled Inside Diameter. 18. F894 - Specification for Polyethylene (PE) Large Diameter Profile Wall Sewer and Drain Pipe. B. American Water Works Association (A W\V A): 1. C 1 04 Cement Mortar Lining for Ductile and Cast Iron Pipe and Fittings. 2. C 1 05 - Polythylene Encasement for Ductile Iron Pipe. 3. C 11 0 - Ductile - Iron and Gray - Iron Fittings, 3 in. through 48 in. for Water and Other Liquids. 4. Clll - Rubber-Gaskets Joints for Ductile-Iron Pressure Pipe & Fittings. 5. C 151 - Ductile - Iron Pipe, Centrifugally Cast, for Water. C. Minnesota Department of Transportation "Standard Specification for Construction," 2000 Edition (MnDOT Spec.): 1. 3760 - Insulation Board (PolystYTene). 1.04 SITE CONDITIONS A. Sanitary sewer lines are shown on the Drawings in a general way. Contractor should anticipate minor variations in both horizontal and vertical directions in locating existing system. 34-04-162 :g 2003 Bonestroo, Rosene, Anderlik & Associates, Inc. 02530-2 SANITARY SEWER 1.05 SUBMITTALS A. Shop Drawings: Indicating information for fabrication and installation of manholes. B. Certification report for precast structures fabrication and installation. c. PVC Pipe: Certification of resin compounding by pipe manufacturer prior to shipment of pipe to job site. D. Video copy on VHS format of sewer televising and two copies of the written report on conditions. 1.06 SEQUENCING Al'ID SCHEDULING A. Do not pursue work causing shut off of utility services (gas, \-vater, electric, telephone, TV, etc.) to consumers until the utility owner is contacted and all consumers are notified ofthe shut-off schedule. B. Verify vertical and horizontal location of sanitary sewers sufficiently in advance of installing new pipe to determine the extent of conflict, if any. C. Successfully complete required inspections and testing before restoration of surface. D. Commence closed circuit TV inspection after all of the backfill is compacted in place. PART 2 - PRODUCTS 2.01 MATERIALS A. Concrete Materials: 1. Standard Portland Cement Type 1, clean washed sand and crushed rock and gravel free from deleterious materials for monolithic concrete manholes and all manhole bases. 2. Portland Cement: Comply with the requirements of ASTM C150. 3. Design Mix: Subject to the approval of the Engineer. Use proper water- cement ratio to obtain (4000 psi) in 28 days. 34-04-162 :g 2003 Bonestroo, Rosene, Anderlik & Associates, Inc. 02530-3 SANITARY SEWER B. Mortar Materials: 1. Cement: Type 1 Standard Portland Cement conforming to ASTM C150. 2. Lime: Normal finishing hydrated lime meeting the requirements of ASTM C206. 3. Mix Proportions: a. One part cement to three parts of suitable plaster sand for mortar used for plastering the exterior \valls of block manholes and catch basins, adjusting rings and lift holes. Use lime or mortar mix in the amount necessary to make a suitable mixture for plastering purposes, but not to exceed 15 percent by volume. b. One part Portland cement to two parts of sand to which lime or mortar mix may be added but not to exceed 15 percent by volume for mortar used for laying concrete block. C. Reinforcing Steel: Comply with the requirements of ASTM A61S, Grade 60. 2.02 MA_i'ffiOLES A. Requirements: ASTM C478, details on the Dra\vings. B. Stmctures: Precast concrete. Segmental block may be used for the lower portion of stmctures over large pipe with the approval of the Engineer. C. Manhole Joints: Rubber O-ring gasket type or approved equal. D. Segmental Block Manholes: Blocks conform to ASTM C139. E. Stmcture Bases: Pre-cast or poured in place. F. Manhole Steps: 1. Manhole steps may be constmcted of any of the following materials: a. Polypropylene Coated Manhole Steps: 1) Polypropylene molded over steel reinforcing rod and similar in design to the cast iron steps specified may be used. 2) All such steps shall be M.A. Industries (SP-I-PF) Manhole Step, or equal. 34-04- [ 62 :g 2003 Bonestroo, Rosene, Anderlik & Associates, Inc. 02530-4 SANITARY SEWER 2.03 NIAi~rtOLE FRAi.\1ES A'0i'D COVERS A. Requirement: ASTM A48. B. Material: Class 35 cast iron. Best grade. Free from injurious defects and flaws. C. Finish: Coal tar pitch varnish. D. Finish Preparation: Sandblast. E. Machine cover and frame contact surface for non-rocking protection. F. Type and Style: As shown on Drawings. G. Covers with t\vo concealed pick holes of approved design. H. Weight: Minimum of380 pounds. 2.04 PIPE MATERIAL A. PSM Poly (Vinyl Chloride) (PVC) Plastic Pipe and Fittings (4 inch through 15 inch diameter): 1. General: Pipe and fittings conform to ASTM D3034. 2. Materials: PVC plastics having a minimum Cell Classification of 1254B or 12454C or 13364B as defined in ASTM D1784. Pipe materials shall have a minimum hydrostatic design stress of2,000 psi as certified by the Plastic Pipe Institute. Additives and fillers including but not limited to stabilizers, antioxidants, lubricants, colorants, etc. shall not exceed 20 parts by weight per 100 of PVC resin in the compound. 3. Design: Integral wall bell and spigot joint and a minimum wall thickness conforming to SDR 35 and/or SDR 26. 4. Joints: Conform to ASTM D3212. Push-on type only \vith the bell-end grooved to receive a gasket. Elastomeric seal (gasket): a basic polymer of synthetic rubber conforming to ASTM F477. Natural rubber gaskets will not be accepted. 5. Marking: Each pipe shall be identified with the name of the manufacturer or trademark and code, nominal pipe size in inches, the PVC cell classification and "Specification D3034." 34-04-162 :g 2003 Bonestroo, Rosene, Anderlik & Associates, Inc. 02530-5 SANITARY SEWER B. Reinforced Concrete (RCP) Pipe and Fittings: 1. General Requirement: ASTM C76 Wall B with circular reinforcing. 2. Materials: Conform to the requirements ofASTM C76 Wall B with circular reinforcing. O-ring gaskets shall be synthetic rubber, circular in cross-section and conform to ASTM C361. 3. Pipe Joints: Bell and Spigot conforming to ASTM C361. 4. Pipe Class: As shown on the Dra\vings. 5. Marking: Each pipe shall be identified with the name of the manufacturer or trade name or trademark and code, identification of plant, date of manufacture, and the pipe class and specification design. 6. Long Radius Bends: Class ofRCP bends used shall correspond to the class of the pipe used in the respecti ve section of pipe. 2.05 INSuLATION A. Meet the requirements ofMnDOT Spec. 3760 for PolystYTene Insulation Board. PART 3 - EXECUTION 3.01 PREPARATION A. By-Pass Pumping: Contractor shall be responsible for all items required to maintain sewer flows during constmction of the new sanitary sewer line. All work and costs for this are considered incidental to the Project, unless otherwise specified. 3.02 INSTALLATION A. Connect to Existing Structures: 1. Connect to existing structure at location shown on the Drawings. 2. Core the hole in the stmcture, tlimming the pipe flush with the stmcture, trimming the pipe Hush with the pipe to seal it within the wall. 3. Reconstruct manhole bench/invert. 4. Make repairs to the stmcture. 34-04-l62 ':9 2003 Bonestroo. Rosene, Anderlik & Associates. Inc. 02530-6 SANITARY SEWER B. Connect to Existing Pipe: 1. A construction j oint shall be used to connect to the existing pipe as approved by the Engineer in the field. C. Installing Pipe: 34-04-162 :g 2003 Bonestroo, Rosene, Anderlik & Associates, Inc. 1. Excavation and Preparation of Trench: Conform to Section 02320 - Trench Excavation and Backfill. 2. Lay and maintain pipe and appurtenances to the aligmnent, grade and location shown on the Drawings and/or staked in the field. No deviation from the draw'ing and/or staked alignment, grade or location is allowed unless approved by the Engineer. ., J. Permanently support, remove, relocate or reconstmct existing utility pipes, cables, structures or other appurtenances when they obstruct the line, grade or location of the pipe or appurtenance. Do the work in cooperation \vith the owner of the utility. Utility owner will determine \vhich method is to be used. 4, General Pipe Installation Procedure: Use joint lubricant in accordance to manufacturer's instnrctions. Lubricate joint, center spigot in bell, push spigot home, bring pipe to proper line and grade and secure pipe in place by properly bedding. 5. Lay pipe upgrade with spigot ends pointing in the direction of flow. 6. Plug all openings to the installed pipe with suitable stoppers to prevent water, dirt and debris from entering the sew'er. 7 I. Remove all foreign matter or dirt from inside the pipe. Keep the bell and spigot clean during and after installation. Take care to prevent dirt from entering the joint space. Remove any superfluous material from inside the pipe after pipe installation by means of an approved follower or scraper. 8. All joints must be watertight. Repair any leaks discovered. 9. No pipe is to be laid in water or \vhen trench conditions are unsuitable for such work. 02530-7 SANITARY SE'NER D. Installing Structures and Appurtenances: 1. Excavation and Preparation of Trench: Conform to Section 02320 - Trench Excavation and Backfill. 2. Bases: Poured in place structure bases must be acceptably reinforced and cured before placing manhole sections. 3. Invert: Shape to the half section of equivalent size inlet and outlet pipe. Provide free uninterrupted flow. All surfaces slope to flow line. Pre-poured manufactured invert for lines 15 inch or smaller are acceptable if conforming to previous requirements. 4. Steps to be placed 90 degrees from main flo\\! through structure on the downstream side except for pipe of 36 inch or greater. 5. The exterior of all block manholes to be plastered with 1/2 inch of Portland cement mortar. 6. Install short precast section (approximately 1.0 foot, no greater than 1.5 foot) immediately below the eccentric cone or precast top slab. 7. Install Rings: Confornl to Section 02280 - Adjust Miscellaneous Structures. 8. Neatly mortar lift holes. 9. All pipes entering the manhole must be cut with a power saw to provide a clean, smooth pipe surface. E. Installation of Insulation: 1. Insulation over pipe in locations as shown on the Drawings. 2. Insulation is to be placed \vherever sanitary sewer line comes within 3 feet of any storm structure or line or within 5 feet of the ground surface. 3.03 PROTECTION A. Plug all entrances and openings to the system promptly and before suspension of operations at the end of working day. B. Secure manholes and stmctures immediately after completion or before suspension of operations at the end of \vorking day with casting or suitable alternative device. C. Mark structure susceptible to being hit by construction or vehicular traffic. 34-04-162 :g 2003 Bonestroo, Rosene. Anderlik & Associates, inc. 02530-8 SANITARY SEWER 3.04 FIELD QUALITY CONTROL A. Scope: 1. Provide all labor, materials and equipment to perform tests. 2. Engineer to observe and verify all tests and to visually inspect the final work for compliance. B. Cleanup: 1. Clean the pipe and all structures. 2. Bailing or flushing of system allowed \vith approval of Engineer, otherw-ise jetting will be required. 3. Completed prior to Substantial Completion and televising. C. Required Tests and Inspections: 1. Infiltration Test: Construct measuring weirs and devices as necessary and directed by the Engineer. The maximum allowable rate of leakage shall not exceed 100 gallons per mile per inch of diameter per day. 2. Lamping: Engineer will verify installation for true line and grade, joints are home, no broken or deflective pipes exist, the installed pipe is structurally sound, and that the structures conform to the specified requirements. 3. Mandrel Test: As part of the PVC Pipe procedures, perform a mandrel test after the sewer main installation has been completed. A minimum waiting time period of 30 days after the pipe installation is required before the deflection test may be performed. Contractor shall furnish the mandrel, all materials and equipment, and the necessary labor force to pull the mandrel through all lines to verify the integrity of the pipe. The mandrel will be pulled in the presence of the Engineer. A deflection greater than 5 percent of the inside diameter of the pipe is considered a failure. Owner reserv-es the right to measure the deflection ofPVC pipe at any time during the correction period. Deflections greater than 5 percent ofthe inside diameter of the pipe shall be considered failure. Contractor may be required to re-excavate the trench, re-compact the backtill material and restore the surface with no additional compensation for such \vark. 34-04-162 :9 2003 Bonestroo, Rosene, Anderlik & Associates. Inc. 02530-9 SANITARY SEWER 4. Air Test: For PVC Pipe procedures, air test the pipe. Pipe shall be cleaned but may be wetted. Pneumatic balls shall be used to plug the ends at manholes. Low pressure air shall be introduced into plugged line until the internal air pressure reaches 4.0 psig greater than the average back pressure of any groundwater pressure that may submerge the pipe. At least 2 minutes shall be allowed for the pressure to stabilize before readings are taken and the timing started. During this time, check all plugs with soap solution to detect plug leakage. If any plugs are found to leak, air shall be bled off, the plugs shall be retightened and the air shall be reintroduced into the line. The sewer line under test will be accepted as having passed the air test if the pressure does not drop more than 0.6 psig in less time than 1/2 minute per inch in diameter of the pipe being tested. The minimum starting pressure is 3.6 psig. 5. Televise: a. Inspect the installed sewer pipe by televising. 3.05 MEASlJREMENT At'ID PAYTvIENT Bid Items have been provided for the following: A. Sanitary Sew'er Pipe, For Each, Type, Size: Measurement and Payment will be based upon units oflineal feet for each size, type and depth increment 0 feet- 10 feet and in 5 foot increments thereafter, for furnishing and installing pipe complete in place as specified. Pipe will be measured from centerline to centerline of manholes or to the connection point of the existing pipe. B. Sanitary Sewer Manhole Structures: Measurement will be based on the size of the manhole up to a depth of 8 feet. Payment will include the manhole, manhole frame, and casting, in place, as specified on the Dra\vings. C. Manhole Overdepth Above 8 Feet: Measurement will be based on the lineal feet of manhole installed, based on the diameter specified on the Drawings. Payment \vill include the cost of furnishing and installing the manhole sections. D. Connect to Existing Manhole: Measurement \vill be based on units of each connection and incidentals for a complete connection. E. Connect to Existing Pipe: Measurement \vill be based on units of each connection and incidentals for a completed connection. F. No Bid Item has been provided for Closed Circuit TV Inspection: This work is considered incidental to the bid. 34-04- I 62 <9 2003 Bonestroo. Rosene, Anderlik & Associates, Inc. 02530-10 SANITARY SE\VER G. All other work and costs of this Section shall be incidental to the Project and included in the TOTAl BASE BID. END OF SECTION 34-04-162 Q 2003 Bonestroo, Rosene, Anderlik & Associates, Inc. 02530-11 SANITARY SEWER SECTION 02535 SAN1TARY SE\VER SERVICES PART 1 - GEl',r:ERAL 1.01 SECTION INCLUDES A. Sanitary sewer service pipe replacement and all appurtenances. 1.02 RELATED SECTIONS A. Section 02320 - Trench Excavation and Backfill. 1.03 REFERENCES A. American Society of Testing Materials (ASTM): 1. D698 - Test Method for Coefficient of Linear Thermal Expansion of Plastics. 2. DI784 - Specification for Rigid Poly (Vinyl Chloride) (PVC) Compounds and Chlorinated Poly (Vinyl Chloride) (PVC) Compounds. B. American Water Works Association (A'vVWA): 1. C900 - Polyvinyl Chloride (PVC) Pressure Pipe 4 Inch through 12 Inch Water Main. 1.04 SYSTEM DESCRIPTION A. This work shall consist of the construction of sanitary sew.er services in accordance with the requirements of the Contract. 1.05 SlJBMITTALS A. None required. 1.06 PROJECT SITE CONDITIONS A. All work must be contined to within the limits of construction easements, or public right-of-way. B. Verify sanitary sewer service locations with Engineer prior to the start of any construction. 34~04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02535-1 SANITARY SEWER SERVICES 1.07 SEQUENCING AND SCHEDlJLING A. Install sanitary sewer service in same trench as the water service or as directed by the Engineer. PART 2 - PRODUCTS 2.01 MANUFACTURED lJNITS A. PSM Poly (Vinyl Chloride) (PVC) Plastic Pipe and Fittings (4 Inch Through 15 Inch Diameter): 1. General: Pipe and fittings conform to ASTM D3034. 2. Materials: PVC plastics having a minimum Cell Classitication of 12454B, 12454C, or 13364B as defined in ASTM D1784. Pipe materials shall have a minimum hydrostatic design stress of2,000 psi as certified by the Plastic Pipe Institute. Additives and fillers, including but not limited to stabilizers, antioxidants, lubricants, colorants, etc., shall not exceed 20 parts by weight per 100 ofPVC resin in the compound. Certification ofresin compounding shall be provided by the pipe manufacturer prior to shipment to the Project Site. 3. Design: Integral wall bell and spigot joint and a minimum wall thickness conforming to SDR 26 and as shown on the Drawings. 4. Joints: Conform to ASTM D3212. Joints shall be push-on type only\vith the bell-end grooved to receive a gasket. Elastomeric seal (gasket) shall have a basic polymer of synthetic rubber conforming to ASTM F477. Natural rubber gaskets will not be accepted. 5. Marking: Each pipe shall be identified with the name ofthe manufacturer or trademark and code, nominal pipe size in inches, the PVC cell classification, and "Specification D3034." 2.02 BEDDING MA TERl4.L A. See Section 02320 - Trench Excavation and Backfill. 34-04-162 :g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02535-2 SANITARY SEWER SERViCES PART 3 - EXECUTION 3.01 INSTALLATION A. Governing Code: Minnesota Plumbing Code and any local ordinances which may apply. B. Minimum 1/4 inch per foot grade, unless otherwise directed by the Engineer. c. PVC Pipe and Fittings: 1. Similar to main line sanitary sewer pipe installation. D. Terminate 5 feet past property line or as shown on Drawings. E. Record Actual Depth at End of Service: 1. Exercise care in determining the depth. 2. The depth recording is incorporated into the "Record Drawings" and becomes a permanent part of City Records. F. Plug ends with 4 inch plug and necessary blocking. 3.02 FIELD QUALITY CONTROL A. Do not backfill trench until the service has been inspected and approved by the Engineer. 3.03 PROTECTION A. Mark end of new service with a wooden 2 inch x 2 inch x "variable" marker: 1. Extend 6 inches below and adjacent to the plug. Extend 2 feet above the ground line. 2. Continuous without any breaks. 3. Vertical or plumb. 34-04-162 @ 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02535-3 SANITARY SEWER SERV1CES 3.04 MEAST.JREMENT Ai\JD PAYMENT A. Bid Items have been provided for 4 Inch PVC, SDR 26 Service Pipe. Measurement will be by linear foot of pipe installed as measured along the axis of the pipe with no regard to intervening fittings. Payment at the Bid Unit Price shall be compensation in full for all work and costs, including excavation, pipe, bedding, backfill, and trench compaction. B. No Bid Items have been included for Service Plugs, or Marking Service Ends. Payment for these items shall be included in the lineal foot price for 4 Inch PVC Service Pipe. C. All other \vork and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. Ef-,;TI) OF SECTION 34-04-! 62 @ 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. 02535-4 SANITARY SEWER SERVICES SECTION 02630 STORLvl DRAINAGE PART 1- GENERA.L 1.01 SECTION INCLUDES A. Storm sewer pIpe, manholes, catch basins, fittings, and miscellaneous appurtenances. 1.02 RELATED SECTIONS A Section 01310 - Proj ect Management and Coordination. B. Section 01570 - Erosion and Sediment Control. C. Section .02280 - Adjust Miscellaneous StruchIres. D. Section 02315 - Excavation and Fill. E. Section 02320 - Trench Excavation and Backfill. F. Section 02635 - Subsurface Drainage. G. Section 02720 - Aggregate Base Course. H. Section 02770 - Concrete Curb and Gutter. 1.03 REFERENCES A. American Society of Testing and Materials (ASTM): 1. A48 - Specification for Gray Iron Castings. 2. A153 - Specitication for Zinc Coating (Hot-Dip) on Iron and Steel Hardware. 3. C76 - Specification for Reinforced Concrete Culvert, Drain, and Se\ver Pipe. 4. C139 - Specification for Concrete Masomy Units for Constmction of Catch Basins and Manholes. 5. C150 - Specification for Portland Cement. 6. C206 - Specification for Finishing Hydrated Lime. 34-04-162 :g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02630-1 STOR.c'vl DR.c"..fNAGE 7. C361 - Specification for Reinforced Concrete Low Head Pressure Pipe. 8. C443 - Specification for Joints for Circular Concrete Se\ver and Pipe, Using Rubber Gaskets. 9. C478 - Specification for Precast Reinforced Concrete Manhole Sections. 10. D 1 784 - Specification for Rigid Poly (Vinyl Chloride) (PVC) Compounds and Chlorinated Poly (Vinyl Chloride) (CPVC) Compounds. 11. D3212 - Specification for Joints for Drain and Sewer Plastic Pipe Using Flexible Elastomeric Seals. 12. F477 - Specification for Elastomeric Seals (Gaskets) for Joining Plastic Pipe. 13. F794 - Specification for Poly (Vinyl Chloride) (PVC) Profile Gravity Sewer Pipe and Fittings Based on Controlled Inside Diameter. B. IvIinnesota Department of Transportation "Standard Specifications for Constmction," 2000 Edition (MnDOT Spec.): 1. 2511 - Rip Rap. 2. 3601 - Rip Rap Materials. 3. 3733 - Geotextiles. 1.04 SEQtTENCING Al"fD SCHEDULING A. Do not pursue work-causing shut off of utility service (gas, water, electric, telephone, TV, etc.) to consumers until the utility owner is contacted and all consumers are notified of the shut-off schedule. B. Successfully complete required inspections and tests before commencement of Section 02720 - Aggregate Base Course and Section 02770 - Concrete Curb and Gutter. 34-04-! 62 :9 2004 Bonestroo, Rosene, .Ju1derlik & Associates, Inc. 02630-2 STORey! DRAiNAGE 1.05 SlJBMITTALS A Conform to Section 01310 - Proj ect Management and Coordination. B. Shop Drawings: 1. All storm sewer structures. C. Manufacturer's Certificate of Compliance for: 1. Gray iron castings. 2. Precast manhole sections. 3. Rip rap. P ART 2 - PRODUCTS 2.01 MATERIALS A. Mortar Materials: 1. Cement: Use Type 1 Standard Portland Cement conforming to ASTM C150. 2. Lime: Use normal finishing hydrated lime meeting the requirements of ASTM C206. 3. Mix Proportions: a. 1 part cement to 3 parts of suitable plaster sand for mortar used for plastering the exterior walls of block manholes and catch basins, adjusting rings, and lift holes. Use lime or mortar mix in the amount necessary to make a suitable mixture for plastering purposes, but not to exceed 15 percent by volume. b. 1 part Portland Cement to 2 parts of sand to which lime or mortar mix may be added, but not to exceed 15 percent by volume for mortar used for laying concrete block. 34-04-162 '9 2004 Boncstroo, Rosene. Anderlik & Associates, Inc. 02630-3 STORivI DRi>\INAGE 2.02 STORlvl :NLt\1'ffiOLE ,t\1'\'D CATCH BASIN F~t\1vIES AL'\'D COVERS A. General: 1. Requirement: ASTM A48. 2. Material: Class 35 cast iron. Best grade. Free from injurious defects and flaws. 3. TY'Pe and Style: ...A.s sho\vn on Dra\ving. Covers \vithollt grate openings shall be stamped "STORM SEWER." 4. Covers \vith 2 concealed pick holes of approved design. 5. Weight: Minimum of 380 pounds. 2.03 STORM MANHOLES AL"iTI CATCH BASINS A. General: 34-04-! 62 it 2004 Bonestroo, Rosene, .A.nder!ik & Associates, Inc. 1. Requirements: ASTM C478, details on the Drawings. J Diameter and special requirements are shown on the Drawings. ..., J. Structures shall be of precast concrete. ;1 '"T. Segmental Manhole Blocks: Blocks conform to ASTM C139. Segmental block may be used for the lower portion of structures over large pipe only when approved by the Engineer. 5. Manhole Joints: Rubber a-ring gasket type meeting ASTM C443. 6. Segmental Manhole Blocks: Blocks conforn1 to ASTM C139. .., I. Structure bases shall be pre-cast. 8. Manhole Steps: Reinforced polypropylene plastic steps with No. 2 deformed grade steel rod. 02630-4 STORM DRAINAGE 2.04 PIPE MATERL4.LS A. Reinforced Concrete (RCP) Pipe and Fittings: 1. General Requirement: ASTM C76 Wall B with circular reinforcing. 2. Materials: Conform to the requirements of ASTM C76, Wall B with circular reinforcing. O-ring gaskets shall be synthetic rubber, circular reinforcing in cross-section, and shall conform to ASTM C361. 3. Pipe Joints: Bell and spigot ASTM C361. 4. Pipe Class: Class 3, unless othenvise noted on the Drawings. 5. Marking: Each pipe shall be identified with the name of the manufacturer trade name or trademark and code, identification of plant, date of manufacture, and the pipe class and specification design. 2.05 TRA.SH GUARDS A. General: 1. General Requirement: ASTM A153. 2. Materials: Galvanized steel rods meeting the requirements m ASTM A153. 3. Bar size and configuration as shown on the Draw'ings. 4. Securely attached to end section. 2.06 RIP R.A.P A General Requirement: Conform to MnDOT Spec. 2511: 1. Riprap Materials: Conform to MnDOT Spec. 3601. 2. Granular Filter: Conform to MnDOT Spec. 3601. 3. Geotextile Filter: Conform to MnDOT Spec. 3733. 4. Grout: Conform to MnDOT Spec. 2461. 34-04-162 '&; 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02630-5 STORi'vl DRAINAGE PART 3 - EXECUTION 3.01 PREPARATION A. Trench Excavation and Backfill shall conform to Section 02320 - Trench Excavation and Backtlll. B. By-Pass Pumping: Contractor responsible for all items required to maintain sew'er flows during construction of the new storm sewer. All work and costs for by-pass pumping is considered incidental to the Project, unless otherwise specified. 3.02 INSTALLATION A. Connect to Existing Structure: 1. Connect to existing structure at location shown on the Dra\vings. 2. Core the hole in the structure and saw cut the pipe flush with the inside wall of the structure. 3. Bulkhead void between outside wall of pipe and edge of opening with mortar and brick. 4. Reconstruct manhole bench/invert. B. Connect to Existing Pipe: 1. Connect to existing pipe at locations shown on the Drawings. 2. Locate and expose end of existing pipe. 3. Remove existing bulkhead or plug and dispose of offsite: a. Take care not to damage existing pipe. b. Any segment of pipe damaged by Contractor shall be replaced with ne\'l materials at no expense to the Project. 4. Utilize standard bell and spigot joint with mbber a-ring gasket if possible. 5. If butt connection must be made to existing pipe, construct concrete collar around joint. Collar shall be minimum 12 inches thick in all locations and shall extend a minimum of 12 inches each \'lay of the joint. 34-04-162 Q 2004 Bonesrroo, Rosene. Anderlik & Associates, Inc. 02630-6 STOfu\>[ DRA.INAGE C. Pipe Installation: 1. Lay and maintain pipe appurtenances to the alignment, grade, and location shown on the Drawings and/or staked in the field. No deviation from the Drawing and/or staked alignment, grade, or location is allowed, unless approved by Engineer. Deviation from grade in excess of 0.05 percent may be cause for removal and relaying pipe at the Contractor's expense. 2. General Pipe Installation Procedures: a. \Vipe joints clean; apply the manufacturer's recommended lubricant compound over the entire joint surface; center spigot in bell and push spigot home; take care to prevent dirt from entering the joint space; bring pipe to proper line and grade, and secure pipe in place by properly bedding. 3. Lay pipe upgrade with spigot ends pointing in the direction of flo\v. 4. All joints must be watertight. 5. Remove all foreign matter or dirt from inside the pipe. Keep the bell and spigot clean during and after installation. Take care to prevent dirt from entering the joint space. Remove any superfluous material from inside the pipe after pipe installation by means of an approved follower or scraper. 6. \Vhere cut-ins make it impossible to construct bell and spigot joints or when dissimilar pipe materials are joined, a reinforced concrete collar shall be placed completely surrounding the joint or the connection shall be made by using an approved adapter. 7. Any pipe which has been disturbed after being laid must be taken up, the joint cleaned and properly relaid as directed by the Engineer. D. Stmctures and Appurtenances Installation: 1. Furnish and install stnrctures in accordance with the Drawings. 2. Excavate to depth and size as shown in the Drawings. 3. Pour inverts shaped to the half section of equivalent size pipe conforming to the inlet and outlet pipe so as to allow' for a free, uninterrupted flow with all surfaces sloping to the flow line. 4. Preformed inverts not allowed w-here pipe grades are 2 percent or greater, unless design grade is built through the manhole. 5. All concrete pipes entering manholes must be cut \'lith a concrete saw. 34-04-162 :9 2004 Bonestroo, Rosene, Ander!ik & Associates, Inc. 02630-7 STOfuv! DfuA.L'iAGE 6. Steps: a. Locate on the downstream side except for pipe 24 inches in diameter or greater. Then place where most appropriate to provide the most suitable access. b. Secure and neatly mortar in place 15 inches on center spacing. 7. Position vertical wall of the eccentric cone on the do\vnstream side. 8. On structures with a build that contains more than 1 barrel section, the section immediately below the precast top slab shall be maximum 16 inch height. 9. Lift holes neatly mortared up. 10. Install Adjustment Rings and Adjust Casting: Conforming to Section 02280 - Adjust Miscellaneous Structures. E. Riprap: 1. General: Conform to MnDOT Spec. 2511. F. Bulkhead Pipe: 1. Bulkhead pipe with brick, non-shrink concrete grout, or concrete block masomy 8 inches thick. 2. Precast concrete plugs may be used in lieu of bulkhead. Plug must fit snugly into pipe opening and be watertight. 3.03 FIELD QUALITY CONTROL A. Scope: 1. All pipeline testing is considered incidental to the Bid cost of the pipe. 2. Engineer to observe and verify that all tests and visual inspections have been completed prior to final acceptance. B. Cleaning: 1. Consists of Cleaning the Pipe and Stmctures: 34-04-! 62 &; 2004 BonestToo, Rosene, Anderlik & Associates, Inc. 02630-8 STORiv[ DRi~INAGE a. If newly installed mains and structures are kept clean during constmction, cleaning will not be required. b. If newly installed mains and/or structures become dirty due to negligence of the. Contractor, cleaning \vill be performed at the sole expense of the Contractor. 2. The bailing or flushing method of cleaning pipe IS acceptable only if adequate provisions, acceptable to the Engineer, for keeping dirt and debris out of the existing sewer system or ponds are employed. Jetting may be required. 3. Complete prior to final inspection for acceptance. C. Required Tests and Inspections: 1. Infiltration: a. To determine the amount of ground water infiltration into the sewers. b. T est waived if no visible infiltration IS observed during the lamping inspection. c. Measurement made by means of 90 degree v-notch weirs placed in the lines as directed by the Engineer. d. Measurements taken at the points where in the Engineer's opinion the flow of water in the sewer is greater than the maximum allowable leakage. e. Maximum Allowable Rate of Leakage: Not more than 100 gallons per mile per inch diameter per day. f Tests may be taken between individual manholes and the infiltration in any given line must not exceed the specitied maximum allowable rate. g. Method of Measurement: Measurement of time for a predetermined volume of flow to occur. 2. Lamping: a. Verify installation is to tme line and grade. b. Verify installed pipe is structurally sound. ];;:1-04-162 ':9 2004 Bonestroo, Rosene. Anderlik & Associates, Inc. 02630-9 STOit\1 DRAIi'iAGE c. Verify there are no broken or deflective pipe. d. Verify that joints are all home. e. Verify structures conform to specified requirements. 3. Mandrel Test: (If using PVC or HDPE Storm Sewer Pipe): a. Perform on PVC or HDPE main after installation has been completed. b. Minimum wmtmg period of 30 days after completion of installation prior to performing test. c. Contractor to furnish the mandrel and all labor, materials, and equipment necessary to perform the test. d. Engineer must be present during pulling of the mandrel. e. Deflection of inside diameter of pipe in excess of 5 percent shall be considered failure of the test. f. Contractor shall repair / replace any failing segment of main such that it successfully passes the test. All costs for such work, including but not limited to excavation, new materials, and restoration of surface to existing condition shall be the sole expense of the Contractor. g. Owner reserves right to measure deflection of PVC pipe at any time during the warranty period. If at any time during the w.arranty period, the inside diameter of the pipe deflects in excess of 5 _ Percent the Contractor shall remove and replace the pipe at their expense. 3.04 PROTECTION A. Plug all entrances and openings to the system promptly and before suspension of operations at the end of working day. B. Secure manholes and structures immediately after completion, or before suspension of operations at the end of \vorking day with castings, or suitable alternative device. C. Mark all stmctures to avoid being hit by construction, or vehicular traftlc. D. Mark each plug location with 4 inch x 4 inch timbers to above grade to aid in marking the future connection. 34-04-162 &; 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02630-10 STORc'vI DRc\lNAGE E. Establish erosion control measures as per Section 01570 - Erosion and Sediment Control. 3.05 l\tlEAS1JREMENT A1~TI P A YNIENT A. Bid Items have been provided for Storm Sewer Pipe. Measurement will be based upon units of lineal feet for each size, type, and class of pipe furnished and installed complete in place as specified, including excavation, backfilling, and compaction. Pipe will be measured from centerline of structure to centerline of structure: 1. Pipe bedding will be paid in accordance with Section 02320 - Trench Excavation and Backfill. 2. In1proved pipe foundation material, if necessary, shall be per Section 02320 - Trench Excavation and Backfill. 3. For Pipe Sizes 12 Inches to 18 Inches: PVC or RCP allowed. 4. For Pipe Sizes Greater than 18 Inches: RCP allowed. B. Bid Items have been provided for Catch Basin, Catch Basin Manhole, and Storm Manhole. Measurement \vill be based upon units of each, according to type and size, to a depth of 8 feet, for furnishing and installing structures complete, including casting frame and cover, and adjusting rings in place as specified. C. A Bid Item has been provided for Reconstruct Storm Sewer Manhole Invert. Measurement will be based upon units of each. D. Bid Items have been provided for Connect Storm Pipe to Existing Structure. Measurement shall be per each connection made, regardless of size of opening, size of the pipe, type of existing bulkhead, type of existing structure, or type of pipe. Saw cutting of the pipe installed in the opening, if necessary, shall be considered incidental. Core cutting the connection and reconstruction of existing structure invert, if necessary, shall also be considered incidental to the connection. E. A Bid Item has been provided for Yard Drain. Measurement will be based upon units of each, according to type and size for furnishing and installing structures complete, including casting frame and cover, and adjusting rings in place as specitied. F. A Bid Item has been provided for 4 Feet Diameter Stmcture Overdepth. Measurement \vill be by the lineal foot of structure depth from the top of casting to the poured invert minus the standard 8 foot depth. Payment shall include all materials and work required for the installation. 34-04-162 &; 2004 Bonesrroo, Rosene, Anderlik & Associates, Inc, 02630-11 STOR,,,l DRf\INAGE G. A Bid Item for Flared Ends of Each Size has been provided on the Bid Form. Measurement will be based upon units of each size installed at locations indicated in the Drawings complete in place as specified, including trash guard, excavation, backfilling, and compaction. F. A Bid Item for Rip Rap Placed at Flared End Sections has been provided on the Bid Form. Measurement will be based upon units of cubic yards of rip rap placed for each class of rip rap including geotextile fabric. H. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. E0<'D OF SECTION 34-04-162 :9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02630-12 STOR.,v! DR."'.fNAGE SECTION 02635 SlTBSURFACE DR.A.INAGE PART 1 - GENERAL 1.01 SECTION INCLUDES A. Storm sewer service. B. Drain tile. 1.02 RELATED SECTIONS A. Section 02320 - Trench Excavation and Backfill. B. Section 02630 - Storm Drainage. 1.03 REFERENCES A. American Society of Testing and Materials (ASTJ'v1): 1. D1784 - Rigid Poly (Vinyl Chloride) (PVC) Compounds and Chlorinated Poly (Vinyl Chloride) (PVC) Compound. 4. F758 - Smooth-Wall Poly (Vinyl Chloride) (PVC) Plastic Under Drain Systems for Highway, Airport, and Similar Drainage. B. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (MnDOT Spec.): 1. 3149 - Granular Material. 2. 3733 - Geotextiles. 1.04 SEQUENCING Al\D SCHEDULING A. Install sanitary sewer, water main, storm sewer, and all pipe deeper than the services prior to the installation of the services. 34-0.:1-162 ,~ 2004 Bonesrroo, Rosene, ,"u1derlik & Associates, Inc. 02635-1 SUBSURFACE DRAINAGE PART 2 - PRODUCTS 2.01 PVC PIPE AND FITTINGS A. Drain Tile: 1. General Requirement: ASTM F758. 2. Materials: Minimum Cell Classification of 12364C as defined in ASTM DI784. 3. Classitication: Minimum pipe stiffness of 46. 4. Joints: Gasket-Type Joints meeting ASTM D3212. 5. Perforations: Circular on 3-1/4 x ::i: 1/4 inch centers. Hole size maximum of 3/8 inch and a minimum of 3/16 inch, arranged in 4 rows along the full length of the pipe. 2.02 BEDDING MA TERlAL A. Granular Borro'w meeting MnDOT Spec. 3149.2B 1 Modified: 1. 100 percent passing by weight the 1 inch sieve. 2. Furnished by Contractor from a location located off the Project Site. 3. No onsite granular material encountered during construction may be used. 2.03 PIPE DRAIN AGGREGATE A Course Filter Aggregate conforming to MnDOT Spec. 3149.2H. 2.04 GEOTEXTILE A. Geotextile vVrap shall conforn1 to MnDOT Spec. 3733, Type 1. 34-04-! 62 ;:g 2004 Bonesrroo, Rosene, Anderlik & Associates. Inc. 02635-2 SUBSURFACE DRAINAGE PART 3 - EXECUTION 3.01 GENERAL A. The location and alignment of the subsurface drains and outlets are shown in a general manner on the Draw'ings. Exact location and alignment to be determined by the Engineer. 3.02 DRAIN TILE INSTALLATION A. Conform to details on Drawings. B. Construct at locations and elevations determined by Engineer or as shown on the Drawings. C. Pipe Bedding: Drain pipe aggregate. D. Grade: Unless otherw'ise specified or shown on the Drawings, the grade of pipes shall not be flatter than 1 in 250. E. Plug upstream end of the drain pipe. F. Sections of the drain pipe shall be firmly joined. G. If perforated drain pipe is used, the pipe shall be placed so that the perforations are in the position indicated on the Drawings or designated by the Engineer. H. Connections: Connect to hole provided in precast structure. Seal joint with mortar: 1. Core drill connection to stmcture where precast hole is not provided. 1. Compaction: Confornl to Section 02320 - Trench Excavation and Backfill. J. Flushing: After installation has been completed, pipes shall be flushed with sufficient water to remove material that has entered the pipes during constmction. 3.03 FIELD QUALITY CONTROL A. Do not backfill trench until the pipe has been inspected and approved by the Engineer. 34-04-! 62 ':9 2004 Bonestroo, Rosene. Anderlik & Associates, Inc. 02635-3 SlTBSURFACE DRAINAGE 3.04 METHOD OF MEASUREMENT AND PAYMENT A. A Bid Item has been provided for 4 Inch Perforated PVC Drain Tile. This Bid Item shall be used for installation of drain tile for sub grade drainage within street areas. Measurement will be by linear feet of pipe along its axis with no regard to intervening fittings. Payment shall include geotextile, aggregate, and fittings. B. A Bid Item has been provided for Connect Drain Tile to Existing Structure. Measurement will be per each. Payment will include all costs related to core drilling a hole in the storm se\ver structure, making the connection, and patching as specified. C. All other \vork and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. E0.TI OF SECTION 34-04-! 62 9 2004 BonestroQ, Rosene, Allderlik & Associates, Inc. 02635-4 SlfBSURFACE DR..AfNAGE SECTION 02720 AGGREGATE BASE COURSE PART 1 - GENERAL 1.01 SECTION INCLUDES A. Requirements for aggregate base course on a prepared sub grade. 1.02 RELATED SECTIONS A. Section 02318 - Subgrade Preparation. B. Section 02740 - Plant Mixed Asphalt Pavement. 1.03 REFERENCES A. Minnesota Department of Transportation "Standard Specifications for Constmction," 2000 Edition (MnDOT Spec.): 1. 2211 - Aggregate Base. 2. 3138 - Aggregate for Surface and Base Courses. 1.04 SUBMITTAl A. Submit gradation report on sample of aggregate base to be used. 1.05 SEQlJENCING ANTI SCHEDuLING A Construct aggregate base only after all of the following have been completed: 1. S ubgrade has been corrected for instability problems and successfully passed a test rolling test performed by the Contractor and witnessed by the Engineer. 2. Subgrade has been checked for conformance to line and grade tolerances (stringline) . P ART 2 - PRODUCTS 2.01 MATERiALS A. Aggregate Base: Conform to MnDOT Spec. 3138, Class 5 aggregate. 34-04-[62 ::9 2004 Bonestroo, Rosene, Ander!ik & Associates, Inc. 02720-1 AGGREGA IE BASE COURSE B. Aggregate Base, Salvaged Reclaimed Material: Material generated from reclaiming the existing bituminous pavement with the existing aggregate base. Conform to MnDOT Spec. 313S, Class 5. Pi~RT 3 - EXECUTION 3.01 PREPARATION A. Prepare the subgrade in accordance with Section 0231S - Sub grade Preparation. B. Sub grade and select granular borrow to be completed and approved by the Engineer prior to installation of aggregate base. C. Reclaim the existing pavement and aggregate base in accordance with Section 02965 - Reclamation. Stock Pile reclaimed material. 3.02 CONSTRUCTION REQUIREMENTS A. Conform to MnDOT Spec. 2211.3: 1. Compact by mechanical means to 100 Percent Standard Proctor Density. 2. Install aggregate base in accordance \vith details on Drawings. 3. Place the salvaged reclaimed material at the bottom of the typical section. 4. Place new Class 5 on top of the salvaged reclaim material. 3.03 FIELD QUALITY CONTROL A. The Owner shall have an independent testing laboratory sample the aggregate base materials, determine the moisture/density relationships and gradation, and perform field moisture/density tests at locations determined by Engineer. B. Line and Grade Tolerance: The final aggregate base surface vvill be checked for conformance to specified tolerances by the "stringline" method prior to approval to pave the surface. Grade shall be i: 0.03 feet of grade. 3.04 PROTECTION A. Protect aggregate base until it is covered by surface pavement. B. Keep aggregate base free of ruts and irregularities until covered by surface paving. C. Place water on aggregate base for dust control as required to eliminate nuisance conditions for adjacent properties. 3:1-04~ 162 .9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc 02720-2 AGGREGATE BASE COURSE 3.05 MEAS1.JREMENT AL~TI PAYNfENT A. A Bid Item has been provided for Aggregate Base, Class 5 (CV). Aggregate Base shall be paid for by the number of cubic yards calculated from the design widths, depths, and lengths. Payment at the Bid Unit Price shall include material, placement, compaction, \vater, and all items incidental to complete aggregate construction. No payment shall be made for additional material used due to low sub grades, spillage, tolerances, etc. B. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 34-04-! 62 .:9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02720-3 AGGREGATE BASE COURSE (2360) PLANT MIXED ASPHA.L T. PAVEMENT Combined 2360i2350 (GyratoryiMarshall D,,esign) Specification For 2004 Construction Seas)o This Speciticadon requires the Contractor to provide: mix that complies with aU of the design, production, and placement ,eq llircmcnts of the speci ficdion. The D"ila!ffilen~' Owner does [lot make any g'.larmty or warranty, either express or implied, iliat compliance with one part ofbis specification guarantees that the Contractor will meet the other aspects of the specification. :2360.1 AU Sections titled 2360 also apply to 2350. DESCRIPTION This work consists of the construction of one or more pavement courses of hat plant mixed asphalt-aggregate mixture on the approved prepared foundation, base cc:urse or existing surface in accordance with the specitications and in confoImity with the lines, grades, thicknesses "~ad typical cross sections ShO\Vil on the plans or ~stablished by the Engineer. Mixture desigr: will he either 2360 or 2:' 50 (gyTatory or Marshall) as described in the ~~Pmr:~,iGr;~ j)r;;l';,illg,:i.:hrough the mixture designation. A ylixture Designations ML'(ture designations for asphalt mixtures cof1tain the following L.l1formation: ( I ) The fust two letters indicate the mixture design type: Sl' = GYTalury Mixlur:: Deslgn LV = Marshall Mb:ture Design - Low Volume, 50 bt..\-v :MV = Marshall Mixture Design -- Medium Volume, : 0 blow SM = G)Tatory Mixture Design for Stone Matrix Aspilalt (SMA.) (2) The t.1ird and fourth leuers indicate the course: WE = Weari.,Ilg and Shoulder Wearing Course NW = Non-Wearh'1g Course (3) The fuib. lene! or number indicates the maximum agg'egate size": A or 4 == 12.5mm [1/2 inch], SP 9.5 mm [3/8 inch]U B or 3 == 19.0mrn [3i4 inch], SP 12.5 mrn [112 inch]'" Cor 2 = 2S.0mril [1 inch], SF 19.0 illlll [314 inch]"''' 5 = 9.5m.m [3/8 inch], 4.75 mm [#4] nominal sze (Marshall design only) E = See provision for S?vL\ design ~ Letter is used in gyratory designation; number is us" d in Marshall designation "" 'Nominal maxil11um aggregate size (4) For Gyratory Design: The sixth di.git indicates the Traffic Level (ESAL's x toO) Th~ requirements for gyratory mixrures in this speciti :ation are based on the 20~year design traffic level of th~ Project expressed in Equival~m Single A,;;Je Loads (ESAL's). The five traffic levels are shmvn below in Table 2360.L-i\. 2360/2350 Combined Specification December Y, 2003 T ndlic Level 2' Table 2360.1-A Traffic Levels 20 Year Desi2TI ESAL's (l x to' ESAL's) < 1 l to <: 3 to < 1 ) 10(0<::0 SMA .. -. - - ... y 4 5 6 l -- (.~Af)T #- 2300) 2 -- (2300< A.ADT <6000) For Marshall Design: The sixth and seventh digit indicate the Marshall desigr blows: 50 blow design tor borb LV and rviV mixtures (5) The last two digits indicate rbe air void requITf:rnem: 40 = 4.0% for SP and S~1 Wear mixtures 35 --- 3.5% for MV Wear and \ou-Wear 30 = 3.0% for LV Wear and Non-Wear and SF Non-Wear fu'1d Shoulder (6) The letter at the end of lie mixture designc.tion identifks the asphah binder grade: A. = PO 52-34 B = PO 58-28 C = PO 58-34 D -= PO 58-40 E = PCI 64-28 F = PO 64-34 o - PO 64-40 H == PO 70-28 I = PO 70-34 L = PO 64-22 Ex: Gyratory MLxture Designation -- SPW"EB540E (Design Type, Lift, A~g Size, Trafflc Level. Voids, Binder) Ex: Marshall Mixture Designatioo- L Vw"E35030B (Nii" T;;pe, Lift. Agf Size, Marshall blows, Voids. Binder) Ex: SM.A. Nli'\.-:ure Designation -- SMW'CE6dOH (Design Type, Lift, Agf Size, Traffic Level, Va ids, Binder) B Minimum Lift thickness jvl.ini.'11um paving lift thickness will be based on maxiffiilffi aggregate size: Aggregate Size A, 4"; B, J~: Aggregate Size 5": Aggregate Size C, 2* (for non-wear only): " Marshall designation ML'1lmum Lift thickness"" 40 mm [1 V: inch] yfinimum :"ift thickness = 20 mm l3/4 inch] y[inimwn :"'ifc thickness = 65 m.rn [2 ~I:: inch] 2360.2 l\'L.\ TERIALS A Aggregate Al General The aggregate shall consist or sound, durable particles (f gravel and sand, crushed stone and sand, or combinations th~ri;;:Qf. It shall be fr.;e of objectionable matter such as c:ceta!, glass, wood, piastlc, brick, rubber, and any ocher macerial baving si...rnilar characterisGcs. Coarse aggregate shail be free Erom coatings of clay and silt to the satisfaction of me Engineer. Page 2 of 4:) 1.360/2350 Combined Specification December 9,2003 The Contractor sha!\nor compcnsatt:: for th::: lack of fl.'leS by adding soil materials such as clay, loam, or silt. Overburden shail not be blended into the asphalt aggrcgat-:. Each different material (source, class, kind, or size) Sf all be fed at a uniform rate from its storage uni.t. }..n individual source, class, type, or size ot'marerial shall not be sl xkpile blended with another sou.rce, cla;s, ty-pe or size of mareriaL A2 Classification The aggregate shall conform to one of the followi.ng classificati.ons. The class of aggregate to be used shall be the Contractor's option unless otherwise speciried in the Cmrract. Ala r:lass A Class A aggregate shall consist of crushed igneous bee rock (specifically; basalt, gabbro, granite, rbyolite, diorite and an.dosite) and rock from the Sioux Quanzite format on. Other igneous or metamorphic rock may be used ',.vith specific approval of the Engineer. Class A materials !!lay comain no more rhan 4.0% non-Class A aggregate. TbJs recognizes the fuel. that semc quarries may contam sma i pockets of Jon-Class A material within tb.at source. Intentional blending or addition ofTIon-Class A material is ;-trictly prohioitcd! A2b Class B Class B aggregate shail consist of crushed rock from a: 1 ocher bedrock sources such as carbonate anti metamorphic rocks. (gneiss or schist) A2e Class C Class C aggregate shall consist of natural or partly cI"..l:'!led natural gravel obtained from a natural gravel deposit. A2d Class D Class D aggregate shall consist of 100 percenr crushed namral gravel. The crushed gravel shall be produced from material retained on a square mesh sieve having an openhg at least twice as large as the Specification pen-nits for the ma.ximum siZt: or the aggregate in the comF )site asphalt nllXD.lrc. The a.-:nount of CaITfover (material finer than) the selected screen shall not exceed ten percent. A2e Class E Class E aggregate shalJ consist of a mi:>..1:ure of any tv..'O or roore of the above classes of approved aggregate (A, B, and 0). The use of Class E aggregate, as well as the relative proportions of th~ di fti:rent constiment aggregates, shaH be subject to the approval of the Engineer. '''he relativc proportions of the constituent aggregates shall be accurately controlled either by the use of a blending l:elt approved by the Engineer prior to production or by separately weighing each aggregate duril1g batching operations. A2f Steel Slag Steet slag may not exceed 25 percem of the lIlass of the toral aggregate. Stockpiles wi\! be accepted for use if the total expansion, detennined by ASTM D4792, is Lss than 0.50%. A2g Taconite Tailings (TT) Taconite railings shall be obtained from ore that is min d westerly of a north-south line located ea","t ofBiwabik, 1vL.'1 (R15\V-RI6'vv"); except thar (aconite railings from ore mined in southweslem Wisconsin will also be permitted for use. Page ::3 of 4S 2360/2350 Combined Specification December 9, 2003 Approved taconite tailing sources are on tile with the L'ep:mment Bituminous Engineer. A2h Scrap Asphalt Shingles Scrap asphalt shingles may be included in both wear ar d non-wear courses to a maxL'1lUm of 5 percent ofille total weig...ht of mixture. Only scrap asphalt shingles fromnanufacturing waste are suitable. TIle percentage of scrap shingles used '.\fill be considered par: of the maxL-:nun allowable RAP percentage. Refer to Section 2360.2 G 1 to select a virgin asphalt bi....der grade (use requiremerts for> 20% RA P, regardless of total RAP/shingle percentage). Scrap Shingle Specifications are on file in the Bitumi..'1ous Office. A'l' ...1 Crushed Concrete and Salvaged Aggregate Crushed concrete is allowed as an aggregate source fOJ up tu 50 percent of the aggregate in non-wear mixtures. Crushed concrete is not allowed in wearing courses. Salvaged aggregate is allowed as an aggr;;:gcle source br up to 1 00 percent of the aggregate in wear and non-wear mixtures. All sdv<1ged <1ggr~gatt: shall be stockpiled uniformly to limit variation in mL\:turc properties. Salvaged aggregates shall meet qu<:.li,' <1nd crushing requirer:len:s as s?ecified herein. A2j Waste Incinerator Ash (\VL"-) \Vaste incinerator ash is al10wed as ar. aggregate sourc: in both ,vear and non-wear courses to a oaximum of 5 percent of the total weight of mixture. Only \VIA that illt:ets the Tier II hazard evaluation criteria as approved by .\1nIDOTs Office of Environmental Servic:;s, Envlronmenr: I Analysis Section, wiE be altowed for use in the mixlure. Approved waste incinerator ash sources arc on file witi; the Department Bituminous Engineer. A3 Recycled Asphaltic Pavement Materials (RAP) The combined RAP aDd virgin aggregate shall meet lb.. composite fine aggregate angularity or calcdated cnlshed requirements (both coarse and tine aggregate) for the nixture being produced (calculated crusbed allowed ror Marshall d<::sign only). K.'\J' contailling any objectionable mlteriaL i.e., road tar, metal, glass, wood, pl[l5~ic, brick. fabric, or any other objectionable mareriai having similar c )2I9.cteristlcs will not be permitted for use iIl. the asphalt pavement miC<.LUre. .:.,sphalt binder coment in the RAP shall be detennined according to Mn/DOT Lab Manual Method 1851 or 1852. B Manufactured Crushed Fines (-4 material) All Class A, B, 0, and E material that passes the 4.75 nrn [#4] screen \"ill be cODsidered as crushed fines. Munubdurd Crushed Filles (-4 material) from Class I; Aggregate. Produce manufactured crushed tilles (-4 material) from a gravel source by passing the gravel ov:r a selected screen, 9.5 nun [3/8 inch] or larger, prior to mecha[1ical crushi.ng. The material which passes the 9.5 nm [3/8 incb] screen shall not be incorporated into the ma:.-lUfuctured crushed fmes bur may be used as it q!lalifies for natural sand. Tne amount of carryover (matt:rial finer than) the selected screen shall not exceed ten pucent. Tne material retained on the 9.5 mm [3/8 inch J screen;hall be crushed. The material that passes the 4.75 mm [#4J scrt:en, after crushing, will be considered as [00% en!: :led fInes. Mau:rial retained on the 4.75 ram [#4] Sc:'een after crushing ""ill not be cOlU1ted as .,..4 crushiIlg umil te;red. Page 4 of .J.S 2360/2350 Combined Specification December 9,2003 c Quality Requirements Cl Los Angeles Rattler Test .........................................................................-................AASHTO T96 The Los Angeles Rattler loss on the coars<: aggregate ft 'lct:on (material retained on the 4.75 mm [#4] sieve shall not exceed 40 percent for <L."'lY individual source used witbin the mix. An aggregate proportion which passes the 4.75 mm [#4] sieve <L.ld exceeds 40 pen:~nl LAR loss OJ. the coarse aggregate fraction is prohibited [rum use ill the mixLure. C2 Soundness (Magnesium Su I fa te).................................................._.........................AASHTO TI04 The magnesium sulfate soundness loss at 5 cycles on tl: e coarse aggregate fraction (material retained on the 4.75 mm [#4]) shall not exceed tIle following for any indi"idual source used \vithin the mix: * a) No more ban ]4 % loss aD the 19 mm[3/4 inch] to 12 5 mm [1/2 inch] and larger fractions. b) No more than 18% loss on the 12.5 rum [1/2 inch] to 9 5 mm [3/8 inch 1 fraction. c) No more th<L.: 23%, loss on the 9.5 mm [3/8 inch] to 4./ 5 mm [#41 fraction. u) No more than 18% for the composite Joss. (Appli<.:s any ifull tb..ree size fractions are tested). ~ 1) if the composite requirement is met but one or more incividua1 components do not, the source may be accepted if no individual component is more than 110% of the requirement for that component. 2) If each individual component requirement is met but th:: composite does not, the :;ourc.:e may be accepted if the composite is no great::;r than llO~''O ofth;: requirement. An aggregate proportion which pa::;ses the 4.75 mm [#4] sieve and exceeds the requirements listed above on the coarse aggregate fraction is prohibited from use in the mixtlre. C3 Spall Materials and Lumps ........................................ ..................MnfDOT Laboratory Manual Spall is defined as shale, iron oxide, uI1S0UnG cherts, pyrite, highly weathered and/or soft phyllite and argillite (may be scratched with a brass pencil), and other materials h lViD.g similar characteristics. Lumps are defined as loosely bonded aggregations and clayey masses. If the percent of lumps measured in the stock:pile or cold feed exceed the values listed below, asrhalt production shall cease and compliance shall be determined by dry batching. This procedure may be repeated at my tL-ne at the discretion of ;he Engineer. J\faxlmurn limits far Spall and lumps, expressed as peCi entJges by mass, are lisred in Table 2360.3-B2a. C4 Insoluble Residue Test................................................. ..................MnfDOT Laboratory Manual If Class B carbonate material is used in the rnL.x, the milus 0.075 mm [#200] sieve size portion of th.e insoluble residue shall not exceed 10 percent. D Aggregate Restrictions Class B carbonate aggregate restrictions are specified 1:1 Table 2360.3-R23. E Gradation Requirement rne coarse and flne aggregate shall be combined in such proportions to produce an asphalt mixr'llfe meeting all of the n:quiremems defined in this speciiication and:hali conform to the gradation as detined in Table 2360.2-t:. Gradation testing shall be conducted in accordance witr' .A.,ASHTO T-11 (-0.075 mill [-#200] wash) and T-27. Page 5 of 48 2360/2350 Combined Specification December 9,2003 ( /0 passing of total wasbed gnl a tlOn) ! Sieve Size I A or 4'" I B or 3 x Cor 2" I 5::r:: E i (mIll [inch]) I (S\lA) 25.0[1 inch] ! I 100 See SMA Provisions 19.0 [3/4 inch] i 100 , 85-10(' i 12.5 fl/2inchl : 100 85-100 I 45-90 I I 9.5 [3/8 inch] I 85-100 , 35.90 100 I , i - , i 4.75 [#41 I 25-90 20-80 2.0-75 i 65-95 I I I ~ " [1-'81 I 20-70 15-65 15-60 45-80 .L..JO f'r I 0.Q75 [#200] I 2.0-7.0 I 2.0-1.0 2.0-7.C 2.0-7.0 Table 2J60.2-E Aggregate Gradation Broud Jands O' d . "'Marshal! Designation F Additives f'...:J. additive is any material added to an asphalt mixnre or material, such as mineral filler, hydrated li.tne, asphalt additives, ami-strip, and simiiar products that d{, not have a specific pay iteIT.. When a COnt7aCl requires additives, compensation is L."'lcluded with the pay it~n.s fur the appropriate mixture. If the Engineer directs the Contractor to incorporate additives, the compcnsa:ion will be ilS Extra \\'ork, at the Wlit price specified in the proposal. The D_;:::':'~::H::-,: O_wTler wiil not compensat: the Contractor for additives incorporated at the Contractor's option. Additives will not be incorporated Into the mixrure \1.irhout approval of me Depamnem Biruminous Eng.ineer. Anti-foaming agents shall be added to asphalt c::merlt at the manufacturer's recommended dosage rate. lvlineral filler and hydrated lime may be added in a quanti)! not to exceed 5 percem and 2 percent, respectively, of the tetal mass of the aggregate. The combination of mineral tiller and hydrated lime shall not exceed 5 percent of the tOlal mass of aggregate. Tne Engin.:er will apt rove or disapprove methods for addition or additi ves. F1 NUn eral Filler. ................ ...................... ........................ ............................................ .......... ....... 3145 F1 Hyd rated Lime ......................................................... ................................................................. 3145 Hydrated lime used in asphalt mixmIes shall meet lh.: requiremenis of ASTM C977 and have a maximum of eight percent unhydrated oxides (as received basis). The nethod of introducing and mixing the hydrated lime and aggregate shall be subject to approval by the Engine':r prior to beginning mixture production. F3 Liquid Anti-Stripping Additive Wne:J. u liquid anti-strip additive is addt;d to thl:: u:;plnlt binder, blendirtg shall be completed before the asphalt binder is mixed with the aggregate. Liquid anti-;trip additi'ces that alter the asphalt binder, such that ir fails to meet the Performance Grade CPG) require:nen:s. shall not be Us'~(l. Liquid anti-strip may be added by the supplier at tbe refinery or by the Contracwr at the piant site. The compny/supplier adding the additive shall be responsible for testing the binder/additive blend to msure compliance '.;ith the _A.A..SHTO M 320, Standard Specification for Performance Graded Asphalt Binder, No paving will be allowed Imcil ,he asphalt binder/additive blend has been tested and results show that binder/additive blend prop.;rties meet the criteria in Section 2360.2G. The testing shaH be done i.11 accordance with a j'VLr.LiDOT approved Aspilalt Binder QC Plan. Requirements for the Asphalt Binder QC Plan are on me in the Bituminous Office. Page 6 uf 48 2360/2350 Combined Specification December 9, 2003 The followbg requirements for f-':2vlA mixrure and as;: hal: binder must also be met when liauid anti-strip is added at the H::'vfA plant site. . . I) 2) 3) 4) 5) 6) 7) 8) 9) F4 C Mixture Requirements at Desi2'n: 1) The Contracwr must design the mixture with the same asphalt binder L.'1at will be supplld to the plant site. (Both Laboratory MLxrure Design (Option lllliid Moditied Mixture Design (Option 2). 2) The Contractor must provide documentation with eim"r design option that includes Tensile Srrength Ratio results with the iiquid anti-strip dosed ,it the optimal rate. Documentation must include verification the binder/additive biend meets A \SHTO M 320 at the optimal dose rate. Contractor Production Tesriu!Z Requirements for Asohalt liinder/LiQuid Anti-Strip Blend: i) The Contractor shall, on a daily basis, sample and test Lle asphalt binder/ami-strip blend. Testing of the blend can be by viscosity, penerration, or dynan ic shear rheometer (DSR). When a pol)mer modified asphalt binder is specified, the Conl~actor shall use the DSR as the daily QC test. 2) The Contractor shall, on a weekly basis, send the Engheer and lvlrjDOT Chemical Laboratory Director a weekly QC report summarizing the results I .f the daily testing as required in number 1. 3) The ContrUclOr shall, on a bi-weekly D<isis, test the bir: jer/anti-strip blend to ensure compliance '.\ith L1.e A_A.SHTO M 320, Standard Specification for )erformance Graded Asphalt Binder (minimum IIproject). Test resuli:s shall be sent to the i~ngineer and .MIl/DOT Chemical Laboratory Direcwr. 4) In addition to the samp1in8 requirements listed above, the Contractor shall obtain asphalt binder/anti-scrip blend field verification samples accO! jing to 2360.4 E12. Liq uid Anti-Strip Additive Metering System: The metering system shall include a liquid ami-strip tl)W meter in additiun to an anti-strip pump. Tne flow metershulJ be connected co the liquid anti-strip supply :0 measure and display only the ami-strip being fed to the asphalt binder. Tne meter readout shall be positioned for convenient cbservation. There shall be a me:lns pro'.:ided for comparin.g the Dc .v meter readout with the calculated output of the anti-strip pump. See number 7. The system shall display in units of liters [gallons] to ;he nearest liter [gallonJ or in units of metric tons [tons] to the nearest 0.001 metric tons [0.001 ton';], the accumulated anti-strip quantity being delivered to the mixer unit. The system shall be calibrated and adjusted to maintail an accuracy of:t one percent error. Calibration shall be required for each plant set-up priG' to production of mixture. The Engineer may require, on a daily basis. the Contr~lctor "stick" the anti-strip tank at the end of the days production to verify anti-strip usage qua..Tltitie;, The system shall provide for a convenient method for ;ampIing the binder/ami-strip after blending has occurred. Alternative blending and metering systems must be pr,~-ap~Jfoved by the Engineer Coating and An ti-Stripping Additiye ....................... .................. ............................................. 3161 Asphalt Binder IV{aterial ......................................................................................AASHTO M 320 Asphalt binder makrial shalL meet the requirements 0:' PG asphait binder testing tolerances, samplmg rates, testing proccdun:~, and acceptance criteria based on the most current :-,.fn!DOT T echnieal l'vlemor..ndum, titled "Inspection, Sampling, and Acceptance ofBimroin,)us Materials." The PG asphalt binder cannot be modified yvith air blowing procedures unless the Department Hiruminous Engineer approves it. The COntractor shall not use petrolelL.'ll distillates such as fuel oil, diesel fuel or other fuels in the asphalt tanks. A stutemerrt shall be provided bJ' the supplier for recommended laboratory Tui;(ing and compaction temperamres and field maximum mixing and compaction temperatures. Page 7 of 48 2360/2350 Combined Specification December 9, 2003 Gl Asphalt Binder Selection Criteria for All Mixture~. with RAP 64-22 i Virgin AsphaItBioder Grade to be used with RAP ! < 20% RAP ! > 20% R..\.P i - 64. Z2 64-23 :-1'0 arade "ijustment No m-ade adiustment Overlay Specified PC Asphalt Binder Grade Other PG Grades New Construction (1) I Specified PG Asphalt i Virgin Asphalt Binder Grade to be used with R.-\P , Binder Grade I < 20% R.~ > 20% RA.P , I 52-34 ! 52-')4 Not allowed '" I 5 8- 2 8 I 58-~8 58-28 58-34 I 58-14 Not allo\ved ~ r 64-28 , 64-,~8 64-28 .. I 64-3.1 i 64-:4 Not allowed '" Otner PG Grades No :rrade alii u~rr:Ient Not allowed ~ '" \Vhen approved by the Engineer, the vir3in ~.:;phalt binder grace CD.l"! be selected by using; the blending chart procedure on file in the Bituminous Office. MwDOT may tak,: production samples for information/verification of compliance with a specified asphalt binder grade. Includes cold L.'1place recycle, reclaiming, and reconsrruction. (1) 2360.3 l\lLXTURE DESIGN A Mixture Design General Dotions. located. The asphalt mix may b~ desig.ned using one of the foJ lowing two Contractor trial mix design Review of mixture designs will be performed in the District Yarerials Laboratory lab where the Project is The addition of aggregates and materials not included in the original mixture submittal is prohibited. It is the Contractor's responsibiEty to design a Marsh, 11 mixUln: in accordance with the mas: current .D...A5HTO T-245, the Asphalt Institute's :\1ix Design \lethods fer Asphalt Concrete MS-2, <L"1d the rvirliDOT Laboratory Manual such that it meets the requirements of this specifica:ion. f or Marshall design, the design air void content of th.: mixture is dependent on the ffiLxture type, regardless of the location in the pavement s:ruct'.lre. Design air void cOltent for LV and M\! mixtures is 3 .O'l-'O and 3.50,'0, respectively. It is the COnlractor's responsibility to design a gyrator}; mixture in accordance with the most currene f\:-\SHTO T-312, the Asphalt Institute's Superpave Mix Design Manual SP-2 (2-hour short term aging period is used for volumetric), and the :\fn/DOT I .aboratory Manual SUI. h tbat it meets the requirements of th is specification. for gyTatory design, the design air void content of tl1<: mixture at design shall be 4.0~'Q at the dcsign number of g)TanOnS (l'i'l<Slzn) for mixture~ placd in the upper 10) !11l'U [4 inches] of the finished surface. Tne design air void content of the mix-ture at design shall be 3.0% at the des gn number of gJTations (Nde'i;?) for mixtures placed \It depth:; more than 100 mm [4 inches] from the surface and on lil (wear and nonwear) shoulders that do not carry tramc. If less than 25% of a layer is '.vithin 100 mrn [4 inches] 0: the surface, the layer may be considered to be below 100 mm [4 inches] for mix design purposes (non-wear). Page 8 of 48 2360/2350 Combined Specification December 9,2003 Design Air Void Requirement for Gyratory Mixtures i SP Wear I SP NO~l-wear i SF Shoulder"'''' Location from 100 [4' b]' I > 100 [4' h]'" I' .1\1.1 Wear and <ur"'lUC'> ::;; rnm mc I mIr lnc N W- ~ _ I i ~ on- ear Air Voids 4.0%' 3,(% 3.0% ... If less than 25% of a layer is withi.:l J 00 mm [4 inch esJ of the surface, the layer may be considered to be below 100 mm [4 inches] for mLX de':ign purposes. .... Shoulders that do not carry traffic. B Laboratory Mixture De.sign (Option 1) Test results and documentation a~ de;:~cribed ill SectioL 2360.3C shall be submitted ",ith the materials described below for wnsideration by the Departmem Biturrlln:)us Engineer or District Materials Engineer to verify compliance with t.l:tese specL"ications and to issue a Mixture Dnign Report. Hl Aggregate sample /~t least lS working days prior to the stan or asphalt p;'oducdon, the Contractor shall ~ubmit co the Department Bimmmous Engilleer or the District Materials Engineer a 3' kg [80 pound] sample of representative aggregate recaL.-led on th;: 4.75 mrn sieve [#4] and 3 15 kg; l35 pound] s<lmple of material passing the 4.75 rom sieve [#4] for quality testing. The Contractor shall provide 24 hour notice ofment to sample aggregates. TIlese samples will be tested for quality of each source, class, type, Ulid size of virgin a;:d non-asphaliic salvage aggregate source used in the mix design. The Contractor shall retain a companion sampk of equ<il size illltil a Mixture Design Report is issued. Quality requirements are defIned L.! Section 2360.2C. Aggregates that require the magnesium sulfate soundl!ess test shall be submitted to the Department Bimminous Engineer or District Materials Engineer at le;:ast 30 calendar days prior to the start of asphalt production. Dispute resolmion procedures for aggregate qualities are Oli file in the Bituminous Office. B2 Mixture sample At least 7 working days prior to the start of asphalt prl:duction, the ContractOr shall submit in ''/Titing a proposed Job ;\-Ex Formula (JMF) for each combi.nation of agFegares co the Department Bituminous Engineer or District i\'laterials Engineer [OT review. A Level II Quality :'ilanagemem mi.:x designer mllst sign the proposed J::YL."'. for each ]:VfF submitted, the Contracwr shall include te.;L data to demonstrate conformance to mix.rure properties as specified i.n Table's 2360.3-82b and 2360.3-B2c. The proposed JMF shall be submitted un forms approved by the Department. Tn addition. the Contractor shall su:,mit an uncompacted mixture sample plus briquettes compacted at the optimum asphalt content and required com~ lCtive effort conforming to the J1\.1F for laboratory examination and evaluation. Mixture sample size and numbn of compacted briquettes are as follows: Item Un-comoacted Mixture Samole Size Number of oompacted bri uettes Marshall Design 18 Kg [40 pounds} 3 B2a Mh:tu re Aggregate Requirements Tne aggregate fractions shall be sized, graded, and cO.nbined in such proportions that the resulting mixture will meet the requirements listed ioi Section 2360.2-E and Tabk 2360.3-B2a shov,rn below. Page 9 of 48 2360/2350 Combined Specification December 9,2003 Table 2360.3-B2a Mixture Aggregate Re uirenents I I TratIlc i Tram< i Traffic I Traffic i SYIA Aggregate Bknd Property Level 2& LV I Level 3 & MV Level 4 I Level 5 I T. Level 6 I i I I I i 3 - 10 10 - 30 I See SivL.; 20 year Design ESAL's <1 million I - 3 mUron i I I million million Provisions I I Coarse Aggregate Angularity i - i I I (ASTMD582!) 30/- I 55 ./ - 85/80 95 ! 90 (one face / two fac:.;), %- \1.( ear I - (one face / two face). %- Non\Vear 30/- I 55 / - 60/ - 80/75 Fine Aggregate Angularity (FAA) (AASHTO 1304, Method A) %- Wear 40(:) 42(1) .:11 45 - ."T %-Non-Wear 40\:) 40(1) ! 40 40 flat and Elongated Particles, max""! % I I 10 , 10 10 - I . I by weiiilit, (ASTM D 4791) (3:1 rati,)) ; (3: 1 ratio) (3: 1 ratio) C1av Contentt~) (Af\SHTO T 176) I - i - : 45 4' - I ..J I - I . . I ! : Total Spall in fraction retained on the I I ; 4.75mm [#.41 sieve 5.0 2.5 1.0 l.0 - ! Ma;xiinUl11 Spall Coment in Total I 5.0 I 5.0 1.0 1.0 - Sample Ma.Th-r:um Percent Lumps in fraction I I I 0':; I 0.5 0.5 0.5 . retained on the 4.75mm [#4] sieve i ; Class B Carbonate Restrictions I I Max.i.mu!n'7o -4.75mrn [-#4] I I i i , Final Lift! All other Lifts 100/100 I l OOil Otl 80/80 50/80 , - Ma.xirnum% ~A.75mm [+#4] I I I Final Lift!All other Lifts 1 DOll 00 100/1011 50/100 onoo - : \ I ! ! G\TalOrv Ma.x. allowable Rf\P percentage 30/40 30/30 3 0/3 0 30/30 Wear i Non Wear i\'f.ars h a 11 I Max. allowable RAP percentage 30/40 30/30 i \Vear / Non \Vear i (1) For Marshall design, the Contractor may determine -4 cr.!shir g by either FAA of uncompacted voids or calculation of crush from the composite bleed. Thc choice m.lsr be made prior tu start of production. Manufactured cn.lshed fLnes requirement is 25%. RAP sand v.ill be considered 500/0 crushed if the uJlgularity index equals or exceeds 40, and lOO% crushed iftl:e angularity index equals or exceeds 45. (2) Not applicable under Marshall design. B2b Mixture Requin:rneuts Mixture evaluation wi.ll be based on the trial ml'i: te its a.-Jd the corresponding requirements listed in Tabk 2360.3-B2b iiJ."1d Table 2360.3-B2c. Page 10 of 43 20 yt:ar Design ESAl,'s GyTarory .tvlixture Re uirements Gyrations for Ninirial G'rTations for Nd"ie::J GyTations for N"':L1:l.'!1= Air Voids, ?/c -- Wear AU- Voids, % -- Non-Wear &; All Shoulder % G= at N\.cical- Wear % Gmm at Niniti;r Non-Wear & All Shoulder ~/o Gmm at N:::a.=u:n- \Vear % Gmm at N:::"-~1l- NonWear & Ail Shoulder Tensile Strength Ratio \ii, min% I Fines/Effective Asphalt VFA. % -- Wear NonWcar Marshall yuxture Re Marshall Blows Air Voids, % Tensile Strength Racio;' " min% Stability, minimum Nib f] Fines/Effective Asphalt Wear Non- \l/ear Table 2360.3-B2b ML'Cture Re uirements Trame L<::v<:1 Traffic Level I Traffic Level 2 3 I 4 < 1 million 1 - 3 million I 3 - 10 million ! 2360/2350 Combined Specification December 9,2003 6 i 8 40 60 90 60 90 140 d..0 4.0 4.0 3.0 3.0 3.0 $ 91.5 ::; 90.5 :::; 92.) :::; 91.5 :s 98.0 s 98.0 :::; 98.0 S; 99.0 S; 99.0 ::; 99.0 75('-,1 7)"2, 80')) 0.6 - l.2 0.6 - 1.2 0.6 .1.2 65 - 78 65 - 78 65 - 76 70 83 70 - 83 70 - 82 LV MV 50 50 3.0 3.5 70' , 70\';' 5000 11251 6000 f1350] 0.6 - l.30 0.6 - 1.30 0.6-1040 0.6-i.40 Traffk Level 5 lO - 30 million S,'viA T. Leyel 6 See SlvL,;" Provisions 8 100 160 4.0 3.0 ::; 90.0 ::; 91.0 ::; 98.0 ::; 99.0 80i> 0.6 - [,2 65 - 76 70 - 82 (I) See Section 2360.4 E9. Use ls0mm [6 inch] spe';;imens for g;ratory and 100rnm [4 inch] specimens for Marshall design. (2) .\ill/DOT Min- == 6S. i)) iY1nJDOTMin == 70, H Mn!DOT Min '" 50 B2c \"yg Criteria The voids in minerai aggregate (VMA) of the mixture at design and during production shall meet tb.e mi.nimum criteria as shO','{!1 m Table 2360.3-82-:: at the specified conpactlon level. VMA shall be calculated according w the procedures outlined in Asphalt Institutes SP-2 or MS-~ manual. VMA is a design and accepta...'1ce/process control relluiri::llli::Uc' Table 2360.3-B2c Voids in Mineral Aggregate (VIYIA) lYIixtll re Re uirements Fine Mixture I VyU,- I~ Coarse Mixture ~.;, Pass 2.36 mm [#8 Minimum' % Pass 2.36 mm [#81 >47 IS.0*" ::;47 > 39 I 14.0 I s: 39 >35 13.0 I ~35 'j 15.0"'" I I C Gradation A or 4 ~ B or 3 ~ Cor 2" 5::: \1;vL,;" Minimum 14.5* 13.5 12.5 E See SMA Provisions .. Marshal] desi gnation. ""For LV 4 and LV 5 mixes lower V;\-L\ requirements by 0.5% Page 11 of48 2360/2350 Combined Specification December 9, 2003 B3 Tensiie Strength Ratio sample Mixture or briquettes that represent the mixrure at opti:r:urn asphalt content, shall be submitted at least 7 days prior to act'clul production for verification of mOlsture sensitiriry retained tensile strength ratio (TSR). Material submitted for TSR verification may be tested for maximum spe.:ific gravity G",m complial1ce in addition to TSR results. Failure to meet the Gmm tolerance will result in rejection of the submitted mix design. A new mix design submittal will be required and will be subject !O provisions descn:)ed in Secti()n 2360.3C. One of t.he following options may be used to verify that the tensile sttength ratio (TSR) meets the requirements in Table 2360.3-B2b. Option A) The Contractor will batch material at thc deign proportions including optimum asphalt. Immediate!y (before cuzing) spiit the sample and allow samples to cool t:l room temperature. Submit 35 kg [77 pounds] of mixture to the District Materials Laboratory for curing a1" d test verification. Both groups \vi1l use a two (2) hQur cure time (:: 15 minutes) at I44"C [2900F] and follow procdures in ASTM D 4867-92, lvin/DOT modified as defmed in the Mn/DOT Laboratory Manual. Option B) Thc Contractor batches, cures (as indicated in option A), compacts, and submits briquettes and u11compactcd mixture as specified below. TallIe 2360.3-B3 Option B Mixture Requiremnts Item I Gyratory Design ! Un-compacted Mixture Sample Size I 8.200 ~. ! Number of compacted briquetksl'.l I 6 I Compacted briq'clette air void content I 6.5 - 7.5% (1) !50m..'n [6 inch] specimens for gyratory design 100rrml [4 inch] specimens tor Marshall design .Marshall Design 8.200 g ':! 6.0 - 8.0% B4 Aggregate Specific Gravity .....................................AASHTO T84 and T85, MruTIOT Modified The Contractor shaH determine the specific gmvity of dl aggregate used in the mixture. c Documentation Each proposed JMf submitted for review under Sectioil 236U.3B and 2360.3D shall L'1clude the following document.ation and test results. (I) The name(s) of the individual(s) responsible for the Qllaliry Conrrol of the mixlure during production. (2) The low projects number on which the mixture will be used. (3) The percentage in units of 1 percent (except the 0.075 :nm sieve [#200J in units of 0.1 percent) of aggregate passing each of the specified sieves for each aggregare to be incorporated into the mixture. The gradation of aggregate from salvaged asrhaltic material shall be derived from the material after the residual asphalt has been extracted. (4) Tne source and description orthe materials to be used. The: aggregate pit or quarry source number. The proportion of each material (in percent oi' cotal aggregate). (5) The composite gradation based on (3) and (4) above. l'[ote: Include virgin composite gradation based on (4) and (5) above for mixtures containing R..~ P. (6) The bulk (dry) and apparent specific gravities and water absorption (by % weight of cLry aggregate) of both coarse and fine aggregate, for each :lroduct used in the mi..xture (including RA.P). Use AASHTO T-84 and T-SS MniDOT modifi,:d as defined in the tv1nlDOT Laboratorj Mil.J.1.ual. The tolerance allowed between the Contractc:' sand t.lte Depa.rrmcnt's specific gravities are G,j (individual) = 0.040 [-'-4 f..:ND -4] and Gsb (con:bined) = 0.020. (7) The composite gradation pioned on a FHWA 0.45 pover chart. (Federal form PR-!!!5) Page 12 of48 236012350 Combined Specification December 9, 2003 (8) F or mixtures containing RAP include extracted aspba!t binder content of the Ri\'P with no retention factor included. (9) The perc<:ntage (in wilts of 0.1 percent) and PG grade of asphalt binder material to be added, based upon t.he total mass of the mixture. (10) Wuen using laboratory mixture design Option 1 (23M .3B) or Option 2 (2360.30), include t~e following: (a) A minimum of three different asphalt biIlder :unlents (minimum 0.4 percent between each point), 'vvith at least one point at, one ab)ve and one below the optimum asphalt binder percentage. (b) The maximum specific gravi:y at each aspha t binder coment. The theoretical maximum specific gravity used for percent air voids de'errnination shall be calculated based on the average of the effective specific gravities me lSUIed by a minimum oitwo maximum specific gravity tests at the asphalt contems "bovc and below the ex-pected optimum asphalt binder content. (c) The test results for the individual and averag:: bul.k specific gravity, density, and heights, of at least two specimens at each asphalt binder content. For Marshall design include the test results for the individual and average bu. k specific gravity, denSIty, height, stability, and fk)w of ill lcasr three specimens at each <!sphalt binder coment. (d) The percent air vOlds in the mixture at each (Isphalt birIdcr content. (e) The percent Voids ia Mineral Aggregate CVMA) at each asphalt binder content. (f) The fines to Effective Asphalt (F/ A) ratio ca culated to the nearest 0.1 percent. (g) TSR results at the optimum asphalt binder centent. (h) Graphs showing air voids, voids in the mineral aggregate, Gmb, Gmm and unit weight vs. percent asphalt binder content for each ofthl three asphalt binder contents submitted with trial mix. (11) Optional Add-Rock/Add-Sand Provisions lIthe Contractor chooses CO use the add-muteriul opti"n to augment the submitted J1vIT, the Contractor shall provide samples of the aggregate for 1uality analysis in accordance with Section 2360.3 B 1. The Contractor shall provide mix. design data for two additional design points per add-material. One poine shall show a proportional ad)usrment to the submitted flvfF that includes 5 percent, by mass, add-material at the S?vIT optimum asphalt percent. The second point shall show a proportional adjustment to the submitted J1vfF that includes 10 percem, by mass, add-material at the nva: optimum asphalt percent. Tbe following information will be reported for e3ch of these two points: (a) The maximum specific gravity (average OftiO tests). (b) The test results for the individual and averag l bulk specific gravity, density, and height of at least t'NO SpeCLi'I'Xn5 at the optimum aspha t binder content. For Marshall design include the test results for the individual and average bulk specific gravity, density, height, stability, and !low of at least three sp':cimens ar the optimum asphalt binder content. (c) Tne percent air voids in the mixture for each POL.'1t. (d) The Fines to Effective Asphalt ratio caiculat;:d to the nearest 0.1 of a percent. (e) Coarse and Fine Aggregate crushing counts Up to tWQ add-materials will be allovied per mix desil~ submittal. Aggregate quality and rnix characteristics are required for each proposed add-ma :eric.l and shall be submitted at the time of the origL'1al trial mjx submittal. No mixture sample O' briquettes are required for these two additional points. Page i:; of 48 2360;2350 Combirled Specification December 9, 2003 Additional Documentation For: Gyratory Design (Gl) The test results from the composite aggregat'~ blend at the proposed IlvlF proportions indicating compliance "'1L.1 Coarse Aggrega1 ~ Angularity and Fine Aggregate Angularity as sho\vn in Table 2360.3-B2a. (G2) The design traffic levei and the initial, design, and maximum number of gyrations Ninitial, l'LJcsigm and N u;aUll':'\;'lI~' (G3) The temperature ranges the mixture is intenc ed to be discharged from the p1at1t and compacted at the roadway shall be provided )y the asphalt binder supplier. Temperatures to be included are, laboratory mixing and co'npaction temperature ranges and maximum field mL"<.ing and compaction temperatures. (G4) Evidence that the compLeted mixture wilt cO'lfoffil lU all specified physical requirements as follows: Design air Voids (Va), V?vlA., VI A, TSR, F,A. (Filles to effective asphalt ratio), Densification %G= arNen;';,'i, Nne';h'11' and N~ ,,;U1I:=' (G5) Labeled gy'Tatory densification tables and c'J::ves, geni::rated from the gyratory compactOr, for all pointS used in the mixture submittal. Marshall Design (M l) The test rcsults from the composite aggregat:: blend at the proposed IlvlF proportions indicating compliance with fine aggregate aIigularity 1.L.'1compacted voids as shown in Table 2360.3-B2a. Or calculuted -4.75 mm-i14J cmshing from the composite blend of the proposed JMF. Selection of either FAA :)[-4.75 rr..rn [-#4] crushing shall be made at the time ofrnix design submittal. This selec:ion ',vill dicrc:ue the choke of method used for determination of compliance and acceptalce for the duradon of time the Mixture Design Report is in force. R~P sand will be considered 50% crushed if the angl.liarity index equals or exceeds 40, and 1009;' crush-.:d if the angularity index equals or exceeds 45. D Modified Mixture Design (Option 2) Test results and documentation as described in Sectio1 2360.3C shall be submitted to the Depamm:nt Bituminous Engineer or the District Materials Engineer co ',erify compliance with mix design requirements and issue a i\tlL'( Design Report. Mixture submittal is not required. The Contractor may use this option if all of the follov'iillg conditions are met: a) The aggregates in the proposed Mix Design Report h, ve been used, in par.., in other Mix Design ReportS. Additionally, the aggregates must have beer! previously tested for and meet all applicable quality requirements in the current construction seasOJ. b) Tne Level II mh designer submining the mixture desgn must have a minimum of2 years experience in IllLxmre design. c) Tne Contractor and his representatives cannot have vi Jlated the requirements of 1512 Unacceptable and Unaurnoriz::u Work re lating to mix:ure design or mixture production within the last 12 month period. D1 JMF Submittal At least 2 working days priQr :0 r..l:le start of asphalt pr)duction, the Contractor shan submit in "'Tiring a proposed Job Mix Formula (J1viF) for each comb illation of ag:;regares to rhe Department Bituminous Engineer or District Materials Engineer for review. A Level II Qualirf vlanagement mix designer must sign w1is proposed flvlF. For each JMF submitted, the Comractor shall include d,)Cumentation as outliI1cd in Section 2360.3C Page 14 of 48 2360/2350 Combined Specification December 9, 2003 to demonstrate conformance to mi.xrure propercies as specifIed in Table 2360.3-B2b and 2360.3-82c. The proposed J1vfF shall be submi~ed on forms approved by rhe Department. D2 Initial Production Test Verification A: the start of production, the testing frequency for tn;: Hrst 1.800 metric tons r2,000 tonsl of each mix type shalL be as specified in Table 2360.4-D. All mixture placed on ;. ~::,;DO~' thi: O',n~'r':; project5 shall meet the specified qualir)' indicators and required field densiry'. Failure to do so will result in reduced payawnt or removal and replacement with acceptable material. The ~a:f'?'n..,ffi- OViTIar shallt<L'<.e a mix verification. ample within the first four samples at the start of production of each mix type. D3 Tensile Strength Ratio sample See Section 2360AE9 D4 Marshall Stability (Ylarshall Design Only) On tbe first day ofprociuction, for each different mix :Iesign, lit the same time the verification sample is obtained, an additional sample shall be obtained for ~l"a,,1'E""i*- OwnC;Levaluation of Marshall stability. This sample may be tested at tb.e discretion of the lJi:::ic:~\aTerH=+:' r:C:,i:::_''':: E!lgill~. The Contractor is not required to test stability on ptoduction mixture. Lfthe Marshall srability fails to mc;c;tlhc minimum recuirements as listed in Table 2360.3-B2c the Contr3cwr shall StOp production i..rlli-nediarely. The Contractor wi]] be [','quired to submit a revised mix design, with bitumiIlOus mixture at optimum asphalt contem, to tne District Material: Laboratory. If the mi.:xture meets the minimum stability requirement production may be resumed. If the stabiiiry fails the second time, the Mix. Design F:eport will be revoked. The Contractor will then be required to submit a new mix design according to Laboratory Mixture Design 2360.3B, Option I. A new Mi., D<:~ign R<:port will be issued upou successful vel-ification of the ne'',' mixmre design submittal. E Mixture Design Report A '["fixture Design Reporc consists oftJh.e Jj\fF (Job Mix Formula). The JMF includes composite gradation, aggregate component proportions, asphalt binder content of be mixture, design air voids, Voids ill Mineral Aggrcgnte, and aggregate bulk specific gravity values. JMf linits will he shmvn for gradation control sieves, percent asphalt binder content, air voids, and VMA. Issuance of a Mixture Design Report confirms the mixrure has been reviewed for and meets volumetric ?ropenies only. N) guaranty or warranty, either express or implied, is made reg::rrding placement and compaction afrhe mixture /'_ Department reviewed Mi.x:ure Design Report is n::q Jirc::i for all paving except for small quantities of material provided under Section 2360.5H. All submitted n:aterials must meet aggregate and mixture desig.,."1 requirements before a Yl1xrure Design Report is issued. The Der artrnent \vili review t\VO trial mix designs per mix type designaTed in the plan, per Contract at no cost to the ConLr'.cwf. Additional mi.'( designs will be verified at a cost of $2000 per design, payable to the Commissioner of ~'ransportation. For city, county, and other agency projccts, the Contr:ctor shall provide to me District Materials Laboratory a complete Proj eet proposal inc1udirlg addenda, supp1ementd agreements, change orders, and 3.i'1Y Plan sheets (including typical sections) that affect me mix de5ign. The Depaitment win not start t.he verification process without this information. Page 15 of 48 2360;2350 Combined Specification December 9, 2003 236004 l\>ILXTURE QUALITY MANAGEMENT (Quality Control/Quality Assurance) A Quality Control <QC) The Contractor shall provide c.nc mai.nrain a quality ci,ntrol program for H..lvrA production. A quality conaol program is def.ned as all activities, induding mix design process conaol inspection, sampling and testi..,g, and necessary adjustments in. t.be process that are related :0 the jToduction of a hot mix asphalt (1-TIvL,;,) pavement which meets l:.L~e requirements of the specifications. Al Contractor Certified Plant HMA Ala Certification Procedure The Contractor shall: (1) Complete application form and request tor pl3.nt inspe :tion. (2) Provide a site map of stod..ll~le iocations. (3) Pass plant and testing t~cility inspection by having the Plant Inspc:ctor and Bituminous Plant Authorized Agent complete and sign the Asphalt Plan inspection Report eTP 02142-02, TP 02143-02). By signing the Asphalt Plam Inspection Feport, the I:-L'vL'\ plant authorized agent agrees to calibrate and mainwln ,,] plant and lahoralo;y equipment within allowable tolerances set forth in L1ese specifications, Standard SpecificaTions f,)r Construction, and the MniDOT Bituminous Manual. (4) Ob:ain a Mixture Desib'11 Report prior tu production. Alb Maintaining Certification To maintain certification, the plam must produce, test and document all certified plant asphalt mixtures in accordance with the above requirements on a continuous ba:: is. Contin.uous basis means all asphalt mixtures supplied from a cerrified plant to any D~pl::-'HBeR~-project with 2360 asphalt mixtures must be sampled and tested in accordance with 2360 requirements and the Schedule of Mater :lIs Control. Tue Contractor shall assure the plant ccrtilication procedure is performed annually after WL'1ter suspension and berore produci.ng material for a Project. In addition, a ii'51-day sampling and testing frequency rate as stated in Table 2360.:1-D shall be followed. The Contractor shall recertify a plant when it is movel to a new location or a previously occupied 1ocarion. Ale Revocation of Plant Certification The Depamnent Construction Engineer may revoke clrtiiication of an asphalt plant when requiremems are not being met or records are falsiiied. The Depamnen: may revoke the Technician Certification for the L1.dividual involved. The DepQ.~em Bituminous E:1gineer and Depar:men: CQfltTact Administrator will maintain a list of companies who have had their asphalt plant cerrification revoked. B Quality Assurance (QA) Tue D2p~:-:'':;::: Ch..-ner Viii! pertonn QA testing as pn ofLfJ.e acceptance process. Tue En;::ineer is responsible tor QA testing, records, and acceptance. The Engineer w: II accomplish the QA process by: Page 16 of 48 2360/2350 Combincd Specif.cation December 9, 2003 (1) (2) (3) (4) (5) (6) Conducting Quality assurance and verification sampliTig and testing. Observ-ing sarIloling and tcsts oerformed bv the QC oe:'SoHllel. Taking additio;'al s~ples at ;ny tirne and'any 10l:atiol during production. r.(onitoring the required QC summary sheets and contr}l chms. Verifying calibration oflaboratory testing equipment. Communicating :.f;-.:::;(;-;:". C);.yner test results w the Ccn;:ractor's QC personnel in a tL.'11ely maimer. Ensuring Independent Assu:ance Siimpling and testing requirements are mc:l. (7) C Contractor's Quality Control CI Personnel Requirements Along with the proposed mix design data, the Contracl:Jr shall submit to the Engineer an organizatiunal chart listing the names and phone numbers of individuals md alternates responsible for mi.'<. design, process comrol acJ.rnipjstrution, and inspection. The Contractor shall alsc post a current organizational char: and if required by the Engineer, post a daily roster or individuals performing Q::: testing in the Contractor's test facility. The Contractor's quality control organization or privat l testing fL--m shaU have Certitieu Technicians who have met the requircments on file with the Depar:mem s Technical Certification program. LtldiYiduals pe,fol1Ili.'13 process control testing must be certified as a Lev II T Bituminous Quality Management (QM) Tester. Lndividuals performing mix: design calculations or mix design adjustments must be certified as Level II Bituminous QM Mix Designer. The Contractor shaH have a Certified L.ve1ll Bituminous QM Mix Designer avaiJahll: to make any necessary process acljusrrnents. The Contractor stall have a minimum or one person per paving operation certified as a Levelll Bituminous Stn:et Tnspector. C2 Laboratory Requirements: The Contractor shall furnish and maintaL'1 a laboratof)' at the plant site or other site as approved by the EngiIleer. The laborawry shall be furnished v{ltll the necessary equirment and supplies for performing Contractor quality contro 1 testing. The laboratory equipment shail meet :he requirements listed in Section 400 of the Mn/DOT Bitul'TIllOUS Manual and these specifications, including having extr<\ction capabilities. The laboratorj shall he calibrated, and operationai prior tu the beginning of production. In at clition to the requirements listed above, the laboratory shall be equipped with a telephone for use by the Contractor I..r the Engineer. A fax machine and copy machine shall be available for use by the Contractor or the Engineer at ti',e laboratory site. The laboratory shail also include a campu:er and printer. The computer shail h:lYe the following ]~inimum requirements: 1) lmel based with ei,her Celeron or Pemium IV processor with a mi...'1imum processor speel. of 1.8 MHZ. 2) CD "Titer with CD/R \V capability 2l'1d a minimum \Illite speed of 16x. 3) Windows 2000 or Whidows XP with Microsoft Excel version 97 or newer. The printer must be able to print control charts. The Engineer shall be allowed to inspect measuring arld testing devices to conflITI1 both calibration and condition. The Contractor shall calibrate a..'1d correlate all testing cq lipment in accordance with the latest version of the MrJDOT Bituminous Ma.rlUa1. D Sampling and Testing The Contractor shall ensure that all QC samples are taicen at random locations. Random number generation and determination of random sample location shall be comis:ent with the Mn/DOT Bituminous Manual Section 5-693.7 Table A or Se<.:tion 5 of ASTM D3665. The Engineer nay approve alternate methods of random number generation. The tests for mixture properties shall bt.: conciucted all representative portions of the mL'\, quartered from a larger sample of mixture taken from behind the paver, or when a:lproved by the Engineer, an alternate sampling location. The procedure for truck box sampling, an alternate ~ illlpling location, is on file in tb.e Birummous Offlce. \V'rrerr an alternate sampli.l,g iocarion i~ approved arld used by the Contr:dctor, the daily verification sample must still be taken from behind the paver. Pa.ge 1 i of 48 2360/2350 Combined Specification December 9, 2003 The Comrac:or shaH obtain a sample of 2.t least 25 kg [55 pounds]. To.is sample may be either split in the field or transporred to the test facility by a method to retain beat [Q facilitate sample quanerJIg , procedures. n,e Contractor shall store and r.etain mix:ure bulk samples and companion smnples for the DeF";.n,:,,: EO!2ii'1S..er.for a period of 7 workiTJ.g days. The Contractor shall maintai:c these split samples in comai..'1ers labeled with companion numbers. The Contractor shall perform QC sampling ,Iod testing according to the following schedule. Determine the planned tonnage for each mixture to b(' produced during the production day. Divide the pla.nnd production by 1000. Round the number to the next iilgller whole nunlber. This number \llill be the number of production tests required for that mixture. Required production tests are listed in Table 23/'i0.4-F.. Split the planned production into even increments and select sample loc ltions as described above. If actual tOllilage exceeds planned tonnage additional tests may be required. During prod']ctioo, mixture volumetric property tests will not be required when mix production is less than 270 metric tons POQ tons]. However, production tests will be required when the accllil1ulative tonnage on successive days exceeds 27) metric tons [300 tOllS]. /\.t the start of production, the t,,~ti..TIg fr~quency forth,: tirst 1800 metrit; tons [2,000 tons] of each mix ty-pe shall be as follows: Production Test Table 2360A-D Production Start-Up Testing Hates Testing Rates 1 test per ~50 metric tons (500 tons] Test Reference i Section AASHTO 1'312,T] 66 :VinJDOT 2360.4 F,2 muuified .A..ASHTO T?09 IvL'lJDOT modified ?3604E3 1 A...ASHTO 1269. 1312 2360.41::4 Bit & Lab !v!arlUai 2.360.4E 1 Al MS 2. & SP 2. 2360.4E5 .V.S HTO Ill, rn, l30MrJDO l modified I 2360.4E6 ASThf DS82I i 2360.4t. 7 I .~.ASHTO T304, Method A 2360.4E8 Buik SpCCUlc GraVity NJaxlmum SDccific Gravity i\ir Voids (calculated) Asonal! Comen: V:VL'\ (Calculated) ! Gradatiun Coarse ,,~Q2JeQate .A..nguIariry Fine Aggregate Angularity (FA-A)P) (1) Marshall design allows -4.75mm [-#4] manufactured crushed fines calculation per N1n!DOT BituJuinous Manual 1 test per 450 metrit; tons (500 tons] i test ner 450 metric tens fSOO tons] ! test Der 450 merri<.: lons [5UO tonsl 1 test ner .+50 meuic tom [500 tons] 1 test ner 900 metric ton:; r 1 000 tons1 1 test Der 900 metric tons r I 000 tons J 1 test per 900 metric tons [1000 rons] E Production Tests \'Inen more than one 1v1.n!DOT approved test procedu'e is available, the Contractor shall select, with the approval of the Engineer, one method at the beginning of the F -oject and use that method for the emin: Projecr. The Contractor and Engineer may agree to cb.::.nge test procedrres during the construction or the Project. Page 18 of 48 I Test Reference I A'\SHTO T312, T245 T166 . Mn/DOT mod , Ai\SHTO TIO'} :VlnlDOT modified I AA,SHTO '[269, nI2 i Bit & Lab Manua! AI !viS 2 & SF 2 AASHTO Tll, 127, I T30\<LlfDOT modified I AST:VI D582 [ I A....\::iHTO T304, \kthod A ASTM D4R67 tvirJDOT modified A'\SHTO T84 & T85, \-tIlJDOT modifled ! Daily unless exempted by Engineer I lvfwDOT 5-693.950 j2360AE 11 I Sample IS< lOild (each grade) L1cn I per I,OOO,OOO litr I MniDOT 5-693.920 I' 7"604E .., l ...uphaJ( Bi.nder f250,OOO gallon-sample size I quart.]. .. _J . L I (I) Marshall design allows -4.75mm [-#4J rnailufactured crushed filles ,alc\ilation per rvWDOT Bituminolls Manual Table 2360.4-[ Production Sampling and Testin:~ Rates Production Test I SamplingiTesting Rates I Dividerhe planned ?:o.duction b;' 1000. Round the numaer to the next n,gner ',,'hole number. ! I I Bulk Sp<::cific Gravity I Maximum Specitic Gravity I Air Voids (calculated) ! Asohalt Content i 1/;YL~ (CaLculated! Gradiltion 11 ~~dation pe~ .1,80? mctric,tons (2,000 tons], or :JO"lon thereOllffilOlmurn or one De, day) . 12 teStS/day for a. mini.mum of 2 days. then I p<::r day U' . c'.l.....'\ is met. If CA:\ >8'% or requiremenr, 1 sarllpl<::!,hy but teSt l/week. ..-- 2 restsJday fur a minimum of 2 days, L'1cn l per day it' F :v\ is me,. If F .A_A. >5% (")f requirement. I sampleliay but test I!week. I ]" semple at 5,000 ton3 or by second day of prodUCri'.lil. ! then samole at everv l8.000 metric tons 120,000 ton!; Coarse Aggregate A.ngularity Fine Aggregate .\ 'no-'u1 ';-r~ v (T: c\ '" ')0) ...'lJ =' ..u. ..~ ...1.~""""4 ~ I TSR Aggregate Specific Gravitv Mix.ture Moisture Content 1 per 9,000 metric tons (IO,OOO tons] 2360/2350 Combined Specification December 9, 2003 Section 2360.41::2 2360AE3 2J60AE4 2360AE l 2360AE5 2360.4E6 2360.4E7 236GAES 2360AE9 2360AEIO (a) (b) (n) (d) Asphalt Binder Content Spot Check (Virgin only)........................................... ........................fvlniDOT Bituminous Manual IncineratOr Oven (I) ..................................................... .. MniDOT Laboratory Manual Method 1853 Cht:mical Extraction. ........................................Mn/DJT Laboratory Manual i'vklhod 1851 or 1852 Mcter Method (Virgi..TJ. only)...................................... .......................lv1nJDOT Bituminous Manual EI (1:; Incinerator Oven ma)' not be used when the Jercentage of Class B material exceeds 50~';' within the composite blend, urJess a correct: on factor is determined by the Contractor and approved by thc Di~lrict Materials Engineer. E2 i\Tarshall Bulk Specific GraYity, GOlD {3 specimensl.....A..ASHTO T166, MnlDOT i\lodiiied, or E2a Gyratory Bulk Specific Grayity, GOlb (2 specirncnn ..................."'.......... AASHTO T312, 1166, MnlDOT Modified E3 Maximum Specific Gravity, GOlm.................,......................AASHTO T209, Mn/DOT Modified Air Voids - Individual and Isolated (calculation)..................................... AASHTO T269, T312 E4 isolated air voids are calculated using the max.imum nixrure specific gravlr;i and the corresponding buLl( speciric gravity from a single test. bdividual air v.)ids are calculated trom the max.imum specific gravity moving average and the bulk specitic gravity from ,ha: single test. For gyratory design, compaction shail be conducted 0 Nm,,--cim= and caiculations ror %Grnrn at Ni:llcial and Nc.esign shal1 be determined by applying the caJculnred correcjon factor as described in the Asphalt Institute SP 2 manual. Production control for % G""" at N;:ti:ia] and Nma.-<itnumlhall not exceed the limit shown in Table 2360.3-B2b by more tban l.0 %. Nlixmre produced beyond these limis, as measured by the moving average oHour Pag.e 19 of 48 2360/2350 Combined Specification December 9, 2003 tests, may result in a ca:J.cellation of the Mix Design Report. A new mi: design and submittal that satisfies these specifIcation criteria may be rey.uird. E- ;, Voids Mineral Aggregate C\/1VfA) (calculation)............................. Asphalt Institute MS-2, SP-2 E6 Gradation - Blended Aggregate..........AASHTO T.ll, T-27, and T-30 (all Mn/DOT modified) Testing to determine the blcmleJ aggregate i2.mdatlon shall be detemined eve:-v [800 mdrlc tons [2,000 tons], or portion thereof (minimum of one per-day), 00 ~amples :aken at the same thue a., 'the required mb:ture samplt: for a gi vt:n llcremt:nl. All gradations require a - 0.075 mIll [-#200] wash. (a) Virgi11 Aggregate [vfixtures - Drum or Scree] .less Plants Belt Samples or extracted production samplrs. (b) All Other MLxmres: 1. Hot Bins - Drybatch (Opriona1) 2. Incinerator Oven rvrniDOT Laborat'lr)' Manual lvfethod 1853 (Optional) except samples that contain over 50~/o cia". B. (1) 3. Extraction ;'I1n;DOT Laboratory Mrnua1 Method 1851 or L852 (Optional) (1) L'1CLT1erator Oven may not 'Je used vihen the percentage of Class R material exceed." 50% witL:in the com.posite blend, unless a cOIT:':ction factor is dderInined by th~ Contractor and approved by the District Materials Engineer. E7 Coarse Aggregate Angulurit:~, ...................................................................................AST1\-1 D5821 CA.A test results shall meet the minimum percent fractured faces as shmvn in Table 2360.3-B2a. ASTM 0-582 L shall be used to determine course aggregate angularity en the composite blend from aggregates used in production of bot mix. asphalt. Mi..'(tu.res that -';Qnlain virgin aggregat::s may be tested from cllmposite belt samples. MixtUJ'cs that contai.n R.A.P must bc tested from extracted ::l!'!;g! egates takcn from standard production samples. The percent2.ge of fractured faces of the composite aggregate blend less than 100~/o shall be tested at the following rates: (1) Perform t\VO tests per day for eOlcn mlxmre blend for: minimum of two days and then one per day if the test samples meet C AA requiremen ts. . (2) If CAA. crushing test results exceed 8 percem oftl1e f':quirement, ra..l(c one sample per dOl; and perform one test per week. C~A.. results must be reported on the tes! summary sh ~et. ML\.ture placed and represemed by results below the minimum requirement, as shovm in Table 2360.3-82<1, will be subject to reduced payment as outliIled in Table 2360A-LJ. Tonnage subjected to reduced payment 51' all be calculated as the wns placed from the sample point of the failing test until the sa~pling point wher: the test rc::ult is back witbin specifications. ES Fine Aggregate Angularity ........................................ ..............................ASTM C1252 Method A FAA. test results shall me:':t the miIl.imum criteri.a sno-.m in Table 2360.3-82a. ASTM C 1252 Method A shall be used to deterrn.iJ.,e tIne aggregate angularity on the c:lIuposite blend from aggregates used in production ofH:NlA.. Mixtures tb.at contain virgin aggregates may be t~ ;red from composite beir samples. IvlLxtures tc'1ar contain R.:.lJ> must be rested from extracted aggregates ta..L.:en from :,taDdard production samples. The percentage of uncompacted voids from the composit:': aggregate blend shall be test:d at the following rates. Page 20 of 48 2360/2350 Combined Specification December 9, 2003 (l) Perform two tests per day for each mixtu.re blend for: mirtimum orrwo days and th::n one per day if the test samples meet FAA requirements. (2) If FA-'\. test results exceed 5 percem of \he requireme.lt, take one sample per day und perform one teSt per week. F .'\..A. r::sults must be repoI1ed on the test summary sheet-Mixture place,i and represented by results below the mLolmums, as 51:10"....'11 in Table 2360.3-82a, wiIi besubj::et to reduced p,'~ment as outlined in Table 2360A-L3. Tonnage is subjected to reduced payment shall be calculated as L'1e tons placed from the sample point of the failing test umil :he sa;npling point when the test result is back within specifica ions. E8a _ 4.75 mm [-#4) Manufactured Crushed Fines ........................................ (calculation) MnIDOT Bituminous Manual Under Marshall design, when the -4.75 mm [-#4] Cf.lS ling is calculated, adjustments in target values from the composi;:e blend must be made at the end of each days raving. If the target quantity (percent of -4.75 m.m [-#4] to be crusbed) changes due to mixture proportion or C0111posite gradation change, a new target shall be established for the m:xt days paving. E9 Field Tensile Strength Ratio (TSR) .......................... ..............ASTM D4867 MniDOT l\lodified A TSR sample shall be obtained within thc first 4,500 metric tons [5,000 tons] ofH:NfA produced or by the second day of production, whichever comes flIst, to verifY ten' ile strength ratio (TSR). These samples may b:: tested at the discretion ofthe-flt~~ ~.:~:~:':Q:~ +'::1;:::; ::!'.Ql\'n~I if the .'.l~:e;-:;lSt: r..;:::ccr ..Q.1Yneuequires the samples to be tested, both the Contractor and the D;p::I".'fT.~:::.: Em!i]J;';;Lwill be required to test these samples within 72 hours alter it is sampled. Sample size shall be 50 kg [110 pOllnd] minimum and spilt in half to provide a sample for the ~p:U:;::cn: J;ng)..TJ.eer a.l1d the Contractor. The !),,;::a:-:r:-,;trr- ..t.DJ?,ine.<:Lcompanion of this split shall be labeled with the date, time, Project numb::r and approximate cumulativ( tonnage to date. The Dop::rt:;:~ Owner companion shall bc given to the De~~E- O,..,ner3 Street Inspector 0" Plant Morutor immediately or delivered to the -9::;:;'[.;: :.1:l::=rn.-+;-Engineer within 24 hours of sampling, as specifie,.1 by the Engineer. Mixture samples shall be ta.\en from behind the paver unless the Engineer approves an alternate s UTI!JIL.,g location. Specimen size shall be 100 mm [4 inch J for Marshall mix design and 150 IT1ln [6 inch] for gjTlltory desigll The Contractor may test the sample at a permanent lab site or a field lab sitt:. AdditionallliyL~ mixture samples for TSR evaluatior shall be sampled at a rate of! per 18,000 metric tons [20,000 tons] increments for all mixtures produced on the P 'oject. These samples may be tested at the discr::tion of thc-9-!-sTf::: Mater~G--ts-En:5"fRecF Owner. I f \he ~rater.iab-!;-f' gilieeF- _O\,\;l1e:' requires the samples to be tested, both the Contractor and the ~pm1.mcrrt. E!12:ineer will be requin d to test these samples. Minimum acceptable TSR values for production are S lawn in Table 2J60A-E9. The Contractor shall stop production immediatdy ifminimum TSR requirements are HI t met. The Contractor will not be allowed to resume production until anti-strip has been added to the asphait binder. Detemlination of who is responsible for lhe cost of the ami-strip is based on ~T. O':'ller and Contractor TSR ',alues as outlined in Tables 2360.4E9A. 2360.4E9B, and 2360AE9C. '\\-'hen M"iDO+- the Owner_is TE:sponsibl<' for the cost of the anti-strip, payment will be made only for me cost of the anti-strip for mixrures placed on that?[ )ject. :,lJ.:'S'OT The O'.v:ner_will not reimburse the Contractor for any delay costs associated with making ch:tnges related to this testing. Table 2360.4-E9 Mixture Ty e- - Minimum 'T'SR Gnatorv Traffic Level 2-3 Cona-actor Mrr'-DG+ Owner 65%, C orrtractor Traffic Level 4-5 Mf1:4).id+ Owner 750/0 80% 70% Pagellof48 2360/2350 Combineci Specification December 9,1003 will be determined by the Engineer using statistically derived stratified r:J.,,'1dom number tablcs or other approved methods of random number generation. These will aiso be used for parr .allors. Roth transverse and longitudinal joints are subject to maximwn density requirements. rfthe random core location falls on an unsupponedjoint, at the time of compaction. (the edge of the mat bei11g placed does not bun up" gainst another mar, pavement surface, etc.) CU1 thc core with the outt:r t:dge of the corc ban'el 0.3 meters [1 foot] aw iy (laterally) from the edge of the top of me mat (joint). If the r<illdom core lucation falls Oil a conflnedjoim (edge 0 :-rhe mat being placed butts up against another mat, pavement surface, curb and gutter, or fixed face), cut with ..he outer edge of the core barrel 150 nun:!: 12.5 mm [6 inches =: 0.5 inch] from the edge of the top of the mat (ex. center of 100 mm [4 inch] core barrel 200 mm i: 12.5 rum [8 i: 0.5 inches] from the edge of the top of the mat). Gxes will not be taken within 300 Il".u11 [1 foot] of any unsupported. edge The Contracwr shall bc responsible for maintenance of traffic, coring, patching the core holes, and sawing the cores if necessary to the proper thickm:,s pDt.r to density testing. B3 Core Testing Cores will be taken and tcsted by the Contractor. Cor., locations will be determined and marked by the Engineer. The Contractor shall schedule the appmximaw th-ne of testing during normal project work hours so that the EngiJleer may observe and record the ,<ilUraleu surface dry aud immersed ,veight of the cores. Density cietermination will be made by the end of the next work11.g day after placement and compaction. If multiple layers are placed in a single day, cores shali be lawn and separated for each layer, tested arld reported by the end of the next working day. The Contractor will cut pavement samples from the ccmpleted work with power equipment, and restore the surface by che end of the next working day with new, well cc mpacted mixture without additional compensation. Failure to restore the surface within 24 hours of coring shall 5;uhjccl the Contractor to a flne of S 1 00 per working day, per lot, l.illtil the core holes are restored. Cores shall b,,, cut using a 100 mm l4 inch] minimum outer diameter coring device. All samples shall be marked with ,he lot lumber and core D.umber or kner. The cores shall be transportd to the laboratory as soon as possible :0 prevem damage due to improper handling or exposure to heat. These companion cores may be tested by the Inspector on Deparrnent scales or transported to the l::~;::c.....tr::l\:;r.t'-:;-fdd L:.ccr:::;):} or D:s:;':c: .\~;::~;.tab- J;.ngineer"s Labora:ory. Mea~ure each core three timcs for thickness prior to s:.w cutting, report the average lift thickness on !J.'1e core sheet. These average thickness will contribute to th \cknt:ss (ompHance as described in Section 2360.7 A If dIe 8<::-p<.'':!'S:1eH-f- O'\':geLcompanion core test result j::Jr bulk specific gravity (Gmt) deviates beyond the allowable tol<::rance of 0.030, substitute geFa."U'!""'f;~- Owner ;ompa.."1ion result for Contractor's core result and then average the P~p~.~ffi'ltmt- O:1:.De.r..resu!t with the nOD.-com:lanion result for the lot density acceptance. If, through analysis of data, it is determined there is a bias in the tt:st res:Ilts, the Engineer will determine which results are appropriate and shall govern. If the G::lO tolerance fails in more than 2 lots in a day c,f either consistently hig.1-J. or low differences between thc companion cores then an investigation Lo determine the sou~ce of errors shall be conducted. Companion cores samples shall be increased to l'.vo per lot and !8sted unil investigation is complete and tolerances are met. The Engineer may allow recoring 0 f a sample only w1' en the core has been damaged through no fault of the Contractor, either during the coring process or in transit to tl: e laboratory. B4 Maximum Density Acceptance and Payment Scheel ule The density of compacted mixture shall be accepted bj pavement cores on a Jot basis. The Contractor's cores will be used for accepta11ce if-he determined bulk specific gravity Gob from AASHTO T-166, .\-inJDOT modified or ASTM D 1188 is within ::::. 0.030 of the ::a:c Qwner companion Gmb value. Payment t~Jr lot densities or compacted ~,ture shall be determirled from Table 2360.6-B4 or 2360.6-B4A. Incentive and disincenrive paymems are for both wearing and non-weari ng courses. Page 33 of 48 2360/2350 Combined Specification December 9, 2003 Wilen the density requirement has been reduced hy ore percent, per Tabie 2360.6-B2, foomote 1 & 2, payment adjusrrnents for lot densities will be made as specified b'-able 2360.6-B4A. incentive payments are excluded when t.~e minimum density has been reduced. However, at th" Contractors request and with approval uf the Engineer, the reduced density requirement may be waived and densi:y evaluated under Table 2360.6-B4, including incentives, for fIrst lift constructed on aggregate base, n:ciaim-:d or cold inplace recycled base courses and first lift of an overlay on a roadway with a 6.35 metric ton (i ton) or les:: spring load restriction (reduced density shall not be waived for the first lift constructed on PCC pavements). Tb request and approval shall be made after the flrst days paving and before the [hird days paving begins. Once the request has been approved, evaluation of density will be in accordance with Table 2360.6-B2 (ex.cluding [oomote 2) and Table 2360.6-B4, and witl remain in et1'ect for the duration of mixture placement on that lift. The Contractor will also be responsible for compliance with any construction requirements on subsequent lifts. Table 2360.6-B4 Pavment Schedule for Maximum Densitv [ax Speci!!c Gravity (2) 'rrun [4 inches] from Surface) tilders (3% Void) .6 and above 14..1 - 94.5 n.o - 94.0 92.0- 92.9 11.5 - 91.9 11.0-91.4 iO.5 - 90.9 10.0 - 90.4 Less than 89.0 (4) L:ss than 90.0 - Percent of Max Specific Gravity \-) Percem of i\ SF Wear (~100 mm [4 inches) from Surface) SP Non-Wear (>101 All MV & LV, SP Shld (4% Void) SP 5h(, 93.6 and above 9L. 93.1 - 93.5 92.0 - 93.0 -- 91.0-91.9 90.5 - 90.9 90.0 - 90.4 89.5 - 89.9 I 89.0 - 89.4 Percent Payment 104 \0) 102 (0) 100 98 95 91 85 70 1..1 Percent of Max Specific Gravity \-i I Percent on.lax Specific Gravity (2) I p SP Wear (~100 nun [4 inchesl from Surface) SF Non-Wear (>10>1 rum [4 inches] from Surface) I percent All MV & LV, SP Shld (4% Void) ~p ~h Id .JD/. V . 1) avment _ ~u ers ( ,0 OlCl, - 91.0 and above 9::.0 and above 100 , 90.0 - 90.9 91.0- 91.9 98 89.7 - 89.9 '10.5 - 90.9 \ 95 i 89.4 - 89.6 ;)1).0 - 90.4 Ii 91 , 89.2 - 89.3 89.5 -89.9 I 85 , 89.0 - 89.1 39.0 - 89.4 70 Less than 89.0 '.4) L':S5 than 89.0 I (") Table 2360_6-B4A (1) 1 % Reduced Table (l) Minimum reduced by one percent for the ftrst lift (onstructed on aggregate base (mainline and shoulder), reclaimed or cold inplace recycled base COLIses and fIrst lift of an overlay on a roadway 'with a 6.35 metric ton [i ton] or less spring load restr'ction (roadway includes shoulders). IvliL'1imurn reduced by one percent on the tust lift comtructed on PCC pavements (reduced density cannot be waived). (2) In calculating the percent of maximum specific gravitJ, report to the nearest tenth. (3) The payment in this portion ofth~ specification shall :'Fply only if the day's weighted average individual production air yoids are within - 0.5 percellt of the target air void value. The weighted average air voids shall be based on all the rni.xtu.re production tests (2360.4e) for the corresponding day and shall be weighted by the tons the correspondilg test represents. (4) The HlvlA. material represented by !l1.e lot shall be paid at a 70% pay factor, unless a single core density is less than 87.0~'o of the maximum specific g:avity (Gmm). Ifa single core density is less than 87.0% of Gmm, t.1e material shall be removed ard replaced by the Contractor at t.l}eir expense Page 39 of 48 2360/2350 Combined Specification December 9,2003 with mixture that meets the densiry requirements; or thl: Engineer may permit ::he \.L1.acceptable material to remain inplace with a 500/0 pay factor. The .irr:.its of the area to be removed wiH be de:ermined by additional core samples. These acidhion it core samples shall be taken at the same offset from centerline as the origmai core; unkss the ollgLnal low density core was taken wilhin 0.45 m [1.5 feet] of an edge of the paver pass. Tn that case, the additional cores shall be taken 0.45 ill [1.5 feet] from the edge of the paver pass. The jensities shall be determined at 15 m [50 foot] intervals, both ahead and beck afthe point afuna,;ceptable core density (less than 87.0% of Gmm), until a point of acceptable core density (87.0% )f Gmm or greater) is tound. If the incremental core density testing extends into a preyiou~: ly accepted lot, removal of me unacceptable material will be required; hO\,yever, the re ;ults or these tests shal1 not be used to recalculate the previously accepted lot density. All COS1:S incurred from additional coring and testing, resulting from unacceptable core density, willI' e paid by the Contractor. Tne unacceptable pavement area is to be computed as the pl'oduet of the longitudinal Limits so determined by the 15 m [50 foot] cores and the full Willh of the paver pass, laying in the traffic lane or lanes. Shoulders shall be exempt from this cakulation u..rl.less density failure occurred in the shoulder area. After the unacceptable material (con: densir)' less than 87.0~/;' of Gmm) has been removed and replaced, the density afthe replaccment material wiU be determined by the average of two cores. Payment for the replacement material win be in aecorcance with Tables 2360.6-B4 or 2360.6-84A, whichever applies. There wlIJ be no pay:nenl for the material removed. The remainder ofthe originallvl shall have a 700/;' pay fact:}r. C Ordinary Compaction Method Ordinarj compaction shall be used for layers identiae.. in the typical sections with a mbimum planned thickness of less than 40 mm (1 1/2 inches J, thin tift leveling, W ~dging layers, parching layers, driveways, areas which cannot be compacted with standard highway construction ec uipment. Unless otherwise indicated in the Plans or Special Provisions recreational trails shaH also be compacted b: ordinary compaction. The ordinary compaction method shall not be used on mainline, ramp, or Ivop paving, unless othenvisc designated in the plans or special provisions. .When density is evaluated by the ordinary \:ornpacti"n method a control strip shall be used to establish a rolling pattern. This soall be used by tree Contractor for the c )mpaction of the asphalt mixture for the layer on which the control strip is constructed, or until a new control strh is constructed. The control strip requirement may be w.aived by the Engineer in small localized areas or I mer areas not conducive to its estab lisbmenr. A control strip shall be constructed at the beginning 0"toe work on each lift of each course. Each control strip shall have an area of at least 330 m1 [395 square ya rds J an,i shall be of the same thickness as the lift it represents. The subgrade or pavement course upon which a control strir is La be constructed shall have the prior approval of the Engineer. The control strips shall remain in place and b::comc part of the completed work. The materials used in the construction of thc control SJrips "hall conform to the specified requirement') for the course. The materials used in the control strip shal be from the same source and of the same type as w.1e materials used in the remainder of the course that me contra! strip represents. The equipment used in the cons:ruction of the control strips shall be approved by the Engineer a11d shall be the same rype and mass used on the remamder oIme pavement course represented by the control strip. A minimum of tWO rollers shall be required. A rolling partem shall be est.blisb.ed for each roller. A pneunlatic.tired roller shall be available for compaction operations within 24 hours after request by the Engineer. The final rollliig shall be performed with a tandem steel-wheeled roller. Aseas tbat are i1: accessible to the conventional type rolling equipment shall be compacted to the required density. by tlsG.1.g trench rc Ilers or mechanical tampers. Construction oIthe control scrips will be as directed by the Engineer. Compaction shail commence as soon as possible after the mix:ure has been spread to thc desired thickness and shall continue until no aDoreciable mcrease in density can be obtained bv additional roller's ccvera9:es. Densities ,,\ill be determined bv ~~ans of a portable nuclear t;sting device or suit~ble approved altematl: and a growth curve shall be developed'to Page 40 of 48 2360/2350 CombiIJ.ed Specification December 9, 2003 determille the Opth'1lUffi roUing pattern. The Contractor shall fu."1lish doc umentation of the growth curve to the Engineer. To detenuine when no appreciable increase in density :an be obtained, t\vo test points shall bt established in the control strip oc. a random basis and the density at each point shall be measured by a ponable nuclear device or suitable approved alternate after each roller pass. Roll.ng shall be suspended when testing' ~hows either a decline or more than 2% of the maxirnum specific gravity or \.vh'~n additional railer passes fail to increase the densit:..;. After said H:sting is accomplished, rolling on the rema nder of that course shall be done in accordance with the pattern developed in the tcst 5wip for that roIler. A ':eparate rolling pattern and time interval shall be established for each roller. A new control strip shall be ordered by the Engineer when: (a) A change in the Jtvlf is made, or (b) A change in the source of material is made or a change in the material from the same source is observed. A new control strip may be ordered by !.he Engineer or requested by the Contractor when: (a) Ten days of production have been accepted 'i,'ithollt construction ora m:w control strip, or (b) There are other reasons to believe that a contl'Ol strip llensity is not representative of the i-LvLA. mixrure being placed. The nuclear testing device shall be furnished and opet ucG by the Contractor. The furnishing of the testing device and the operator will be considered incidental to the ti.mishing and placement of the HMA mixture and shall not be compensated for separately. The device shall be calibrated according to procedures described in the Mn/DOT Bituminous Manual. Each course shall be uniformly compacted until tbere is no further evidence of consolidation and all roller marks are eliminated. W11(:0 this method is employed, and the quantity of mix-iure placed by the paver exceeds 100 metric tons [110 tons] per hour, at least '''';0 rollers are reo.! :ired for compactLng the mixture placed by each paver. Cl Rollers The following requirements for rollers applyonly wh,':n compaction is obtained by the ordinary compaction met.'lod. . C2 Steel-Wheeled Rollers Steel-wheeled rollers shall be self-propelled and has, minimum total mass of?.3 metric tons [8 tons], or as othenvise specified in the Contract. \'v'11en vibratory rollers arc used, they shall produce 45 kJ.'\i per meter [3,085 lbf per foot] of width. The frequency should be at least 2400 "Tm and amplirude ,erring low. The roller shall be capable of reversing without backlash and shall be equipped wi:h spray artacn...'1lems for moistening all rellers on both sets of wheels. C3 Pneumatic-Tired Rollers The pneumatic-tired roller shall have a compacting wdth of 1.5 m [5 feet] or more. It shall be so constructed that the gross wheel load force shall be a minimum of 13 kj'j [3,000 pounds] per wheel for LV and MV mixrures and SP LeveL 2-3 mL'\.'iures and 22 lc'i [5,000 puunds] per wht.el for SF Level 4-6 mixtures and can be va....ied as directed by the Engineer. The tire arrangement shall be such hat full compaction will be obtained over the full widtb. with each pass of the roller. Page 41 of 48 2360/2350 Combined Specification December 9, 2003 The roller may be sell' propelled or provided with suilable tracdve equipment, urJess otlwr>vlse specified in the Contract. Ifmore rhan one roiler is propelled by a sing e tr;;,crive unit, then that combination will be counted as a single roller unit. C4 Trench Rollers Trench rollers shall be self propelled. and have a mas:: of not less than 4,400 kg per meter [1,960 pounds per footJ of width. C5 Mixture Temperature Controls If compaction is obtained by the oruinary cOIDpactior' method., rhe minimum laydov.n temperature in all courses (as measured behind the paver or spreading machL'1e) of dIe asphalt mixture shall be in accordance with the temperature requirements of Table 2360.6-C5. Unless directed by the Engineer l.'1 \vTiting, no paving is allowed under the Ordinary Compaction Method Wh<':Il thl: ClIT tcrnpcratlll'c is below QCC [32cF]. IV inure Temperature amra Air I Compacted Mat Thidmcss, mm i,A) Temperature cC [OF] i 25 IIllll [1 inch 1 40 IIlIn [1-1/2 inchl 1 iO IIlE1 [2 inch 1 ; >75 mrn [3 inch] I +0-5 [32-40J , -- 129 \:11 [265] I 124 [255] 121 [250] + 6-10 [41-50] i 130 ',"} [270] 127 [260] 121 r2501 1\8 [245] + ! [-15 [51-60] . 127 (::Jj i260] 124 [255J 1181245J 115 [240] + 16-21 [61-70] i 121\lJ] [250] , 118 [245J 115 [2401 113[2351 + 22-27 [il-80] I 118 [2451 1 [5 [240] 113 [235] \1 ~ '''3 '51 I J..) L- ~ I + 28-37 [81-901 I 113 [235] lID [2301 I \10 [2301 II 0 f2301 I +33[91+] I 110 [230] 11 0 [230] I 110 [230] 107 [225] I Table 2360.6-C5 I C CA.) (B) Based on approved or specified compacted lift thickne~ " A mir..in1um of one pneumatic-tire roUer shall be used hr intermediate rolling unless otherwise directed by the Engineer. The Engineer may specify 01 modify in "Tiring (v,:ith concurrence from the Deparrmem Bituminous Engilleer) a miP.im.um layd,)\vn temperature. 2360.7 THICK.'iESS A1'11) SURFACE SMOOTHNISS R EQU1REMENTS A Thickness After compaction the thickness or eilcn Ii IT shall be within a tolerance of 6 mm [1/4 inch] of the thickness shown in the Plans, except that. if automatic grade controls aT : used, this thickness requirement will not apply to the first lift placed. This thiclrness requirement will not apply 0 a leveling lift whether or not autoIIlatic grade controls are required. The Engineer may require removal and ref laceIIlent, at the Contractor's expense, of any part orany lifl that is constructed to less than the minimum required uli.:kness. On that pam on of any lift constructed to more than tb ~ maximum permissible lfIickness, the materials used in the excess mLxture above that required to construct tha t portion of the Ii ft to the Plan thickness plus 6 mm (1/4 inch] will be excluded from the pay qual1tities and at the disc n:tion of the Engineer and at the Contractor's expense may be required to be removed alld replaced. Cores taken for density determination shall be IIleasured for thickness also. Each core shall be measured 3 times for thickness orior [0 sawing. Report the average of tlJese three measureIIlents. Each lot's average core thickness shall be docume~ted and submItted t~ the Enginee;. If the average of the 1'\vo Contractor cores ~ exceed the specified tolerance, an addirional two cores may be taken in :he lot in question. Tue average of all core thickness measurements per lift will be used to determine cOIIlpJiance with thickness specifications. Page 42 of 48 2360i2350 Combined Specification December 9,2003 B Surface Requirements After compaction, tht: fmisht:u ~urface 0 f each lift sna! l be reasonably free of segregated, open and torn sections, and shall be smooth and true to the grade mu cross SC::CtiOCI shown on the Plans ",'ith the following tolerm1ces: (1) W11ere a leveling lift is specifid, it shall be constructe:i to within a tolerance of 15 mm [1/2 inch] of the elevations and grades i.:stablisned by the Engine,:r. This requirement shall also apply to the flIst lift placed other than leveling when automatic cOlltrols are used, (2) The surface ofthc fmal two lifts placed shall shov, nOiariarion greater than 6 mID [1/4 inch] from the edge of a 3 m [10 foot) straightedge laid parallel tc' or at right angles to the centerline. Shoulder surfacing and surfacing on temporary connections and bypasses shall show no variations greater than 6 mm [114 inch] from the edge of a 3 ill [:I 0 foot] straightedge laid parallel to the centerline. (3) After fmal compaction, all finallin asphalt wearing su-races adjacent to concrete pavements shall be slightly higher (but not to exceed 6 mill [1/4 inch] 11an the concrete surface. After final compaction, all asphali surfaces adjacent tc gutters, manholes, pavement headers, or O1her fixed stn;ctures shall be slighrly higher (bur not tl exceed 6 mm [1/4 inch] than the surface of the structure. . (4) Transverse joints (construction joints), at the beginni 19 and end of a project, at paving exceptions, or caused by suspension of daily paving oreration~, shall show no variation greater than 6 nun [1/4 inch] from the edge of a:' m [10 foot] straightedge centered longitudinally across the transverse joint. The Engineer may require correcl.on by diamond grinding when material is placed outside the above described limitations. (5) The transverse slope of the surfucc of each lift, exclusi ie of the shoulder wearing lift, shall not vary from the slope shown in the Plans by more than 04 percent. (6) The distance betvieen the edge of each lift and tbe estallished centerline shall be no less tha..'1 the Plan distance nor more than 75 rom [3 inches] sreaterhan the Plan distance. In addition. the edge alignment of [he wearing lift on tangent sections and 0'1 curve sections of 3 degrees or less shall not deviate from the established alignment by more th,~n 25 mm (1 inch] in any 7.5 m [25 foot] section. (7) The tinished surtace of each lift shall be reasonably free of segregated and open and tom sections. Any material placed outside the above descn'bed liminltions shall be removed and replaced after being cur or sawed at no expense to the ::)"pc.:-::ne:1t O'.\'ner or with the ,.pproval oEthe Engineer, allowed to remain inplace at a reduced cost calculated at S 12 per square meter [S10 per sq l~ are yard]. c Pavement Smoothness Cl General Pavement smoothness will be evaluated on the final tI'ainline pavement surface using a California type profilograpb or llertial Pro filer (IP) with a 5 mn1 [0.2 inch] biankiD~ band. Unless otherwise authorized by the Engineer, all smoothness testing shall be performed in the presence of th,: Engineer. The Engineer and tbe Contractor shall mutually agree upon scheduling of smoothness teSting s,) that testing can be observed. AllY testing performed without the Engineer's presence, urlless otherwise authorized, may be ordered retested at the Contractors ex?ense. The rollowing table shows pavement surfaces, whicb are exdu It:d tram profilograpb testing, but subject to Section 2360.7B surface requirements. Page 43 of 48 3.04 JOINT CONSTRUCTION A. Conform to MnDOT Spec. 2531.3C, except as modified herein: 1. Maximum spacing of expansion joints for slip formed shall be 200 feet. 2. Contraction joints, 10 foot intervals. 3.05 METAL REINFORCEMENT A. Conform to MnDOT Spec. 2531.3D, except as modified herein: 1. Install two #4 steel reinforcing rods in lo\ver portion of the curb section, with a minimum of 2 inches coverage on all sides: a. Placement shall extend 10 feet on each side of a catch basin. 3.06 PLACING Ai\TI) FINISHING A. Conform to MnDOT Spec. 2531.3E and 2531.3F, except as modified herein: 1. The top surface of the curb and gutter shall have a brush finish at right angles to the curb line. 3.07 CONCRETE ClTRING AND PROTECTION A Conform to MnDOT Spec. 2531.3G and 2531.3G2 (Membrane Curing Method), except as modified herein: 1. All surfaces shall be coated with membrane curing compound within 30 minutes after finishing at the specified rate. 2. The membrane-curing compound must contain a fugitive dye and be applied in 2 different directions perpendicular to each other. 3. A second application of membrane curing compound shall be applied 4 to 8 hours after the first application at the specified rate. 4. Cold weather curing, when temperatures fall below 400 during placement or w'ithin the following 24 hours, shall conform to MnDOT Spec. 2531.3G 1 blanket curing method, or method approved by the Engineer. 5. The freshly finished surface shall be protected, surfaces pitted by rain will be considered unacceptable. 34-04-162 ,:g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02770-4 CONCRETE CURB AND GUTTER 6. Removal and replacement any curb section damaged by traffic, rain, cold weather, or other causes occurring prior to final acceptance shall be the responsibility of the Contractor. 3.0S BACKFILLING A. Conform to MnDOT Spec. 2531.3J, except as modified herein: 1. Initial Backfilling: a. Follow the 72 hour curing period with completion within 6 days of original placement. b. Tolerance within 0.3 feet to the top of curb elevation. 2. Curb damaged during backfilling is the responsibility of the Contractor to replace at no cost to the owner. 3.09 WORK.i\lLAl'\JSHIP Ai~'D FINISH A. Conform to MnDOT Spec. 2531.3K, except as modified herein: 1. Any deviation in the design curvature of concrete edges in excess of 3/S of an inch, measured with a 10 foot straight edge, \vill be considered unacceptable. 2. Acceptance of work by price reduction will not be allowed. 3.10 MEASlJREMENT AL"'\JTI P A'r''MENT A Bid Items have been provided for B61S Concrete Curb and Gutter. Measurement . of curb and gutter shall be by the lineal foot measured along the face of the curb at the gutter line for each type. Payment shall include materials, preparation, placement, finishing, curing, protection, reinforcement, and backfilling. B. No separate measurement or payment for modifications at curb ramps, or transition sections. D. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. Ei'<'D OF SECTION 34-04-162 ;:g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02770-5 CONCRETE CURB AND GUTTER SECTION 02775 CONCRETE WALKS. MEDIANS. l<\l~TI DRIVE\V A YS PART 1- GENERAL 1.01 SECTION INCLUDES A. Construction of cast-in-place concrete walbvays, medians, driveways, and valley gutters. 1.02 RELATED SECTIONS A. Section 02315 - Excavation and Fill. B. Section 02720 - Aggregate Base Course. C. Section 02770 - Concrete Curb and Gutter. D. Section 02740 Plant Mixed Asphalt Pavement. 1.03 REFERENCES A. American Society of Testing Materials (ASTM): 1. C260 - Air-Entraining Admixtures for Concrete. B. Minnesota Department of Transportation "Standard Specifications for Construction," 2000 Edition (MnDOT Spec.): 1. 2211 - Aggregate Base. 2. 2461 - Structural Concrete. 3. 2521 - Walks. 4. 2531 - Concrete Curbing. 5. 3702 - Preformed Joint Filers. 6. 3754 - Membrane Curing Compound. 34-04-162 :g 2004 Bonestroo, Rosene, AJlderlik & Associates, Inc. 02775-1 CONCRETE WALKS. MEDL'\NS, AND DRI'lEWA YS 1.04 SUBMITTALS A. Submit one - 7 day and two - 28 day concrete test results for all concrete pours in any given day. B. Submit design mix for each concrete mix used. 1.05 SEQUENCING AL'\TD SCHEDULING A. Constmction of the concrete driveway apron shall begin no sooner than 24 hours after placement of the adjacent concrete curb and gutter with completion within 5 days of curb placement. PART 2 - PRODUCTS 2.01 MA TERlALS A. Concrete to conform to MnDOT Spec. 2461, except as modified herein: 1. Portland Cement: Conform to MnDOT Spec. 3101: a. Type 3 air-entraining concrete produced by using Type IA air- entraining Portland Cement. 2. Air-Entraining Admixtures: conforn1 to MnDOT Spec. 3113: a. Conforming to ASTM C260. b. Not to be added to the concrete mixtures m the field without approval from Engineer. 3. Mix Designation and Classification: a. Manual Placement Mix No. 3Y32C. b. Slip Form Placement Mix No. 3Y22C. c. Exposed Aggregate Mix No. 3Y36C. B. Preformed Joint Filler: Conform to MnDOT Spec. 3702. C. Curing Compound: Conform to MnDOT Spec. 3754. 34-04-162 ':9 2004 Bonestroo, Rosene, A..11derIik & Associates, Inc. 02775-2 CONCRETE WALKS, MEDIANS, AND DRJVEWA YS D. Sub-Grade Base Material: 1. Select Granular Material: Conform to Section 02315 - Excavation and Fill. 2. Aggregated Base: Conforming to Section 02720 - Aggregate Base Course. PART 3 - EXECUTION 3.01 GENERAL A. Provide copies of batch tickets for concrete mix at the time of material delivery to Project Site. B. Construct concrete walkway, median, driveways, and valley gutters at the locations, and elevations indicated on the Drawings. C. Construct walkways and medians to conform to the typical section shown on the Drawings. D. Constmct concrete driveway aprons to conform to the Drawings. E. Construct concrete valley gutters to conform to the Drawings. F. Constmct concrete curb ramp to conform to the Drawings. G. Verify locations with Engineer in the field prior to constmction. H. The completed concrete work shall give the appearance of uniformity in surface contour and texture, and shall be accurately constructed to line and grade. The required joints, edges, and flow lines shall show neat workInanship. 1. Retempering of concrete, which has partially hardened, with or without additional materials or water, is prohibited. 3.02 FOUNDATION PREPARATIONS A. Placement of the aggregate base or granular material to support the concrete work shall conform to Section 02720 - Aggregate Base Course or Section 0231S - Sub grade Preparation. Compaction of sub grade base shall conform to MnDOT Spec. 2211.3C 1. B. The foundation shall be approved by the Engineer prior to placement of concrete material. 34-04-162 :1::; 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02775-3 CONCRETE WALKS, MEDIANS, AND DRNEWA YS 3.03 FORMS A. Conform to MnDOT Spec. 2521.3B. 3.04 JOINT CONSTRUCTION A. Conform to MnDOT Spec. 2521.3C2, except as modified herein: 1. Maximum spacing of expansion joints for walkways shall be 60 feet. 2. Match joints of adjacent concrete work. 3.05 METAL REINFORCEMENT A. Conform to MnDOT Spec. 2531.3D, except as moditied herein: 1. Install three #4 steel reinforcing rods in lower portion of the valley gutter section with minimum 2 inch coverage on all sides. 3.06 PLACING fu,\;1) FINISHING A. Conform to MnDOT Spec. 2521.3Cl and 2531.3.F for slip form, or 2531.3.K for manual placement, except as moditied herein: 1. Any deviation in the design curvature of concrete edges in excess of 3/8 of an inch, measured with a 10 foot straight edge, will be considered unacceptab le. 2. Any surface area allo\ving the entrapment of water at a depth 1/8 inch, or greater will be considered unacceptable. 3. Unacceptable work shall be removed and replaced with acceptable work as directed by the Engineer. Acceptance of work by price reduction will not be allowed. B. Exposed aggregate finish shall conform to MnDOT Spec. 2521.3.C.1a: 1. For the pedestrian curb ramps as sho\vn on the Drawings. 3.07 CONCRETE ClJRING i\l,\;1) PROTECTION A. Conform to MnDOT Spec. 2521.3C3 and 2521.3C3b (Membrane Curing Method), except as modified herein: 1. All surfaces shall be coated with membrane curing compound within 30 minutes after finishing at the specified rate. 34-04-[62 :9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02775-4 CONCRETE WA.LKS, MEDL".NS, AND DRIVEWAYS 2. The membrane-curing compound must contain a fugitive dye and be applied at 2 different directions perpendicular to each other. 3. A second application of membrane curing compound shall be applied 4 to S hours after the first application at the specified rate. 4. Cold weather curing, when temperatures fall below 400 during placement or within the following 24 hours, shall conform to MnDOT Spec. 2521.3C3a blanket curing method, or method approved by the Engineer. 5. The freshly finished surface shall be protected, surfaces pitted by rain will be considered unacceptable. 6. Removal and replacement of any concrete section damaged by traffic, rain, cold weather, or other causes occurring prior to final acceptance shall be the responsibility of the Contractor. 3.0S BACKFILLING A. Conform to MnDOT Spec.2521.3E, except as modified herein: 1. Perform backfilling to protect the concrete no sooner than 72 hours after placement of the concrete. 3.09 MEASUREMENT Ai'JD PA'r''MENT A Bid Items have been provided for 6 Inch Concrete Driveway Pavement and 4 Inch Concrete Sidewalk. Measurement shall be by the square yard top surface area. This Bid Item shall include: 1. Concrete materials. 2. Select granular subgrade base material, 4 inches thick. Additional base material will be paid as select granular borrow if required. 3. Preparation. 4. Placement of materials. 5. Finishing. 6. Curing and protection. 7. Backfilling. S. Reinforcement. 34-04-162 :g 2004 Bonesrroo, Rosene, Anderlik & Associates, Inc. 02775-5 CONCRETE WALKS, ?vlEDL'\NS, AND DRfYEWA YS B. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. END OF SECTION 34-04-! 62 :g 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02775-6 CONCRETE WALKS, MEDL-\NS, AND DRNEWA YS SECTION 02920 LA WNS AJ.'ID GRASSES PART 1 - GENERAL 1.01 SECTION INCLu1)ES A. Restoration of construction area by installation of topsoil, seed, sod, soil amendments, mulch, and erosion control. 1.02 RELATED SECTIONS A. Section 01570 - Erosion and Sediment Control. B. Section 02315 - Excavation and Fill. 1.03 REFERENCES A Minnesota Department of Transportation "Standard Specifications for Constmction," 2000 Edition (MnDOT Spec.): 1. 2575 - Turf Establishment. 2. 3877 - Topsoil Borrow. 3. 3878 - Sod. 4. 3881 - Commercial Fertilizer. B. "Minnesota Department of Transportation Seeding Manual 2000," (MnDOT Seeding Manual). 1.04 SUBMITTALS A. Provide source and invoice for seed to be used for this Project. 1.05 QUALITY ASSlJRANCE A. At the conclusion of the establishment period, which will be 1 year following initial installation, a final inspection of planting will be made to determine the conditions of areas specified for seeding. All areas with insufficient plant establishment as determined by the Engineer will be noted. This material shall be re-supplied and planted in the next growing season at no additional cost to the Owner. Evaluation of plantings shall be done in accordance with Early Maintenance and Evaluation of Plantings, MnDOT Seeding Manual 2000, and with MnDOT Spec. 2575.3. 34-04- ! 62 :g 2004 Bonestroo. Rosene. Anderlik & Associates, Inc. 02920-1 LAWNS AND GRASSES 1.06 FIELD QUALITY CONTROL A. Provide Engineer with bags and tags of seed used for identification purposes. PART 2 - PRODUCTS 2.01 MATERIALS A. Topsoil: Topsoil Borro\v conforming to MnDOT Spec. 3877.2.A. B. Soil Amendments: Conform to MnDOT Spec. 3881 and 3879. Fertilizer shall be complete fertilizer containing 8 percent nitrogen, 16 percent phosphoric acid, and 8 percent potash. C. Sod: Conform to MnDOT Spec. 3878. P ART 3 - EXECUTION 3.01 EXN\ilINATION A. . Review restoration areas with the Engineer. Determine locations for seed, or sod. Schedule for restoration of areas may be revised to fit field conditions. B. Notify the Engineer at least 3 days in advance of hauling topsoil borrow on Project Site, so the Engineer may visually inspect and sample for testing if deemed necessary. C. Finish grades are to be inspected and approved by the Engineer prior to start of restoration. 3.02 PREPARATION A. General: Conform to MnDOT Spec. 2575.3.A. B. Soil Preparation: Conform to MnDOT Spec. 2575.3.B. C. Fertilizers and Conditioners: Conform to MnDOT Spec. 2575.3.C: 1. Apply fertilizer at a rate of450 lbs. per acre (10 lbs./l000 sq. ft.). 2. Where soil pH is lower than 5.5, apply ground limestone at 3 tons per acre (140 lbs./l000 sq. ft.). 3.03 PLACING SOD A. Conform to MnDOT Spec. 2575.3.1. 34-04-[62 :g 2004 Bonestroo, Rosene, Anderlik & Associates. Inc. 02920-2 L\ WNS AND G~A.SSES 3.04 FIELD QUAlITY CONTROL A. Maintain restored areas in accordance with MnDOT Spec. 2575.3L. B. Restored areas that have been satisfactorily completed and are disturbed by additional construction activity required by the timing and sequencing of the \vork shall be restored over to the same requirements of the original work. C. Any sod that does not show definite growth and establishment 30 days after laying shall be replaced and established, at the proper season by the Contractor at his expense. D. Watering of seeded and sodded areas shall be done for a period of 30 days from installation sufficient, to ensure establishment of permanent vegetation. 3.05 MEASUREMENT AND PATh1ENT A. A Bid Item has been provided for Sodding, Lawn Type. Measurement will be based upon units of square yards of sod installed complete in place as specitied, including installing topsoil; soil amendments; furnishing and installing sod; preparation of surface maintenance; and all incidental items associated with the work. The actual quantity installed multiplied by the appropriate Bid Unit Price will be considered payment in full for all work and costs of this Bid Item. B. A Bid Item has been provided for Topsoil Borro\v (LV) on the Bid Form. Measurement will be based upon units of cubic yards of material placed (loose volume) hauled to and installed complete in place as specified. The actual quantity installed multiplied by the appropriate Bid Unit Price will be considered payment in full for all work and costs of this Bid Item. C. All other work and costs of this Section shall be incidental to the Project and included in the TOTAL BASE BID. ENTI OF SECTION 34-04- ! 62 :9 2004 Bonestroo, Rosene, Anderlik & Associates, Inc. 02920-3 LA. WNS AND GRASSES This document has important legal consequences; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the Controlling Law. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT Prepared by ENGINEERS JOINT CONTR~CT DOCUMENTS COMMITTEE and Issued and Published Jointly By ----------- ACEC National Society of Professional Engineers" ..k""_,,,w~ ~"'", ,~', ",.._wr-,n~.,~,',___. _,~ Professional Engineers in Priyale Practice .;:.l!.:;kIL.\.' CVl':-<(.ll,..I;,. E.'GI:-':U:.HI:"C CU."ll'.'~lt~ PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE a practice division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS AtvIERICAt"T COUNCIL OF ENGINEERING COMP At"TIES ~.. AtvlERICi\N SOCIETY OF CIVIL ENGII\TEERS This documenl has been approved and endorsed by ~"':-t~~ft'(/~ I~ /.. \, -+ r?lA;,~;'f)9 ~;J/!}!y ~~^== L.!.!.~h;:-_~~ ~ The Associated General Contractors of America ~ Knowiedge for Creating ~ and Sustaining the Built Environment Construction Specifications Institute EJCDC C-700 Standard Gcncral Conditions of thc Construction Contract- Copyright:g 2002 National Socicty of Profcssional Enginccrs for EJCDC. All rights rcscrvcd. 00700 - 1 Copyright @2002 National Society of Professional Engineers 1420 King Street, Alexandria, V A 22314 American Council of Engineering Companies 1015 15th Street, N.W., Washington, DC 20005 American Society of Civil Engineers 1801 Alexander Bell Drive, Reston, VA 20191-4400 These General Conditions have been prepared for use with the Suggested Forms of Agreement Between Owner and Contractor Nos. C-520 or C-525 (2002 Editions). Their provisions are interrelated and a change in one may necessitate a change in the other. Comments concerning their usage are contained in the EJCDC Construction Documents, General and Instructions (No. C-001) (2002 Edition). For guidance in the preparation of Supplementary Conditions, see Guide to the Preparation of Supplementary Conditions (No. C-800) (2002 Edition). EJCDC C-700 Stnndard Genernl Conditions of the Construction Contrnct. Copyright <9 2002 Nntional Society of Professional Engineers for EJCDC. All rights reserved. 00700 - 2 TABLE OF CONTENTS Pa2:e ARTICLE 1 - DEFINITIONS Al~D TERMINOLOGY ..............................................................................................................6 1.01 Defined Terms .............. ..... ............ ............. ................. ................ ........ ............. ... ....... ...... ........... ......... .... ... ...... .......6 1. 02 Terminology...................................................................................................................... .......................................8 ARTICLE 2 - PRELIMINARY MATTERS................................................................................................................................9 2.01 Delivery of Bonds and Evidence of Insurance .........................................................................................................9 2.02 Copies of Documents .. .............. ... ... .... ...... ... ..... ....... ..... ........ ................... ...... ............ .......... ...... ...... ........ ... ....... ......9 2.03 Commencement of Contract Times; Notice to Proceed ...........................................................................................9 2.04 Starting the Work '" .............. ..... ... ........ ............... ...... ... ............... ....... .......... .... ... ... ....... ... ............... .... ...... ......... ......9 2.05 Before Starting Construction .... ........... ................. .... ................ .......... ....... ...... ... ... ............. .... ......... ... ........... ....... ...9 2.06 Preconstruction Conference............................................................................................................................ .........9 2.07 Initial Acceptance of Schedules ...... ............ ........... ............. ...... ................. ......... ....... ... ....... ...... ................. ............. 9 ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, A..lvIENDING, REUSE.......................................................................lO 3.01 Intent............................................................................................................................... .......................................10 3.02 Reference Standards ............ ............... ................ ........ ................... .................. ........... ...... .................. ..... ..............10 3.03 Reporting and Resolving Discrepancies ................................................................................................................1 0 3.04 Amending and Supplementing Contract Documents ..............................................................................................11 3.05 Reuse of Documents ...............................................................................................................................................11 3.06 Electronic Data.. ........... ............ ............. ..... ............... ......... ................................ ................. ........... ...................... .11 ARTICLE 4 - A V AILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; HAZARDOUS ENVIRONNIENTAL CONDITIONS; REFERENCE POINTS ................................................................................................11 4.01 A vailability of L[lnds ..............................................................................................................................................11 4.02 Subslllface and Physical Conditions ............ ............. .................. ................. .......... .... ............................................12 4.03 Differing Subsurface or Physical Conditions ............... ..... ........ .......... ......... .......... .......... .......... ................. .......... .12 4.04 Underg round Facilities ........ ................ .......................... ..... ........... ..... ...... ...... .... ...... ........ ... .... ........... ........... ....... .13 4.05 Reference Points ........ ....... ........ ........... ............. ....... ..... ...... ................ ... .... ...... .......... .... ...... .... ........... .................. .13 4.06 Hazardous Environmental Condition at Site .........................................................................................................13 ARTICLE 5 - BONDS l\ND INSURANCE .............................................................................................................................14 5.01 Performance, Payment, and Other Bonds..............................................................................................................14 5.02 Licensed Sureties and Insurers ..............................................................................................................................15 5.03 Certificates of Insurance ...... ..... ........... ................ ........ ....... ................................................. ............... .......... .........15 5.04 Contractor's Liability Insurance.. ........... .......... ............. ..................... ............. .......... .......... ............... ..... ......... .....15 5.05 Owner's Liability Insurance ..................................................................................................................................16 5.06 P ropeny Insurance ....... ................ ....... ....................... ............ ....... ............. ................................... ........ ............ ....16 5.07 Waiver of Rights. ........... ....... ........... ............ ................. ..... ...... ........... ............... ..... ............. .... .................. .............17 5.08 Receipt and Application of Insurance Proceeds ....................................................................................................17 5.09 Acceptance of Bonds and Insurance; Option to Replace .......................................................................................17 5.10 Partial Utilization, Acknowledgment of Property Insurer .....................................................................................18 ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES ..........................................................................................................18 6.0 I Supervision and Superintendence ........ ............ ................... ...... ...... .... ................ ................. .... ............ ................. .18 6.02 Labor; Working Hours ...........................................................................................................................................18 6.03 Services, i'vlaterials, and Equipment.......................................................................................................................18 6.04 Progress Schedule... ....................................................... ......... ............................. ......................... ...... .............. .....18 6.05 Substitutes and "Or-Equals" .................................................................................................................................19 6.06 Concerning Subcontractors, Suppliers, and Others...............................................................................................20 6.07 Patent Fees and Royalties ...........:..........................................................................................................................21 6.08 Permits ....... .... .............. .......... ......... .............................. ...... ................................ ................. ....... ................ .......... .21 6.09 Laws and Regulations..................... ....... ........ ................ ..... ...... ........... ............... ................. .................. ............... .21 6.10 Taxes........................................................................................................................... ...........................................22 6.11 Use of Site and Other Areas...................................................................................................................................22 6.12 Record Documents........... ....................... ............ .......... ..... ................................. ..... ........................... ..... .... ...... ....22 6.13 Safety and Protection .... ............... ................................ ..... ............... ........... ...... ..... ............. ........ ........... ............... .22 6.14 Safety Representative .. ......... ..... ....... ............. ..... ....... ..... ..... .......... ........ ...... ...... ......... ... .... ....... ........ .................. ....23 6.15 Hazard Communication P rog rams.......................... ........... ................................ ................. ...... ................ ............23 E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright:g 2002 National Society of Professional Engineers for E.JCDC. All rights reserved. 6.16 Emergencies.. .... .............. ...... ...... .................... ......... ........ ................... ..... ......... ............... .... .... ............ ............ ......23 6.17 Shop Drawings and Samples ....... ..... ............... .................... ........ ............. ................ ........ .......... .......... ........... .,. ....23 6.18 Continuing the Work.... ....... ...... .................... ........... ................................... .... ........ ................... ....... ....... ..... ..... ....24 6.19 Contractor's General Warrant)' and Guarantee ....................................................................................................24 6.20 Indemnification................................................................................................................... .................................. .24 6.21 Delegation of Professional Design SenJices ..........................................................................................................25 ARTICLE 7 - OTHER WORK AT tHE SITE .........................................................................................................................25 7.01 Related Work at Site ...............................................................................................................................................25 7.02 Coo rdination ..................................................................................................................................... .................. ...26 7.03 Legal Relationships..... ................... ........... .......... .:. .... ..... ............ ................... ... ............... ........ ..................... ..... ....26 ARTICLE 8 - OWi\TER'S RESPONSIBILITIES ......................................................................................................................26 8.01 Communications to Contractor ..... ..... ........ ..... .... ........ ..... ... ... ...... .... ... ..... ....... ...... ........ ............. .... ................ ........26 8.02 Replacement of Engineer .... ...................... .......... .... ............ ......... ....... ........ ...... ......... .................... .................... ....26 8.03 Fum ish Data.................................................................................................................................. ...................... ..26 8 .04 Pay When Due.................................................................................................................................... ....................26 8.05 Lands and Easements; Reports and Tests ..............................................................................................................26 8.06 Insurance............................................................................................................................. .................................. .26 8.07 Chang e Orders............................................................................................................................... ...... ..................26 8.08 Inspections, Tests, and Approvals ................. ...... ........ ........ ................ ..................... ..... ................... .......... ............26 8.09 Limitations on Owner's Responsibilities ....... ........ ... ........ ... ........ ..... ... ..... ........... ......... .... ....... .... ...... ............ ... ......27 8.10 Undisclosed Hazardous Environmental Condilion................................................................................................27 8.11 Evidence of Financial Arrangements .....................................................................................................................27 ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION.....................................................................................27 9.01 Owner's Representative .............. ......... ..... ..... ................... ...... ........... ........... ............. .............. ...................... ........27 9.02 Visits to Site .............. ........... ........ ........... ........ ........... .... ..... ..... ............. ......... .... .............. ........... .... .......... ...... ........27 9 .03 Project Representative. ......... .... ................. ......... ... .... ... ............ ........... ....... ..... ............ .... .......... .... ............ ............27 9.04 Authorized Variations in Work....... ... .................. ....... ... .......... ............ ................ ............. ... ....... .... ...... .............. ....27 9 .05 Rejecting Defective Work................................................................................................................................... . ...27 9.06 Shop Drawings, Change Orders and Payments .....................................................................................................28 9.07 Determinations for Unit Price Work ............. ...... ........... ..... ........ ............. ........... .................... ................. ..............28 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work ...................................................28 9.09 Limitations on Engineer's Authority and Responsibilities .....................................................................................28 ARTICLE 10 _ CHANGES IN THE WORK; CLAIMS ...........................................................................................................28 10.01 Authorized Changes in the Work.. ............. ..... ............... ............ .......... ....... ...... .......... ....................... ............ ..... ....28 10.02 Unauthorized Changes in the Work .......................................................................................................................29 10.03 Execution of Change Orders.......... ... ........ ..... ........ ..... ........ ........ ................ .......... ........... ......... ........... .... .... ...... ....29 10.04 Notification to Surety... ......... .... ...................... .... ............. ... ........ .., .......... .... ......... ... ............... ...... .... ....... .... ..........29 10.05 Claims................................................................................................................................ ................................... .29 ARTICLE 11 - COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK..................................................................30 11.01 Cost of the Work.... ......... ..... ........... ................ ........... ............... ........... ............ ........................... .... ............ ...... ......30 11.02 Allowances ............ ....... ....... ........ ......... ..... ..... .... ....... ............... ............. ...... ..... ................ ....... ......... ........ .......... ....31 11.03 Unit Price Work ........................................ .............................................................................................................31 ARTICLE 12 - CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES .....................................................32 12.01 Change of Contract Price ..... ............ ..... .......... .............. ..................... ................ ............. ........................ .......... ....32 12.02 Change of Contract Times ... ............. .......... ............................... ......... ........... ..... ................ ....... ........................ ....33 12.03 Delays........................................................................................................................... .........................................33 ARTICLE 13 - TESTS ANTI INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK.......33 13.01 Notice of Defects ....... .... ................................ ............................... ............................ ..... ................. ....... ......... ..... ...33 13.02 Access to ~1lork... ........... .......................................... ..... .................. ..... ...... ........ ...... ........................... ........ .......... ..33 13.03 Tests and Inspections .... ......... .......... ..................................... ............................. .............. ........ ............ ......... ....... ..33 13.04 Uncovering Work .......... ......... ........................ ......... .................... ... ..... .......... ............. ...... ........ ......... ... .............. ....34 13.05 Owner j'vlay Stop the Work ............................................................................................................................,........34 13.06 Correction or Removal of Defective Work .............................................................................................................34 13.07 Correction Period. ....... ........ ................... .......... ........... ........ ....................... ........ ................ ...... ........ ............... ......34 13.08 Acceptance of Defective Work ...............................................................................................................................35 13.09 Owner l'vlay Correct Defective \Vork ...... ........ .................. ........... ........ ................ ............. .......... ....................... .....35 ARTICLE 14 - PAYMENTS TO CONTRACTOR .A.t'\TD COMPLETION...............................................................................36 14.01 Schedule of Values....................................................................................................................... .......................... 3 6 14.02 P rag ress Payments........... ................... ...... .... ......... ............... ...... ...... ............ ..... ........... ....... ...... ...... ........ .......... ....36 14.03 Contractor's Warran ty of Title ... .......... .......... .... ......... .... ........ ...... .......... ... ....... ........ ............ ... ........ ....... .... ... .......37 14. 04 Substantial Completion........................................................................................................................ ..................37 EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700 - 4 14.05 Parried Utiliz.ation . .......... ........ ........... ................ ........ ......... ........ ............... ............ .............. ....................... ...........38 14.06 Final Inspecrion . ............... ........ ..... ...................... ................. ............ ......... ...... ................ .......... ....... ....... ......... .....3 8 14. 07 Final Payment........................................................................................................................... .............................38 14.08 Final Completion Delayed .... .............. ..... ................ ........... ..... ... ...... ........... ................ .... .......... ...... .... ... ... ............39 14.09 Wa i v e r of C la ims .... .. ... . ............. .. .. .... ........... ............ . ....... . .. . .. .. ... .. .. .. ........ .... .. ........ ........ . .. ........ . .... .. ...... ... .... ........39 ARTICLE 15 - SUSPENSION OF WORK A...l~D TERMINATION.........................................................................................39 15.01 Owner !'viay Suspend Work ........... ........ ..... ........ ........ ........... .... ................. ....... ........................... ....... ............ ........39 15.02 Owner lday Terminate for Cause ................................................ ...........................................................................39 15.03 Owner !'viay Terminate For Convenience ...............................................................................................................40 15.04 Contractor !'viay Stop Work or Terminate ............;..............................................................................."................40 ARTICLE 16 - DISPUTE RESOLUTION ................................................................................................................................41 16.01 I'd ethods and Procedures .................. ........... ..... ....... ............ ....... ....... ....... .......... ............ ........... ....... .................. ...41 ARTICLE 17 - IvIISCELLANEOUS ... ......... ... ........ ...... ................ ...... .................. ........... ...... ............... ......... ............ ...............41 17.01 Giving Notice .............................................................................. ...........................................................................41 17.02 Computation of Times ....................... ........ ..... .......... ..... ..... ......... ........ ...... ................. ......... ..... ................. ......... ....41 17.03 Cumulative Remedies ... .... ......... ..... ... ........................ .......... ......... .... ... ........................ .... ............................ ...........41 17.04 Survival of Obligations .................. ..... ......... ................ ................... ............. .... ...... .......... ............. ........ ............ .....41 17.05 Controlling Law ...................................................................................................................................... ...............41 17 .06 Headings.................................................................................................................................... ........................... .41 ElCDC C-700 Standard General Conditions or the Construction Contract. Copyright <9 2002 National Society or Proressional Engineers ror El CDC. All rights rcsened. 00700 - 5 GENERAL CONDITIONS ARTICLE 1 - DEFINITIONS Al'1"D TERMINOLOGY 1.01 Defined Terms A. Wherever used in the Bidding Requirements or Contract Documents and printed with initial capital letters, the terms listed below \vill have the meanings indicated which are applicable to both the singular and plural thereof. In addition to terms specifically defined, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms. 1. Addenda-- Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the proposed Contract Documents. 2. Agreement--The written instrument which is evidence of the agreement between Owner and Contractor covering the Work. 3. Application for Payment--The form acceptable to Engineer which is to be used by Contractor during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 4. Asbestos--Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Safety and Health Administration. 5. Bid--The offer or proposal of a Bidder submitted on the prescribed form setting forth the prices for the Work to be performed. 6. Bidder--The individual or entity who submits a Bid directly to Owner. 7. Bidding Requirements and the (including all Addenda). Docllments-- The Bidding proposed Contract Documents 8. Bidding Reqllirements--The Advertisement or Invilation to Bid, Instructions to Bidders, bid security of acceptable form, if any, and the Bid Form with any supplements. 9. Change Order--A document recommended by Engineer which is signed by Contractor and Owner and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, issued on or after the Effective Date of the Agreement. 10. Claim--A demand or assertion by Owner or Contractor seeking an adjustment of Contract Price or Contract Times, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. 11. Contract--The entire and integrated written agreement between the Owner and Contractor concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral. 12. Contract Docllments-- Those items so designated in the Agreement. Only printed or hard copies of the items listed in the Agreement are Contract Documents. Approved Shop Drawings, other Contractor's submittals, and the reports and drawings of subsurface and physical conditions are not Contract Documents. 13. Contract Price--The moneys payable by Owner to Contractor for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of Paragraph 11.03 in the case of Unit Price Work). 14. Contract Times--The number of days or the dates stated in the Agreement to: (i) achieve Milestones, if any, (ii) achieve Substantial Completion; and (iii) com- plete the Work so that it is ready for final payment as evidenced by Engineer's written recommendation of final payment. 15. Contractor--The individual or entity with whom Owner has entered into the Agreement. 16. Cost of the Work--See Paragraph 11.01.A for definition. 17. Drawings-- That part of the Contract Documents prepared or approved by Engineer which graphically shows the scope, extent, and character of the Work to be performed by Contractor. Shop Drawings and other Contractor submittals are not Drawings as so defined. 18. Effective Date of the Agreement--The date indicated in the Agreement on which it becomes effective, but if no such date is indicated, it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. 19. Engineer--The individual or entity named as such in the Agreement. EJCDC C-700 Standard Gcneral Conditions of thc Construction Contract. Copyright:g 2002 National Socicty of Profcssional Enginecrs for EJCDC. All rights rescrvcd. 00700 - 6 20. Field Order--A written order issued by Engineer which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 21. General Reqllirements--Sections of Division 1 of the Specifications. The General Requirements pertain to all sections of the Specifications. 22. Hazardous Environmental CondirionuThe presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto in connection with the Work. 23. Hazardous Waste--The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 24. Laws and Regulations; Laws or Reglllations- -Any and all applicable laws, rules, regulations, ordinanc- es, codes, and orders of any and all governmental bodies, agencies, authorities, and courts ha ving jurisdiction. 25. Liens--Charges. security interests, or encumbrances upon Project funds, real property, or personal property. 26. MilestoneuA principal event specified in the Contract Documents relating to an intermediate comple- tion date or time prior to Substantial Completion of all the Work. 27. Notice of A ward-- The written notice by Owner to the Successful Bidder stating that upon timely compliance by the Successful Bidder with the conditions precedent listed therein, Owner will sign and deliver the Agreement. 28. Notice to ProceeduA written notice given by Owner to Contractor fixing the date on which the Con- tract Times will commence to run and on which Contractor shall start 10 perform the Work under the Contract Documents. 29. Owner--The individual or entity with whom Contractor has entered into the Agreement and for whom the Work is to be performed. 30. PCBs--Polychlorinated biphenyls. 31. PetroleLlm--Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non-Hazardous Waste and crude oils. 32. Progress Schedule--A schedule, prepared and maintained by Contractor, describing the sequence and duration of the activities comprising the Contractor's plan to accomplish the Work within the Contract Times. 33. Project--The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part. 34. Project L'vlallllal--The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 35. Radioactive lVJaterial--Source, special nucle- ar, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 36. Related Entity -- An officer, director, partner, employee, agent, consultant, or subcontractor. 37. Resident Project Representative-- The autho- rized representative of Engineer who may be assigned to the Site or any part thereof. 38. Samples--Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 39. Schedule of Sllbmittals--A schedule, prepared and maintained by Contractor, of required submittals and the time requirements to support scheduled performance of related construction activities. 40. Schedule of ValuesuA schedule, prepared and maintained by Contractor, allocating portions of the Contract Price to various portions of the Work and used as the basis for reviewing Contractor's Applications for Payment. 41. Shop Drawings--All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the \V ork. 42. Site--Lands or areas indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights-of-vvay and easements for access thereto, and such other lands furnished by Owner which are designated for the use of Contractor. 43. Specifications--That part of the Contract Documents consisting of written requirements for materials. equipment, systems, standards and workmanship as applied to the Work, and certain EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright:g 2002 National Society of Professional Engineers for E.JCDC. All rights reserved. administrati ve requirements and procedural matters applicable thereto. 44. Subcontractor--An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the Site. 45. Substantial Completion--The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. 46. Successful Bidder--The Bidder submitting a responsive Bid to whom Owner makes an award. 47. Supplementary Conditions--That part of the Contract Documents which amends or supplements these General Conditions. 48. SupplieruA manufacturer, fabricator, suppli- er, distributor, materialman, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or any Subcontractor. 49. Underground Facilities--All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including those that convey electricity, gases, steam, liquid pelroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 50. Unit Price Work--Work to be paid for on the basis of unit prices. 51. Work-- The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. but is evidence that the parties expect that the change ordered or documented by a Work Change Directi ve \vill be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times. 1.02 Terminology A. The following words or terms are not defined but, when used in the Bidding Requirements or Contract Documents, have the following meaning. B. Intent of Certain Terms or Adjectives 1. The Contract Documents include the terms "as allowed," "as approved," "as ordered", "as directed" or terms of like effect or import to authorize an exercise of professional judgment by Engineer. In addition, the adjectives "reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of like effect or import are used to describe an action or determination of Engineer as to the Work. It is intended that such exercise of professional judgment, action or determination will be solely to evaluate, in general, the Work for compliance with the requirements of and information in the Contract Documents and conformance with the design concept of the completed Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective is not intended to and shall not be effective to assign to Engineer any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility contrary to the provisions of Paragraph 9.09 or any other provision of the Contract Documents. C. Day 1. The word "day" means a calendar day of 24 hours measured from midnight to the next midnight. D. Defective 1. The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it: a. does not conform to the Contract Documents, or b. does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents, or 52. Work Change Directive--A written statement to Contractor issued on or after the Effective Date of the Agreement and signed by Owner and recommended by Engineer ordering an addition, deletion, or revision in the Work, or responding to differing or unforeseen subsurface or physical conditions under which the Work is to be performed or to emergencies. A Work Change Directive will not change the Contract Price or the Contract Times EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for E.JCDC. All rights reserved. 00700 - 8 c. has been damaged prior to Engineer's - recommendation of final payment (unless responsibility for the protection thereof has been assumed by Owner at Substantial Completion in accordance with Paragraph 14.04 or 14.05). E. Furnish, Install, Pelform, Provide 1. The word "furnish," when used in connection with services, materials, or equipment, shall mean to supply and -deli ver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install," when used in connection with services, materials, or equipment, shall mean to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3. The words "perform" or "provide," when used in connection with services, materials, or equipment, shaIl mean to furnish and instaIl said services, materials, or equipment complete and ready for intended use. 4. When "furnish," "instaIl," "perform," or "pro- vide" is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of Contractor, "provide" is implied. F. Unless stated otherw'ise in the Contract Docu- ments, words or phrases which have a weIl-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2 - PRELIMINARY MATTERS 2.0 I Delivery of Bonds and Evidence of Insurance A. When Conlractor delivers the executed counterparts of the Agreement to Owner, Contractor shaIl also deliver to Owner such bonds as Contractor may be required to furnish. B. Evidence of Insurance: Before any Work at the Site is started, Contractor and Owner shaIl each deliver to the other, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance which either of them or any additional insured may reasonably request) which Contractor and Owner respectively are required to purchase and maintain in accordance with Article 5. 2.02 Copies of Documents or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the Agreement. In no event wiIl the Contract Times com- mence to run later than the sixtieth day after the day of Bid opening or the thirtieth day afler the Effective Date of the Agreement, whichever date is earlier. 2.04 Starting the Work A. Contractor shall start to perform the Work on the date when the Contract Times commence to run. No Work shall be done at the Site prior to the date on which the Contract Times commence to run. 2.05 Before Starting Construction A. Preliminal}' Schedules: Within 10 days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), Contractor shaIl submit to Engineer for timely review: 1. a preliminary Progress Schedule; indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2. a preliminary Schedule of Submittals; and 3. a preliminary Schedule of Values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdi- vides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. 2.06 PrecollStruction Conference A. Before any \Vork at the Site is started, a conference attended by Ovmer, Contractor, Engineer, and others as appropriate \viIl be held to establish a working understanding among the parties as to the Work and to discuss the schedules referred to in Paragraph 2.05.A, procedures for handling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. 2.07 Initial Acceptance of Schedules A. Al least 10 days before submission of the first Application for Payment a conference attended by Contractor, Engineer, and others as appropriate \vill be held to review for acceptability to Engineer as provided below the schedules submitted in accordance with Paragraph 2.05.A. Contractor shall have an additional 10 days to make corrections and adjustments and to complete and resubmit the schedules. No progress payment shaIl be A. The Contract Times wiIl commence to run on made to Contractor until acceptable schedules are the thirtieth day after the Effective Date of the Agreement submitted to Engineer. E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for E.JCDC. All rights reserved. 00700 - 9 A. Owner shall furnish to Contractor up to ten printed or hard copies of the Drawings and Project Manual. Additional copies wiIl be furnished upon request at the cost of reproduction. 2.03 Commencement of Contract Times; Notice to Proceed 1. The Progress Schedule will be acceptable to Engineer if it provides an orderly progression of the Work to completion within the Contract Times. Such acceptance will not impose on Engineer responsibility for the Progress Schedule, for sequencing, scheduling, or progress of the Work nor interfere with or relieve Contractor from Contractor's full responsibility therefor. 2. Contractor's Schedule of Submittals will be acceptable to Engineer if it provides a workable arrangement for reviewing and processing the required submittals. 3. Contractor's Schedule of Values will be acceptable to Engineer as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. ARTICLE 3 - CONTRACT DOCUNIENTS: AivIENDING, REUSE INTENT , 3.01 Intent A. The Contract Documents are complementary; what is required by one is as binding as if required by all. B. It is the intent of the Contract Documents to describe a functionally complete Project (or part thereof) to be constructed in accordance with the Contract Docu- ments. Any labor, documentation, services, materials, or equipment that may reasonably be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the intended result will be provided whether or not specifically called for at no additional cost to Owner. C. Clarifications and Contract Documents shall be provided in Article 9. interpretations of the issued by Engineer as 3.02 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations 1. Reference to standards, specifications, manuals, or codes of any lechnical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the standard, specification, manual, code, or Laws or Regula- tions in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. responsibilities of Owner, Contractor, or Engineer, or any of their subcontractors, consultants, agents, or employees from those set forth in the Contract Documents. No such provision or instruction shall be effective to assign to Owner, or Engineer, or any of, their Related Entities, any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake respon- sibility inconsistent with the provisions of the Contract Documents. 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies 1. ColltraclOr's Review of Contract Documents Before Starting Work: Before undertaking each part of the Work, Contractor shall carefully study and compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error, ambiguity, or discrepancy which Contractor may discover and shall obtain a written interpretation or clarification from Engineer before proceeding with any Work affected thereby. 2. ContraclOr's Review of Contract Documents During Pelformance of Work: If, during the performance of the Work, Contractor discovers any conflict, error, ambiguity, or discrepancy within the Contract Documents or between the Contract Documents and any provision of any Law or Regulation applicable to the performance of the Work or of any standard, specification, manual or code, or of any instruction of any Supplier, Contractor shall promptly report it to Engineer in writing. Contractor shall not proceed with the Work affected thereby (except in an emergency as required by Paragraph 6.16.A) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in Paragraph 3.04. 3. Contractor shall not be liable to Owner or Engineer for failure to report any conflict, error, ambigu- ity, or discrepancy in the Contract Documents unless Contractor knew or reasonably should have known thereo f. B. Resolving Discrepancies 1. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and: a. the provisions of any standard, specification, manual, code, or instruction (whether or not specifically incorporated by reference in the Contract Documents); or 2. No proViSion of any such standard, specification, manual or code, or any instruction of a b. the provisions of any Laws or Regulations Supplier shall be effecti ve to change the duties or applicable to the performance of the Work EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright:g 2002 National Society of Prol'essionaI Engineers l'or EJCDC. All rights reserved. 00700 - 10 (unless such an interpretation of the proVisIOns of the Contract Documents would result in viola- tion of such Law or Regulation). 3.04 Amending Documents and Contract Supplementing A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof by either a Change Order or a Work Change Directive. B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may be authorized, by one or more of the following ways: 1. A Field Order; 2. Engineer's approval of a Shop Drawing or Sample; (Subject to the provisions of Paragraph 6.17.D.3); or 3. Engineer's clarification. written interpretation 3.05 Reuse of Documents A. Contractor and any Subcontractor or Supplier or other individual or entity performing or furnishing all of the Work under a direct or indirect contract with Contractor, shall not: 1. have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of Engineer or Engineer's consultants, including electronic media editions; or 2. reuse any of such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of Owner and Engineer and specific written verification or adaption by Engineer. B. The prohibition of this Paragraph 3.05 will survive final payment, or termination of the Contract. Nothing herein shall preclude Contractor from retaining copies of the Contract Documents for record purposes. 3.06 Electronic Data A. Copies of data furnished by Owner or Engineer to Contractor or Contractor to Owner or Engineer that may be relied upon are limited to the printed copies (also known as hard copies). Files in electronic media format of text, data, graphics, or other types are furnished only for the convenience of the receiving party. Any conclusion or information obtained or derived from such electronic files will be at the user's or sole risk. If there is a discrepancy between the electronic files and the hard copies, the hard copies govern. B. Because data stored in electronic media format can deteriorate or be modified inadvertently or otherwise without authorization of the data's creator, the party receiving electronic files agrees that it will perform acceptance tests or procedures within 60 days, after which the receiving party shall be deemed to have accepted the data thus transferred. Any errors detected within the 60- day acceptance period will be corrected by the transferring party.. C. When transferring documents in electronic media format, the transferring party makes no representations as to long t"rm compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by the data's creator. ARTICLE 4 AVAILABILITY SUBSURFACE AT'lD PHYSICAL R1.\Z ARD 0 US ENVIRONMENT AL REFERENCE POINTS OF LANDS; CONDITIONS; CONDITIONS; 4.01 A. vailability of Lands A. Owner shall furnish the Site. Owner shall notify Conlractor of any encumbrances or restrictions not of general application but specifically related to use of the Site with which Contractor must comply in performing the Work. Owner will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. If Contractor and Owner are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, as a result of any delay in Owner's furnishing the Site or a part thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. B. Upon reasonable written request. OViOer shall furnish Contractor with a current statement of record legal title and legal descriplion of the lands upon which the Work is to be performed and Owner's interest therein as necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with applicable Laws and Regulations. C. Contractor shall provide for all additional lands ancl access thereto that may be required for temporary construction facilities or storage of materials and equipment. E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright (9 2002 National Society of Professional Engineers for E.JCDC. All rights reserved. 4.02 Subsurface and Physical Conditions A. Reports and Drawings: The Supplementary Conditions identify: 1. those reports of explorations and tests of subsurface conditions at or contiguous to the Site that Engineer has used in preparing the Contract Documents; and 2. those drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) that Engineer has used in preparing the Contract Documents. B. Limited Reliance by Contractor on Technical Data Authoriz.ed: Contractor may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their Related Entities with respect to: 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions, or information. 4.03 Differing Subsurface or Physical Conditions A. Notice: If Contractor believes that any subsur- face or physical condition at or contiguous to the Site that is uncovered or revealed either: 1. is of such a nature as to establish that any "technical data" on which Contractor is entitled to rely as provided in Paragraph 4.02 is materially inaccurate; or 2. is of such a nature as to require a change in the Contract Documents; or 3. differs materially from that shown or indicaled in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then Contractor shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connec- tion therewith (except in an emergency as required by Paragraph 6.16.A), notify Owner and Engineer in writing about such condition. Contractor shall not further disturb such condition or perform any Work in connection therewith (except as aforesaid) until receipt of written order to do so. B. Engineer's Review: After receipt of written notice as required by Paragraph 4.03.A, Engineer will promptly review the pertinent condition, determine the necessity of Owner's obtaining additional exploration or tests with respect thereto, and advise Owner in writing (with a copy to Contractor) of Engineer's findings and conclusions. C. Possible Price and Times Adjustments 1. The Contract Price or the Contract Times, or both, will be equitably adjusted to the extent that the existence of such differing subsurface or physical condition causes an increase or decrease in Contractor's cost of, or time required for, performance of the Work; subject, however, to the following: a. such condition must meet anyone or more of the categories described in Paragraph 4.03.A; and b. with respect to Work that is paid for on a Unit Price Basis, any adjustment in Contract Price will be subject to the provisions of Paragraphs 9.07 and 11.03. 2. Contractor shall not be entitled to any adjustment in the Contract Price or Contract Times if: a. Conlractor knew of the existence of such conditions at the time Contractor made a final commitment to Owner with respect to Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract; or b. the existence' of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, explo- ration, test, or study of the Site and contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for Contractor prior to Contractor's making such final commitment; or E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright :g 2002 National Society of Professional Engineers for E.J CDC. All rights resened. 00700 - 12 c. Contractor failed to give the written notice as required by Paragraph 4.03.A. 3. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, a Claim may be made therefor as provided in Paragraph 10.05. However, Owner and Engineer, and any of their Related Entities shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. 4.04 Underground Facilities A. Shown or Indicated: The information and data shown or indicated in the Contract Documents with respect to eXlstmg Underground Facilities at or contiguous to the Site is based on information and data furnished to Owner or Engineer by the owners of such Underground Facilities, including Owner, or by others. Unless it is otherwise expressly provided in the Sup- plementary Conditions: 1. Owner and Engineer shall not be responsible for the accuracy or completeness of any such information or data; and 2. the cost of all of the following will be included in the Contract Price, and Contractor shall have full responsibility for: a. reviewing and checking all such information and data, b. locating all Underground Facilities shown or indicated in the Contract Documents, c. coordination of the Work with the owners of such Underground Facilities, including Owner, during construction, and d. the safety and protection of all such Under- ground Facilities and repairing any damage thereto resulting from the Work. B. Not Shown or Indicated promptly review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to reflect and document the consequences of the existence or location of the U nder- ground Facility. During such time, Contractor shall be responsible for the safety and protection of such Underground Facility. 2. If Engineer concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflect and document such consequences. An equitable adjustment shall be made in the Contract Price or Contract Times, or both, to the extent that they are attributable to the existence or location of any Underground Facility that was not shown or indicated or not shown or indicated with reasonable accuracy in the Contract Documents and that Contractor did not know of and could not reasonably have been expected to be aware of or to have anticipated. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment in Contract Price or Contract Times, Owner or Contractor may make a Claim therefor as provided in Paragraph 10.05. 4.05 Reference Points A. Owner shall provide engineering surveys to establish reference points for construction which in Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.06 Hm:.ardous Environmental Condition at Site A. Reports and Drawings: Reference is made to the Supplementary Conditions for the identification of those reports and drawings relating to a Hazardous Environmental Condition identified at the Site, if any, that have been utilized by the Engineer in the preparation of the Contract Documents. B. Limited Reliance by Contractor on Technical Data Authoriz.ed: Contractor may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," Contractor may not rely upon or make any claim against Owner or Engineer, or any of their Related Entities with respect to: 1. If an Underground Facility is uncovered or revealed at or contiguous to the Site which was not shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, Contractor shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by Paragraph 6.16.A), identify the owner of such Underground Facility and give written notice to that owner and to Owner and Engineer. Engineer will EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright :g 2002 National Society of Proressional Engineers ror EJCDC. All rights reserved. 00700 - 13 1. the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences and procedures of construction to be employed by Contractor and safety precautions and programs incident thereto; or 2. other data, interpretations, opInIOns and information contained in such reports or shown or indicated in such drawings; or 3. any Contractor interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions or information. C. Contractor shall not be responsible for any Hazardous Environmental Condition uncovered or re- vealed at the Site which was not shown or indicated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work. Contractor shall be responsible for a Hazardous Environmental Condition created with any materials brought to the Site by Contractor, Subcontractors, Suppliers, or anyone else for whom Contractor is responsible. D. If Contractor encounters a Hazardous Environmental Condition or if Contractor or anyone for whom Contractor is responsible creates a Hazardous Environmental Condition, Contractor shall immediately: (i) secure or otherwise isolate such condition; (ii) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by Paragraph 6.16.A); and (iii) notify Owner and Engineer (and promptly thereafter confirm such notice in writing). Owner shall promptly consult with Engineer concerning the necessity for Owner to retain a qualified expert to evaluate such condition or take corrective action, if any. E. Contractor shall not be required to resume \Vork in connection with such condition or in any affected area until after Owner has obtained any required permits related thereto and delivered to Contractor written notice: (i) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work; or (ii) specifying any special conditions under which such Work may be resumed safely. If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, or both, as a result of such Work stop- page or such special conditions under which Work is agreed to be resumed by Contractor, either party may make a Claim therefor as provided in Paragraph 10.05. entitlement to or on the amount or extent, if any, of an adjustment in Contract Price or Contract Times as a result of deleting such portion of the Work, then either party may make a Claim therefor as provided in Paragraph 10.05. Owner may have such deleted portion of the Work performed by Owner's own forces or others in accordance with Article 7. G. To the fullest extent permitted by Laws and Regulations, Owner shall indemnify and hold harmless Contractor, Subcontractors, and Engineer, and the officers, directors, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hazardous Environmental Condition: (i) was not shown or indicated in the Drawings or Specifications or identified in the Contract Documents to be included within the scope of the Work, and (ii) was not created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06. G shall obligate Owner to indemnify any individual or entity from and against the conse- quences of that indi vidual's or entity's own negligence. H. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, partners, employees, agents, consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition created by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 4.06.H shall obligate Contractor to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. 1. The provisions of Paragraphs 4.02, 4.03, and 4.04 do not apply to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 5 - BONDS Al'fD INSURANCE 5.01 Performance, Payment, and Other Bonds F. If after receipt of such written notice A. Contractor shall furnish performance and Contractor does not agree to resume such Work based on payment bonds, each in an amount at least equal to the a reasonable belief it is unsafe, or does not agree to Contract Price as security for the faithful performance and resume such Work under such special conditions, then payment of all of Contractor's obligations under the Owner may order the portion of the Work that is in the Contract Documents. These bonds shall remain in effect area affected by such condition to be deleted from the until one year after the date when final payment becomes Work. If Owner and Contractor cannot agree as to due or until completion of the correction period specified EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright <9 2002 National Society of Professional Engineers for EJCDC. All rights resened. 00700 - 14 in Paragraph 13.07, whichever is later, except as provided otherwise by Laws or Regulations or by the Contract Documents. Contractor shall also furnish such other bonds as are required by the Contract Documents. B. All bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the current list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Compa- nies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All bonds signed by an agent must be accompanied by a certified copy of the agent's authority to act. C. If the surety on any bond furnished by Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in any state where any part of the Project is located or it ceases to meet the requirements of Paragraph 5.01.B, Contractor shall promptly notify Owner and Engineer and shall, within 20 days after the event giving rise to such notification, provide another bond and surety, both of \vhich shall comply with the requirements of Paragraphs 5.01.B and 5.02. 5.02 Licensed Sureties and Insurers A. All bonds and insurance required by the Contract Documents to be purchased and maintained by Owner or Contractor shall be obtained from surety or insurance companies that are duly licensed or authorized in the jurisdiction in which the Project is located to issue bonds or insurance policies for the limits and coverages so required. Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided in the Supplementary Conditions. 5.03 Certificates of Insurance A. Contractor shall deliver to Owner, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Owner or any other additional insured) which Contractor is required to purchase and maintain. B. Owner shall deliver to Contractor, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by Contractor or any other additional insured) which Owner is required to purchase and maintain. 5.04 Contractor's Liability Insurance from claims set forth below which may arise out of or result from Contractor's performance of the Work and Contractor's other obligations under the Contract Documents, whether it is to be performed by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers' compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury. occupational sickness or disease, or death of Contractor's employees; 3. claims for damages because of bodily injury, sickness or disease, or death of any person other than Contractor's employees; 4. cla.ims for damages insured by reasonably available personal injury liability coverage which are sus- tained: a. by any person as a result of an offense directly or indirectly related to the employment of such person by Contractor, or b. by any other person for any other reason; 5. claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 6. claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle. B. The policies of insurance required by this Paragraph 5.04 shall: 1. with respect to insurance required by Paragraphs 5.04.A.3 through 5.04.A.6 inclusive, include as additional insured (subject to any customary exclusion regarding professional liability) Owner and Engineer, and any other individuals or entities identified in the Supple- mentary Conditions, all of whom shall be listed as addi- tional insureds, and include coverage for the respective officers. directors, partners, employees, agents, consultants and subcontractors of each and any of all such additional insureds, and the insurance afforded to these additional insureds shall provide primary coverage for all claims covered thereby; 2. include at least the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or required by Laws or Regulations, whichever is greater; A. Contractor shall purchase and maintain such liability and other insurance as is appropriate for the Work being performed and as will provide protection EJCDC C-700 Stundard General Conditions of the Construction Contract. Copyright:g 2()02 National Society of Professional Engineers for EJCDC. All rights reserved. 3. include completed operations insurance; 4. include contractual covering Contractor's indemnity Paragraphs 6.11 and 6.20; liability insurance obligations under 5. contain a provision or endorsement that the coverage afforded will not be canceled, materially changed or renewal refused until at least 30 days prior written notice has been gi ven to Owner and Contractor and to each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance has been issued (and the certificates of insurance furnished by the Contractor pursuant to Paragraph 5.03 will so provide); 6. remain in effect at least until final payment and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work in accordance with Paragraph 13.07; and 7. with respect to completed operations insur- ance, and any insurance coverage written on a claims- made basis, remain in effect for at least two years after final payment. a. Contractor shall furnish Owner and each other additional insured identified in the Supple- mentary Conditions, to whom a certificate of insurance has been issued, evidence satisfactory to Owner and any such additional insured of continuation of such insurance at final payment and one year thereafter. 5.05 Owner's Liability Insurance A. In addition to the insurance required to be provided by Contractor under Paragraph 5.04, Owner, at Owner's option, may purchase and maintain at Owner's expense Owner's own liability insurance as will protect Owner against claims which may arise from operations under the Contract Documents. 5.06 Property Insurance A. Unless otherwise provided in the Supple- mentary Conditions, Owner shall purchase and maintain property insurance upon the Work at the Site in the amount of the full replacement cost thereof (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). This insurance shall: 1. include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them, each of whom is deemed 10 have an insurable interest and shall be listed as an insured or additional insured; 2. be written on a Builder's Risk "all-risk" or open peril or special causes of loss policy form that shall at least include insurance for physical loss or damage to the Work, temporary buildings, false work, and materials and equipment in transit, and shall insure against at least the following perils or causes of loss: fire, lightning, extended coverage, theft, vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, water damage, (other than caused by flood) and such other perils or causes of loss as may be specifi- cally required by the Supplementary Conditions; 3. include expenses incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers and architects); 4. cover materials and equipment stored at the Site or at another location that was agreed to in writing by Owner prior to being incorporated in the Work, provided that such materials and equipment have been included in an Application for Payment recommended by Engineer; 5. allow for partial utilization of the Work by Owner; 6. include testing and startup; and 7. be maintained in effect until final payment is made unless otherwise agreed to in writing by Owner, Contractor, and Engineer with 30 days written notice to each other additional insured to whom a certificate of insurance has been issued. B. Owner shall purchase and maintain such boiler and machinery insurance or additional property insurance as may be required by the Supplementary Conditions or Laws and Regulations which will include the interests of Owner, Contractor, Subcontractors, and Engineer, and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them, each of whom is deemed to ha ve an insurable interest and shall be listed as an insured or additional insured. C. All the policies of insurance (and the certifi- cates or other evidence thereof) required to be purchased and maintained in accordance with Paragraph 5.06 will contain a provision or endorsement that the coverage afforded will not be canceled or materially changed or renewal refused until at least 30 days prior written notice has been given to Owner and Contractor and to each other additional insured to whom a certificate of insurance has been issued and will contain wai ver provisions in accor- dance with Paragraph 5.07. D. Owner shall not be responsible for purchasing and maintaining any property insurance specified in this Paragraph 5.06 to protect the interests of Contractor, Subcontractors, or others in the Work to the extent of any EJCDC C-iOO Standard Gcncral Conditions of the Construction Contract. Copyright @ 2002 National Society of Profcssional Enginccrs for EJCDC. All rights reserved. OOiOO - 16 deductible amounts that are identified in the Supple- mentary Conditions. The risk of loss within such identified deductible amount will be borne by Contractor, Subcontractors, or others suffering any such loss, and if any of them wishes property insurance coverage within the limits of such amounts, each may purchase and maintain it at the purchaser's own expense. E. If Contractor requests in writing that other special insurance be included in the property insurance policies provided under Paragraph 5.06, Owner shall, if possible, include such insurance, and the cost thereof will be charged to Contractor by appropriate Change Order. Prior to commencement of the Work at the Site, Owner shall in writing advise Contractor whether or not such other insurance has been procured by Owner. 5.07 Waiver of Rights A. Owner and Contractor intend that all policies purchased in accordance with Paragraph 5.06 will protect Owner, Contractor, Subcontractors, and Engineer, and all other individuals or entities identified in the Supple- mentary Conditions to be listed as insureds or additional insureds (and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them) in such policies and will provide primary coverage for all losses and damages caused by the perils or causes of loss covered thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any of the insureds or additional insureds thereunder. Owner and Contractor waive all rights against each other and their respective officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them for all losses and damages caused by, arising out of or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive all such rights against Subcontractors, and Engineer, and all other individuals or entities identified in the Supplementary Conditions to be listed as insured or additional insured (and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them) under such policies for losses and damages so caused. None of the above waivers shall extend to the righls that any party making such waiver may have to the proceeds of insurance held by Owner as trustee or otherwise payable under any policy so issued. B. Owner waives all rights against Contractor, Subcontractors, and Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them for: 1. loss due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to Owner's property or the Work caused by, arising out of, or resulting from fire or other perils whether or not insured by Owner; and 2. loss or damage to the completed Project or part thereof caused by, arising out of, or resulting from fire or other insured peril or cause of loss covered by any property insurance maintained on the completed Project or part thereof by Owner during partial utilization pursuant to Paragraph 14.05, after Substantial Completion pursuant to Paragraph 14.04, or after final payment pursuant to Paragraph 14.07. C. Any insurance policy maintained by Owner covering any loss, damage or consequential loss referred to in Paragraph 5.07.B shall contain provisions to the effect that in the event of payment of any such loss, damage, or consequential loss, the insurers will have no rights of recovery against Contractor, Subcontractors, or Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them. 5.08 Receipt and Application of Insurance Proceeds A. Any insured loss under the policies of insurance required by Paragraph 5.06 will be adjusted with Owner and made payable to Owner as fiduciary for the insureds, as their interests may appear, subject to the requirements of any applicable mortgage clause and of Paragraph 5.08.B. Owner shall deposit in a separate account any money so received and shall distribute it in accordance with such agreement as the parties in interest may reach. If no other special agreement is reached, the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof, and the Work and the cost thereof covered by an appropriate Change Order. B. Owner as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within 15 days after the occurrence of loss to Owner's exercise of this power. If such objection be made, Owner as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach. If no such agreement among the parties in interest is reached, Owner as fiduciary shall adjust and settle the loss with the insurers and, if required in writing by any party in interest, Owner as fiduciary shall give bond for the proper performance of such duties. 5.09 Acceprance of Bonds alld Insurance; Option to Replace A. If either Owner or Contractor has any objection to the coverage afforded by or other provisions of the bonds or insurance required to be purchased and maintained by the other party in accordance with Article 5 on the basis of non-conformance \vith the Contract EJCDC C-700 Standard General Conditions of thc Construction Contract. Copyright @ 2002 National Society of Prol'essional Engineers for E.J CDC. All rights reserved. Documents, the objecting party shall so notify the other party in writing within 10 days after receipt of the certificates (or other evidence requested) required by Paragraph 2.0 l.B. Owner and Contractor shall each provide to the other such additional information in respect of insurance provided as the other may reasonably request. If either party does not purchase or maintain all of the bonds and insurance required of such party by the Contract Documents, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. Without prejudice to any other right or remedy, the other party may elect to obtain equi valent bonds or insurance to protect such other party's interests at the expense of the party who was required to provide such coverage, and a Change Order shall be issued to adjust the Contract Price accordingly. 5.10 Pm'lial Utilization, Acknowledgment of Property Insurer A. If Owner finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in Paragraph 14.05, no such use or occupancy shall commence before the insurers providing the property insurance pursuant to Paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES 6.01 Supervision and Superintendence A. Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction. Contractor shall not be responsible for the negligence of Owner or Engineer in the design or specification of a specific means, method, technique, sequence, or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. B. At all times during the progress of the Work, Contractor shall assign a competent resident superin- tendent who shall not be replaced without written notice to Owner and Engineer except under extraordinary circumstances. The superintendent will be Contractor's representative at the Site and shall have authority to act on behalf of Contractor. All communications given to or received from the superintendent shall be binding on Contractor. 6.02 Labor: Working Hours A. Contractor shall provide competent, suitably qualified personnel to survey and layout the Work and perform construction as required by the Contract Docu- ments. Contractor shall at all times maintain good disci- pline and order at the Site. B. Except as otherwise req uired for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during regular working hours. Contractor will not permit the performance of Work on a Saturday, Sunday, or any legal holiday without Owner's written consent (which will not be unreasonably withheld) given after prior written notice to Engineer. 6.03 Services, iVlaterials, and Equipment A. Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start-up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications shall expressly run to the benefit of Owner. If required by Engineer, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. C. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 6.04 Progress Schedule A. Contractor shall adhere to the Progress Schedule established in accordance with Paragraph 2.07 as it may be adjusted from time to time as provided below. EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright:g 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700 - 18 1. Contractor shall submit to Engineer for acceptance (to the extent indicated in Paragraph 2.07) proposed adjustments in the Progress Schedule that will not result in changing the Contract Times. Such adjust- ments will comply with any provisions of the General Re- quirements applicable thereto. 2) it will conform substantially to the detailed requirements of the item named in the Contract Documents. 2. Substitute Items 2. Proposed adjustments in the Progress Schedule that will change the Contract Times shall be submitted in accordance with the requirements of Article 12. Adjustments in Contract Times may only be made by a Change Order. a. If in Engineer's sole discretion an item of material or equipment proposed by Contractor does not qualify as an "or-equal" item under Paragraph 6.05.A1, it will be considered a proposed substitute item. 6.05 Substillltes and" Or-Equals" b. Contractor shall submit sufficient information as provided below to allow Engineer to determine that the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requ.ests for review of proposed substitute items of material or equipment will not be accepted by Engineer from anyone other than Contractor. A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or-equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be submitted to Engineer for review under the circumstances described below. c. The requirements for review by Engineer will be as set forth in Paragraph 6.05.A2.d, as supplemented in the General Requirements and as Engineer may decide is appropriate under the circumstances. 1. "Or-Equal" Items: If in Engineer's sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by Engineer as an "or-equal" item, in which case review and approval of the proposed item may, in Engineer's sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this Paragraph 6.05 .Al, a proposed item of material or equipment will be considered functionally equal to an item so named if: d. Contractor shall make written application to Engineer for review of a proposed substitute item of material or equipment that Contractor seeks to furnish or use. The application: 1) shall certify that the proposed substi- tute item will: a) perform adequately the functions and achieve the results called for by the general design, a. in the exercise of reasonable judgment Engineer determines that: b) be similar m substance to that specified, and 1) it is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics; c) be suited to the same use as that specified; 2) will state: 2) it will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole, a) the extent, if any, to which the use of the proposed substitute item will preju- dice Contractor's achievement of Substantial Completion on time; 1) there will be no increase in cost to the Owner or increase in Contract Times, and EJCDC C-700 Standard General Conditions or the Construction Contract. Copyright 19 2002 National Society or Proressional Engineers 1'01' EJCDC. All rights reserved. b) whether or not use of the proposed substitute item in the Work will require a change in any of the Contract Docu- ments (or in the provisions of any other direct contract with Owner for other work on the Project) to adapt the design to the proposed substitute item; and 3) it has a proven record of performance and availability of responsive service; and b. Contractor certifies that. if approved and incorporated into the Work: c) whether or not incorporation or use of the proposed substitute item in con- nection with the Work is subject to payment of any license fee or royalty; 3) will identify: a) all variations of the proposed substitute item from that specified, and b) available engineering, sales, maintenance, repair, and replacement servIces; 4) and shall contain an itemized esti- mate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and claims of other contractors affected by any resulting change, B. Substitute Construction lvJethods or Proce- dures: If a specific means, method, technique, sequence, or procedure of construction is expressly required by the Contract Documents, Contractor may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by Engineer. Contractor shall submit sufficient information to allow Engineer, in Engineer's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The requirements for review by Engineer will be similar to those provided in Paragraph 6.05.A.2. C. Engineer's Evaluation: Engineer will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to Paragraphs 6.05.A and 6.05.B. Engineer may require Contractor to furnish additional data about the proposed substitute item. Engineer will be the sole judge of acceptability. No "or equal" or substitute will be ordered, installed or utilized until Engineer's review is complete, which will be evidenced by either a Change Order for a substitute or an approved Shop Drawing for an "or equal." Engineer will advise Contractor in writing of any negative determination. D. Special Guarantee: Owner may req1llre Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respecI to any substitute. E. Engineer's Cost Reimbursement: Engineer will record Engineer's costs in evaluating a substitute proposed or submitted by Contractor pursuant to Paragraphs 6.05.A.2 and 6.05.B Whether or not Engineer approves a substitute item so proposed or submitted by Contractor, Contractor shall reimburse Owner for the charges of Engineer for evaluating each such proposed substitute. Contractor shall also reimburse Owner for the charges of Engineer for making changes in the Contract Documents (or in the proVISIons of any other direct contract with Owner) resulting from the acceptance of each proposed substitute. F. Contractor's Expense: Contractor shall provide all data in support of any proposed substitute or "or-equal" at Contractor's expense. 6.06 Concerning Subcontractors, Suppliers, and Others A. Contractor shall not employ any Subcon- tractor, Supplier, or other individual or entity (including those acceptable to Owner as indicated in Paragraph 6.06.B), whether initially or as a replacement, against whom Owner may have reasonable objection. Contractor shall not be required to employ any Subcontractor, Supplier, or other individual or entity to furnish or perform any of the Work against whom Contractor has reasonable objection. B. If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers, or other individuals or entities to be submitted to Owner in advance for acceptance by Owner by a specified date prior to the Effective Date of the Agreement, and if Contractor has submitted a list thereof in accordance with the Supplementary Conditions, Owner's acceptance (either in writing or by failing to make written objection thereto by the date indicated for acceptance or objection in the Bidding Documents or the Contract Documents) of any such Subcontractor, Supplier, or other individual or entity so identified may be revoked on the basis of reason- able objection after due investigation. Contractor shall submit an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity, and the Contract Price will be adjusted by the difference in the cost occasioned by such replacement, and an appropriate Change Order will be issued. No acceptance by Owner of any such Subcontractor, Supplier, or other individual or entity, whether initially or as a replacement, shall consti- tute a \vaiver of any right of Owner or Engineer to reject defective Work. C. Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as Contractor is responsible for Contractor's own acts and omissions. Nothing in the Contract Documents: 1. shall create for the benefit of any sLlch Subcontractor, Supplier, or other individual or entity any contractual relationship between Owner or Engineer and any such Subcontractor, Supplier or other individual or entity, nor 2. shall anything in the Contract Documents create any obligation on the part of Owner or Engineer to payor to see to the payment of any moneys due any sLlch Subcontractor, Supplier, or other individual EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright:g 2002 National Society of Professional Engineers for EJCDC. All rights rcserved. 00700 - 20 or entity except as may otherwise be required by Laws and Regulations. D. Contractor shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with Contractor. E. Contractor shall require all Subcontractors, Suppliers, and such other individuals or entities per- forming or furnishing any of the Work to communicate with Engineer through Contractor. F. The divisions and sections of the Specifica- tions and the identifications of any Drawings shall not control Contractor in dividing the Work among Subcon- tractors or Suppliers or delineating the \Vork to be performed by any specific trade. G. All Work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appro- priate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of Owner and Engineer. \Vhenever any such agreement is with a Subcontractor or Supplier who is listed as an additional insured on the property insurance provided in Paragraph 5.06, the agreement between the Contractor and the Subcontractor or Supplier will contain provisions whereby the Subcontractor or Supplier waives all rights against Owner, Contractor, and Engineer" and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or additional insureds (and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them) for all losses and damages caused by, arising out of, relating to, or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work. If the insurers on any such policies require separate waiver forms to be signed by any Subcontractor or Supplier, Contractor will obtain the same. 6.07 Palent Fees and Royalties A Contractor shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product. or device is specified in the Contract Documents for use in the performance of the Work and if to the actual knowledge of Owner or Engineer its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by Owner in the Contract Documents. B. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. 6.08 Permits A. Unless otherwise provided in the Supple- mentary Conditions, Contractor shall obtain and pay for all construction permits and licenses. Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. Owner shall pay all charges of utility owners for connections for providing permanent service to the Work. 6.09 Laws and Regulations A Contractor shall give all notices required by and shall comply with all Laws and Regulations applica- ble to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither Owner nor Engineer shall be responsible for monitoring Contractor's compliance with any Laws or Regulations. B. If Contractor performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work. However, it shall not be Contractor's pnmary responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor's obligations under Paragraph 3.03. C. Changes in Laws or Regulations not kno\'iD at the time of opening of Bids (or, on the Effective Date of the Agreement if there \vere no Bids) having an effect on the cost or time of performance of the Work shall be the subject of an adjustment in Contract Price or Contract Times. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in Paragraph 10.05. EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright :g 2002 National Society of Professional Engineers for EJ CDC. All rights rescned. 6.10 Taxes A. Contractor shall pay all sales, consumer, use, and other similar taxes required to be paid by Contractor in accordance with the Laws and Regulations of the place of the Project which are applicable during the performance of the Work. 6.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas 1. Contractor shall confine construction equip- ment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. Should any claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against Owner, Engineer, or any other party indemnified hereunder to the extent caused by or based upon Contractor's performance of the Work. B. Removal of Debris During Performance of the Work: During the progress of the Work Contractor shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall conform to applicable Laws and Regulations. C. Cleaning: Prior to Substantial Completion of the Work Contractor shall clean the Site and the Work and make it ready for utilization by Owner. At the com- pletion of the Work Contractor shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D. Loading Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 6.12 Record Documents A. Contractor shall maintain in a safe place at the Site one record copy of all Drawings, Specifications, Addenda, Change Orders, "Vork Change Directives, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved Samples and a counterpart of all approved Shop Drawings \vill be available to Engineer for reference. Upon completion of the Work, these record documents, Samples, and Shop Drawings will be delivered to Engi- neer for Owner. 6.13 Safety and P rotectioll A. Contractor shall be solely responsible for initiating, maintaining and supervising all safety precau- tions and programs in connection with the Work. Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safely and protection. Contractor shall notify owners of adjacent property and of Underground Facilities and other utility owners 'ivhen prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. C. All damage, injury, or loss to any property referred to in Paragraph 6.13.,A..2 or 6.13.A.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor (except damage or loss attributable to the fault of Draw- EJCDC C-700 Stand8rd Gener81 Conditions or the Construction Contr8ct. Copyright <9 2002 N8tiormI Society or Proression81 Engineers ror EJCDC. All rights reserved. 00700 - 22 ings or Specifications or to the acts or orrusslOns of Owner or Engineer or , or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of Contractor or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them). D. Contractor's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and Engineer has issued a notice to Owner and Contractor in accordance with Paragraph 14.07.B that the Work IS acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.14 Safety Representative A. Contractor shall designate a qualified and experienced safety representative at the Site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. 6.15 Hawrd Communication Programs A. Contractor shall be responsible for coordi- nating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations. 6.16 Emergencies A. In emergencies affecting the safety or protec- tion of persons or the Work or property at the Site or adjacent thereto, Contractor is obligated to act to prevent threatened damage, injury, or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby or are required as a result thereof. If Engineer determines that a change in the Contract Documents is required because of the action taken by Contractor in response to such an emergency, a \Vork Change Directive or Change Order will be issued. 6.17 Shop Drawings and Samples A Contractor shall submit Shop Drawings and Samples to Engineer for review and approval in accor- dance with the acceptable Schedule of Submittals (as required by Paragraph 2.07). Each submittal will be identified as Engineer may require. 1. Shop Drawings b. Data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Engineer the services, materials, and equipment Contractor proposes to provide and to enable Engineer to review the information for the limited purposes req uired by Paragraph 6.17.D. 2. Samples: Contractor shall also submit Samples to Engineer for review and approval in accor- dance with the acceptable schedule of Shop Drawings and Sample submittals. a. Submit number of Samples specified In the Specifications. b. Clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as Engineer may require to enable Engineer to review the submittal for the limited purposes required by Paragraph 6.17 .D. B. Where a Shop Drawing or Sample is required by the Contract Documents or the Schedule of Submittals , any related Work performed prior to Engineer's review and approval of the pertinent submittal will be at the sole expense and responsibility of Contractor. C. Submittal Procedures 1. Before submitting each Shop Dra\ving or Sample, Contractor shall have determined and verified: a. all field measurements, quantities, dimensions, specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; b. the suitability of all materials with respect to intended use, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; c. all information relative to Contractor's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto; and d. shall also have reviewed and coordinated each Shop Drawing or Sample Draw'ings and Samples requirements of the Work Documents. with other Shop and with the and the Contract 2. Each submittal shall bear a stamp or specific written certification that Contractor has satisfied Contractor's obligations under the Contract Documents EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright@ZOOZ National Society of Professional Engineers for EJCDC. All rights reserved. a. Submit number of copies specified In the General Requirements. A To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner and Engineer, and the officers, directors, partners, employees, agents, consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not A. Contractor shall carryon the Work and adhere limited to all fees and charges of engineers, architects, Progress Schedule during all disputes or attorneys, and other professionals and all court or EJCDC C-700 Standard General Conditions of the Conslruction Contract. Copyright @ 2002 National Society of Professional Engineers for EJ CDC. All rights reserved. 00700 - 24 with respect to Contractor's review and approval of that submittal. 3. With each submittal, Contractor shall give Engineer specific written notice of any variations, that the Shop Drawing or Sample may have from the requirements of the Contract Documents. This notice shall be both a written communication separate from the Shop Drawing's or Sample Submittal; and, in addition, by a specific notation made on each Shop Drawing or Sample submit- ted to Engineer for review and approval of each such variation. D. Engineer's Review 1. Engineer will provide timely review of Shop Drawings and Samples in accordance with the Schedule of Submittals acceptable to Engineer. Engineer's review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Docu- ments. 2. Engineer's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of con- struction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3. Engineer's review and approval shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Paragraph 6.l7.C.3 and Engineer has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample. Engineer's review and approval shall not relieve Contractor from responsibility for complying with the requirements of Paragraph 6.17.C.1. E. Resubmittal Procedures 1. Contractor shall make corrections required by Engineer and shall return the required number of cor- rected copies of Shop Drawings and submit, as required, new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous submittals. 6.18 Continuing the Work to the disagreements with Owner. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by Paragraph 15.04 or as Owner and Contractor may otherwise agree in writing. 6.19 Contractor's General Warranty and Guarantee A. Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Engineer and its Related Entities shall be entitled to rely on representation of Contractor's warranty and guarantee. B. Contractor's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, modification, or improper maintenance or operation by persons other than Contractor, Sub- contractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or 2. normal wear and tear under normal usage. C. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor's obligation to perform the Work in accordance with the Contract Documents: 1. observations by Engineer; 2. recommendation by Engineer or payment by Owner of any progress or final payment; 3. the issuance of a certificate of Substantial Completion by Engineer or any payment related thereto by Owner; 4. use or occupancy of the Work or any part thereof by Owner; S. any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of acceptabil- ity by Engineer; 6. any inspection, test, or approval by others; or 7. any correction of defective Work by Owner. 6.20 llzdemnificarion arbitration or other dispute resolution costs) arising out of or relating to the performance of the Work, provided that any such claim, cost, loss, or damage is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom but only to the extent caused by any negligent act or omission of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work or anyone for whose acts any of them may be liable. B. In any and all claims against Owner or Engineer or any of their respective consultants, agents, officers, directors, partners, or employees by any employ- ee (or the survi vor or personal representative of such employee) of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under Paragraph 6.20.A shall not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for Contractor or any such Subcontractor, Supplier, or other individual or entity under workers' compensation acts, disability benefit acts, or other employee benefit acts. C. The indemnification obligations of Contractor under Paragraph 6.20.A shall not extend to the liability of Engineer and Engineer's officers, directors, partners, employees, agents, consultants and subcontractors arising out of: 1. the preparation or approval of, or the failure to prepare or approve, maps, Drawings, opinions, reports, surveys, Change Orders, designs, or Specifications; or 2. giving directions or instructions, or failing to gIve them, if that is the primary cause of the injury or damage. 6.21 Delegation of Professional Design Services A. Contractor will not be required to provide professional design services unless such services are specifically required by the Contract Documents for a portion of the Work or unless such services are required to carry out Contractor's responsibilities for construction means, methods, techniques, sequences and procedures. Contractor shall not be required to provide professional services in violation of applicable law. shall appear on all drawings, calculations, specifications, certifications, Shop Drawings and other submittals prepared by such professional. Shop Drawings and other submittals related to the Work designed or certified by such professional, if prepared by others, shall bear such professional's written approval when submitted to Engineer. C. Owner and Engineer shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals, provided Owner and Engineer have specified to Contractor all performance and design criteria that such services must satisfy. D. Pursuant to this Paragraph 6.21, Engineer's review and approval of design calculations and design drawings will be only for the limited purpose of checking for conformance with performance and design criteria given and the design concept expressed in the Contract Documents. Engineer's review and approval of Shop Dra wings and other submittals (except design calculations and design drawings) will be only for the purpose stated in Paragraph 6.17 .D.l. E. Contractor shall not be responsible for the adequacy of the performance or design criteria required by the Contract Documents. ARTICLE 7 - OTHER WORK AT THE SITE 7.01 Related Work at Site A. Owner may perform other work related to the Project at the Site with Owner's employees, or via other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Con- tract Documents, then: 1. written notice thereof will be gIven to Contractor prior to starting any such other work; and 2. if Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim may be made therefor as provided in Paragraph 10.05. B. Contractor shall afford each other contractor who is a party to such a direct contract, each utility owner B. If professional design services or and Owner, if Owner is performing other work with certifications by a design professional related to systems, Owner's employees, proper and safe access to the Site, a materials or equipment are specifically required of reasonable opportunity for the introduction and storage of Contractor by the Contract Documents, Owner and materials and equipment and the execution of such other Engineer will specify all performance and design criteria work, and shall properly coordinate the Work with theirs. that such services must satisfy. Contractor shall cause Contractor shall do all cutting, fitting, and patching of the such services or certifications to be provided by a Work that may be required to properly connect or properly licensed professional, whose signature and seal otherwise make its several parts come together and E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for E.JCDC. All rights reserved. properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering their work and will only cut or alter their work with the written consent of Engineer and the others whose work will be affected. The duties and responsibilities of Contractor under this Paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of Contractor in said direct contracts between Owner and such utility owners and other contractors. C. If the proper execution or results of any part of Contractor's Work depends upon work performed by others under this Article 7, Contractor shall inspect such other work and promptly report to Engineer in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects and deficiencies in such other work. 7.02 Coordination A. If Owner intends to contract with others for the performance of other work on the Project at the Site, the following will be set forth in Supplementary Condi- tions: 1. the individual or entity who will have authority and responsibility for coordination of the activities among the various contractors will be identified; 2. the specific matters to be covered by such authority and responsibility will be itemized; and 3. the extent of such authority and responsibili- ties will be provided. B. Unless otherwise provided in Supplementary Conditions, Owner shall have authority and responsibility for such coordination. 7.03 Legal Relationships A. Paragraphs 7.0 LA and 7.02 are not applicable for utilities not under the control of Owner. B. Each other direct contract of Owner under Paragraph 7.0 I.A shall provide that the other contractor is liable to Owner and Contractor for the reasonable direct delay and disruption costs incurred by Contractor as a result of the other contractor's actions or inactions. C. Contractor shall be liable to Owner and any other contractor for the reasonable direct delay and disruption costs incurred by such other contractor as a result of Contractor's action or inactions. the sole ARTICLE 8 - OWNER'S RESPONSIBILITIES 8.01 Communications CO Contractor A. Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer. 8.02 Replacemellt of Engineer A. In case of termination of the employment of Engineer, Owner shall appoint an engineer to whom Contractor makes no reasonable objection, whose status under the Contract Documents shall be that of the former Engineer. 8.03 Furnish Data A. Owner shall promptly furnish the data required of Owner under the Contract Documents. 8.04 Pay When Due A. Owner shall make payments to Contractor when they are due as provided in Paragraphs 14.02.C and 14.07.C. 8.05 Lo.nds and Easements; Reports and Tests A. Owner's duties in respect of providing lands and easements and providing engineering surveys to establish reference points are set forth in Paragraphs 4.01 and 4.05. Paragraph 4.02 refers to Owner's identifying and making available to Contractor copies of reports of explorations and tests of subsurface conditions and drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site that have been utilized by Engineer in preparing the Contract Documents. 8.06 Insurance A. Owner's responsibilities, if any, in respect to purchasing and maintaining liability and property insur- ance are set forth in Article S. 8.07 Change Orders A. Owner is obligated to execute Change Orders as indicated in Paragraph 10.03. 8.08 Inspections, Tests, and A.pprovals A. Owner's responsibility in respect to certain inspections, tests, and approvals is set forth in Paragraph 13.03.B. .. EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights rescned. 8.09 Limitations on Owner's Respollsibilities A. The Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents. 8.10 Undisclosed Conditioll Hazardolis Environmental A. Owner's responsibility in respect to an undis- closed Hazardous Environmental Condition is set forth in Paragraph 4.06. 8.11 Evidence of Financial Arrangemems A. If and to the extent Owner has agreed to furnish Contractor reasonable evidence that financial arrangements have been made to satisfy Owner's obligations under the Contract Documents, Owner's responsibility in respect thereof will be as set forth in the Supplementary Conditions. ARTICLE 9 ENGIr{EER'S STATUS DURING CONSTRUCTION 9.01 Owner's Representative A. Engineer will be Owner's representative during the construction period. The duties and responsi- bilities and the limitations of authority of Engineer as Owner's representative during construction are set forth in the Contract Documents and will not be changed without written consent of Owner and Engineer. 9.02 Visits to Site A. Engineer will make visits to the Site at inter- vals appropriate to the various stages of construction as Engineer deems necessary in order to observe as an experienced and qualified design professional the progress that has been made and the quality of the various aspects of Contractor's executed Work. Based on information obtained during such visits and observations, Engineer, for the benefit of Owner, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. Engineer will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. Engineer's efforts will be directed toward providing for Ow'ner a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, Engineer will keep Owner informed of the progress of the Work and will endeavor to guard Owner against defective 'Hork. B. Engineer's visits and observations are subject to all the limitations on Engineer's authority and responsibility set forth in Paragraph 9.09. Particularly, but without limitation, during or as a result of Engineer's visits or observations of Contractor's Work Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. 9.03 Project Representative A. If Owner and Engineer agree, Engineer will furnish a Resident Project Representative to assist Engineer in providing more extensi ve observation of the Work. The authority and responsibilities of any such Resident Project Representative and assistants will be as provided in the Supplementary Conditions, and limitations on the responsibilities thereof will be as provided in Paragraph 9.09. If Owner designates another representative or agent to represent Owner at the Site who is not Engineer's consultant, agent or employee, the responsibilities and authority and limitations thereon of such other indi vidual or entity will be as provided in the Supplementary Conditions. 9.04 Authorized Variations in Work A. Engineer may authorize minor vanatlOns in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Docu- ments. These may be accomplished by a field Order and will be binding on Owner and also on Contractor, who shall perform the Work involved promptly. If Owner or Contractor believes that a field Order justifies an adjustment in the Contract Price or Contract Times, or both, and the parties are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment , a Claim may be made therefor as provided in Paragraph 10.05. 9.05 Rejecting Defective fVork A. Engineer will have authority to reject Work which Engineer believes to be defective, or that Engineer believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Engineer will also have authority to require special inspection or testing of the Work as provided in Paragraph 13.04, whether or not the Work is fabricated, installed, or completed. EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for E.J COCo All rights reserved. 9.06 Shop Drmvings, Change Orders and Payments A. In connection with Engineer's authority, and limitations thereof, as to Shop Drawings and Samples, see Paragraph 6.17. B. In connection with Engineer's authority, and limitations thereof, as to design calculations and design drawings submitted in response to a delegation of professional design services, if any, see Paragraph 6.21. C. In connection with Engineer's authority as to Change Orders, see Articles 10,11, and 12. D. In connection with Engineer's authority as to Applications for Payment, see Article 14. 9.07 Determinations for Unit Price Work A. Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor. Engineer will review with Contractor the Engineer's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). Engineer's written decision thereon will be final and binding (except as modified by Engineer to reflect changed factual conditions or more accurate data) upon Owner and Contractor, subject to the provisions of Paragraph 10.05. 9.08 Decisions on Requirements of Contract Documents and Acceptability of Work A. Engineer will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. All matters in question and other matters between Owner and Contractor arising prior to the date final payment is due relating to the acceptability of the Work, and the interpretation of the requirements of the Contract Documents pertaining to the performance of the Work, will be referred initially to Engineer in writing within 30 days of the event giving rise to the question B. Engineer will, with reasonable promptness, render a written decision on the issue referred. If Owner or Contractor believe that any such decision entitles them to an adjustment in the Contract Price or Contract Times or both, a Claim may be made under Paragraph 10.05. The date of Engineer's decision shall be the date of the event gi ving rise to the issues referenced for the purposes of Paragraph 1O.OS.B. C. Engineer's written decision on the issue referred will be final and binding on Owner and Contractor, subject to the provisions of Paragraph 10.05. partiality to Owner or Contractor and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. 9.09 Limitations on Engineer's Authority and Responsibilities A. Neither Engineer's authority or responsibility under this Article 9 or under any other provision of the Contract Documents nor any decision made by Engineer in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by Engineer shall create, impose, or give rise to any duty in contract, tort, or otherwise owed by Engineer to Contractor, any Subcontractor, any Supplier, any other indi vidual or entity, or to any surety for or employee or agent of any of them. B. Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with LaViS and Regulations applicable to the performance of the Work. Engineer will not be respon- sible for Contractor's failure to perform the Work in accordance with the Contract Documents. C. Engineer will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other indi vidual or entity performing any of the \Vork. D. Engineer's review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by Paragraph 14.07.A will only be to determine generally that their content complies with the require- ments of, and in the case of certificates of inspections, tests, and approvals that the results certified indicate compliance with the Contract Documents. E. The limitations upon authority and responsi- bility set forth in this Paragraph 9.09 shall also apply to, the Resident Project Representative, if any, and assistants, if any. ARTICLE 10 - CHANGES IN THE WORK; CLAIMS 10.01 Aurhorized Changes in [he vFork A. Without invalidating the Contract and without notice to any surety, Owner may, at any time or from time to time, order additions, deletions, or revisions in the D. When functioning as interpreter and judge Work by a Change Order, or a Work Change Directive. under this Paragraph 9.08, Engineer will not show Upon receipt of any such document, Contractor shall E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for E.JCDC. All rights resened. 00700 - 28 promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise speci ficall y provided). B. If Owner and Contractor are unable to agree on entitlement to, or on the amount or extent, if any, of an adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Work Change Directive, a Claim may be made therefor as provided in Paragraph 10.05. 10.02 Unauthoriz.ed Changes in the Work A.Contractor shall not be entitled to an increase In the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented as provided in Paragraph 3.04, except in the case of an emergency as provided in Paragraph 6.16 or in the case of uncovering Work as provided in Paragraph 13 .04.B. 10.03 Execution of Change Orders A. Owner and Contractor shall execute appropri- ate Change Orders recommended by Engineer covering: 1. changes in the Work which are: (i) ordered by Owner pursuant to Paragraph 10.0 l.A, (ii) required because of acceptance of defective Work under Paragraph 13.08.A or Owner's correction of defective Work under Paragraph 13.09, or (iii) agreed to by the parties; 2. changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive; and 3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by Engineer pursuant to Paragraph 10.05; provided that, in lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal, Contractor shall carryon the Work and adhere to the Progress Schedule as provided in Paragraph 6.18.A. 10.04 Notification lO Surety A. If notice of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times) is required by the provisions of any bond to be given to a surety, the giving of any such notice will be Contractor's responsibility. The amount of each applicable bond will be adjusted to reflect the effect of any such change. 10.05 Claims A. Engineer's Decision Required: All Claims, except those waived pursuant to Paragraph 14.09, shall be referred to the Engineer for decision. A decision by Engineer shall be required as a condition precedent to any exercise by Owner or Contractor of any rights or remedies either may otherwise have under the Contract Documents or by Laws and Regulations in respect of such Claims. B. Notice: Written notice stating the general nature of each Claim, shall be delivered by the claimant to Engineer and the other party to the Contract promptly (but in no event later than 30 days) after the start of the event gi ving rise thereto. The responsibility to substantiate a Claim shall rest with the party making the Claim. Notice of the amount or extent of the Claim, with supporting data shall be delivered to the Engineer and the other party to the Contract within 60 days after the start of such event (unless Engineer allows additional time for claimant to submit additional or more accurate data in support of such Claim). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of Paragraph 12.01.B. A Claim for an adjustment in Contract Time shall be prepared in accordance with the provisions of Paragraph 12.02.B. Each Claim shall be accompanied by claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The opposing party shall submit any response to Engineer and the claimant within 30 days after receipt of the claimant's last submittal (unless Engineer allows additional time). C. Engineer's Action: Engineer will review each Claim and, within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any, take one of the following actions in writing: 1. deny the Claim in whole or in part, 2. approve the Claim, or 3. notify the parties that the Engineer is unable to resolve the Cl~im if, in the Engineer's sole discretion, it would be inappropriate for the Engineer to do so. For purposes of further resolution of the Claim, such notice shall be deemed a denial. D. In the event that Engineer does not take action on a Claim within said 30 days, the Claim shall be deemed denied. E. Engineer's written action under Paragraph 10.05.C or denial pursuant to Paragraphs 10.05.C.3 or 1O.05.D will be final and binding upon Owner and Contractor, unless Owner or Contractor invoke the dispute resolution procedure set forth in Article 16 within 30 days of such action or denial. E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. F. No Claim for an adjustment in Contract Price or Contract Times will be valid if not submitted in accordance \vith this Paragraph 10.05. ARTICLE 11 COST OF THE WORK; ALLOW Ai'-!CES; UNIT PRICE WORK 11.01 Cost of the Work A. Costs Included: The term Cost of the Work means the sum of all costs, except those excluded in Paragraph 11.01.B, necessarily incurred and paid by Contractor in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to Contractor will be only those additional or incremental costs required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by Owner, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall include only the following items, and shall not include any of the costs itemized in Paragraph 11.0 I.B. 1. Payroll costs for employees in the direct employ of Contractor in the performance of the Work under schedules of job classifications agreed upon by Owner and Contractor. Such employees shall include, without limitation, superintendents, foremen, and other personnel employed full time at the Site. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits, which shall include social security contributions, unemployment, excise, and payroll taxes, workers' compensation, health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on Saturday, Sunday, or legal holidays, shall be included in the above to the extent authorized by Owner. 2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts shall accrue to Contractor unless Owner deposits funds with Contractor with which to make pay- ments, in which case the cash discounts shall accrue to Owner. All trade discounts, rebates and refunds and returns from sale of surplus materials and equipment shall accrue to Owner, and Contractor shall make provisions so that they may be obtained. Contractor and shall deliver such bids to Owner, who \vill then determine, with the advice of Engineer, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee shall be determined in the same manner as Contractor's Cost of the Work and fee as provided in this Paragraph 11.01. 4. Costs of special consultants (including but not limited to Engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed for services specifically related to the \Vork. S. Supplemental costs including the following: a. The proportion of necessary transportation, travel, and subsistence expenses of Contractor's employees incurred in discharge of duties connected with the Work. b. Cost, including transportation and mainte- nance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site, and hand tools not owned by the workers, which are consumed in the perfor- mance of the Work, and cost, less market value, of such items used but not consumed which remain the property of Contractor. c. Rentals of all construction equipment and machinery, and the parts thereof whether rented from Contractor or others in accordance with rental agreements approved by Owner with the advice of Engineer, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs shall be in accordance with the terms of said rental agreements. The rental of any such equip- ment, machinery, or parts shall cease \vhen the use thereof is no longer necessary for the Work. d. Sales, consumer, use, and other similar taxes related to the Work, and for which Contractor is liable, imposed by Laws and Regulations. e. Deposits lost for causes other than negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. f. Losses and damages (and related expenses) caused by damage to the Work, not compensated by insurance or otherwise, sustained by Contractor in connection with the performance 3. Payments made by Contractor to of the Work (except losses and damages within Subcontractors for Work performed by Subcontractors. If the deductible amounts of property insurance required by Owner, Contractor shall obtain competitive established in accordance with Paragraph bids from subcontractors acceptable to Owner and S.06.D), provided such losses and damages have EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC All rights resened. resulted from causes other than the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of Owner. No such losses, damages, and expenses shall be included in the Cost of the Work for the purpose of determining Contractor's fee. g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, expresses, and similar petty cash items in connection with the Work. i. The costs of premiums for all bonds and insurance Contractor is required by the Contract Documents to purchase and maintain. B. Costs Excluded: The term Cost of the \Vork shall not include any of the following items: 1. Payroll costs and other compensation of Contractor's officers, executives, principals (of partnerships and sole proprietorships), general managers, safety managers, engineers, architects, estimators, attor- neys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by Contractor, whether at the Site or in Contractor's principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in Paragraph 11.01.A.l or specifically covered by Paragraph 11.01.AA, all of which are to be considered administrati ve costs covered by the Contractor's fee. 2. Expenses of Contractor's principal and branch offices other than Contractor's office at the Site. 3. Any part of Contractor's capital expenses, including interest on Contractor's capital employed for the Work and charges against Contractor for delinquent payments. 4. Costs due to the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. S. Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraphs 11.01.A and 11.01.B. C. Conrractor's Fee: When all the Work is performed on the basis of cost-plus, Contractor's fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, Contractor's fee shall be determined as set forth in Paragraph 12.01.C. D. Documentation: Whenever the Cost of the Work for any purpose is to be determined pursuant to Paragraphs 11.0 I.A and 11.0 I.B, Contractor will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in a form acceptable to Engineer an itemized cost breakdown together with supporting data. 11.02 Allowances A. It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the \Vork so covered to be performed for such sums and by such persons or entities as may be acceptable to Owner and Engineer. B. Cash Allowances 1. Contractor agrees that: a. the cash allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allO\vances to be delivered at the Site, and all applicable taxes; and b. Contractor's costs for unloading and handling on the Site, labor, installation, overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment on account of any of the foregoing will be valid. C. Contingency Allowance 1. Contractor agrees that a contingency allowance, if any, is for the sole use of Ow'ner to cover unanticipated costs. D. Prior to final payment, an appropriate Change Order will be issued as recommended by Engineer to reflect actual amounts due Contractor on account of Wark covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.03 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. EJCDC C-700 Standard General, Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. B. The estimated quantItIes of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by Contractor will be made by Engineer subject to the provisions of Paragraph 9.07. C. Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractor's overhead and profit for each separately identified item. D. Owner or Contractor may make a Claim for an adjustment in the Contract Price in accordance with Paragraph 10.05 if: 1. the quantity of any item of Unit Price Work performed by Contractor differs materially and signifi- cantly from the estimated quantity of such item indicated in the Agreement; and 2. there is no corresponding adjustment with respect any other item of Work; and 3. Contractor believes that Contractor is entitled to an increase in Contract Price as a result of having incurred additional expense or Owner believes that Owner is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. ARTICLE 12 - CHANGE OF CONTRACT PRICE; CHAL'\iGE OF CONTRACT TIMES 12.01 Change of Contract Price A. The Contract Price may only be changed by a Change Order. Any Claim for an adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be determined as follows: 1. where the Work involved is covered by unit prices contained in the Contract Documents, by applica- tion of such unit prices to the quantities of the items invol ved (subject to the provisions of Paragraph 11.03); or 2. where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily In accordance with Paragraph 12.01.C.2); or 3. where the Work involved is not covered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under Paragraph 12.01.B.2, on the basis of the Cost of the Work (determined as provided in Paragraph 11.01) plus a Contractor's fee for overhead and profit (determined as provided in Paragraph 12.01.C). C. Contractor's Fee: The Contractor's fee for overhead and profit shall be determined as follows: 1. a mutually acceptable fixed fee; or 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: a. for costs incurred under Paragraphs ll.0l.A.l and 11.01.A.2, the Contractor's fee shall be IS percent; b. for costs incurred under Paragraph 11.01.A.3, the Contractor's fee shall be five percent; c. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of Paragraph 12.01.C.2.a is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under Paragraphs 11.01.A.l and 11.01.A.2 and that any higher tier Subcontractor and Contractor will each be paid a fee of five percent of the amount paid to the next lower tier Subcontractor; d. no fee shall be payable on the basis of costs itemized under Paragraphs 11.01.A.4, 11.01.A.5, and 11.01.B; e. the amount of credit to be allow'ed by Contractor to Owner for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a deduction in Contractor's fee by an amount equal to five percent of such net decrease; and f. when both additions and credits are involved in anyone change, the adjustment in Contractor's fee shall be computed on the basis of the net change in accordance with Paragraphs 12.01.C.2.a through 12.01.C.2.e, inclusive. 12.02 Change of Contract Times A. The Contract Times may only be changed by a Change Order. Any Claim for an adjustment in the Contract Times shall be based on written notice submitted E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700 - 32 by the party making the Claim to the Engineer and the other party to the Contract in accordance with the provisions of Paragraph 10.05. B. Any adjustment of the Contract Times covered by a Change Order or any Claim for an adjustment in the Contract Times will be determined in accordance with the provisions of this Article 12. 12.03 Delays A. Where Contractor is prevented from completing any part of the Work within the Contract Times due to delay beyond the control of Contractor, the Contract Times will be extended in an amount equal to the time lost due to such delay if a Claim is made therefor as provided in Paragraph 12.02.A. Delays beyond the control of Contractor shall include, but not be limited to, acts or neglect by Owner, acts or neglect of utility owners or other contractors performing other work as contemplat- ed by Article 7, fires, floods, epidemics, abnormal weather conditions, or acts of God. B. If Owner, Engineer, or other contractors or utility owners performing other work for Owner as contemplated by Article 7, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Price or the Contract Times , or both. Contractor's entitlement to an adjustment of the Contract Times is conditioned on such adjustment being essential to Contractor's ability to complete the Work within the Contract Times. C If Contractor is delayed in the performance or progress of the Work by fire, flood, epidemic, abnormal weather conditions, acts of God, acts or failures to act of utility owners not under the control of Owner, or other causes not the fault of and beyond control of Owner and Contractor, then Contractor shall be entitled to an equitable adjustment in Contract Times, if such adjustment is essential to Contractor's ability to complete the Work within the Contract Times. Such an adjustment shall be Contractor's sole and exclusive remedy for the delays described in this Paragraph 12.03.C. D. Owner, Engineer and the Related Entities of each of them shall not be liable to Contractor for any claims, costs, losses, or damages (including but not limited to all fees and charges of Engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Contractor on or in connection with any other project or anticipated project. ARTICLE 13 TESTS Ai'TD INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.01 Notice of Defects A. Prompt notice of all defective Work of which Owner or Engineer has actual knowledge will be given to Contractor. All defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.02 Access to "\Vork A. Owner, Engineer, their consultants and other representatives and personnel of Owner, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspecting, and testing. Contractor shall provide them proper and safe conditions for such access and advise them of Contractor's Site safety procedures and programs so that they may comply therewith as applicable. 13 .03 Tests and Inspections A. Contractor shall give Engineer timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. Owner shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents except: 1. for inspections, tests, or approvals covered by Paragraphs 13.03.C and 13.03.D below; 2. that costs incurred in connection with tests or inspections conducted pursuant to Paragraph 13.04.B shall be paid as provided in said Paragraph 13.04.C; and 3. as otherwise specifically provided in the Con- tract Documents. C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Engineer the required certificates of inspection or approval. E. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delays D. Contractor shall be responsible for arranging within the control of Contractor. Delays attributable to and obtaining and shall pay all costs in connection with and within the control of a Subcontractor or Supplier shall any inspections, tests, or approvals required for Owner's be deemed to be delays within the control of Contractor. and Engineer's acceptance of materials or equipment to E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to Owner and Engineer. E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of Engineer, it must, if requested by Engineer, be uncovered for observation. F. Uncovering Work as provided in Paragraph 13.03.E shall be at Contractor's expense unless Contractor has given Engineer timely notice of Contractor's intention to cover the same and Engineer has not acted with reasonable promptness in response to such notice. 13.04 Uncovering Work A. If any \V ork is covered contrary to the written request of Engineer, it must, if requested by Engineer, be uncovered for Engineer's observation and replaced at Contractor's expense. B. If Engineer considers it necessary or advisable that covered Work be observed by Engineer or inspected or tested by others, Contractor, at Engineer's request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as Engineer may require, that portion of the Work in question, furnishing all necessary labor, material, and equipment. C. If it is found that the uncovered Work is defecti ve, Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. D. If, the uncovered Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Times, or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, Contractor may make a Claim therefor as provided in Paragraph 10.05. 13.05 Owner lvlay Stop the Work A. If the Work is defecti ve, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, Owner may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of Owner to stop the Work shall not gi ve rise to any duty on the part of Owner to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 13.06 Correction or Removal of Defective Work A. Promptly after receipt of notice, Contractor shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by Engineer, remove it from the Project and replace it with Work that is not defective. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). B. When correcting defective Work under the terms of this Paragraph 13.06 or Paragraph 13.07, Contractor shall take no action that would void or otherwise impair Owner's special warranty and guarantee, if any, on said Work. 13.07 Correction Period A. If within one year after the date of Substantial Completion (or such longer period of time as may be prescribed by the terms of any applicable special guarantee required by the Contract Documents) or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made available for Contractor's use by Owner or permitted by Laws and Regulations as contemplated in Paragraph 6.11.A is found to be defective, Contractor shall promptly, without cost to Owner and in accordance with Owner's written instructions: 1. repair such defecti ve land or areas; or 2. correct such defective Work; or 3. if the defective Work has been rejected by Owner, remove it from the Project and replace it with Work that is not defective, and 4. satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting therefrom. EJCDC C-700 Standard General Conditions or the Construction Contract. Copyright @ 2002 National Society or Professional Engineers for E.JCDC. All rights reserved. B. If Contractor does not promptly comply with the terms of Owner's written instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or repaired or may have the rejected Work re- moved and replaced. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. C. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications. D. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this Paragraph 13.07, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. E. Contractor's obligations under this Paragraph 13.07 are in addition to any other obligation or warranty. The provisions of this Paragraph 13.07 shall not be construed as a substitute for or a waiver of the provisions of any applicable statute of limitation or repose. 13.08 Acceptance of Defective Work A. If, instead of requiring correction or removal and replacement of defective Work, Owner (and, prior to Engineer's recommendation of final payment, Engineer) prefers to accept it, Owner may do so. Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to Owner's evaluation of and determination to accept such defective Work (such costs to be approved by Engineer as to reasonableness) and the diminished value of the Work to the extent not otherwise paid by Contractor pursuant to this sentence. If any such acceptance occurs prior to Engineer's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and Owner shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work so accepted. If the parties are unable to agree as to the amount thereof, Owner may make a Claim therefor as provided in Paragraph 10.05. If the acceptance occurs after such recommendation, an appropriate amount will be paid by Contractor to Owner. 13.09 Owner i'yfay Correct Defective Work A. If Contractor fails within a reasonable time after written notice from Engineer to correct defective Work or to remove and replace rejected Work as required by Engineer in accordance with Paragraph 13.06.A, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, Owner may, after seven days written notice to Contractor, correct or remedy any such deficiency. B. In exercising the rights and remedies under this Paragraph 13.09, Owner shall proceed expeditiously. In connection \vith such corrective or remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, take posses- sion of Contractor's tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's representatives, agents and employees, Owner's other contractors, and Engineer and Engineer's consultants access to the Site to enable O\vner to exercise the rights and remedies under this Paragraph. C. All claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 13.09 will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and Owner shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount of the adjustment, Owner may make a Claim therefor as provided in Paragraph 10.05. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor's defective \Vork. D. Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to the exercise by Owner of Owner's rights and remedies under this Paragraph 13.09. ARTICLE 14 - PAYMENTS TO CONTRACTOR Ai~D COMPLETION 14.01 Schedule of Values A The Schedule of Values established as provid- ed in Paragraph 2.07.A will serve as the basis for progress EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJ CDC. All rights reserved. 00700 - payments and will be incorporated into a form of Applica- tion for Payment acceptable to Engineer. Progress payments on account of Unit Price Work will be based on the number of units completed. 14.02 Progress Payments A. Applications for Payments 1. At least 20 days before the date established in the Agreement for each progress payment (but not more often than once a month), Contractor shall submit to Engineer for review an Application for Payment filled out and signed by Contractor covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other documentation warranting that Owner has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect Owner's interest therein, all of which must be satisfactory to Owner. 2. Beginning with the second Application for Payment, each Application shall include an affidavit of Contractor stating that all previous progress payments received on account of the Work have been applied on account to discharge Contractor's legitimate obligations associated with prior Applications for Payment. 3. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. B. Review of Applications 1. Engineer will, within 10 days after receipt of each Application for Payment, either indicate in writing a recommendation of payment and present the Application to Owner or return the Application to Contractor indicating in writing Engineer's reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the Application. 2. Engineer's recommendation of any payment requested in an Application for Payment will constitute a representation by Engineer to Owner, based on Engineer's observations on the Site of the executed Work as an experienced and qualified design professional and on Engineer's review of the Application for Payment and the accompanying data and schedules, that to the best of Engineer's knowledge, information and belief: b. the quality of the Work is generally in accor- dance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the results of any subsequent tests called for in the Contract Documents, to a final determination of quantities and classifications for Unit Price Work under Paragraph 9.07, and to any other qualifications stated in the recommendation); and c. the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe the Work. 3. By recommending any such payment Engineer will not thereby be deemed to have represented that: a. inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsi- bilities specifically assigned to Engineer in the Contract Documents; or b. that there may not be other matters or issues between the parties that might entitle Contractor to be paid additionally by Owner or entitle Owner to withhold payment to Contractor. 4. Neither Engineer's review of Contractor's Work for the purposes of recommending payments nor Engineer's recommendation of any payment, including final payment, will impose responsibility on Engineer: a. to supervise, direct, or control the Work, or b. for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or c. for Contractor's failure to comply with Laws and Regulations applicable to Contractor's performance of the Work, or d. to make any examination to ascertain how or for what purposes Contractor has used the moneys paid on account of the Contract Price, or e. to determine that title to any of the Work, materials, or equipment has passed to Owner free and clear of any Liens. 5. Engineer may refuse to recommend the whole or any part of any payment if, in Engineer's opinion, it would be incorrect to make the representations to Owner stated in Paragraph 14.02.B.2. Engineer may also refuse to recommend any such payment or, because of subse- quently discovered evidence or the results of subsequent EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. a. the Work has progressed to the point indicat- ed; inspections or tests, revise or revoke any such payment recommendation previously made, to such extent as may be necessary in Engineer's opinion to protect Owner from loss because: a. the Work is defecti ve, or completed Work has been damaged, requiring correction or replace- ment; b. the Contract Price has been reduced by Change Orders; c. Owner has been required to correct defective Work or complete Work in accordance with Paragraph 13.09; or d. Engineer has actual knowledge of the occurrence of any of the events enumerated in Paragraph 15.02.A. C. Payment Becomes Due 1. Ten days after presentation of the Application for Payment to Owner with Engineer's recommendation, the amount recommended will (subject to the provisions of Paragraph 14.02.D) become due, and when due will be paid by Owner to Contractor. D. Reduction in Payment 1. Owner may refuse to make payment of the full amount recommended by Engineer because: a. claims have been made against Owner on account of Contractor's performance or furnish- ing of the Work; b. Liens have been filed in connection with the Work, except where Contractor has delivered a specific bond satisfactory to Owner to secure the satisfaction and discharge of such Liens; c. there are other items entitling Owner to a set-off against the amount recommended; or d. Owner has actual knowledge of the occurrence of any of the events enumerated in Paragraphs 14.02.B.5.a through 14.02.B.S.c or Paragraph IS.02.A. 2. If Owner refuses to make payment of the full amount recommended by Engineer, Owner will give Contractor immediate written notice (with a copy to Engineer) stating the reasons for such action and promptly pay Contractor any amount remaining after deduction of the amount so withheld. Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by Owner and Contractor, when Contractor corrects to Owner's satisfaction the reasons for such action. 3. If it is subsequently determined that Owner's refusal of payment was not justified, the amount wrongfully withheld shall be treated as an amount due as determined by Paragraph 14.02.C.l. 14.03 Contractor's Warranty of Title A. Contractor warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to Owner no later than the time of payment free and clear of all Liens. 14.04 Substantial Completion A. When Contractor considers the entire Work ready for its intended use Contractor shall notify Owner and Engineer in writing that the entire Work is substantially complete (except for items specifically listed by Contractor as incomplete) and request that Engineer issue a certificate of Substantial Completion. B. Promptly after Contractor's notification, Owner, Contractor, and Engineer shall make an inspection of the Work to determine the status of completion. If Engineer does not consider the Work substantially complete, Engineer will notify Contractor in writing giving the reasons therefor. C. If Engineer considers the Work substantially complete, Engineer will deliver to Owner a tentative certificate of Substantial Completion which shall fix the date of Substantial Completion. There shall be attached to the certificate a tentative list of items to be completed or corrected before final payment. Owner shall. have seven days after receipt of the tentative certificate during which to make written objection to Engineer as to any provisions of the certificate or attached list. If, after considering such objections, Engineer concludes that the Work is not substantially complete, Engineer will within 14 days after submission of the tentative certificate to Owner notify Contractor in writing, stating the reasons therefor. If, after consideration of Owner's objections, Engineer considers the Work substantially complete, Engineer will within said 14 days execute and deliver to Owner and Contractor a definitive certificate of Substantial Completion (with a revised tentative list of items to be completed or correct- ed) rdlecting such changes from the tentative certificate as Engineer believes justified after consideration of any objections from Owner. D. At the time of delivery of the tentative certificate of Substantial Completion, Engineer will deliver to Owner and Contractor a written recommen- dation as to division of responsibilities pending final payment between Owner and Contractor with respect to security, operation, safety, and protection of the Work, maintenance, heat, utilities, insurance, and warranties and guarantees. Unless Owner and Contractor agree otherwise in writing and so inform Engineer in writing prior to Engineer's issuing the definitive certificate of Substantial E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJ CDC. All rights reserved. Completion, Engineer's aforesaid recommendation will be binding on Owner and Contractor until final payment. E. Owner shall have the right to exclude Contractor from the Site after the date of Substantial Completion subject to allowing Contractor reasonable access to complete or correct items on the tentative list. 14.05 Partial Utiliz.ation A. Prior to Substantial Completion of all the Work, Owner may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which Owner, Engineer, and Contractor agree constitutes a separately functioning and usable part of the Work that can be used by Owner for its intended purpose without significant interference with Contractor's performance of the remainder of the Work, subject to the following condi- tions. 1. Owner at any time may request Contractor in writing to permit Owner to use or occupy any such part of the Work which Owner believes to be ready for its intended use and substantially complete. If and when Contractor agrees that such part of the Work is substantially complete, Contractor will certify to Owner and Engineer that such part of the Work is substantially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work. 2. Contractor at any time may notify Owner and Engineer in writing that Contractor considers any such part of the Work ready for its intended use and substan- tially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work. 3. Within a reasonable time after either such request, Owner, Contractor, and Engineer shall make an inspection of that part of the Work to determine its status of completion. If Engineer does not consider that part of the Work to be substantially complete, Engineer will notify Owner and Contractor in writing giving the reasons therefor. If Engineer considers that part of the Work to be substantially complete, the provisions of Paragraph 14.04 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 4. No use or occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of Paragraph 5.10 regarding property IDsurance. 14.06 Final Inspection that the Work is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 14.07 Final Paymenr A. Application for Payment 1. After Contractor has, in the opInion of Engineer, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance certificates of inspection, marked-up record documents (as provided in Paragraph 6.12), and other documents, Contractor may make application for final payment following the procedure for progress payments. 2. The final Application for Payment shall be accompanied (except as previously delivered) by: a. all documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by Paragraph S.04.B.7; b. consent of the surety, if any, to final payment; c. a list of all Claims against Owner that Contractor believes are unsettled; and d. complete and legally effective releases or waivers (satisfactory to Owner) of all Lien rights arising out of or Liens filed in connection with the Work. 3. In lieu of the releases or waivers of Liens specified in Paragraph 14.07.A.2 and as approved by Owner, Contractor may furnish receipts or releases in full and an affidavit of Contractor that: (i) the releases and receipts include all labor, services, material, and equipment for which a Lien could be filed; and (ii) all payrolls, material and equipment bills, and other indebtedness connected with the Work for which Owner or Owner's property might in any way be responsible have been paid or otherwise satisfied. If any Subcontractor or Supplier fails to furnish such a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to Owner to indemnify Owner against any Lien. B. Engineer's Review of Application and Acceptance 1. If, on the basis of Engineer's observation of A. Upon written notice from Contractor that the the Work during construction and final inspection, and entire Work or an agreed portion thereof is complete, Engineer's review of the final Application for Payment Engineer will promptly make a final inspection with and accompanying documentation as required by the Owner and Contractor and will notify Contractor in Contract Documents, Engineer is satisfied that the Work writing of all particulars in which this inspection reveals has been completed and Contractor's other obligations EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJCDC. All rights reserved. 00700 - 38 under the Contract Documents have been fulfilled, Engineer wilL within ten days after receipt of the final Application for Payment, indicate in writing Engineer's recommendation of payment and present the Application for Payment to Owner for payment. At the same time Engineer will also give written notice to Owner and Contractor that the Work is acceptable subject to the provisions of Paragraph 14.09. Otherwise, Engineer will return the Application for Payment to Contractor, indicat- ing in writing the reasons for refusing to recommend final payment, in which case Contractor shall make the necessary corrections and resubmit the Application for Payment. C. Payment Becomes Due 1. Thirty days after the presentation to Owner of the Application for Payment and accompanying docu- mentation, the amount recommended by Engineer, less any sum Owner is entitled to set off against Engineer's recommendation, including but not limited to liquidated damages, will become due and, will be paid by OViDer to Contractor. 14.08 Final Completion Delayed A. If, through no fault of Contractor, final completion of the Work is significantly delayed, and if Engineer so confirms, Owner shall, upon receipt of Contractor's final Application for Payment (for Work fully completed and accepted) and recommendation of Engineer, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by Owner for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if bonds have been furnished as required in Paragraph 5.01, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by Contractor to Engineer with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a wai ver of Claims. 14.09 Waiver of Claims A. The making and acceptance of final payment will constitute: 1. a waiver of all Claims by Owner against Contractor, except Claims arising from unsettled Liens, from defective Work appearing after final inspection pursuant to Paragraph 14.06, from failure to comply with the Contract Documents or the terms of any special guarantees specified therein, or from Contractor's continuing obligations under the Contract Documents; and with the requirements herein and expressly acknowledged by Owner in writing as still unsettled. ARTICLE 15 - SUSPENSION OF \VORK Al'W TERMINATION 15.01 Owne.r Ivlay Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 90 consecutive days by notice in \\ifiting to Contractor and Engineer which will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be granted an adjust- ment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension if Contractor makes a Claim therefor as provided in Paragraph 10.05. 15.02 Owner ivla.v Terminate for Cause A. The occurrence of anyone or more of the following events will justify termination for cause: 1. Contractor's persistent failure to perform the \Vork in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the Progress Schedule established under Paragraph 2.07 as adjusted from time to time pursuant to Paragraph 6.04); 2. Contractor's disregard of La ws or Regulations of any public body having jurisdiction; 3. Contractor's disregard of the authority of Engineer; or 4. Contractor's violation in any substantial way of any provisions of the Contract Documents. B. If one or more of the events identified in Paragraph IS.02.A occur, Owner may, after giving Contractor (and surety) seven clays written notice of its intent to terminate the services of Contractor: 1. exclude Contractor from the Site, and take possession of the Work and of all Contractor's tools, appliances, construction equipment, and machinery at the Site, and use the same to the full extent they could be used by Contractor (without liability to Contractor for trespass or conversion), 2. incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere, and 2. a waiver of all Claims by Contractor against Owner other than those previously made in accordance E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @2002 National Society of Professional Engineers for EJCDC. All rights resened. 3. complete the Work as Ow'ner may deem expedient. C. If Owner proceeds as provided in Paragraph IS.m.B, Contractor shall not be entitled to receive any further payment until the "Vork is completed. If the unpaid balance of the Contract Price exceeds all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by Owner arising out of or relating to completing the Work, such excess will be paid to Contractor. If such claims, costs, losses, and damages exceed such unpaid balance, Contractor shall pay the difference to Owner. Such claims, costs, losses, and damages incurred by Owner will be reviewed by Engineer as to their reasonableness and, when so approved by Engineer, incorporated in a Change Order. When exercising any rights or remedies under this Paragraph Owner shall not be required to obtain the lowest price for the Work performed. D. Notwithstanding Paragraphs lS.02.B and 15.02.C, Contractor's services will not be terminated if Contractor begins \vithin seven days of receipt of notice of intent to terminate to correct its failure to perform and proceeds diligently to cure such failure within no more than 30 days of receipt of said notice. E. Where Contractor's services have been so terminated by Owner, the termination will not affect any rights or remedies of Owner against Contractor then existing or which may thereafter accrue. Any retention or payment of moneys due Contractor by Owner will not release Contractor from liability. F. If and to the extent that Contractor has provided a performance bond under the provisions of Paragraph S.01.A, the termination procedures of that bond shall supersede the provisions of Paragraphs IS.02.B, and IS.02.C. 15.03 Ovvner lvlay Terminate For Convenience A. Upon seven days written notice to Contractor and Engineer, Owner may, without cause and without prejudice to any other right or remedy of Owner, terminate the Contract. In such case, Contractor shall be paid for (without duplication of ariy items): 1. completed and acceptable Work executed in accordance with the Contract Documents prior to the effecti ve date of termination, including fair and reasonable sums for overhead and profit on such Work; 2. expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials, or equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; 3. all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred in settlement of terminated contracts with Subcontractors, Suppliers, and others; and 4. reasonable expenses directly attributable to termination. B. Contractor shall not be paid on account of loss of anticipated profits or revenue or other economic loss arising out of or resulting from such termination. 15.04 CO/lfractor JHay Stop \Vork or Terminate A. If, through no act or fault of Contractor, (i) the Work is suspended for more than 90 consecutive days by Owner or under an order of court or other public authority, or (ii) Engineer fails to act on any Application for Payment within 30 days after it is submitted, or (iii) Owner fails for 30 days to pay Contractor any sum finally determined to be due, then Contractor may, upon seven days written notice to Owner and Engineer, and provided Owner or Engineer do not remedy such suspension or failure within that time, terminate the Contract and recover from Owner payment on the same terms as provided in Paragraph 15.03. B. In lieu of terminating the Contract and without prejudice to any other right or remedy, if Engineer has failed to act on an Application for Payment within 30 days after it is submitted, or Owner has failed for 30 days to pay Contractor any sum finally determined to be due, Contractor may, seven days after written notice to Owner and Engineer, stop the Work until payment is made of all such amounts due Contractor, including interest thereon. The provisions of this Paragraph 15.04 are not intended to preclude Contractor from making a Claim under Paragraph 10.05 for an adjustment in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to Contractor's stopping the Work as permitted by this Paragraph. ARTICLE 16 - DISPUTE RESOLUTION 16.01 IVlethods and Procedures A. Either Owner or Contractor may request mediation of any Claim submitted to Engineer for a decision under Paragraph 10.05 before such decision becomes final and binding. The mediation will be E.JCDC C-700 Standard General Conditions of the Construction Contract. Copyright @ 2002 National Society of Professional Engineers for EJ CDC. All rights reserved. 00700 - 40 governed by the Construction Industry Mediation Rules of the American l\rbitration Association in effect as of the Effective Date of the Agreement. The request for mediation shall be submitted in writing to the American A.rbitration Association and the other party to the Contract. Timely submission of the request shall stay the effect of Paragraph 1O.05.E. B. Owner and Contractor shall participate in the mediation process in good faith. The process shall be concluded within 60 days of filing of the request. The date of termination of the mediation shall be determined by application of the mediation rules referenced above. C. If the Claim is not resolved by mediation, Engineer's action under Paragraph 10.05.C or a denial pursuant to Paragraphs 10.05.C.3 or 10.05.D shall become final and binding 30 days after termination of the mediation unless, within that time period, Owner or Contractor: 1. elects in wf!tmg to invoke any dispute resolution process provided for in the Supplementary Conditions, or 2. agrees with the other party to submit the Claim to another dispute resolution process, or 3. gives \vritten notice to the other party of their intent to submit the Claim to a court of competent jurisdiction. ARTICLE 17 - MISCELLAJ."1"EOUS 17.01 Giving Notice A. Whenever any provision of the Contract Documents requires the gi ving of written notice, it will be deemed to have been validly given if: 1. delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or 2. delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the gi ver of the notice. 17.02 Computation of Times A. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. 17 .03 CUlIlulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regula- tions, by special warranty or guarantee, or by other provisions of the Contract Documents. The provisions of this Paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply. 17 .04 Survival of Obligations A. All representations, indemnifications, warran- ties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Docu- ments, will survive final payment, completion, and acceptance of the Work or termination or completion of the Contract or termination of the services of Contractor. 17 .05 Controlling Law A. This Contract is to be governed by the la \v of the state in \vhich the Project is located. 17.06 Headings A. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions. EJCDC C-700 Standard General Conditions of the Construction Contract. Copyright @2002 National Society or Proressional Engineers for EJCDC. All rights reserved. '-0 1- i~ I::' ~ I"" n"'O l.Il 0 ~ ~ ~ ~ 12 ~ 2 9 ~! ~ ~ "' , ,.... ~ ~ -< "'"'1 n ..." ~ ~ ~ .., ~ " e 8 f'1 ~ ~ ~ g ~ ~ ~, ~ ~ '" co ~ 55 is ~ ...., -< Vl -< z: o:J g Vl ~ ~ I ~ ~ ~ =; f'1 ::t ~ ~ g ~ :::: :::." n o " z c i ~ g ~ " ~ ;i ~. ~ ~ ~ co ; i m c ~ 8 " > ~ l.1 ro c::r ;:::: c: C :..; ;v ;v a 8 8 ~ ~ ~ ~ ~ .... 0 < , m o ~ o - - '= e - o -j -< o 11 z m ~ I o LJ m I r r (J) o m -1 m :D :D )> o m o m < m r o -0 ~ m z -1 (J) -1C :D-1 mr m- -1~ ~(J) -0-1 :D:D Om <m m-1 ~~ mz ~o (J) o ~ lJ ::rJ o c m o -I Z P '-J ::::;! ~r:r OJ j. ?~ -g Q) 8 .-.\. .~. Z ~:g1J ,;j" o'Z (b-c......._ ~[}1 3~OO 00 tD OJ --- n --I a. -:rt'D !'T1)> ~["Ci)~ ~o c.. - 'U "'< =to m ~ ~ w- g ~ <l> 0 ::l if 3;;;; c..:::J...,_ (i)-4; ~~!E..:::' ::'3:: .... CD:. OJ m ""'.., t/"I -Z Cb @ -. :I: -t ~ Q..Vl. (tl ~ 0- ~Q :r r-..,) ::I: ~ :; f":"" --l ::I: I\) o o .P- o ~ o 'll 'll o j; r en ~ooens::eno m~On1)>IO <_C<:o)>Z mmC)m-<:O enr)>ZC)OO O~Z)>~ZO Z O. _)>r oOmenZ, c: :oO:OOf-om )>~ens::m)>:O rims::zen rcZm::;igj fl1 :o-Z 000 0 o 0 0 0 C C C C . Z Z Z Z },.s::QQQQ :::j)>rrrr OZS::S::S::S::s:: )>mmmm)> :OZC)s::s::s::s::-< mmmmmmO -<:ommmm:o :0 :0 :0 :0 f'f! r~ ~ ix QgQggD.~~~~g ~8B~S~Se~~s U1:Jl ;0 ~i ~ ~ ~ ~ om C ~~ Z Pi"" ..,.., ~~ ~ r o o )> -i 5 Z 'll r )> Z -2-- It II qi ~Ij~ . U~ -; Vi ~ ~ ~ ~ Z tr. ~ r;; "1 Vi ,-c.. ~~,~ ::.o.:t St. Paul Office 2335 W..,St Highway 35 St. P"ul, MN SSllJ Pt\cn!:<: 551-635-4600 J.L1& 8onestroo "CEI ~~~~~JTk & 1\11 Associates NEW HOPE, MINNESOTA HilLSIDE TERRACE DEVELOPMENT TITLE SHEET I~ 10 I~ -z- ifIl" il ~5 ",' =T~~~ : ~;~:- St. Paul Office 2335 WeSt Highway 36 St. P<'lul, t-1r~ 55113 Pt'.OO!;: 651-536-.1;600 + 1"'1 X I ~ J1JI ~~~:~~oo ~ AnderJik & .\h AssociatES ENS/GN A VENUE NORTH ;...:- ~. rI ~- ~'REE/"/ EEA.f~//'S NEW HOPE, MINNESOTA HILLSIDE TERRACE DEVELOPMENT LOCATJOt.J PLAU () -" o w- I I I C( T E R P"!" ---- ---~ ~.c '.7e l'"".r St. Paul Office 2335 W€:St H;{jllw<:;y 35 St_ Peul, l.iN 55!13 f'1l0n,,: 65l-536-4600 J!.JJ Bonestroo IlCJ:I R.osene ,~u, ~~~;;f~~e~ f"'J"'e",~ &. ,\:CIl,'l~"IS ~: -z- T I . II IH I III III ENSIGN A VENUE NORTH -------- -) --==-> -) -) ------- ------- , , ------ I L, """""r I ~~...)~ - "'= - ~ \ j-- l / I ~ \ ~ , ~\L~__ \> -o~ ;- - - l\rn 1 \ I) ~ L/-~~ ~~ ~- ~:;: ! ~ 7 Vi =;; rr \' -fTi- ~r If F.;:;f~ln .,..... \ -;58> f'lL,..J r r ZU1 \/ J2:- R-r"i j\ o~~ f"1 ;' \ -< -<..::;. ~ .I 82lf) f -i -i / ~ ~g:~ / "" '-...-~s:/ .~~ ~ .~; ~. - {!ff'~ I . //// 5~. /.'/,<'~''-'' I ,t(!:;>/>:~ - ~ -"Tr1f~ ~--, .-- /. I" 'f; " i i rr . "" I :", 'I , c I IT f Ii- "I _ I _ : : ! _ tCi"1 \ I ~ ~ 11"I,,iII~ II i . vj I ": I" '1 ' !! ;b j:1' II r ! I j, ,j, I" NEW HOPE, MINNESOTA HILLSIDE TERRACE DEVELOPMENT ERQSIOH CONTROL PLAN (') --' o '" ~~ ~~ ~WN ~O~O>~IZ >' ~. Z>. ~~~OZ 0 r~ (~ nIp r~,ZOO~ m~ ~ -<I ~-~ o~ o~ m~ go>r O~~~WZ~ xo ~~ z, o=:r:>>o ~~ O~ ~8~ 8~~~~; 0> ~~ ,>fg ;O::j~~~~ 77 vO ~Z~ >00 66 h~ oo~ ~zz~~~ o '-""':1 m::v!::Q .....Oi71 .Vi ~::v n -~o T~non~ ~g 0> ~zz ~>::v_~~ :>C mZ v:U1 -:nuZ:;oLn, In -(0 >>=!;::~~>~ (j~ ~~ ~~ ~~:5~= Q22S r>lo 0 :::Do c> :?~~::D CD ~;o8~r.i . ~ . ~ itj ~~66;o z >6~~S: o ::;;><oz;::: ~z z -z-. ..~c ~ I i L I 0 ;O:::V (JfT1 uS:: Ij);U 0 .\ jTj ill U) < ~s: --'in ~o 0 :::::J< ;:]'-1 o~ i ~~ )> U) I tf) I....- -:-i n'l rio , ~o :r:~ I '2)...,., ~~II", I ~ COWAJ "7: d )>fT1rr1 -- Iii I W - _ _ ENS/GN .2VENU~ NORTH ~--\ ~J-1_"":- ~ Z ~ ~ - - - >----rr'0-"~('". > _ ~ U; ) '-)-)-""'""'1.". -1--; -'_ -=- -=- -=- -=- _";'L~~" ',_ ~ ~ . ~-I .,--- I >'"~ I I I <U1~ I I I v <D AJ C'1 0 ~ > W AJI I Ie r:i U )> en rr1 ~ ~ < >- Z ).> fTl I' 02:S::.:J < :s: 1'1 rr1 -iOZS: :r:wO ~Wo- Zo ~::o I -i-i-; $:-<< -,-:"}~ :::0........>'< I I ~ 5 ~ ~ : I' ;g ~ 0; ~ :' II I '. 0 y~ U1 Ui 0-0-:..... x z'-rj~co -f :::D U ... "'~. I" ' ;0 -:::U".; O~r I I...,., <oil ,>&_- ...,.,~...,., ~ ~ x An AJ I ~~", I I~ I I -<]) I -." TO- R,!,C-'E:! 'C'ClJA4I'r '7Rc-.c-~' c R I r: R I.... R i ~ J '. '.~~"'M J : - -~ ~; > AJf1- '\'''' 'I ~, " i ....~!'I~ 'j / CC"""ull"1 'gj'" I. OAJ. I \ ~ -,;0 -oS: '""":'""Jr:1 ; "/ ~ m 0 AJIO IS:, W' I I n 00< ::r: \""0 I \ \ ~ AJ>ZXl"1 N< : 1/ 70 h Zl"1 1\- I 0 ~ t;1 I [Yi I ~ OJ - I r: ' l"1U1I;!:: L'O I '----- s::: r I ; If ;---7) ill 2-_____ If ! / $: \---\ If ~\ ~ Q) /( ~ \ N \ 1..1f I f J I \ /l ~ I '---- ___ 1 /' n \ \ / --- ___ --- ___ ) ~Ij \ '> / ------~ \ I '.\ U1 ;- _ \~ / Ir- \\ / ~ / rr- ~/ / / \ \ I \ /' \ / / \\ \ i.' / ""-, I J> ',\ '..:.J ~ ~ ,-crT. }:;:" i.' .f ~ iZ / \~\ - (r..z(>.J'<!;;~;U ':~:).J r oo..oo~r....--J" ~ J / ,-,~. \........ octC9i, r:. , .! / lJ' c~ ~oO,,~ -L~--~G "" '.. ""-.. ..- '-;-"" rf- o,-.p ~ (";...v........ GrAs ......... / 'V / -., ~";Ci:;'Trq"'i 0:<:''-' (" ('_ I - '"' ~u '" .~ ''-iT';' ~_ - - '~;::ocPi' >--Y-' 'W .~ c.~ !.- - ,_.____J) ~2:g~ .;'S"t j \. ~~.----- ~--_/~~...600'~-''..... I ~ ----:::;::::::::-- -------=--::----- -- - ~ ..~''-\ \ .::t.- ----==-- -~- ===---------:--- --- ---- -- - -~- ~ ~~ -- --- ..-- ..-- - -- _ H _---- ',... _..,_..;..,-- -.......... ~ ::::-:.-z--;:-r: =----:::-- _- ~_ __ ~H-- -.. \ "\._ ......-::::-:. ~ ~:/ ::-~'-:::-::-:~--:::':----~:Gr:'::::___" .I. 'fr';-,- j.~ ; ,/ ~.,;-::.---- ~ /----...--:.::..;----'; YI, \ ,\1 I " /~ ," ,:. ::--:~),-.;:--"":: -::::::.~~-:- /::,':?<~_" ','; ,r _:; / ~, / _ _ _ '/ r ,..-,/-:,.:c_--.::====-==--___--- j / ~v/ ~// /' <. // /() .' I X" / __ ;' /~//===--=-- --- ----- ///'~.~//;:.;:." / ~ /~>Y/>/.// ./ /' liJ I I q.! '.~.. ,,~t ~~M' . .~~~ St. Paul Office 2335 W",st Highw<::y 36 St. Paul. !'IN 55113 Phone: 651.626..;E:OO Jill Bonestroo I!CJ;I Rosene 1\11 ~~%g~J~~e~ f"""'t.'~r~ ~ ;;t{I:i:~a ~..... .......",,"" "'''' NEW HOPE, MINNESOTA HILLSIDE TERRACE DEVELOPMENT REMOVAL PL4N Ii I' I o o GJ \ rr ~',l ~\i W . i I I \ ;--z--L 1', ! I I JJ~ I ! ~, ' ! .. NORTri A VENUE ENS/e;,' <.0 .". o <.0 U o CRa:,' I I I t.l:E.l;.!....~S I I i I i L ,- I , I i 4. VJ CJ1 -l I )> < fT1 Z C fT1 Z o ;0 -l I I (f) )> Z -l )> ;0 -< (f) fT1 ::E fT1 ;0 !..l:-PiO '7'?QP y;~e~ "'?~f2 ~v.~ ~ !'~~O ~ I . ~ ,0 o R=> ::E )> -l fT1 ;0 s: )> z -- o < !"". ~ ~ > !"" ~ ~ ~ <.0 o 0 9.;S~ :t C :'.:.;9,2: 0 945.6 l.~ 945;5 9";0.1 0 9..7;/3 947;4 ~. 0 947.1 94:5;7 0 0 945,;3 945.7 - 9.;58 '"' 945.g, :'; 945;0 '"' 9';';.6 0 945,0 943.3 C 932:5 937.3 ~ 935.1 ~ 93~LO :'; 935.5 c' 93:;,0 ~ 939.5 0 0;:.. ""tl'T'lO> J'T1r- ::oC,~r- ;jr- o;;c....:r- ZUl ~r-:g:::: o~ :::B.9~' :~ i~:~ ':g~ cF:!ilFi i!~~ii~ . Q -<0' r-l_~8:~g ~t;;'g~ CJ','r'T\ ~tflo C;;;::;.c; a'~ ; ~F ~~ S~ => g~ ~~ m,< z~ 9?: ,.",... p~ Q m Q ~ '"' ~ ~i !! I!!l O::P ("}.....o -< ~~ ~ r~ 8 c~ M 5 rfi -Ea. ._i.~~~ H~ . ~ z ~ '" .....;> ~ 0-< g ~m ~ o~ F q~ B~ "Ogj ~c g:g EO ~ m ~ St. Paul Office 2335 West hignway 35 St. P"wl. 1.lt,. 55113 Fhone: 65l.5:35-..:(;00 ..JflA Sonestroo lieD Rosene 1\]1 ~~~;;l~~e~ NEW HOPE, MINNESOTA HillSIDE TERRACE DEVELOPMENT SANITARY SEWER &: WATER I/AIN-35TH AV'Et-JUE NORTH () .t:>- O ~ co r r- A. I- \ ..~ ;:yr., i ~,' , r---' I ---- 0; -~ o ~/ ~ ~ - '10'V' I 0/, )) 0./ // / ,( \ \ \ No - <D o <D o o 949;3 54E.9 94(;.5 546,2 947.5 947: S 945:7 946.1 945.7 9.;5,7 545;5 944.9 944.5 9';5,0 94.3.0 935.6 9.37:0 G"';;..c' C.:::l;.l" 930,0 924,0 ~ g L". ~ " ~ g ~ c c ~ c c c c g c g o c g ~ g~~ ~~~~ ~of:: ~Mt:W'l ~~~ ~~~ ~~~ ~~~ ii Iii g'~O ii" ~~ c Ii o 6 o o ~ g ~ I .liRt.O!r Cl:Hl."" :,...1 J.G ........,. ~"'::C.fc..J.:;..'. Cil; R!i' h...o: 1"~~f'''=.!.P !!T "'!: c.'i CI<O.~R ..r :lc'i!Cl ~"':::II;-:S'C', "',J It..l ,~.. w~r 1C!:I~Q !'ji~:~;:s.;c:a.:. ~ICo'UR ~:~:~i< ":;l.<::Fi~rt~~l:"-i-C\t:;:~~"'C\e f :;M~/;:B- ~~~?~ St. Paul Office 2335 Wo;st Higt'lwi::y 36 St. Paul, /-11, S51l3 Phone: 651-636-4600 JLJJ ~~~:~~oo ~ AnderJik & 1\J1 Associates ~"g."'<:c'n l> ;'..::;"1<:.-1:5 <D '" o NEW HOPE, MINNESOTA HILLSIDE TERRACE DEVELOPMENT STORM SEWER-35TH AVEr;UE NORTH <D m o <D en o <D .:- o <D t>I o <D N o o U1 o ....... ~~c i ~: CD " o CD OJ o "? <5 CD U o CD '" o CD o I I ~1l -~ r~/' - I ~ P;: :-Pb '" "f.'!I"U t.O ~ ";"e: ~ ~ ~~; - " "::: i.::: ~ c. " -z_. 0 g 5.;9.60 949.15 54855 0 945.20 947.85 g: 9-47.50 9.;7.15 t..,: g 9';6.79 9..6.40 g 945.00 9':;5.6; ~ 9';::.2; g 945.20 -- ENS/GN A ~=N0= ... - GJ (J1 -1_ :::r::t -- (f) -I :::0 fT1 fT1 -I ~ U :::0 o < fT1 ~ fT1 Z -I (f) ~ -IVlQ n> OC' G- ;~~ ~~ ~gB 8~ '" > ~~a ~~ ~~~ g~ g~~ ~~ Z.-oO . . g8 ~~ o ~;j~~ ~ ~~~~ ~ ~OZ ~ ~~= ~ =f;; -< ~-i ?p ,,0 ~ ~~ ~ ~~ b ,~ .~~ ~ , ' o 0 ~ ~ c ~ !lll ~~~ g:;;~ n"'r 00 gF :.~ ~~ 8g ~;, ~~ o ~ "~nn CC' ES::: j~i iii ~~~3 St. Paul Office 2335 WeS! Highw2y 35 St. Pawl, ',11-1 55!13 Phon:::: f::51-635..:;(;OO Sonestroo Rosene Anderlik & .4ssociares jlJA lCJ:1 1'01 NEW HOPE, MINNESOTA HILLSIDE TERRACE DEVELOPMENT STREET IMPROVEMENTS-35TH AVENUE NORTH () Ol o ~ T ~ ~ ~ ~ l~ " " I' - ....c E ... 1_ ~. Z ~ in II ~ i if ~ ~ ~ 1 ! ~, ~ ~ 1"'1 cv, 5 ~~ o >c lJ) 61~ " =p ; :~ " ~~ 1; COED r----,LJ ~""c . .;:Q H" " ' ;; '~1' . U~I g L: __: MJ :~~ ~~~ ~I-I - i '~ee ~g8~g g~g I, ~~" r 1 <:. c__ "_ J' C": ~ ~ I "".~'::.~", ':::,' 11 11'! 11 I.." p:::;::::l.J.i~ 'n", cCHr.. ""' """ '" t=uf1 '"1ffi m~! l~~lW if; i1 1j ! II ! , 'ilil! Hi!! !1ii' hi ! I r '" ~ il! ~~ H~~ ~~ t2~: ~ n Q ~ ... ~ ;{ -n- ,'<, 0/11 -~;r:1-:;;91 ~ I I I i:.."" :;". e:F ;~ !I;~! ! j ~ ~ "U g~ ~ ~rE ~ !~ "k'Cl. g ~~ " " =0 ~ ,;1':~;~' . dt : ill ',I 11 II I . !~i<j., 'I .~~ ~: ~ (':~" ~~,. ' ~~ H \.v,..._. W:",," :F~;~' '. I"j ?Ti~, _ ~~ :~! f=1=1JJ1i[ r ULC't m ~ I I ". ,h ;;; I ____ <::.>~ . 1- j 1/7'~ ; Ln.! ! "''':6) ~! i ~~b ~ ~ ~ ~ b~~ ~;I g a ~ ~~~ ~ g J<],i I! i I" I ,~ ! f i ~ '" I' II I r~: :f i r-]J'O'" I J ~. Su P~r I res.:,~~' 0~l !;jii!:E Ii ~'=~ I' ",~1~!.1\-~ III ! i!f~ tfi Et i, -J"I j II _"~~ 1.;~ 'I Y .gf.f ~F- .~-~ '~>v '~......"" ,~ 'i~ ,..,.",,~ I ." I'~' ~ 9 t/l )~ H~ i'i b n:;;;q ~ ~ ~ n o z Qkn a~ ~~ ~b ~~ "'" ~ . \"> "J\l rtJ::\-.....-J~ ~ ;Y'.~ ~~.-\ ~ (~ ~~ /~'iJ,; Q (// 8 r-'i31 t"t ' ;1 ~ Q,,\ f~ ~..,!~,! i ~ ~'!I ~~\,' [~I i Ln-. , . . ~ , ~~ E~ 'p g~ NEW HOPE, MINNESOTA HILLSIDE TERRACE DEVELOPMENT STANDARD DETAILS CiTY PROJECT No. E04-0 i w\ ~1~~ln ~a i!! ~ '~~i~1 . -" "'. !lI~ III il! -!. r+.r.1lo q', < !;:t~l.I:O ?-.. f~ ~f~ In"' ! ~, ,~ ~ ~~ !~llll H~~ ~~ a;;- EO. I I" I' 1+ S"l:: c~. {~ I~ a ~i b~~; I ~ '1 81 I~ '" ' ,1 . n \;,;.>-.;.!...;.. /'"'!I It" \' , I 'b:::::Y m u 11 llil - f H Hi ~~ ~ [ i I" i~~ I~ '" ~~ IS6 I~ q of> of ;:;;l.I1 I 0: _0' (b ) Him ~Im ,.t~ "., ij'~I_'I< '.- f~tW FtH e~~ . ~';i~ lIb c~ ~i jH tbJ i~ ~ "'..2 m m :;'!i ~ 'r I~ u~ ~ I-~ i3f , . .II bi~ ~r _ T7/ flI~1 ~ s:i. n ."-4'. [I J.leJ 11 I~ ...!..L- \' !1 II ..'" MA . -- F $~ . " ~e II ~~ ~: l ~r ~ g i{ '" 8 15 '" ...; o~ ~.~ . ~ .,g H ,. }1 f " " o = i~ -". ~" 0,= ~b g51 s:G ~ mm iitW 1'1' , , I rei ~ [.h ~ IJS /~\ ; :~jf ~ w~ ",0;: ~2- 1m ~ 3~ "p =s ~ Inlnlnlnjnlnlnle lDl I~ 61~1~ 6 6 61ffi ~I ,- - - - -1+ S"'i IJ~I~I!~!~I~llle ~I fjY' ~ILf.tp ~ffi~ /"'I....!m'".Ic.N_[;)cl 'I I I ~'" :"1-1' '-1"'11"'11 ~I' 1c.I'u~l~ t.-.:t...I~....;> o Oit:: 0 0 a C) -< Vl 1"""".1"'''''''1.....,,= l"I"';::;"""INC'1Z < <I <1< < m " I! IIIII ~I~ \i"'I~\iI'''''I''''I:'-rf;: 0 ~J I~I~ ln1ln LnF~' ~ II:;:" . j;i VJ ! I ~ ~ ~ I~ ~ I~ II I~ .r:;; I I' 1"1"/-1 I, ....J"''!' I -. :::E!:::E?'"J , !] 0;1 ~1 I < I r' I~ ~10j! -1;/ r -1 J If i~ ~ I;Q I" IZ fi! II llf~!l ~ ~~ ~ ~ ~ ~~ :6 ~ [;; ~f~ ~g~ ~~~ Q~g 0' f? ) \ ' .~\:. '1 '~\r<~, \" \\ \ \\ , \', ."'" \\ '~\~ !' If y,' m ,z;'~ " Q =" ~;. it it ,~. "1- ".0 ,;: r; f f",!l'"~"''"^j"''' "" ~" '" n... !l ;"'- _ 0 0 i I{ - f l' " It ' 1,ln,-=:-" f1'ji:L ,t ; j l' f ~ r"'~11 j f: ill ~ f ~""":~I'>.l 11 n o z v. ~;:n. ~~~ ~s~ ;; 6 ~~~ -t:!1Il r vr. St. Paul Office 2335 West Highway 35 St. Pilul, r~N 55113 Phone: 65!-636-";500 Fax: 651-635-1311 ;"C.:l.~~:;!,.f.""C::1<'_"'.L.':;~l, J!14 Bonestroo &:lllI Rosene 1\11 ~~~~;:~~e~ En;~"ceers & Ar'"..r.':e~..s NEW HOPE. MINNESOTA HillSIDE TERRACE DEVELOPMENT STANDARD DETAILS CITY PROJECT No. E04-0B () (Xl o N In > n I~ if; I' I'~ ~ EI"-C 1 Ie II~ J' I ~~ I_~~ 12 I; > ;:.:: I~ 14~ -I [SffI'1 '!'"'!!J:,...J . 1.:.\..{ ; "I'I"~ ! ~:; i',.ll ~ i -irl~ ! E I~ ~ 'II "- III ile. ~ il~ i 1 ~~ -ril (2 ~!~ ,I ~ ?i A~ " l~ ~ I !~ 1= Ir I n~ C I> :2[;; ~ i~ ~b ~~ o ~~ 5~ :"15,' gb sF ..~ f3 ~,~ 1 1 I ,~'. \ Qi f;: I \ \.' \ !! LJ ~ : I'll ~ '\ \ \ , \ I! il d !f -6 d ~ . = w 1~ ..;.... ;J JL_": . B'I ;!; '-l. Hi 1,:\-0.; f~; frl';':] n? ~if..\.... m ~ i )\.,'.. ;:1 . "':. ' .,. t.~""'~ -~........"r ,~."..,.: I. <<'''''''''__wer ~ [:. ,,0: - ~/~'\ I/~ I . .J i(~~' .. I" ~ ", '\ \, ";x:,y\1 ;, \~'~i ' -II :.rB ,a:; "I'l '" In I;I~ ~n ~ ~.;. ~ll I." e ~ 0_ ;:;~~ ~~~ u~ lTloq n-:::r;::' ~~(;; n c J~ ~~ ~ zz ~ g~ ,,'" ,,'" ~ St. Paul Office 2335 West Highway 35 SL f'ilul, I-Hi SS1l3 PtlO:H:: 65l-636'4600 fax: jflA 6onestroo Cl;m ~~~~~I~k & lvl Associates fn;;i"c~'n' S. """C:l,:"a.l NEW HOPE, MINNESOTA HILLSIDE TERRACE DEVELOPMENT STP.NDARD DETAILS ITY PROJECT No. E04-06 o OJ o 0l n IT ~ r~ rz ~ F '" ~ Ln r~ r.~ ~ 9 i~ ~.~~. ii.' ~ CD ).- U1 f"'1 U1 C 0; J2 ~~.~-., ,- , I 6.: .::=. I J nil ~ I r c--....m-L.; :: .~ " ~, ,- ii' g" 'I' I' ." 0 I, Ie "'-, it ! Li~f' 111 , " W N Co I~ ~ b e ~ r'~l: 1__ 4' .. I .' . . - .1 I' '" _ ~~ m'l~ ~ !. \1 'UjllD;' r I . I ~ ' i~ 1 'U "11 ~L'. . '~~ . ;~ I I "J ~ ~ . g ~ ~~ ~ ~ = ~ \ \ ) I "~ 'it- rg: %-1> '0 ?~ .." ,. .. c=: rea' ! ..!:; ~; : ~ ;;of' Ii ~ ~ ~ ;;; ~ ~ ;;; 5 f5 0 m. I""l 'i' G 1 oL ".1'\ Ii ~ " ,,'" n= f;;,~ 1 .. ,. - B ' ". ,," :;;;c; I If i~ ~~~ I. 0 s" - I' ' I : I '" , T '" ~~I ",,"""'...c"':',,=, @ ;j~~l J ~>>. 1111 11 j~l!i q q!~ ~ ~ ~ F~ f[~ ~~~ ~ c ~~~ ~~! E."OM ~~~ ~ 1,1) '" 6~ ~~ n ~~ ~! ~ i~ ~,. ~;; \\ "'!: 7f O;S 1~- ~~: '., g,. 11111'11 ~~ lIill!! ir;~ n i ~ ~8 ~ =: ~ 0 ~ ~ ~ z I ~ St. Paul Office 2335 W<::st Highway 36 Sr. Paul, !'IN 55113 Ph{,Hle: 651-635-4600 Fa:>>: J!]J Eonestroo II=- Rosene 'V12~~~;/~~e~ rn~.;~,,,~,~ ~ ""',l't,I<"':, NEW HOPE, MINNESOTA HillSIDE TERRACE DEVELOPMENT STANDARD DETAilS CITY PROJECT No. E04-05 n OJ o .j:>. COUNCIL Request for Action Originating Department Approved for Agenda Agenda Section Public Warks December 12, 2005 Consent Item No. By: Guy Jolu1son 6.7 Resolution to accept the Hillside Terrace infrastructure project and to approve the final payment request (improvement project 771) Requested Action Staff recommends that Council approve a motion to accept the Hillside Terrace infrastructure project and authorize final payment to Carl Bolander and Sons Company in the amount of $21,910.06, for the consh'uction of a city street, cul-de-sac, and necessary infrastruchlre improvements. Background Allen Chazin Homes entered into an agreement with St. Joseph's Church to purchase out lot A on the \vest edge of the church property. A plat plan that includes seven lots was proposed for the development. In order for the development to proceed, a street, cul-de-sac, and the associated infrastructure needed to be installed. The City Council authorized the preparation of plans and specifications for construction of the necessary infrastruchlre on June 14, 2004, and approved plans and specifications on June 28, 2004. Six bids were received on July 19, 2004. The lowest responsible bid for the construction of the infrastructure was from Carl Bolander & Sons Company. The engineer's construction cost estimate was $202,000 for the 35th A venue extension, the cul-de-sac, and the utilities. The city of New Hope is responsible for the installation of a trunk storm water pipe serving existing neighborhoods. The city is also responsible for a portion of the street construction costs associated with reconstruction of the existing 35th Avenue, between Ensign Avenue and out lot A, which was impacted by the trunk storm water pipe installation. The balance of the contract cost is the responsibility of the developer through an assessment agreement. Motion by \ /)-'j r '1/lLF,( f lLi.:J uS - / to I Second by To: Ii I: \RF A \ PUBWORKS\2005\ 771 Hillside Terrace Final.doc Request for Action December 12, 2005 Page 2 Funding The total construction cost for the project was $191,189.48. The city's cost for its portion of the project is $53,527.15. The balance of the project's construction costs, $137,662.33, is the responsibility of the developer through the assessment agreement. The city's portion of this project was funded through the street infrastructure fund and storm water fund. Attachments Copies of the resolution, engineer's memorandum recommending the acceptance of the project, and the final pay request are attached. I: \ RF A \ PUBWORKS\2005 \ 771 Hillside Terrace Final.doc City of New Hope Resolution No. 05- 161 Resolution to accept the Hillside Terrace infrastructure project and approve the final payment request (improvement project 771) WHEREAS, the city has entered into a contract with Carl Bolander and Sons Company for construction of the Hillside Terrace infrastructure project; and, WHEREAS, staff is recommending that the Council adopt a resolution to accept improvement project 771 and approve final payment to Carl Bolander and Sons Company in the amount of $21,910.06; and, WHEREAS, the city engineer has reported that all work has been satisfactorily completed and recommends that final payment be made to Carl Bolander and Sons Company. NOW, THEREFORE, BE IT RESOLVED, by the City Council of the city of New Hope, Hennepin County, Minnesota: 1. That the City Council accepts the Hillside Terrace infrastructure project from Carl Bolander and Sons Company. 2. That the city manager is hereby directed to authorize the final payment of $21,910.06 to Carl Bolander and Sons Company subject to submittals of the required IC-134 Forms. Adopted by the City Council of the city of New Hope, Hennepin County, Minnesota this 12th day of December, 2005. /JI~~ I Ma or l.::.. Attest: ~~ l../ City Clerk [:RF A \Pubworks \ 2005\ 771 Final Resolution n Bonestroo II:lII!III Rosene 1f\II Anderlik & . \11 Associates Engineers & Architects 2335 West Highway 36 . St. Paul, MN 55113 Office: 651-636-4600 · Fax: 651-636-1311 www.bonestroo.com December 5,2005 Mr. Guy Johnson City of New Hope Public Works 5500 International Parkway New Hope, MN 55428 Re: Hillside Terrace Infrastructure Improvements City Project No. 771 Bonestroo Project No. 000034-04162-0 Dear Guy: Enclosed fInd the signed fInal pay request and IC-134 forms for the Hillside Terrace Infrastructure Improvements project. All work involved in this project has been completed. We recommend fmal payment in the amount of$21,91O.06. The fmal contract amount is for $202,545.31. The fmal value of work completed is $191,189.48, or $11,355.83 (5.6%) less than the contract. Savings were realized due to reduced quantities required for multiple Bid Items. Some of the items that required less than esthliated quantity include 8" Gate Val've, Improved Pipe Foundation, and Silt Fence. If you have questions, please contact me at 651-604-4938. Sincerely, BONESTROO, ROSENE, ANDERLIK & ASSOCIATES, INe. ~~ Jason Quisberg enclosures a St. Paul, St. Cloud, Rochester, MN a Milwaukee, WI a Chicago, IL Affirmative Action/Equal Opportunity Employer and Employee Owned ~ Bonestroo Owner: Cit G ~~~~r~ik& For Period: 6/24/2005 to 12/2/2005 .~. Associates Contractor: Carl Bolander & Sons Com Engineers & Architects Date: December 2, 2005 Re uest No: 4 AND FINAL St., St. Paul, MN 55107 CONTRACTOR'S REQUEST FOR PAYMENT HILLSIDE TERRRACE INFRASTRUCTURE IMPROVEMENTS BRA FILE NO. 000034-04162-0 CITY PROJECT NO. 771 SUMMARY 1 Original Contract Amount $ 191,811.31 2 Change Order - Addition $ 10,734.00 3 Change Order - Deduction $ 0.00 4 Revised Contract Amount $ 202,545.31 5 Value Completed to Date $ 191,189.48 6 Material on Hand $ 0.00 7 Amount Earned $ 191,189.48 8 Less Retainage 0% $ 0.00 9 Subtotal $ 191,189.48 10 Less Amount Paid Previously $ 169,279.42 11 Liquidated damages - $ 0.00 12 AMOUNT DUE THIS REQUEST FOR PAYMENT NO. 4 AND FINAL $ 21.910.06 Recommended for Approval by: BONESTROO, ROSENE, ANDERLlK & ASSOCIATES, INC. ~~ Approved by Contractor: CARL BOLANDER & SONS COMPANY I ~ ~/ IN 1~ ///' (J Approved ~ Owner: CITY OFjH:W HOPE r ( v1 . , .; I /! I \.., /~I\ / f',/i /' /, / I I 1/ I ! ',I' / I I. / I ii L' /i / 1\ / SpecifieOContract Completion Date: August 15, 2005 Date: /J//J/OC:; / / 3404162REQ4FINAL.x1s Contract Unit Current Quantity Amount No. Item Unit Quantity Price Quantity to Date to Date PART 1 - SANITARY SEWER: 1 MOBILIZATION LS 1 8300.00 0.1 1 $8,300.00 2 TRAFFIC CONTROL LS 1 1920.00 0.1 1 $1,920.00 3 REMOVE SANITARY SEWER PIPE LF 158 12.92 158 $2,041.36 4 CORE DRILL CONNECTION TO EXISTING MANHOLE EA 1 790.00 1 $790.00 5 8" PVC SANITARY SEWER, SDR 35,0'-10' DEEP LF 55 17.35 20 $347.00 6 8" PVC SANITARY SEWER, SDR 35,10'-15' DEEP LF 275 20.85 310 $6,463.50 7 8" X 4" PVC WYE, SDR 35 EA 7 211.00 7 $1,477.00 8 4' DIAMETER SANITARY MH WITH RINGS & CASTING EA 1 1500.00 1 $1,500.00 9 4' DIAMETER SANITARY MANHOLE OVERDEPTH LF 7 147.00 7 $1,029.00 10 IMPROVED PIPE FOUNDATION, PER 6" INCREMENT LF 330 1.50 $0.00 TOTAL PART 1 - SANITARY SEWER: $23,867.86 PART 2 - WATER MAIN: 11 REMOVE DIP WATER MAIN LF 145 7.00 145 $1,015.00 12 DUCTILE IRON FITTINGS LB 800 1.30 835 $1,085.50 13 CONNECT TO EXISTING 8" WATER MAIN EA 2 441.00 2 $882.00 14 6" DIP WATER MAIN, CLASS 52 LF 8 15.60 8 $124.80 15 8" DIP WATER MAIN, CLASS 52 LF 575 19.65 575 $11,298.75 16 8" GATE VALVE AND BOX, IN PLACE EA 2 1140.00 1 $1,140.00 17 6" GATE VALVE AND BOX, IN PLACE EA 1 960.00 1 $960.00 18 INSTALL HYDRANT EA 1 1820.00 1 $1,820.00 19 IMPROVED PIPE FOUNDATION, PER 6" INCREMENT LF 583 1.50 $0.00 TOTAL PART 2 - WATER MAIN: $18,326.05 PART 3 - SERVICES: 20 4" PVC, SCH. 40 SANITARY SEWER SERVICE COMMON TRENCH LF 315 6.93 315 $2,182.95 21 1" CORPORATION STOP EA 7 110.00 7 $770.00 22 1" CURB STOP AND BOX EA 7 260.00 7 $1,820.00 23 1" TYPE "K" COPPER WATER SERVICE, COMMON TRENCH LF 305 7.00 305 $2,135.00 TOTAL PART 3 - SERVICES: $6,907.95 PART 4 - TRUNK STORM SEWER: 24 REMOVE PVC STORM SEWER LF 75 10.00 75 $750.00 25 REMOVE AND INSTALL NEW CASTING EA 1 528.00 1 $528.00 26 REMOVE CATCH BASIN EA 1 147.50 1 $147.50 27 SILT FENCE, TYPE MACHINE SLICED LF 320 5.00 $0.00 28 CONNECT TO EXISTING STORM MANHOLE EA 2 352.00 1 $352.00 29 30" RCP STORM SEWER, CLASS 3,8'-10' DEEP LF 57 52.60 57 $2,998.20 30 30" RCP STORM SEWER, CLASS 3, 0'-8' DEEP LF 503 45.30 503 $22,785.90 31 30" FLARED END SECTION, INCLUDING TRASH GUARD EA 1 1730.00 1 $1,730.00 32 CLASS III RIPRAP, PLACED AT FLARED END SECTION CY 25 40.00 $0.00 33 4.5' DIA STORM SEWER CBMH, 8' DEEP, WITH RINGS AND CSTG EA 3 1935.00 3 $5,805.00 34 5' DIA STORM SEWER CBMH, 8' DEEP, WITH RINGS AND CSTG EA 1 2268.00 1 $2,268.00 35 4.5' DIAMETER STRUCTURE OVERDEPTH LF 5 135.00 5 $675.00 36 IMPROVED PIPE FOUNDATION, PER 6" INCREMENT LF 770 1.50 $0.00 37 RECONSTRUCT INVERT EA 1 352.00 $0.00 38 SWALE EXCAVATION LS 1 2700.00 0.5 $1,350.00 TOTAL PART 4 - TRUNK STORM SEWER: $39,389.60 PART 5 - LATERAL STORM SEWER: 39 15" RCP STORM SEWER, CLASS 5, 0'-8' DEEP LF 157 20.95 157 $3,289.15 40 15" RCP STORM SEWER, CLASS 5, 8'-10' DEEP LF 25 23.90 25 $597.50 41 12" RCP STORM SEWER, CLASS 5,0'-8' DEEP LF 65 19.45 65 $1,264.25 42 YARD DRAIN, INCL. CSTG. EA 1 938.00 1 $938.00 43 RECONSTRUCT INVERT EA 1 352.00 1 $352.00 44 15" RCP FLARED END SECTION, INCL TRASH GUARD EA 1 492.00 1 $492.00 45 2' X 3' CATCH BASIN EA 1 1025.00 1 $1,025.00 TOTAL PART 5 - LATERAL STORM SEWER: $7,957.90 PART 6 - STREET IMPROVEMENTS: 46 SAWING BITUMINOUS PAVEMENT LF 95 4.10 95 $389.50 3404162REQ4FINAl.xls Contract Unit Current Quantity Amount No. Item Unit Quantity Price Quantity to Date to Date 47 REMOVE BITUMINOUS PAVEMENT SY 575 2.75 575 $1,581.25 48 REMOVE DRIVEWAY PAVEMENT SY 95 16.00 95 $1,520.00 49 REMOVE CONCRETE CURB AND GUTTER LF 335 1.80 335 $603.00 50 PROTECTION OF CATCH BASIN IN STREET EA 5 49.15 $0.00 51 COMMON EXCAVATION (CV) CY 510 5.28 510 $2,692.80 52 SELECT GRANULAR BORROW (CV) CY 690 15.25 690 $10,522.50 53 AGGREGATE BASE, CLASS 5 (CV) CY 425 27.50 425 $11,687.50 54 CONNECT DRAIN TILE TO STRUCTURE EA 4 154.00 4 $616.00 55 4" PERFORATED PVC DRAIN TILE, SCHEDULE SDR 35 LF 418 6.65 418 $2,779.70 56 TYPE LV NON-WEARING COURSE MIXTURE TN 153 45.85 122 $5,593.70 57 SODDING, LAWN TYPE SY 333 9.75 382 $3,724.50 58 TOPSOIL BORROW (CV) CY 37 50.15 108 $5,416.20 59 ADJUST MANHOLE AND CASTING EA 1 447.00 $0.00 60 ADJUST CATCH BASIN CASTING EA 3 447.00 $0.00 61 RECLAIM BITUMINOUS PAVEMENT SY 1260 1.20 630 $756.00 62 SUBGRADE PREPARATION SY 1260 1.40 1260 $1,764.00 63 TYPE LV NON-WEARING COURSE MIXTURE TN 197 44.80 182 $8,153.60 64 TYPE LV WEARING COURSE MIXTURE TN 148 50.50 233.24 233.24 $11,778.62 65 BITUMINOUS MATERIAL FOR TACK COAT GAL 50 2.00 100 100 $200.00 66 SAW AND SEAL TRANSVERSE JOINTS IN BITUMINOUS WEAR COURSE LF 340 5.00 $0.00 67 B618 CONCRETE CURB AND GUTTER LF 305 11.25 519 $5,838.75 68 D418 SURMOUNTABLE CONCRETE CURB AND GUTTER LF 485 11.25 258 $2,902.50 69 6" CONCRETE DRIVEWAY APRON SY 55 41.00 $0.00 70 TYPE LV 4 BITUMINOUS MIXTURE (B), FOR DRIVEWAY~ TN 50 92.00 33 $3,036.00 71 GEOTEXTILE FABRIC, TYPE V SY 2450 1.00 2450 $2,450.00 72 MOTOR GRADER WITH OPERATOR HR 5 110.00 $0.00 73 STREET SWEEPER WITH PICK UP BROOM WITH OPERATOR HR 5 110.00 $0.00 TOTAL PART 6 - STREET IMPROVEMENTS: $84,006.12 CHANGE ORDER NO.1 1 STRUCTURE CHANGES LS 1992.00 $1,992.00 2 STORM SEWER STRUCTURE REPLACEMENT LS 8742.00 $8,742.00 TOTAL CHANGE ORDER NO.1 $10,734.00 TOTAL PART 1 - SANITARY SEWER: TOTAL PART 2 - WATER MAIN: TOTAL PART 3 - SERVICES: TOTAL PART 4 - TRUNK STORM SEWER: TOTAL PART 5 - LATERAL STORM SEWER: TOTAL PART 6 - STREET IMPROVEMENTS: TOTAL CHANGE ORDER NO.1 TOTAL WORK COMPLETED TO DATE $23,867.86 $18,326.05 $6,907.95 $39,389.60 $7,957.90 $84,006.12 $10,734.00 $191,189.48 3404162REQ4FINAl.xls PROJECT PAYMENT STATUS OWNER CITY OF NEW HOPE CITY PROJECT NO. 771 BRA FILE NO. 000034-04162-0 CONTRACTOR CARL BOLANDER & SONS COMPANY CHANGE ORDERS No. Date Description Amount 1 6/23/2005 This Change Order provides for additions to this project. See $10,734.00 Change Order. Total Change Orders $10,734.00 PAYMENT SUMMARY No. From To Payment Retainage Completed 1 08/16/2004 12/13/04 123,341.64 6,491.67 129,833.31 2 12/14/2004 04/06/05 10,197.30 7,028.37 140,567.31 3 04/07/2005 06/23/05 35,740.48 8,909.44 178,188.86 4 AND FINAL 06/24/2005 12/02/05 21,910.06 191,189.48 Material on Hand Total Payment to Date $191,189.48 Oriainal Contract $191,811.31 Retainaqe Pay No. 4 AND FINAL Chanqe Orders $10,734.00 Total Amount Earned $191,189.48 Revised Contract $202,545.31 3404162REQ4FINAL.xls Carl Bolander & Sons Co. TRANSMITT AL No. 00047 251 Starkey Street St. Paul. MN 55107 Phone: 651-224-6299 Fax: 651-223-8197 PROJECT: Hillside Ten-ace DATE: 11/28/2005 TO: Bonestroo Rosene Anderlik & Assoc. 2335 W. Hwy 36 Roseville. l\1N 55113 REF: JOB#: CONTRACT #: Closeout Infonnation 24-2860 24-2860 ATTN: Jason Quisberg WE ARE SENDING: SUBMITTED FOR: ACTION TAKEN: 0 Shop Drawings [0 Approval 0 Approved as Submitted 0 Letter [0 Your Use 0 Approved as Noted 0 Prints 0 As Requested 0 Returned After Loan 0 Change Order tr Review and Comment n Resubmit 0 Plans 0 Submit 0 Samples SENT VIA: 0 Returned 0 Specifications [0 Anached 0 Returned fix Corrections 0 Other: 0 Separate Cover Via: 0 Due Date: ITEM NO. COPIES DATE ITEM NUMBER REV. NO. DESCRIPTION STATUS 11/28/200: Closeout Information Remarl,s: CC: Bolander Project File S;g.,d, J~t Jeff Fye F\.p;:dlllOn Bond # 104 370 252 OWNER D ARCHITECT D CONTRACTOR D SURETY ~ OTHER D CONSENT OF SURETY TO FINAL PAYMENT Conforms with the American Institute of Architects, AlA Document G707 (Name al/d address) City of New Hope 4401 Xylon Avenue N. New Hope, MN 55428 ARCHITECT'S PROJECT NO.: TO OWNER: CONTRACT FOR: PROJECT: Municipal Utility & Street Construction Hillside Terrace infrastructure lmprovemetns CONTRACT DATED: August 31 2004 (Name al/d address) In accordance with the provisions of the Contract between the Owner and the Contractor as indicated above, the (II/serrl/ame al/d address of Surer)") Travelers Casualty and Surety Company of America 3000 Riverchase Parkway Birmingham, AL 35244 , SURETY, on bond of (insert name and address a/Co/ltractor) Carl Bolander & Sons Co. 251 Starkey Street St. Paul, MN 55107 , CONTRACTOR, hereby approves of the final payment to the Contractor, and agrees that final payment to the Contractor shall not relieve the Surety of any of its obligations to (Insert name and address afOwneT:) City of New Hope 4401 Xylon Avenue N. New Hope, MN 55428 , mVNER, as set forth in said Surety's bond. IN WITNESS WHEREOF, the Surety has hereunto set its hand on this date: November 3 2005 (Insert in writing the month followed by the numeric date and year.) :tte~,: vUoJt4fi JG~ (:::.eal): U Travelers Casualty and Surety Company of America (Surely) /~ LJ f d uf7M C~ :if (Signature of au(horized represemative) Mark W. Edwards, II Attorney-in-Fact (Primed name and title) S-2134/GEEF 10/01 FRP TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA TRAVELERS CASUALTY A..rw SURETY CO:MP ANY FARMINGTON CASUALTY COMPAt.....'Y Hartford, Connecticut 06183-9062 POWER OF ATTOR.1,rEY A.ND CERTIFICATE OF AUTHORITY OF ATTORNEY(S)-IN-FACT KNOW ALL PERSONS BY THESE PRESENTS, THAT TR.A VELERS CASUALTY AJ..TD SURETY COMPA-NY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FA.R.MINGTON CASUALTY CO:MPA.NY, corporations duly organized under the laws of the State of Conne..r-ticut, and having their principal offices in tl'1.e City of Hartford, County of Hartford, State of Connecticut, (hereinafter the "Companies") hath made, constituted and appointed., and do by these presents make, constitute and appoint: Mark W. Edwards, II, Ronald B. Giadrosich, or Birmingham, Alabama, their true and lav,rful Attorney(s)-in-Fact, with full power and authority hereby conferred to sign, execute and acknowledge, at any place within the United States, the following instrument(s): . by hislher sole signature and act, any and all bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond., recognizance, or conditional undertaking and an'] and all consents incident thereto and to bind the Companies, thereby as fully and to the same extent as lithe same were signed by the duly author...zed officers of the Companies, and. all the acts of said Attorney(s)-in-Fact, pursuant to the authority herein given, are hereby ratified and confirmed.. This appointment is made under and by authority of the following Standing Resolutions of said Companies, which Resolutions are now in full force and effect: VOTED: Tnat the Chainna.,'l, the President, any Vice Chainnan, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Tre8.b-urer, any ft..ssistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact a..'1d Agents to act for and on behalf of the company al1d may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's n.ame and seal with llie Company's seal bonds, recognizances, contracts of indeninity, and ollier \vritings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her. VOl'w: Tnat the Chairman, t"1e President, any Vice Chairmfu1.., any Executive Vice President, any Se.,,-uor Vice President or any Vice President may delegate all or E..'1Y part efllie foregoing authority to one or more officers or employees of this Company, provided t.1w.t each such delegation is in writing and a copy [!"Jereof is filed in the office of the Secretary. VOTED: That any bond.., recogi:rizance, contract of indemnity, or writing obligatory in llie nature of a bond, recognizance, or conditional und..."'Ii:aking shall be valid and,bmding upon ihe Company when (a) signed by the President, any Vice Chainnan, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, t.ie Treasurer, any .A..ssistant Treasurer, the Corporate Secreta.ry or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretfu-y or Assistant Secretary, or (b) duly executed (under seal, if required) by one or more Attorneys-il'l-Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursua."1t to a written delegation of authority. This Power ai-Attorney and Certificate of Authority is signed and sealed by facsimile (mechanical or printed) under and by authority of the following Standing Resolution voted by the Boards of Directors of TRAVELERS CASU.AL TY AND SURETY COMPA1\ry OF A...l\1ERICA, TRAVELERS CASUALTY A.."N"D SURETY COMPANY and FARMINGTON CASUALTY CO:M:PAj~y, which Resolution is now in full force aud effect: VOTED: That t."le signature of-each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, E..'1Y Secretary, !lilY Assistant Secretfu-y, and the seal of the Company may be affixed by facsimile to any power of attorney or to any cerJiicate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in-Fact for pllJ.-poses only of executing and attes-'illlg bonds and undertakings and other \vritings obligatory in the nature thereot: and E..TJ.)' such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and. any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking to which it is attached.. puo8 lliJe:j.a.lOas :j.UE'fS!SS'\f uosuellOr "VI! pO)i ~W_~ ^8 JO A:BP '~ooz;" .I<:lqlll<:l.L\ON p.I( Srq-J. p:m~o: ':).mpo:muoJJo a:).B:).S 'plOJJ.mHJO 4rJ aq1. U]: 'AuuduroJ QlpJo QOmo QuroH ::nP:).13 p:r[Uas pUU p:mB!S' . 'QOlO] U]:k\.OU Q.m '4y..rotpny.]O QlEOy:p.r~;).alp U]: 4'.;.10J :).QS S"B 'SlO:).::lal"fG JO spreog Qlp JO suopnlosaa: BUWUU+S ::llI+ :).trq:). ':lIOIIllQtp.rtlJ puu ~PQ)'[OAQI UQ;:lq :).OU SEt! puu ~OIOJ IJ!lJ U]: SU~BUIal Al'f.Iotpny JO :l:;13oy:p.ra;:).pm MWOPV JO I:lAl.Od P:lt!oU+:;u puu l5UfOBdIOJ dt[l. :;Blp .l.i!ll1I3:;) AEI3:'dtIH 00: lmp.o:lUUO;) J.O ::l:).B:).S :n.p JO SUO]:+BIOdrOO y':OOlS 'ANVdJ1\IOJ A.LTVIlSVJ NO.LD-Nll'\11IVa pIre A...\.TVdWOJ X.L:1I1L.IlS UNV UTVIlSVJ S'H3:'IaA v""RJ. 'y:::mI'J[J"i\,TV ,[0 llTVdItJOJ ALmIIlS aN-V llWllSYJ 51:I;['1;!L\ YRl, JO Ln:q.:l.IJ<lS +Ire+SP,sy 'pauB]:Slapun alp. 'I aLYJliiU'd3:J +/ne8Jfal .~ apew o!lqnd fu8+0N 900e: 'OS aunr s9J!dxe UO!SS!WWOO ^VI! ~~ ~w .. Joal:llr+ suopnlosaa: EUTIJIre:).S alp rapun :logJo 1:lIIlsFlr]'o 4y..r01{lnU Aq S'UOPBlOdrOO Qq1. JO JfB1{Qq liO :;lia!l:ITI.I:).S'Uj: p]:Bs Qq1. p::l:;IDQXa at!sjQt! :;Bq1. pm :SfB::lS ::l:).BIOdrO::l t!ons a.m :;ua!l:ITI.I:).sT.I! P]:Bs ::lIp 0:; paxIDB SfB;}S' :l1:fl. :).trq:). :SUOPBIOdrOO P]:Bs ].0 SfB::lS ::lIp SA\OIDI al[sj:nr:).trq:). ::;ua!l:ITI.I:).suF QAOqB Q1:fl. PQ:;no::lx::l t!orqAl. puu u~ p~qy..rOS::lp suo-p.Blodioo ~tp. 'ANVdJ.\IOJ X.L'IVIlSYJ NO.LD-NIli\ffiV.!I pU11 x...,TVdWO;) X.LaRIlS. QNV XJ..'1VIlSV::> SR:!I'I:!fA'V&L 'YJlliID>\l-Y irO Ji..kTVdli\IOJ A.Lrn..rlSaNV X.LT'V'llSVJ S"H:!r'IUYliJ. JO +uapp;a.ra a:l!A .fOruas s]: a1{s/:lt[ :).Bt[l. :ABS puu asodap PTP 'moA\S A'[11P am Aq EUj:aq 'OtrA\. 'uAl.oIDf am 0:). NOSdJi\IORL '/tA lIf>HO:!rf> :lUrno AJ1B1Ioslad am :llOJaq tOO;:: 'ABJi\IJO ABp 1sT sj:T..p uO - ~.~Rr ^8 ~uap!saJd a::>!^ JO!uaS uosdwolU 'M aOJoaE) Ak~illWO::>XL~nsV::>NOL~Nll~~~ Ak~dJi\IO::>.&L~ Q""~ XL'IYflSY::> SR~rDIAvaL V::>ili'HJ\!V .!IO .A.NV illWO::> .iUirnTI.S ffiN .iU ~.flSYJ SR'R'IM vaL mIOiLDIVH dO A.LNtl08 plO]J.nr.d 'SS { lfl.811JR."W08 dO 2.lVlS . soar ABWJO i;:BP 'J.Sl sflP. p:lxYJB O:j.:ll:l1.J: aq 0:;' sfB;:;JS ;:;JlBIOdio:; 11:lt[l. pm fn~P!sa.Id ;};)!A .Io!uas l"f~t[l. Aq p::lffi5~s ~q 01 :;u~~ sflP. p~sn"B::> aA1TIJ: .:u...TVa:wOJ A..LTVil.SYJ N:O.L~NIli\.11IY.[. pnu XN:Ya:w:O::> .iU.aRIlS 01\.'V .i\..LTVLlSY::> S1I:H:'1UW.L 'Y::>nIIDA.TV .!IO .Ji..NVdWO::> umms U1\.TV Ji..,L'IVLls\.r::> S'H:lI:'1MW.L '.!IOIDI:trn:A\ SS3:N.LIA\ NI MINNESOTA Department of Revenue Withholding Affidavit for Contractors NrN 1 rz 1- IC-134 This affidavit must be approved by the Minnesota Department of Revenue before the state of Minnesota or any of its subdivisions can make final payment to contractors. Please type or pnnt clearly. This INil! be your mailing label for returning the completed form .... c: 'i: Q. .... o Q) Q. ~ Company name Carl Bolander & Sons Co. Address 251 Starkey Street City St. Paul Daytime phone 651-224-6299 Total contract amount S202.S45.31 Amount still due Minnesota withholding tax 10 number 8048310 Month/year work began 9/04 Month/year work ended 10/05 Zip Code 55107 State MN S2l.9l0.00 c: o ~ ......<<1 to) E Q) .... ..... 0 e.... 0..": Project number Project location 24-2860 35th Ave./Ensign Ave. New Hope, MN Project owner Address City of New Hope 4401 Xylon Avenue N. Did you have employees work on this project? ~ Yes LJ No If no. who did the work? Zip code 55428 City New Hope State MN Check the box that describes your involvement in the project and fill in all information requested. Sole contractor o Subcontractor Name of contractor who hired you Address Q) Co Z' ... o ..... () ~ ... ..... t: o U ~ Prime contractor- If you subcontracted out any work on this project, all of your subcontractors must file their own IC-134 affidavits and have them certified by the Department of Revenue before you can file your affidavit. For each subcontractor you had, fill in the information below and attach a copy of each subcontractor's certified IC-134. If you need more space, attach a separate sheet. Business Name Address Owner/Officer PO Box 448. Farmington. MN 55024 PO Box 299. Hamel. MN 55430-0299 C.R. Fischer & Sons Inc. Curt Fischer Guy Gussell OM] Corporation Q) ... Q) J:: r: OJ Ci5 I declare that all information I have filled in on this form is true and complete to the best of my knowledge and belief I authorize the Department of Revenue to disclose pertin QJ information relating to this project including sending copies of this form. to the prime contractor if I am a subcontractor, and to any :,;ubcontractors I" am aprime contractor. and to the contracting agency con(t~j;~~~~A 0C&~d)G-~~j M~o:MN Dept f Revenue. Withholding Division, Mail Station 6610, St. Paul, MN 55146-6610 Date Ii-/(, -0:)' Certificate of Compliance Based on records of the Minnesota Department of Revenue, I certify that the contractor who has signed this certificate has fulfilled all the requirements of Minnesota Statutes 290.92 and 290.97 concerning the withholding of Minnesota income tax from wages paid to employees relating to contract services with the state of Minnesota and/or its subdivisions. Date MINNESOTA. REVENUE Withholding Affidavit for Contractors This affidavit must be approved by the Minnesota Department of Revenue before the state of Minnesota or any of its subdivisions can make final payment to contractors. IC134 NO\l 1 ~ 'ltlQ5Please type or print clearly. This will be your mailing label for retuming the completed form. ~-----------------\ Company name Daytime phone I C. R. Fischer & Sons, Inc. I (651) 463-7300 I Address Total contract amount I 3240 220th Street W PO Box 448 $ 7927.00 I City State Zip Code I Amount still due ~armington _ _ _ _ MN _ _ ~502~ _ _ _..J $ 881.00 Minnesota tax ID number 1605604 Month/year work began 09/04 I Month/year work ended 10/05 Project number 24-2860 Project location 35th Ave.lEnsign Ave. New Hope, MN Address City New Hope State Zi p code Project owner City of New Hope 4401 Xylon Ave N Did you have employees work on this project? DYes DNO If no, who did the work? MN 55428 Check the box that describes your involvement in the project and fill in all information requested. D Sole contractor [2] Subcontractor Name of contractor who hired you Carl Bolander & Sons, Inc Address 251 Starkey Street St. Paul, MN 55107 D Prime contractor-If you subcontracted out any work on this project, all of your subcontractors must file their own IC134 affidavits and have them certified by the Department of Revenue before you can file your affidavit. For each subcontractor you had, fiB in the information below and attach a copy of each subcontractor's certified IC134. If you need more space, attach a separate sheet. Business name Address Owner/Officer I declare that al/ information I have fil/ed in on this form is true and complete to the best of my knowledge and belief. I authorize the Department of Revenue to disclose pertinent information relating to this proIect, including sending copies of this form, to the prime contractor if I am a subcontractor, and to any subcontractors if I am a prime contractor, and to the contracting agency. Mail to: Minnesota Revenue, Mail Station 6610, St. Paul, MN 55146-6610 1 Certificate of Compliance Based on records of the Minnesota Department of Revenue, I certify that the contractor who has signed this certificate has fulfilled all the requirements of Minnesota Statutes 290.92 and 290.97 concerning the withholding of Minnesota income tax from wages paid to employees re.lating to contract services with the state of Minnesota and/or its subdivisions. . /' ...... :,:. ,'>-::. i"'~."l'!Il'''''",!" """", ,~. DepartTT)ent'ofRevimueapPr.o"vai i'f' ....,;..c~;':""~\ Date ,......-.......' , " Stock No. 5000134 (Rev. 2/03) 11/0i/2005 MaN 13:40 F.~ i63 4i8 3295 DMJ CORP/KD & co. G1.I 003 .Page 1 or r ~ T 7005 & ~ 't!. MiNNESOTA- REVENUE Contractor's Withholding Affidavit Confirmation D [If. J CORP ID 3142780 Please keep this information for your records. Submit a copy of this page to the business that hired you to receive your final payment. Confirmatio!ll1umcer Project owner Project number Project begin date Project end date Project location Subcontractors 104623 Man Nov 07 12:32:40 CST 2005 CITY OF NEW HOPE 24-2860 December 2004 October 2005 35TH AVENUE AND ENSIGN AVENUE NEW HOPE No subcontractors listed. https:/ lwww.mndor.state.nm.us/we! aetion! confirmati onPrint 1 I 17/2005 No. 1031 (Rev. 1962) Miller-Davis Co., Minneapolis RECEIPT AND WAIVER OF MECHANICS' LIEN RIGHTS N. B. It is important that the following directions be closely followed as otherwise the receipt WILL NOT BE ACCEPTED. 1. This is a LEGAL INSTRUMENT and must be executed accordingly by officers of corporations and by partners of co-partnerships. 2. It is important that ALL the blanks be completed and that the AMOUNT PAID BE SHOWN. 3. If payment is not in full to date, so state. SHOW UNPAID BALANCE, and strike out last three lines. 4. A receipt similar to this or legal waiver of lien rights will be required for all plumbing, heating and plastering materiaL etc. 5. NO ERASURES OR AL TERA TlONS MUST BE MADE. (DATE) The undersigned acknmvledges having received pc(vment of Seven Thousand Nine Hundred Twenty Seven and OO/! 00 C\am~ ofPaYlJf; DOLLARS ($ 7,927.00 rOJ+ioJ in .fi+l+Payment of ) (Amount Paid) j;'om Carl Bolander & Sons Co. all Labor and Malel iab (Kind of \Iaterial or Labor) by the undersigned delivered orfilrllished to (or pel:formed at).. Hillside Terrace Utility and Street Imps (cbs#24-2860) (Street Address or Legal Description) muf-jOr ~'allle--reee-i'V'e-d hercby ;vmrcs alll'iglus which may have bee:? ac~--./ry' the llnders.i.g.rw.d-tQ-j"ik me-tfhc-m-f.e.&!-l-f.e:n.fi.-fl.gainst .w.id..j}Pe-mises-jor labor, ski!! 0." materialfitrl1ished to .mid premis-eY]JrtOY'7o lhe- ..dat.e-heT'COf" l-- . . C..RC'S.. ohee & Soos h 0 By .~.; V PLUMBING. HEATING ~ PLASTERING ,. U l" contractors must sign statement on I'everse hereof (TITLE) Address 11/07/2005 MaN 13:40 F.~ 763 478 3295 DMJ CORP/KD & co. [4J 002 [\0.1031 (Rev. 1962) MilIcl~Davi5 Co., Miuueapoli;, RECEIPT AND WAIVER OF MECHANICS' LIEN RIGHTS N. 13. It is important that the following directions be closely followed as otherwisc the receipt WTLL NOT BE ACCEPTED. I. This is a LEGAL iNSTRUMENT and must be executed accordingly by officer;; of corporations and by partners of co-partnerships. 2. It is important that ALL the blanks be completed and that the AMOUNT PAID BE SHOWN. 3.ifpaymem is not in full to date, so state. SHOW UNPAID BALANCE, and strike out last three lines. 4. A receipt similar to this Or legal waiver of !jen rightS will be required for all phunbing, hearing and plastering material, etc. S. NO ER...I\SURES OR ALTERATlONS MUST BE MADE. (DATE) The undersig-aed aclrnowledges having received payment 0/ Sixteen Thollsand Twenty Nine and 69/100 (Amount Paid) DOLLARS ($ 16,029.69 / from Carl Bolander & Sons Co, in full payment of .(Name orr_~Lorl . _. all Labor and Materials . '(Kind of Matenal or labor) by the undersigned delivered orfumished to (orpelformed at).. Hlllside T~lTace Utility ami Street imps (cbs#24-2860) . I .' (Sll'.~er Addrcss 0:' Legal DescriPtiOn). . andfor value receIved, hereby Walves all rzghlS whIch may have been acquired by the underSIgned to file mechanic.)" liens agai~st said premisesf()r labor, skiLL or material furnished to said premises prior to the dale hereof i DMJ C' t' . i r .orporil ()!, i I PLUMBING, HEAl1'LNG und PLASTERING contractors must sign hatem-;; 011 reverse hereof I I ! i By (TITLE) Address PL~. ~~~.:;f ~&J~.dl ~-U Dw' -.: UCO O!C~O ~.~~ .ahokJ jO~ No. 1031 (Rev. 1962) Miller-Davis Co., Minneapolis RECEIPT AND WAIVER OF MECHANICS' LIEN RIGHTS N. B. It is impOltant that the following directions be closely followed as othenvise the receipt WILL NOT BE ACCEPTED. I. This is a LEGAL INSTRUMENT and must be executed accordingly by officers of corporations and by partners of co-partnerships. 2. It is impOltant that ALL the blanks be completed and that the AMOUNT PAID BE SHOWN. 3. lfpayment is not in full to date, so state. SHOW UNPAID BALANCE, and strike out last three lines. 4. A receipt similar to this or legal waiver of lien rights \vill be required for all plumbing, heating and plastering materiaL etc. 5. NO ERASURES OR AL TERA TlONS MUST BE MADE. (DATE) The undersigned acknowledges having received payment of Two Thousand One Hundred Fifty Five and 56/ I 00 (Amount Paid) Carl Bolander & Sons Co. DOLLARS ($ 2,155.56 ) fj'om (\ame of P~,Yi"t:'.) infilll payment of all Labor and Materials (Kind of Material or Labor) by the undersigned delivered orjilrllished to (or lJelformed at).. Hillside Terrace Utility and Street Imps (cbs#24-2860) (Street Address or Legal Description) andlor value received hereby waives all rights lvhich may have been acquired by the undersigned tofile mechanics' liens against said premises for labor. skill or materialfill71ished to said premises prior to the date here (?f.' PLUMBING, MEA TING and PLASTERING contractors must sign statement on reverse hereof Ess Brothers & Sons, lnv,\ By .~ Address (TITLE) No. 1031 (Rev. (962) !\liller-Davis Co., !\Iinneapolis RECEIPT AND WAIVER OF MECHANICS' LIEN RIGHTS N. B. It is important that the following directions be closely followed as otherwise the receipt WILL NOT BE ACCEPTED. 1. This is a LEGAL INSTRUMENT and must be executed accordingly by officers of corporations and by pattners of co-partnerships. 2. It is impOltant that ALL the blanks be completed and that the AMOUNT PAID BE SHOWN. 3. lfpayment is not in full to date, so state. SHOW UNPAID BALANCE, and strike out last three lines. 4. A receipt similar to this or legal waiver oflien rights will be required for all plumbing, heating and plastering material, etc. 5. NO ERASURES OR ALTERATIONS MUST BE MADE. (DATE) The undersigned acknmvledges having received pa.vment of Eighteen Thousand Seven Hundred Forty One and 26/l 00 DOLLARS ($ 18,741.26 (Amount Paid) fi'om Carl Bolander & Sons Co. all (:\ame of I'ayor) Labor and Materials (h:ind of !\Iaterial or Labor) infztll paynzent of by the undersigned delivered Ol:fitrnished to (or pelformed at).. Hillside Terrace Utility and Street Imps (cbs#24-2860) (Street.-\ddress or Legal Description) andfor value received hereby lvaives all rights which ma.v have been acquired by the undersigned toflle nlechanics' liens against said premisesfor labor. skill or materialfitrnished to said premises prior to the date hereof NOIthern Water Works PLUMBING, HEATING and PLASTERING contractors must sign statement on reverse hereof Ev ./J ,-,11ch '-_ ,;:fD ~v hl;Z.,v,- Address (TITLE) 0/ j5 r A/& IV E; Alai >i.G i 5.!J- 'f-!-I'y No. 1031 (Rev. 1962) Miller-Davis Co., Minneapolis RECEIPT AND WAIVER OF MECHANICS' LIEN RIGHTS N. B. It is important that the follO\ving directions be closely followed as otherwise the receipt WILL NOT BE ACCEPTED. I. This is a LEGAL INSTRUMENT and must be executed accordingly by officers of corporations and by partners of co-paltnerships. 2. It is important that ALL the blanks be completed and that the AMOUNT PAID BE SHOWN. 3. lfpayment is not in full to date, so state. SHOW UNPAID BALANCE, and strike out last three lines. 4. A receipt similar to this or legal waiver of lien rights will be required for all plumbing, heating and plastering materiaL etc. 5. NO ERASURES OR ALTERATIONS MUST BE MADE. (DATE) The undersianed acknmvledaes havina receivedpa1Jment of' b b b J. F our Thousand Three Hundred Twenty Three and SO/! 00 DOLLARS ($ 4,323.50 ) (Amount Paid) (i'om Carl Bolander & Sons Co. all (Name of Pavor) Labor and Materials (Kind of Material or Labor) infitll payment of by the undersigned delivered OIjzll'llished to (or pel.lormed at).. Hillside TetTace Utility and Street Imps (cbs#24-2860) (Street Address or Legal Description) andfor value received hereby lWtlVeS all rights lvhich may have been acquired by the undersigned to fife mechanics' liens against said premises for labor. skill or materialfitrnished to said premises prior to the date hereof' Premier Services. LLC PLUMBING. HEATING and PLASTERING contractor's must sign statement on reverse hereof Bv ;;J[ Address / '-/ -3 '7 (TITLE) If c~ 5tJC / tc, 11/22/2005 1i:29 ~~1 i15 443 3i68 COUNTY MATERIAL [4] 002 11/22/2805 17-:- 2S G514:J15G5D 11/1Q(2QOS 10: 39 FAX.~65J.2233l97 C:'IRr-G---!;A1'tDSTR8~~ CARL BOh~~E~ & SONS !""ACC 82/ [12 ~UU6/. uu.. ~':rf.....D:l.yll;CO., M;,,~...pol;~ No. 11)';11 IR.v, I~\. REC'En-T AND w..uvER OF 'WCHAl"l jCS' LjJjj!i lUGA',I.'6' N. B. this lm'porCant thatthe following l1;rnccions be closely followed as ot:hej'"l.\ll~e me re; eipt WILL NOT BE ACCEPTEO. J. '11ii"s' lS' a Lc..GAL 1NSnUiYm'iu w(d-m\.l~t.'~<iI".,e""""d l1.~'J,:,,..A;"'e'y h~ officers of co''Oorarjons and by partn~s of ca-parmCr3hips. 2. It is \mpor..ant that ALL the bla.nks be oompler,c:d and that the AMOUm PA1D 'BE SHOWN. 3. Jf-paymel1t is not in fu.!l to c1lt", 66 ~tato,-SHQW UNPAID BALr...NCI?" imd~. Q.Q,!; last thr<i>e lln<~. 4. A receipt siwi1nr to t.l)is. or lcgs.l waiver of lien dg..1ts will be required fur <loll plumbing, he-sting and plastmin%: material, etc. S. 1'10 ERASUReS OR At.:reAA TIONS MU~T t:U:l MP;V:E:. .......... ,. ([l/l,'iS) from The. und.ersign.ed acknowledges having rece:tvedpa~;;mt1r.t of l'wemy Sevo:n Thousand Six Hundred Twenty and 44/1 0Ll .. "(AtUOIIDT l'~,;;) ....- , - - .,... - C:1rl Bolander & Sons Co. . . -~ '(N3~~ =it'~itY;M" . _.._._~.-- Labor and Materials " . - .. (1I:inlhfl\.L\reml.-ir 1...llo~l . ,_..,-".-.. by [he undersigned dettvered orfurnished to (Qt' pe.rformed al').. _ _ ._. -'-.-'-'- -.----- Hil~side T~l~c.:e Utm~y l'Inq Street 1m?S (c~~~~.d-~860) , u_"._ -. ,.,. DOLLARS ($ ~7,620A4 \ / infu.tl payment of all _" _._... ....___.... .... .._____- "'l - --.- ..-....... .....-. , . -- .- ----.........- (s..'1'~~f Add m, or L~l!~1 Description) andfor value received hereby waives all rights which may have been acquired by the undersigned to file mech.anics'lfem against said pr~mise.s for labor, skill or material fUrnished to said pr emfses prior to th~ date hereof coun.ty n~s fLUJYrBING, HEATING ~ PLAS-TE'R.D1'E By -- L-.-.. c:Z. , coutr:lctors UHL.~t sign statement uii n:"~i"Se he.evf Y7 I- _/73-6'1//6 ~r/<f7~ Addres{ ._ AFFIDAVIT OF MAILING HEARING NOTICE IMPROVEMENT PROJECT NO. 771 STATE OF MINNESOTA) COUNTY OF HENNEPIN) ss CITY OF NEW HOPE ) I, the undersigned being the duly qualified City Clerk of the City of New Hope, Minnesota, hereby attest and certify that: On September 19, 2005, acting on behalf of the said City, I deposited in the United States mail at New Hope, Minnesota, a copy of the attached notice of a hearing on Improvement Project No. 771, mailed first class, with postage thereon fully prepaid, addressed to the persons at the addresses appearing opposite their respective names, list attached. There is a delivery service by United States mail between the place of mailing and the places so addressed. _/J /~LU' City Clerk b .... j?t7YuL ~ I Subscribed and sworn to before me this /;Z~.Iday of My commission expires January 31,2010. 2005. b! C:2:;rZd~~ c: Notary Public Hennepin County Ii ~~~a~7f- tI UNDA C. SWEASY NmMY~oMtNNeSOTA My~~Jafl.31,.2010 Mr. Alan Chazin Alan Chazin Homes Inc. 5353 Wayzata Boulevard, Suite 602 Minneapolis, MN 55416 Seven notices listing addresses: 8800 35th Avenue North 8808 35th Avenue North 8816 35th Avenue North 8801 35th Avenue North 8809 35th Avenue North 8817 35th Avenue North 8825 35th Avenue North TO: PROPOSED ASSESSMENT: INTEREST RATE/TERM: TIME AND PLACE GENERAL NATURE OF IMPROVEMENTS: ASSESSMENT ROLL OPEN TO INSPECTION: AREA PROPOSED TO BE ASSESSED: NOTICE OF HEARING ON ASSESSMENTS FOR IMPROVEMENT PROJECT NO. 771 ALAN CHAZIN HOMES, INC. Property address: 8800 35TH Avenue North - Assessment: $24,526.93 (to be adjusted for any payments made prior to certification of assessment roll to Hennepin County). 7% Over 10 Years Notice is hereby given that the City Council of the City of New Hope, Minnesota, will meet in the City Hall at 4401 Xylon Avenue North in the City of New Hope, Minnesota, on Mondav, October 10,2005, at 7 a' clock p.m. to consider the proposed assessments for Hillside Terrace development. The general nature of the improvement is as set forth in the July 30, 2004, Hillside Terrace Petition for Public Improvement and Assessment Agreement. Basically, the scope of the project was the construction of the street/cul-de-sac on 35th Avenue North just east of Ensign Avenue North including sanitary sewer, storm sewer, residential water service and all other appurtenant works and services to complete the project. The developer/owner has agreed to pay for costs associated with installing these improvements. The City will pay the project costs associated with construction of a trunk storm water line serving the existing neighborhood. The proposed assessment roll is on file with the City Clerk and open to public inspection. The area proposed to be assessed consists of every lot, piece or parcel of land benefited by said improvement, which has been ordered made and is as follows, in the City of New Hope, Minnesota: Addresses 8800 35th Avenue North 8808 35th Avenue North 8816 35th Avenue North 8801 35th Avenue North 8809 35th Avenue North 8817 35th Avenue North 8825 35th Avenue North PIO Nos. 19-118-21-21-0061 19-118-21-21-0060 19-118-21-21-0059 19-118-21-21-0062 19-118-21-21-0063 19-118-21-21-0064 19-118-21-21-0065 CITY OF NEW HOPE 4401 Xylon Avenue North · New Hope, Mirmesota 55428-4898 . www.ci.new-hope.mn.us City Hall: 763-531-5100. Police (non-emergency): 763-531-5170" Public Works: 763-592-6777 + TDD: 763-531-5109 City Hall Fax: 763-531-5136" Police Fax: 763-531-5174 + Public Works Fax: 763-592-6776 TOTAL AMOUNT OF PROPOSED ASSESSMENT: RIGHT OF APPEAL: LIMITATION ON APPEAL: DEFERMENT OF ASSESSMENTS: SPECIFIC AMOUNT TO BE ASSESSED: INTEREST RATE ASSESSMENT INSTALLMENTS: The total amount of the proposed assessment for all property within the assessment area is $171,688.54. Pursuant to the July 30, 2004, Hillside Terrace Petition for Public Improvement and Assessment Agreement, the developer/owner of the property to be assessed has waived his rights to appeal the amount of the assessment to the district court of Hennepin County pursuant to Minnesota Statutes, Section 429.081. The developer/owner may appeal any arbitrary, unreasonable or capricious actions of the City in connection with this project to district court pursuant to Minnesota Statutes, Section 429 by serving written notice of the objection upon the Mayor or Clerk of the City within 30 days after the adoption of the assessment and filing such notice with the district court within 10 days after service upon the Mayor or Clerk. No appeal may be taken as to the amount of the assessment based on the waiver of appeal set out in the referenced Assessment Agreement. Objections to the regularity of these proceedings may be made verbally at the hearing or by written objection signed by the developer/owner and filed with the City Clerk or Mayor before or at the hearing. Objections not received at the assessment hearing in this manner as prescribed by Minnesota Statutes, Section 429.061 are waived, unless the failure to object is due to a reasonable cause. Under the provisions of Minnesota Statutes, Sections 435.193 to 435.195, the City may, at its discretion, defer the payment of assessments for any homestead property owned by a person 65 years of age or older for whom it would be a hardship to make the payments. The procedure for applying for such a deferment is set forth in New Hope Code 1.60 et. aI., a copy of which is available upon request at the office of the City Clerk. The amount to be specifically assessed against your particular lot, piece, or parcel of land is stated on the first page of this notice. This assessment may be adopted by the City Council at this hearing. If the assessment is not paid within 30 days from the adoption of the assessment roll, interest will accrue on the assessment at the rate of 7%. Unless you choose to prepay your assessment, the assessment will be certified to your real estate taxes commencing with taxes payable in 2006. The assessment will be spread in equal annual installments over 10 years bearing interest at 7%. The first installment will include interest on the total assessment from November 1, 2005, through December 31, 2006, or 14 months' interest. PAYMENT OPTIONS THIS YEAR: PAYMENT IN SUCCEEDING YEARS: 1) FULL PAYMENT - You may prepay the entire assessment to the Finance Director or Assessment Clerk of the City prior to November 15, 2005, when the assessment roll is certified to the County Auditor. To avoid paying interest, you need to prepay the assessment in full within 30 days of the adoption of the assessment. 2) PARTIAL PAYMENT - One partial payment per property will be accepted and credited to any special assessment levied against real property in the City within 30 days from the date the City Council adopts a resolution approving said special assessments. Payments must be made to the Finance Director or Assessment Clerk. The remaining unpaid balance will be certified to the County Auditor and apportioned to the property' s real estate taxes for payment per the collection procedure established in Minnesota Statute Chapter 429. In subsequent years, the principal balance remaining may be paid to the Finance Director or Assessment Clerk at any time prior to November 14 of any year. Dated: September 1 9, 2005 BY ORDER OF THE CITY COUNCIL ~PA"AcL1L , Valerie Leone, City Clerk P:\Attorney\SAS\ 1 Client Files\2 City oi New Hope\99-67711IHillside Terracel\mailed notice-Chazin- adopt special assess. doc September 19, 2005 Mr. Alan Chazin Alan Chazin Homes Inc. 5353 Wayzata Boulevard, Suite 602 Minneapolis, MN 55416 Dear Mr. Chazin: .~closed is the public hearing notice regarding the Hillside Terrace Infrastructure Improvement Project 771. The public hearing will be held on October 10, 2005. I understand one lot has already been sold and a pre-payment has been made to the city. However, in order to properly document the special assessment levy, the full final assessment amount will be certified to Hennepin County in November. Subsequently, the city will notify the County of any pre-payment(s) which will be reflected on the tax rolls. Please contact me if you have any questions. Sincerely, ~~ Valerie Leone, CMC City Clerk Enc. CITY OF NEW HOPE 4401 Xylon Avenue North + New Hope, Minnesota 55428-4898 + www.ci.new-hope.mn.us City Hall: 763-531-5100 + Police (non-emergency): 763-531-5170 + Public Works: 763-592-6777. TDD: 763-531-5109 City Hall Fax: 763-531-5136 + Police Fax: 763-531-5174. Public Works Fax: 763-592-6776 GORDON L. JENSENl CLARISSA M. KLUG GLEN A. NORTON AMY E. PAPENHAUSEN STEVEN A. SOJ'l.'DRALL ARIC T. STIE1'i'ESSEN STACY A. WOODS OF COUNSEL LORENS Q. BRYi'.'ESTAD 'Real Property Law Specialist Certified By The Minnesota State Bar Association JENSEN & SONDRALL, P.A. Attorneys At Law September 14, 2005 The New Hope-Golden Valley Sun-Post 10917 Valley View Road Eden Prairie, MN 55344 Attn: Marianne Re: Notice of Hearing Our File No. 99.67711 Dear Marianne: 8525 EDINBROOK STE. BROOKLYN PARK, MINNESOTA 55443-1968 TELEPHONE (763) 424-8811 · TELEFAX (763) 493-5193 e-mail law@jensen-sondrall.com Via Facsimile Only To (952) 392-6871 Attached please find a Notice of Hearing on Assessments for Hillside Terrace Infrastructure Improvement No. 771, the City of New Hope, for publication in the September 22, 2005 edition of the New Hope-Golden Valley Sun-Post. Please forward your affidavits of publication and statement in the usual manner. Thank you for your assistance. Sincerely, --I~~ Peri Houser Secretary to Steven A. Sondrall City of New Hope Attachment (1) cc: Valerie Leone, City Clerk, City of New Hope (wiatt.) P:\Auomey\SAS\ 1 Client Files\2 City of New Hope\99-67711(Hillside Terrace)\Sun-Post Ltr-Sending Notice of Hearing.doc NOTICE OF HEARING ON ASSESSMENTS FOR IDLLSIDE TERRACE INFRASTRUCTURE IMPROVEMENT NO. 771 Notice is hereby given that the City Council of the City of New Hope, Minnesota, will meet in the City Hall at 4401 Xylon A venue North in the City of New Hope, Minnesota, on the 10TH day of October 2005 at 7:00 o'clock p.m. to consider objections to the proposed assessments for the Hillside Terrace Infrastructure Improvement No. 771 heretofore ordered by the City Council. The general nature of the improvement is the construction of a street extension on 35th A venue North just east of Ensign A venue North with a public street/cul-de- sac and all other necessary infrastructure improvements to serve seven residential building lots being developed and platted as Lots 1-7, Block 1, Hillside Terrace. The proposed assessment roll is on file with the City Clerk and open to public inspection. The area proposed to be assessed consists of every lot, piece or parcel of land benefited by said improvement, which has been ordered made and is as follows, in the City of New Hope, Minnesota: Lots 1,2,3,4,5,6 and 7, Block 1, Hillside Terrace. 19-118-21-21-0061 8800 35th Avenue North 19-118-21-21-0060 8808 35th Avenue North 19-118-21-21-0059 8816 35th Avenue North 19-118-21-21-0062 8801 35th Avenue North 19-118-21-21-0063 8809 35th Avenue North 19-118-21-21-0064 8817 35th Avenue North 19-118-21-21-0065 8825 35th Avenue North The total amount proposed to be assessed is $171,688.54. Written or oral objections will be considered at the hearing. An owner of property to be assessed may appeal the assessment to the district court of Hennepin County pursuant to Minnesota Statutes, Section 429.081 by serving notice of the appeal upon the Mayor or Clerk of the City within 30 days after the adoption of the assessment and filing such notice with the district court within ten days after service upon the Mayor or Clerk. No appeal may be taken as to the amount of any assessment adopted by the City Council unless a written objection signed by the affected property owner is filed with the Clerk prior to the assessment hearing or presented to the presiding officer at the hearing. All objections to the assessments not received at the assessment hearing in the manner prescribed by Minnesota Statutes, Section 429.061 are waived, unless the failure to object to the assessment hearing is due to a reasonable cause. Under the provisions of Minnesota Statutes, Sections 435.193 to 435.195, the City may, at its discretion, defer the payment of assessments for any homestead property owned by a person 65 years of age or older for whom it would be a hardship to make the payments. The procedure for applying for such a deferment is set forth in New Hope Code S 1.60 et. al., a copy of which is available upon request at the office of the City Clerk. The notice of this hearing mailed to property owners contains additional information. DATED: September 14, 2005. BY ORDER OF THE CITY COUNCIL sl Valerie Leone City Clerk (Published in the New Hope-Golden Valley Sun-Post on the 22nd day of September, 2005.) P:\Attomey\SAS\l Client Filcs\2 City of New Hope\99~67711(Hillside Terrace)\public hearing notice~adoption of assessmems(Public<ltion Version).doc 2 COUNCIL REQUEST FOR ACTION Originating Department Approved for Agenda Agenda Section Community Development 10-10-05 Public Hearing Item No. By: Kirk McDonald, Director of CD By: 7 .2 Public Hearing: Resolution Relating to a Public Hearing and Adoption of Assessments for Hillside Terrace Street and Infrastructure Improvement No. 771 Requested Action This is a public hearing to consider the attached resolution establishing the special assessment for Hillside Terrace street and infrastructure improvements. The total amount of the special assessments is $171,688.54 or $24,527 per single family lot. Staff recommends that the council conduct the public hearing, close the hearing at the conclusion of any testimony and adopt the attached resolution. This action is necessary at this time to ensure the special assessment is levied against each property for the pay 2006 taxes. Policy/Past Practice The city has worked with development firms in the past to make certain improvements to the city's infrastructure and be reimbursed through the use of special assessments. Background On August 9,2004, the city entered into a development agreement with Alan Chazin Homes to construct the cul-de-sac extension and related utilities to 35th Avenue to accommodate the Hillside Terrace development. At that time, Alan Chazin Homes agreed to reimburse the city for its expenses to install the street and utilities through a special assessment that would be charged to each property. The developer agreed to pay up to $182,750.08 based on the city's contract with Bolander and Sons. The work is nearly complete with the final wear course will be installed later this month. The city engineer has estimated the final cost and it will be no greater than $171,688.54. Each property will be responsible for paying $24,527 to cover the expenses related to the extension of the city's infrastructure. Alan Chazin Homes agreed to pay the city over a 10 year period with an annual interest rate of 7%. In order to begin collecting the re-payment for each lot with the pay 2006 taxes, it is necessary for the City Council to conduct this public hearing, close the public hearing and adopt the attached resolution which was prepared by the city attorney. Alan Chazin Homes has waived its right to dispute this special assessment and city staff is pleased the costs for the project is less than what was originally anticipated. The assessment may be paid within 30 days without interest. One lot was sold to a builder and paid the assessment upon the transfer of ownership. The assessment that was paid is higher than the final cost and a minor refund will be remitted. MOTION BY TO: 5. I:\RFA \ PLANNING \ Housin \ Hillside Terrace 5 ecial Assessments.doc Request for Action Page 2 October 10, 2005 Recommendation City staff recommends the city council conduct the public hearing, close the hearing at the conclusion of the testimony and adopt the enclosed resolution. Attachments · Resolution · City Attorney Correspondence . Public Hearing Notification · City Engineer Correspondence · Development Agreement DOUGLAS J. DEBNERz GORDON L. JENSEN! GLEN A. NORTON STEVEN A. SONDRALL STACY A. WOODS OF COUNSEL LoRENS Q. BRYNESTAD i Real Prope ny Law Specialist Certified By The Minnesota State Bar Association 'Admitted in Iowa JENSEN & SONDRALL, P.A. Attorneys At Law 8525 EDINBROOK CROSSING, STE. 201 BROOKLYN PARK, MINNESOTA 55443-1968 TELEPHONE (763) 424-8811 . TELEFAX (763) 493-5193 e-mail law@jensen-sondrall.com September 13, 2005 VIA E-MAIL TO ssiders@ci.new-hope.mn.us AND BY REGULAR U.S. MAIL Shawn Siders Community Development Specialist City of New Hope 4401 Xylon Avenue North New Hope, MN 55428 Re: Resolution Adopting Assessments/ Infrastructure Improvement Project 711(Hillside Terrace) Our File No.: 99.67711 Dear Shawn: Attached is the proposed Resolution Relating to Public Hearing and Adoption of the Assessments For Hillside Terrace Street and Infrastructure Improvement No. 771 for consideration at the October 10, 2005 City Council meeting. Please attach the following documents to the resolution as exhibits: 1. Exhibit A - Hillside Terrace Petition for Public Improvements and Assessment Agreement, 2. Exhibit B - the proposed assessment roll to be prepared by the City Clerk and City Engineer. As per the Assessment Agreement, the final cost of the project will be allocated equally between the seven residential lots. The term of the assessment is for 10 years with a 7% per annum interest rate. I am also attaching the public hearing notice I will send to the paper. Val needs to mail our typical notice to the property owner which contains the additional information as indicated in the notice. Let me know when we have the final figure on project costs from the City Engineer. I will provide you with a corrected resolution incorporating this cost into the resolution. Call if you have any questions. September 13, 2005 Page 2 Very truly yours, Y- Steven A. Sondrall, City Attorney, JENSEN & SONDRALL. P .A. Enclosure(s) cc: Valerie Leone Kirk McDonald Daryl Sulander P:IAttomeylSASII Client Filesl2 City of New Hopel99.6771l(HiIlside Terrace)lltr s. siders adopting assessment.doc Memo Project Name: Hillside Terrace Infrastructure Improvements, #771 Client: New Hope File No: 000034-04162-0 To: Shawn Siders Date: Sept. 13, 2005 From: Jason Quisberg Re: Final Estimated Project Construction Costs The Hillside Terrace development project began in 2004 and substantial completion was reached the spring of 2005. All work has been completed except the installation of the final lift of bituminous pavement (wear course). The construction of storm sewer connecting the intersection of 35th and Ensign Avenues to the regional pond constructed near the development property was added and completed as part of this project. This connection was to improve existing conditions and was not necessary to satisfy drainage requirements of the development. Therefore, the City plans to take responsibility for all costs associated with these improvements. Estimates for the total project costs along with the city participation amount and the development responsibility are summarized below. Work Completed to Date Estimated Remaining Work Total Construction Costs Soft Costs (25%) Total Project Costs City Participation Development Responsibility $178,188.86 +$12,277.50 $190,466.36 +$47,616.59 $238,082.95 -$66,394.41 $171,688.54 A detailed estimate including showing all costs is available ifneeded. Please feel free to contact me if you have any questions. Jason 651-604-4938 Bonestroo, Rosene, Anderlik and Associates, Inc. www.bonestroo.com o 5t. Paul Office: 2335 West Highway 36 51. Paul, MN 55113 Phone: 651-636-4600 Fax: 651-636-1311 o Milwaukee Office: 1516 West Mequon Road Mequon, WI 53092 Phone: 262-241-4466 Fax: 262-241-4901 o Rochester Office: 112 7'h Street NE Rochester, MN 55906 Phone: 507-282-2100 Fax: 507-282-3100 o WilImar Office: 205 5th Street SW Willmar, MN 56201 Phone: 320-214-9557 Fax: 320-214-9458 o 5t. Cloud Office: 3721 23'd Street S SI. Cloud, MN 56301 Phone: 320-251-4553 Fax: 320-251-6252 o Grayslake Office: 888 East Belvidere Road Grayslake, IL 60030 Phone: 847-548-6774 Fax: 847-548-6979 September 19,2005 Mr. Alan Chazin Alan Chazin Homes Inc. 5353 Wayzata Boulevard, Suite 602 Minneapolis, MN 55416 Dear Mr. Chazin: ~nclosed is the public hearing notice regarding the Hillside Terrace Infrastructure Improvement Project 771. The public hearing Will. be held on October 10, 2005. I understand one lot has already been sold and a pre-payment has been made to the city. However, in order to properly docu.rnent the special assessment levy, the fuJl final assessment amount will be certified to Hennepin County in November. Subsequently, the city will notify the County of any pre-payment(s) which will be reflected on the tax rolls. Please contact me if you have any questions. Sincerely, ~~ Valerie Leone, CMC City Clerk Enc. CITY OF NEW HOPE 4401 Xylon Avenue North + New Hope, Minnesota 55428-4898 + WW1N. ci.new-hope.mn.us City Hall: 763-531-5100 + Police (non-emergency): 763-531-5170 + Public Works: 763-592-6777 + TDD: 763-531-5109 City Hall Fax: 763-531-5136. Police Fax: 763-531-5174 + Public Works Fax: 763-592~6776 Mr. Alan Chazin Alan Chazin Homes Inc. 5353 Wayzata Boulevard, Suite 602 Minneapolis, MN 55416 Seven notices listing addresses: 8800 35th Avenue North 8808 35th Avenue North 8816 35th Avenue North 8801 35th Avenue North 8809 35th Avenue North 8817 35th Avenue North 8825 35th Avenue North TO: PROPOSED ASSESSMENT: INTEREST RA TEITERM: TIME AND PLACE GENERAL NATURE OF IMPROVEMENTS: ASSESSMENT ROLL OPEN TO INSPECTION: AREA PROPOSED TO BE ASSESSED: ~&H' .-. . . - '.. ,. ........ . , '. ~ ' NOTICE OF HEARING ON ASSESSMENTS FOR IMPROVEMENT PROJECT NO. 771 ALAN CHAZIN HOMESr INC. Property address: 8800 35TH Avenue North - Assessment: $24r526.93 (to be adjusted for any payments made prior to certification of assessment roll to Hennepin County). 7% Over 10 Years Notice is hereby given that the City Council of the City of New Hoper Minnesotar will meet in the City Hall at 4401 Xylon Avenue North in the City of New Hope, Minnesota, on Monday, October 10,2005. at 7 0' clock p.m. to consider the proposed assessments for Hillside Terrace development. The general nature of the improvement is as set forth in the July 30, 2004, Hillside Terrace Petition for Public Improvement and Assessment Agreement. Basically, the scope of the project was the construction of the street/cul-de-sac on 35th Avenue North just east of Ensign Avenue North including sanitary sewer, storm sewer. residential water service and all other appurtenant works and services to complete the project. The developer/owner has agreed to pay for costs associated with installing these improvements. The City will pay the project costs associated with construction of a trunk storm water line serving the existing neighborhood. The proposed assessment roll is on file with the City Clerk and open to public inspection. The area proposed to be assessed consists of every lot, piece or parcel of land benefited by said improvement, which has been ordered made and is as follows, in the City of New Hope, Minnesota: Addresses 8800 35th Avenue North 8808 35th Avenue North 8816 35th Avenue North 8801 35th Avenue North 8809 35th Avenue North 8817 35th Avenue North 8825 35th Avenue North PIO Nos. 19-118-21-21-0061 19-118-21-21-0060 19-118-21-21-0059 19-118-21-21-0062 19-118-21-21-0063 1 9-11 8-21-21-0064 19-118-21-21-0065 CITY OF NEW HOPE 4401 Xylon Avenue North q New Hoper MhLnesota 55428-4898" www.ci.new-hope.mn.us City Hall: 763-531-5100. Police (non-emergency): 763-531-5170? Public Works: 763-592-6777 ~ TDD: 763-531-5109 City Hall Fax: 763-531-5136 ~ Police Fax: 763-531-5174 +- Public Works Fax: 763-592-6776' TOTAL AMOUNT OF PROPOSED ASSESSMENT: RIGHT OF APPEAL: LIMITATION ON APPEAL: DEFERMENT OF ASSESSMENTS: SPECIFIC AMOUNT TO BE ASSESSED: INTEREST RATE ASSESSMENT INSTALLMENTS: The total amount of the proposed assessment for all property within the assessment area is $171,688.54. Pursuant to the July 30, 2004, Hillside Terrace Petition for Public Improvement and Assessment Agreement, the developer/owner of the property to be assessed has waived his rights to appeal the amount of the assessment to the district court of Hennepin County pursuant to Minnesota Statutes, Section 429.081. The developer/owner may appeal any arbitrary, unreasonable or capricious actions of the City in connection with this project to district court pursuant to Minnesota Statutes, Section 429 by serving written notice of the objection upon the Mayor or Clerk of the City within 30 days after the adoption of the assessment and filing such notice with the district court within 10 days after service upon the Mayor or Clerk. No appeal may be taken as to the amount of the assessment based on the waiver of appeal set out in the referenced Assessment Agreement. Objections to the regularity of these proceedings may be made verbally at the hearing or by written objection signed by the developer/owner and filed with the City Clerk or Mayor before or at the hearing. Objections not received at the assessment hearing in this manner as prescribed by Minnesota Statutes, Section 429.061 are waived, unless the failure to object is due to a reasonable cause. Under the provisions of Minnesota Statutes, Sections 435.193 to 435.195, the City may, at its discretion, defer the payment of assessments for any homestead property owned by a person 65 years of age or older for whom it would be a hardship to make the payments. The procedure for applying for such a deferment is set forth in New Hope Code 1.60 et. aI., a copy of which is available upon request at the office of the City Clerk. The amount to be specifically assessed against your particular lot, piece, or parcel of land is stated on the first page of this notice. This assessment may be adopted by the City Council at this hearing. If the assessment is not paid within 30 days from the adoption of the assessment roll, interest will accrue on the assessment at the rate of 7%. Unless you choose to prepay your assessment, the assessment will be certified to your real estate taxes commencing with taxes payable in 2006. The assessment will be spread in equal annual installments over 10 years bearing interest at 7%. The first installment will include interest on the total assessment from November 1, 2005, through December 31, 2006, or 14 months' interest. PAYMENT OPTIONS THIS YEAR: PAYMENT IN SUCCEEDING YEARS: 1) FULL PAYMENT - You may prepay the entire assessment to the Finance Director or Assessment Clerk of the City prior to November 15, 2005, when the assessment roll is certified to the County Auditor. To avoid paying interest, you need to prepay the assessment in full within 30 days of the adoption of the assessment. 2) PARTIAL PAYMENT - One partial payment per property will be accepted and credited to any special assessment levied against real property in the City within 30 days from the date the City Council adopts a resolution approving said special assessments. Payments must be made to the Finance Director or Assessment Clerk. The remaining unpaid balance will be certified to the County Auditor and apportioned to the property' s real estate taxes for payment per the collection procedure established in Minnesota Statute Chapter 429. In subsequent years, the principal balance remaining may be paid to the Finance Director or Assessment Clerk at any time prior to November 14 of any year. Dated: September 19, 2005 BY ORDER OF THE CITY COUNCIL ;:; Ld L/ oln1L . Valerie Leone, City Clerk P:IAttorneylSASll Client Filesl2 CitY of New HopeI99-67711IHillside Terracellmailed notice-Chazin- adopt special assess.doc RESOLUTION NO. 05- 135 RESOLUTION RELATING TO PUBLIC HEARING AND ADOPTION OF ASSESSMENTS FOR IDLLSIDE TERRACE STREET AND INFRASTRUCTURE IMPROVEMENT NO. 771 WHEREAS, Alan Chazin Homes, Inc., a Minnesota corporation (hereafter Owner) and the City of New Hope, a Minnesota municipal corporation (hereafter City) entered into the Hillside Terrace Petition For Public Improvement And Assessment Agreement (hereafter Assessment Agreement) on July 30, 2004 a copy of which is attached as Exhibit A, and WHEREAS, the purpose of the Assessment Agreement was to induce the City to construct a public improvement project known as the Hillside Terrace Infrastructure Improvement No. 771 (hereafter Project). The scope ofthe Project was to extend 35th Avenue North just east of Ensign A venue North with a public street/cul-de-sac and all other necessary infrastructure improvements to serve residential property being platted and developed by Owner into seven residential building lots to be known as Lots 1-7, Block 1, Hillside Terrace, and WHEREAS, the Assessment Agreement further provides that Lots 1-7, Block 1, Hillside Terrace have been specially benefited by the construction of the Project and in consideration for the City's construction of the project the Owner agrees Lots 1-7, Block 1, Hillside Terrace shall be specially assessed $182,750.08 plus any additional costs relating to change orders increasing the Project costs proportionally allocated to Lots 1-7, Block 1, Hillside Terrace as determined by the City Engineer per Minn. Stat. Chap. 429, and WHEREAS, the City Engineer has determined the fmal costs to be assessed to Lots 1-7, Block 1, Hillside Terrace including all additional costs resulting from change orders shall be $171,688.54 and per the Assessment Agreement that said costs shall be equally allocated to the seven lots payable over a ten year period with a yearly seven per cent interest rate. The first assessment payment to be payable with the real estate taxes payable in 2006, and WHEREAS, the City Clerk, with the assistance of the City Engineer, has prepared for adoption an assessment roll for the Hillside Terrace Infrastructure Improvement No. 771, and said proposed assessment roll is attached hereto as Exhibit B and is on file with the City Clerk and open to public inspection; WHEREAS, pursuant to the Assessment Agreement, the City Clerk has caused notice of this October 10, 2005 public hearing before the New Hope City Council to consider the adoption of this special assessment to be duly published in the September 22, 2005 edition of the Sun Post newspaper and the City Clerk has further caused mailed notice of this hearing to be to be sent to the Owner of Lots 1-7, Block 1, Hillside Terrace. The City Council hereby ratifies and approves -1- this action taken by the City Clerk to notice and call for the public hearing to consider the adoption of these assessments. NOW THEREFORE, BE IT RESOLVED by the City Council of the City of New Hope, Minnesota, as follows: 1. The proposed assessments, in the total amount of $171 ,688.54, attached hereto and made a part hereof as Exhibit B are hereby accepted and per the Assessment Agreement attached as Exhibit A shall constitute the special assessments against Lots 1-7, Block 1, Hillside Terrace, and each lot is hereby found to be benefited by the proposed improvement. 2. Such assessments shall be as follows: a. The assessments shall be payable in equal annual installments extending over a period of ten (10) years, the first of said installments to be payable with general taxes for the year 2006, collectible with such taxes during the year 2006. b. To the first installment shall be added interest at the rate of seven (7%) percent per annum on the entire principal amount of the assessment from the date of this resolution until December 31 of the year in which such installment is payable. To each subsequent installment, when due there shall be added interest for one year at said rate on the unpaid principal amount of the assessment. c. The Owner of the property so assessed may at any time prior to the certification of the assessment or the first installment thereof to the County Auditor, pay the whole of the principal amount of the assessment on such property with interest accrued to the date of payment to the City Finance Director or Assessment Clerk, except that no interest shall be charged if the entire assessment is paid within 30 days from the date hereof; and such property owner may at any time prior to November 15 of any year pay to the County Auditor the entire principal amount of the assessment remaining due with interest accrued to December 31 of the year in which said payment is made. 3. The City Clerk shall forthwith transmit a certified duplicate copy of this assessment to the County Auditor to be extended on the tax list of the County. 4. If the adopted assessment differs from the proposed assessment as to any particular lot, piece or parcel of land, the Clerk shall mail to the owner a notice stating the amount of the adopted assessment. Owners must also be notified by mail of any changes adopted by the Council in interest rates or prepayment requirements from those contained in the mailed notice of the proposed assessment. -2- Adopted by the City Council this 10th day of October, 2005. Attest: ~ ~ Valerie Leone, City Clerk P:IAttomeylSASII Client Filesl2 City of New Hopel99-67711(Hillside Terrnce)IResolution relating to Pub. hrg. on Special Assess.doc -3- ~{ EXHIBIT A (of Resolution 2005-135) HILLSIDE TERRACE PETITION FOR PUBLIC Il\rIPROVEMENT AND ASSESSMENT AGREEMENT 1. Parties - The parties to this Agreement are the City of New Hope, a Minnesota municipal corporation (hereafter City) and The Church of St. Joseph, a Minnesota corporation (hereafter Fee Owner) and Alan Chazin Homes, Inc., a Minnesota corporation (hereafter Developer). 2. Purpose - The Owner and Developer, hereby request and petition the City to construct a public street/cul-de-sac and all necessary infrastructure improvements therein, including sanitary sewer, storm sewer and water main with all bituminous pavement, concrete curb and gutter, pipe, valves, fittings, residential water services, sod, topsoil restoration and all other appurtenant works and services reasonably required to complete the street/cul-de- sac and infrastructure improvements. These public improvements and project is identified as Hillside Terrace Infrastructure Improvement Project 771 (the Project) and will extend 35th Avenue North just east of Ensign Avenue North to serve property being platted by Developer with Owner' consent into seven (7) new residential lots to be known as Lots 1-7, Block 1, Hillside Terrace located in the City of New Hope, County of Hennepin, and State of Minnesota, (hereafter Property) and is now legally described as follows: (see Exhibit A attached) The purpose of this Agreement is to set out the respective cost sharing agreement between the City and Developer relating to the Project. The Project is more fully described in the Memorandum from the Bonestroo, Rosene, Anderlik & Associates, engineers for the City, dated June 23, 2004 with Engineer's Estimate attached as Et:hibit B. All work shall be done in conjunction with the Project. The Church of St. Joseph hereby warrants and represents it owns in fee 100% of the property legally described on Exhibit A. Alan Chazin Homes, Inc. hereby warrants and represents it has entered into a purchase agreement with The Church of St. Joseph to buy in fee all of the property legally described on Exhibit A and that it has submitted an application to the City to plat the property as Lots 1-7, Block 1 Hillside Terrace. Developer further acknowledges and agrees the property legally described on Exhibit A will be specially benefited from the Project and also submits this petition for the purposes set out in Minn. Stat. &429.031 subd. 3. 3, Description of Work - The public improvements described above shall be constructed according to plans and specifications prepared by the City engineers for the Project as referenced in his June 23,2004 Memorandum attached as Exhibit B. 4. Costs - The City has received bids from several contractors to construct the described public improvements per its advertisement for bids published L'l the Construction Bulletin on July 2 and 9, 2004 and in the New Hope-Golden Valley Sun Post on July 8, 1 2004. The City opened bids on July 19, 2004 and intends to award a contract to the lowest responsible bidder Carl Bolander & Sons Co. in an amount of $191,811.31. Added to the actual construction cost is an additional amount of $47,952.83 for engineering, legal and administrative costs resulting in a total public improvement cost of $239,764.14, Developer agrees to this total cost of the Project. The City agrees it is responsible for and will pay $57,014.16 of said total cost that relates to the installation of a trunk stonn water line serving the existing neighborhood. The Developer agrees that $182,750.08 of said total cost shall be assessed against the Property and is the amount of the Project attributable to installing the street/cul-de-sac, sanitary sewer, stonn sewer, residential water service and all other appurtenant works and services to complete the Project specially benefiting the Property referenced above (hereafter the Assessed Amount). This Assessed Amount is based on construction costs and engineering, legal and administrative cost for the entire Project. The Developer and the City understand and agree that change orders can affect the cost of the Project, including change orders based upon per unit costs. Change orders are generally the result of unforeseen construction circumstances or project design changes. Developer acknowledges and agrees to pay on a pro rata basis, as detennined by the New Hope City Engineer, all change order costs which increase total Project costs and the Assessed Amount under this Agreement. Developers acknowledge and agree to pay the unit costs of the project based upon the actual units used for construction of the project which may increase the actual construction costs and the Assessed Amount referenced above. 5. Special Assessment - The Developer acknowledges and agrees that the proposed construction of the Project specially benefits the Property legally described on Exhibit A. In consideration for the City's action to cause the construction of the Project at the Owners' and Developers' request, the Developer agrees that the fair market value of the Property \-vill increase in an amount equal to or greater than $182,750.08 and that it will pay the Assessed Amount by a special assessment levied against the Property pursuant to Minn.. Stat. Chapter 429 over a period of ten (10) years at an interest rate of seven (7) per cent per annum. The first installment is anticipated to be payable with real estate taxes due in 2005. The Developer expressly waives all objections to any irregularity \-vith regard to the special assessment for the Project and any claim that the Assessed Amount of $182,750.08 to be levied against the Property is excessive. The Developer further waives any and all rights to appeal the special assessment in District Court under Millll. Stat. Chapter 429 and more specifically 1W1l1l. Stat. 9429.081 or any other federal, state, or local law, rule, or regulation. Provided, however, the Developer shall retain the right to object to any arbitrary, unreasonable or capricious actions of the City in connection with the Project, other than the propriety of this project, the Developers' share in the cost thereof as set out above, or the City's right to levy an assessment therefore against the Property. 6. Indemnification - The Alan Chazin Homes, Inc. agrees to indemnifY, reimburse and hold the City harmless for all costs to make the improvements described above in the event the special assessment against the Property is held invalid and unenforceable for any reason, due to the improvements or special assessments being challenged by the 2 Owner or the owners of individual lots in the Hillside Terrace plat, or anyone claiming through the Owners or the individual lot owners. This indemnification shall include reasonable attorney's fees and costs to collect and enforce the special assessment and this Agreement. 7. Owner's Special Assessment Liabilitv. - The City agrees not to start construction of the improvements described in paragraph 2 herein until the City receives a copy of the signed deed by Owner conveying to Developer title in fee to the Property. Further, the City and Developer aclmowledge and agree the Owner shall not be responsible to the City or Developer for any of the Project Costs described in paragraph 2 herein, nor shall the Property be specially assessed for any Project Costs until and unless Owner conveys to Developer title in fee to the Property. It is anticipated by the parties hereto this conveyance will occur on or before September 1,2004. Dated: 7/3Q / ) 2004 Alan Chazin Homes, Inc. CiryofNewRope 9ft/- ~~-- CollIer Its ayor( Daniel J. onahue Its City Manager Bi~ ~~ By: ])a/JI{I./ Uor\cu7ue Its (JilL; (j//Cuia.fl_e-i-- i/ .J By: The Church of St. Joseph By: ~~tJ OV/v,-~ Its: (\Q..i.i.57"B2 ' By: Its: ST ATE OF MINNESOTA) ) S5. 3 COUNTY OF 'the- ) was acknowledged before me this 30 ~ day of , 2004 by ~~ and , the. zz. 'dv:rJ and respectively, of Alan Chazin Homes, Inc., a Minnesota corporation, on behalf of said corporation, The foregoing '7Jl~ STATE OF MINNESOTA ) / / " ) ss. COUNTY OF ~~ (/ The foregoing was acknowledged before me this Sday of J)/~ iJil) L3N~;J ~~-7L/~. ~~ Notary P~!JIL~.<..:<:..c.~...~ """. --: =' . SHARON C. SANNEL NOTARY PUBLIC. MINNESOTA My Commission Expires Jan. 31. 2005 "..: ~~/f- ,2004, by and the ----j7~1.\. Sil.::,,=: and respectively of The Church of St. Joseph, a Minnesota corporation, on behalf of said corporation. F;~~;;;l:;;;;Z;;;;;Pf;~~~~ . 'i! '.~'}.:;;:. Dp-,V1D E. K€.lRI~Ejq \~~'{~~:t;~.f.~~ . (J!J It- /) ,.7 ': v---/? t:t______ Notary Public STATEOFMINNESOTA ) ) ss. COUNTY OF HENNEPIN ) The foregoing was), acknowledged before me this C;-..J~ day of IJD (!{~[:J t , 200,0'/ by Don Collier and Daniel J. Donahue, the Mayor and City Manager/respectively, of the City of New Hope, a Minnesota municipal corporation, on behalf of said municipal corporation. ;(uW/~ Notary Public - I 4 Exhibit A Le!!al Description Outlot A, Parish Community of St Joseph, Hennepin County, Minnesota 5 & 11. Bonestroo e Rosene "1\11 AnderJik & 1'J' Associates Engineers IS. Archite<:tS 2335 \tIest Highway 36 . Sr. Paul,. MN 55J8 Office: 651-636-4600 . Fax: 651-636-1311 wV\.'W:b onesrroo.C:orr. EXHIBIT B June 23, 2004 Mr. Guy Johnson City of New Hope 5500 International Pkwy. New Hope, MN 55428 Re: Hillside Terrace Infrastructure Improvements, City Project No. 771 Approval of Plans and Specifications/Authorize Bids BRAA # 34-04-162 Dear Guy: Attached find copies of the plans for the 2004 Infrastructure Improvements project and the Advertisement for Bid. The proposed construction will include approximately 600 LF of street reconstruction, new stree~ trunk storm sewer and water main and sanitary sewer extension. The proposed infrastructure is necessary for the proposed Hillside Terrace Development. Also, a .. ili trunk storm sewer will be extended from35 Avenue and Ensign Avenue to the proposed future St. Joseph Regional Pond. This work is consistent with the City's Surface Water Management Plan and the Bassett Creek Watershed 2nd Generation Plan CIP. The current cost estimate for the entire project is $202,000 as presented in the attached estimate. Of this total cost, approximately $24,000 is the responsibility of the City relating to the trunk storm sewer. $178,000 is the responsibility of the development. The proposed schedule is as follows: Approve Plan and Sp~c/ Authorize Ad for Bid Open Bids Receive Bids and Approve Contract Begin Construction June 28, 2004 July 19 July 26 August We recommend Council approve the plans and specs at the June 28th Council meeting and authorize the advertisement for bids. The bids would be reviewed at the July 26th meeting. .'. Sincerely, BONESTROO ROSENE ANDERLIK & ASSOCIATES, INC. Vincent T. Vander Top Enclosure EXHIBIT B (of Resolution 2005-135) Report Name: Peneting Special Assessments by SA 771 S/A Number Description Hillside Terrace public improvements Prooerty ill City of New Hope Pending Special Assessments by S/A Number Printed: 10/5/2005 Page: 1 19-118-21-21-0059 19-118-21-21-0060 19-118-21-21-0061 19-118-21-21-0062 19-118-21-21-0063 19-118-21-21-0064 19-118-21-21-0065 Total Assessment Amt Closed Desc Total: $24,526.94 $24,526.94 $24,526.94 $24,526.93 $24,526.93 $24,526.93 $24,526.93 $171,688.54 CITY OF NEW HOPE HILLSIDE TERRACE SITE DEVELOPMENT AGREEMENT THIS AGREEMENT is entered into by Alan Chazin Homes, lnc, a Minnesota corporation, (~~r,einafter "D~veloper") and the City of Nevv Hope (hereinafter "City"), this L day of Hl.lG;USr ,_004. / WHEREAS, on June 14,2004, by Resolution No. 2004-118, the City Council approved Developer's preliminary plat (hereinafter the "Plat") for certain real property to be known and legally described as Lots 1-7, Block 1 Hillside Terrace located in the City of New Hope, County of Hennepin, State of Minnesota, legally described currently as follows: (see Exhibit A attached) (hereinafter "Property") to allow for the development of seven (7) single family residential building lots at the Property, and \VHEREAS, the City Council also approved Developer's site development plans for the Property as set forth in Planning Case 04-03 (hereinafter "Plans"), and WHEREAS, the approvals were granted subject to the following conditions: 1. Developer must enter into a Development Agreement v,.ith the City and provide an appropriate financial guarantee to secure the required work (amount to be determined by City Engineer and Building Official). 2. Developer must comply '"'lith the City Engineer's recommendations as set forth in his May 13 and May 26, 2004 memoranda attached hereto as Exhibits Band C. 3. Developer must obtain approval of its building plans from the City's Building Official. 4. Developer must obtain approval of its building plans from the West Metro Fire District 5. Developer shall pay the appropriate park dedication fee as required by the New Hope City Code upon final plat approval. 6. Developer must comply with the City Planner's recommendations as follows: a) retaining \vall details shall be provided to the City Engineer for revievi and approval. b) drainage easements shall be sized and configured to cover all backyard drainage swales. c) Developer shall provide adequate documentation of pemlission for right of entTY or easement to grade into adjacent 281 Independent School District property. d) Developer shall provide an inventory of vegetation to be preserved on the Property as part of the development (i.e., description of planting types and sizes), e) Developer shall provide a description of vegetation measures that will be implemented on site during construction, f) All new plantings shall be located within the plat and new spruce trees shall be six to eight feet in height, and g) Developer shall provide at least one tree, two inches in diameter, per lot. 7. In lieu of constructing an on-site st0n11 water pond, Developer shall pay a stoml water ponding fee to the City upon final plat approval (amount to be determined by the City Engineer). 8. Final plat approval shall be waived by the New Hope Planning Commission. WHEREAS, the Developer has also agreed it ",,-ill petition the City per Minll. Stat 9429.031 subd. 3 to construct a public street extension/cuI-de-sac with all necessary infrastructure utilities (sanitary sewer, stonn sewer and water main) on 35th Avenue North east of Ensign Avenue North to serve the Property's seven proposed residential lots, and \vill enter into an Assessment Agreement with the City for the construction of said public street extension/cuI-de-sac and infrastructure utilities in a form attached hereto as Exhibit D. NOW, THEREFORE, IT IS HEREBY AGREED as follows: 1. INCORPORATION OF RECITALS. The recitals above are incorporated herein by reference, specifically including the conditions of approvals. 2. THE WORK. The Work shall consist of the site improvements described in the Plans, including the Secured Work as described below, and including any anlendments to the Plans which are approved by the City Council. The Work shall be performed by the Developer to the City's satisfaction and in compliance v'Iith all applicable codes, ordinances, standards, and policies of the City. 3. THE SECURED WORK. The Secured \Vork includes all on-site exterior amenities shown on the Plans that are listed below. Item Quantity a) Site Grading b) Soil Borrow c) Erosion Control and Restoration LS LS LS $44,000.00 $5,000.00 $6.000.00 Construction Total + 50% Bond Increase Total Amount of Financial Guarantee $55,000.00 $27,000.00 $82,500.00 4. COMPLETION. The Developer agrees that the Work shall be completed in its entirety on or before the 31th day of December, 2005 (the Completion Date), except as this period of time is extended by resolution of the Council, or by the City taking no action to require completion hereunder on a timely basis. It is understood and agreed that failure of the City to promptly take action to draw upon the bond or other security to enforce this Agreement after the expiration of the time in which the Work is to be completed hereunder will not waive, estop Qr release any rights of the City and the City can take action at any time thereafter to require completion of the Work, and payment for same. Furthermore, the term of this Agreement shall be deemed to be automatically extended until such time as the City Council declares the Deve]oper in default thereunder, and the statute oflimitations shall not be deemed to commence running until the City Council has been notified in writing by the Developer that the Developer has either complied with this Agreement, or that it refuses to for any reason. ll1ese provisions shall be applicable to any person who shall give a financial guarantee to the City as required below. 5. COST OF WORK. The Developer shall pay for all costs of persons doing \'lork or furnishing skill, tools, machinery or materials, or insurance premiums or equipment or supplies and all just claims for the same, and the City shall be under no obligation to pay the Developer or any subcontractor any sum whatsoever on account thereof, ,;vhether or not the City shall have approved the subcontract or subcontractor, and the Developer and its surety shall hold the City hann]ess against any such claims, and provide the City with all necessary lien waivers. 6. DEFAULT. In the event of default by the Developer as to any of the Secured Work to be performed hereunder, the City may, at its option, perform the Secured Work and the Developer shall promptly reimburse the City for any expense incurred therein by the City, provided the Developer is first given v'lritten notice by United States Mail of the Secured Work in default and required to be done by the Developer, not less than 7 days being given thereby to the Developer to remove the default status, said notice being addressed to the Deve]oper at the address set forth below. Notice given in this marmer being sufficient as described, by agreement of the parties hereto. Notice to the Developer shall also constitute, without further action, notice to any contractor or subcontractor, whether they are approved and accepted by the City or not. In the event of emergency, as detemlined by the City Engineer, the 7 day notice requirement to the Deve]oper shall be and hereby is waived in its entirety by the Deve]oper, and the Developer shall reimburse the City for any expense so incurred by the City in the same manner as if mailed notice as described above had been given. It is understood by the parties, however, that the responsibility of the Developer is limited by strikes and force m~ieure. 7. ADMLNlSTRATlON COSTS. Developer agrees to reimburse the City for the actual costs to the City associated \.\~th Planning Case 04-03 and this Agreement. including but not ... '-' ............ limited to, engineering and al1omey's fees. Developer agrees that the financial guarantee shall not be released until all such costs have heen paid to the City. 8. HOLD HARMLESS. The Developer agrees to indemnify and hold hannless the City and its agents, employees, and representatives against any and all claims, demands, losses, damages and expenses (including attomey fees) arising out of or resulting from the Developer's negligent or intentional acts, or any violation of any safety law. regulation or code in the performance of this Agreement, without regard to any inspection or review made or not made by the City, its agents, employees, or representatives, or failure by the City, its agents, employees, or representatives to take any other prudent precaution. In the event any City employee, agent or representative shall come under the direct or indirect control of the Developer, or the City, upon the failure of the Developer to comply with any conditions oftrus Agreement. performs said conditions pursuant to the financial guarantee, the Developer shall indemnify and hold harmless the City, its employees, agents and representatives for its O\\!TI negligent or intentional acts in the performance of the Developer's required work under this Agreement. 9. COST OF ENFORCEMENT. The Developer agrees to reimburse the City for all costs incurred by the City in the enforcement of this Agreement, or any portion thereof, including court costs and reasonable engineering and attorney's fees. 10. FINANCiAL GUARANTEE. TIle Developer shall furnish the City \'Vith a financial guarantee acceptable to the City in one of the following forms: a) cash escrow; b) a perfornlance bond issued by an approved corporate surety licensed to do business in the State of Minnesota, and executed by the Developer as the principal; c) an irrevocable letter of credit; d) an automatically rene\ving certificate of deposit in Developer's name but assigned to the City; e) other financial instruments which provide equivalent assurance to the City. Said tinancial guarantee shall be fumished to the City as security to assure completion of the items of Secured Work as set forth above, and payment of the costs of administration as set forth above. The financial guarantee shall be in an amount of 150% of the cost of the Secured Work as estimated by the City Engineer. TIle financial guarantee provided shall continue in full force and effect until the landscaping guaranty is satisfied, the City Council approves and accepts all of the Secured Work undertaken, and releases the surety and/or the Developer from any further liability, and until all administrative costs are paid in fulL including payment of the park dedication and storm \vater ponding fees. The City Council may reduce the amount of the financial guarantee upon partial completion of the Secured Work, payment of all outstanding administrative costs and fees and satisfaction of the landscaping guaranty. i1 11. NOTICE. The address of Developer, for purposes of this Agreement is as follows, and any notice mailed by the City to this address shall be deemed sufficient notice under this Agreement, until notice or a change of address is given to the City in writing: Alan Chazin, President Alan Chazin Homes, Inc. 5353 Wayzala Blvd. Suite 602 Minneapolis, MN 55416 (952)546-3385 12. SEVERABILITY. If any portion, section, subsection, paragraph, sentence, clause or phrase of this Agreement is for any reason held to be invalid, such decision shall not affect the validity of the remaining pOItion of this Agreement. 13. SUCCESSION. This Agreement shall be binding upon the parties, their heirs, successors or assigns, as the case may be. 14. PARK DEDICATION FEE. The Developer specifically acknowledges that the park dedication fee required in connection with development of the Property pursuant to the Plans is in the amount of $1 0,500.00 and must be paid in full upon approval of the final plat for the Property. 15. STORM WATER PONDING FEE. The Developer specifically acknowledges that the storm water ponding fee required in connection with development of the Property pursuant to the Plans is in the amount of $30,250.00 and must be paid in full upon approval of the final plat for the Property. 16. LANDSCAPING GUARANTY. The Developer specifically acknowledges it will guaranty the life of all new plantings on the Property required by this agreement until JW1e 1, 2006. Developer 8.bTfees it will replace at its cost any required plantings that fail to survive until June 1,2006. IN VlIThTESS WHEREOF. we have hereunto set our hands and seals. ALAN CHAZIN HOMES, INC. CITY OF NEW HOPE By Its f4n ~_ (0~,y/J!J.yyf Byd egj Its M~ c -' By Olvl/f-:'I J I]onahli e I /'/' -L... . ts \.- T (..j )l."i!uilLtf2Y (/ -, I J B~jJ~d<<- Its City Manage I STATE OF MINNESOTA ) ) ss. COUNTY OF HENNEPIN ) The foregoing instrwnent was acknowledged before me this ~ day of 0.[( 4Ci.J-t , 2004, by Don Collier and Daniel J. Donahue, the Mayor and Manager, respecllvely, of the City of New Hope, a municipal corporation of the State of Minnesota, on behalf of said municipal corporation. ~.~""~~e~:er~~~....e'"'dee-~re=r~. \;;,l "N' ONE ~ ~~ '~~" VALERIEJ.lE ~ ;~) \:f~:'\:~: NOTARY PUBLIC-MiNNESOTA _ C~ ,\~~~!~.~~~~'i~S~Q~~~~::~.J2~:~!. 20JJ t'~ ~ ... <".. . , ,."] ~ 2lb/vLt i~~ Notary Public STATE OF'-rr1V'vvrt..vJ?;-[c.,... ) (;! .) ss. COUNTY OF U"t/UJ&/'I ) Otfti ,), v"",,' C;o , The foregoing instrum~nt was acknowledg.ed before me this day of ~vtA... UM~ , 2004, by U~:vv'- Ct1.U.,...... 0,r-..-' and , the !.)v.,,,,'i5 d-.&--/tX:. and'J, respectively, of Alan Chazin Homes, Inc., a Minnesota corporation, on behalf of said corporation. /.2. .' -........=xq '. ~~~~~t~;' ~ . J _VYV-lYl/ DRAFTED BY: Jensen & Sondrall, P.A. 8525 Edinbrook Crossing, #201 Brooklyn Park, MN 55443 (763) 424-8811 BARBARA J. NELSON NOTARY PUBLIC. MINNESOTA My Commission Expires Jan. 31. 2005 P:\.<\llomcy'..sA..,;;\l Oicnl Flies\:! City tlfNcw Hope'..l".'9-6711I(HiJL<cidc Tcrra::::c)\Dt.....'clo~t 0 I altcn1..;1lc due 6 Exhibit A Legal Description Outlot A, Parish Community of St Joseph, Hennepin County, Minnesota ., I COUNCIL REQUEST FOR ACTION Originating Department Approved for Agenda Agenda Section Public Works July 26,2004 ment and Plannin Item No. 8.7 B RESOLUTION AWARDING CONTRACT FOR THE CONSTRUCTION OF HILLSIDE TERRACE INFRASTRUCTURE IMPROVEMENT NO. 771 REQUESTED ACTION Staff is recommending that Council approve the resolution approving a contract between the city of New Hope and Carl Bolander and Sons Company for the construction of a city street, cul-de-sac, and necessary infrastructure improvements in the amount of $191 ,811.31. BACKGROUND Allen Chazin Homes has entered into an agreement with St. Joseph's Church to purchase the out lot A on the west edge of the church property. A plat plan that includes seven lots has been proposed for the development. In order for the development to proceed, a street, cul-de-sac, and the associated infrastructure must be installed. The City Council authorized the preparation of plans and specifications for construction of the necessary infrastructure on June 14, 2004, and approved plans and specifications on June 28,2004. Six bids were received on July 19, 2004. The lowest responsible bid for the construction of the infrastructure was from Carl Bolander & Sons Company for $191,811.31. The engineer's construction cost estimate was $202,000 for the 35th Avenue extension, the cul-de-sac, and the utilities. The city of New Hope is responsible for the installation of a trunk storm water pipe serving existing neighborhoods, at a construction cost of $26,148.70. The city is also responsible for a portion of the street construction costs, estimated at $19,462.55, that is associated with the reconstruction of the existing 35th Avenue, between Ensign Avenue and out lot A, that will be impacted by the trunk storm water pipe installation. The balance of the contract cost would be the responsibility of the developer through an assessment agreement. FUNDING Funds for the city's portion of this project are available through the Street Infrastructure Fund and Storm Water Fund. ATTACHMENTS Copies of the resolution, engineers memorandum, bid tabulation, and the proposed division of costs are attached MOTION BY (./ di-' / ' :..f ,/' , ".. f 4 jJU! U I - . . I/L--Clv SECOND BY V /1- // /1/./1 ' hL:::/J-c.$"/'L/ TO: I /0 I:RFA\Pubworks\2004\771 Award Contract