Loading...
Imp. Proj. #194 If? /tf/I :' STATE OF MINNESOTA ,- DEPARTMENT OF HEALTH /' UNIVERSITY CAMPUS MINNEAPOLIS 55440 December 8, 1967 Village Council of New Hope c/o Mrs. Betty Pouliot, Clerk Village Hall 7701 - 42nd Avenue North lvlinneapolis, ~Iinnesota Gentlemen: '\1e are enclosing a copy of our report covering an examination of plans and specifications on an elevated water tank for your village. P. cop:;r of the identified plans and specifications is also enclosed. If you have any questions in regard to the information contained in this report, please write us. Yours very truly, ~0~i .b. /1 t,/.~ '~J ",?tl.&~r, "~ #~2f ;-? v- ~ F 0 Lo\Aloodward,Director Division of Environmental Health Enclosures cc: Orr,Schelen, Ma~reron and Associates Dr. R. Williams, Health Officer ~@ ].f1J]'~I~lliSOT it DEP p.J'LrrltfR:%'JT OF Division ...'.........~.. Eil"C'lil~OrlIlle 3:1't, 0..1 H ea~l Je,h, SectioIl ..., te:r ana. (}el1.e l~al Engineeri:ng :C~.l ~~ ~~~ Pla,:ns a net S~pecifica.tio:-ns OIl an Rle1,rated \(iTa tel' V'J..L 1\1 e.&"J- hO!)e $ lJfinn.e so ta Dec61nbe:-e 7;; t ..L ..Lo P J_.al~i s SI~>e cifica/tjio:ns 1J re lJared a:r.tc~ J(, ted. ()rr SI S"C 11e1 en .t} 8,11C1 .fl1ssociates ill ErLgine ers , 110 l{~ Cl1rrie J::.~+le rll18 1) !>iinrleaIJolis, }!~~i:n.11e SO~ a% ,...., Da'J.:,e Recei"'flec1 - - - ~...,. .l 1967 File };JQ 0 Z=1515 ~iO !~ O~'l enlti e r .::':4 , jo SCC1J8 1i1"11"e a21cl~ specifi,catioIiS ~ . "I elevated. t,Y&Ia t, e r 1:,-&110: tjo ~ {1eS:Cl~lD:e a.J.1 IJ2"8 SSU.1'^'S on, tile S~l.st en:l@ Fabricatio11 deta.ils :t::'l:l :(a sllccessful bidder be StJ.bI'Hitted 1:;e1:o1"e COIlstr11ct.ioil Kias ]:lhi s <~~Q~yeln.s the ,.-..P ttlis ]:.Jrc jeet iIlsofar ~."'). :~ tk18 safet;l al1CL sa,rll. "Ca:Cjr ~~...;.. 0,0 the 7J'Ja.t e r !)u.blic COflS1J1ftl)t iOil be affe cted. alIa app_L~es 1:,0 this i10t ~tc) '\:.11'8 e l} t, l1(~:6 S:V"S tenl other .rJar~t tl1ereo.f 0 L;i~ 0 50 ~ff() .C.d, i:,.i.o 11. .~;! ~ al~l(l A1.'ellUe l\,Ior 4(.,h .$ elev8:.ted steel tal1k 70 CONS TRUC:rr OJ] SElUL PLACE RJ(CEPI.r jJ:8 ,*4.CCORDPJ~ C E TBF~ P~PPR,OTV~,D PIJtl\~S PJ\[D SPEGI1'11ICATIO:DJS. 0 If it is d.esired. to rna.1:s:e cieviatio:n.s 1.1-- or11 1:, l:} e s~pecifica,tio:n.s , tIle State DepartrfLent or Health 5h.o;J 1 d COlnStLLted ~ the CD.an,ges obtained b.efore constru..ction is ('-} 'T I .t .. otherlsdse, SUCll co:t1st:-cuction, is in. at/all ed "-"fa tho 1],"(;, alJproval s'c,Citr"C6Cl ; !)l~ol)er M<:t-J. .l tiol1 c:ceate "CO lPulilic J:1ealth.o E...;qo e 11fii t. u..re s ofptlb'lic ~~..... n. -r~ .al~.e 11.e -L~c:t to be illegal 0 Co 1'1cliJLSic,):n SIJe ci:fi ca't:,io11S t~11 tl1is l:';Toje.ct ill F{ erier';s.l f}f t,lTe f'dIi rille sot, a Dep artrnerrc. r~ Fieal"C,h al10. aJ.~ e r e 'COilllItei1.d ed or t:ts~~TLal reserva~ti()]1S as stated o:n .J(,~he a~~ tach.ad sheet anti llelat:~i "'"a tn p 1~11~1 v ~~~~/?/'7_,P:;? Eo Ao O'd de :' wt,c~..,V~J-~>U4o/~^G ~A~ssocia..~te Ptlblic 1~1 eal ~t ~h t.."../ .... " .. .;;.,,'" .......-... )' j' ,/ ;<..; I/"v' V ~ P~tll a J 0 l"Ftl>fforl ~ Chief SectioTn of' ,:J~\Ja. tel' SllPI:ly ~jlINNESOTA DEPARTlvlE1\JT OF HEALTH Divi~ion of EnviroP~ental Health InformAtion Relativ~ to Plan Examination The examination of plans and specifications for water supply, sewerage and plumbing systems is made to provide information concerning the sanitary features of projects presented for consideration in accord- ance with Regulations 10873 and 10904 of the State Board of Health, The approval of such plans is given upon the supposition that the survey and other data on which the design is based are correct, and that neces- sary legal authority has been obtained to construct the project. The responsibility for the design of structural features and the efficiency of equipment must be taken by the engineer or architect who designs the project. liJater supply plans are examined 11ith regard to the location, con- struction and operational features of the design and maintenance of all parts of the system which may affect the safety and sanitary quality of the water. Examination is based on the standards contained in the Manual of Water Supply Sanitation. Plans of sewage disposal systems considered by this Department are limited to those systems that can utilize soil absorption. They are examined with regard to the features of design which concern location, construction, operation and maintenance of the system and which may affect the public health. The examination is based upon the bulletins entitled, "Tentative Standards for Design of Small Sewage \\Torks, If July 1962, and the recommended "Ordinance and Code Regulating Individual Sewage Disposal Systems, 'I 1962. Plans on plumbing systems are examined only insofar as the provisions of the l~Ii:rLflesota Plumbing Code apply.. The State Board of Health reserves the right to withdraw its approval of plans if construction of the project is not undertaken ~"ithin a period of tvlO years. The fact that plans have been approved by the State Board of Health does not necessarily mean that recommendations for alterations or additions may not be offered at some later time when changed conditions or advanced knowledge make improvements necessary. !\i ,..1 \/ ,,-\ :; ~ Q 67 I ~ L} \, :~. l~: 1.:J , l\: ' , I::;j r (11: U EALT H "I C.'i. iJ;_1 t. d; n DiV. OF Ef'~V. HEALTH :y \ :\ j~ The U nd e l~S .:1..g11G d fltl~.'tlle r p !"\oposes ""GO execute "t~he COr1t1:~act Agreec= '"'t~ meilt; a11d to fUl~!1ish satisf',actol~~Y carla YJi i ~t. hi n "~en f'10' da,~js a,f;fter~ \ ~~, ) not~ice -~ "the a7J1Ei:t"";e ~ _':'I CO!1~G rac t~ llEtS been ree ei v"ed 0 jl'jr~ ,0 Undei~s igk1.ed u...~ UJ.. ~...,o:._ fltl~t11er~ proposes ~GO begin t~ork O$S specified, .to cODlplete th's ~~lork 01" or before date speci:fied !J and 1;0 maintain aJt; all t i ~!les a~ C011tl~8<!Ct; ,,""q Borld $' approved by ~tl1e ,?\T ill $.,g e. , :Ln an amO~ln t~ equal to ",~ l"'Q t 01;, al bidQ V.&~>;"I f:.~" AcCOmpal.lying t11is p~opo8aJ~ 1~ tIle Bid See U l"it y reauij~ed --GO be dO _t:..o< furn:tshe.d oy tr16 COll"";; l'1e~:c ~c DOCUJllen"'GS !) tile s ~Xlle bein,g stlbjec"t to fo;~"feit U..l~e :1.11 event o.~ det au. 1 t b~l .f-h - lJ!1.der.s iglleoo ~ " J.. u__t 6,~ ~ Bubrni ttirlg .this 1):r"oposa2, it is u.ndeI~stood .!chat trls right is re.ser.'l'ed by the 01ri11 erJ to l~ejec "t a~ny a/i~r1 a.,J~l p 2~OpOS s.J,ls "'t.o "'''''''''''' .~\j a~ ve i tlforlllEtl.j... ?t; iea 0 1'7' lJl stlbxni t~JGj_ilg i;his oc{jh e Urloersigl1,s'd ac }:;:nOif le'dges { w J; l~e (~.6:t, P 1:; of A.odentla D t~o .JG11e DOCUf!1,el1~€S 0- ==-=-====-===='=-~==-====' - ~.~~~~~ .f..l Vo pas,ala per~iod 90 P> j~ f;; s~te4~Ge '? ~ . "--"~.~""."~~ - - .~ ~_ ~~~",="~~~~~~,~-i:"~~~~~~~~,______ ,y__~';:"'~~~""",~~~~.~~y ~""'~'__"..Y~ .,,~~~~i~~:'~~.='~~^,..~ ~..........._. ~~~~~ a, j i1911ie s 0 ~~~...., ,~,.....----~..,;.,I'~~~~-~~~~~~~,:,:<..", ~ .~ ,- ...~' _.~ .~,y"', ~~~~~. --.-.:-.-.-': :~y'" --.....-- ,~-~~:::;;:..~~~~ ~~~~~..w"~.0'f~~~~~~~~~~~~~ ,~........:J ~, ,~ ~~-.,..~ ..... - -'" ~~~~.,. I\IsJne -.......y.........:~~~~-#tl;~"'.......__. _,~~.:-~ ~,_ '_....r~ ~- . . - ,- ~ ~ ......- ~~~~~ ~.~~~~,~ - ~, -+:_,~ ~._._.. ..~-----~~ ..N __ _~~. . .___~ ~ " '........-- ' ~.....r -~.......'~~ tle ~~ -, " ~~-~~ ~~~~..IId'.....~ ...~,~.-w N' _, , ~~~~ DEtte: ~tle .C=-~~~~=-~.... -~~~ =', - -' - - - ~,~~~~~-~~ <==> 3 """" ~ ~~ .....,J ~1~~~D~~~ ADDENDiJI\:! NO" czo"" DEe 6 ~-..:.._._...:.~._..~.~ ~. '~._..<:"..: .~.__ .... >;r_ 1967 ~ro MINN. DEPT. OF HEAL TH C OfifTRA c'lr DOCilJr/iElfrS DIV. OF ENV. HEALTH ?... >r.;:- .~.... ~~ FOR ~o 5, fJ!!l~L5ro!~~I~~!=:O!EL~V ATED It!ii/fER TFlrr:t{~ AIlD l~PPURTENi\N'T \~rORK .~ - .... c \'\1 8,,~C er 2,., , s~te.el. A-P cons ..true ':c1 on VJ.. sUl;>ported l~ise:r~ I) Page 1 of 3 :~ 0 """" '"' " :;;;' 1: , f I ! I i t SOIL ENGINEERING SERVICES" INC~ 615 NORTH COUNTY RD. 18 MINNEAPOLIS, lv/INN. 55427 · 544-2739 ~ - ---------- --------- ---- J. S. BRAUN. P.E. ,-,h.:tober 18, 1967 ~ , It" Orr-Schelen-Mayeron & j\s S oc i ate s ~, ( eI 1104 Cllrrie Avenue Jv1inne ap 0 1 is; fvlinnesota 55404 i\.ttn: Ivi T .~ n .Jill. .. 1\1ittelsteadt s P~Ec Do Re: 67-27 SOIL BORINGS Elevated \Vater ft.l. -'1 e N 0 Gentlerrien: Pel" YOLIT" request t \tJO soil borings have been taken on the a.bove referenced site n oTcler to e\Tal Lla te foundation conditions fa r the proposed~ 1 c 5 mil ion gallon elevated water tanko TIle center of the tank had been staked and you then requested tviO 'hO-ril1crS on a 45-foot radius 0 The bor ings f~lere then taken at the ~ A :: ~ ~ ~"\ M" described on tIle attached soil boring log sheet. Surfa..ce J.. 0 Ca. .~ 1..0 ;u. s ele1lation.s \vere referenced to tIle centerline of County Road 18 due ipIeS t of the center of tile tank;; vl}li eh "\vas o..ssumedas eleilation lOO1JO, The borings \tJ"ere taken, on October 1 '"7 and 1 8, with a truck-mounted ........ j core and auger drill equipped -viith hollo-v'J-stemaugers.(t 0 Sanlples ii/ere obtained with the standard 2-incf1 OD split samplerj dri v-en by. a 140- pound hammer falling 30-inches, thru the hollow-stem augers~ B 1 01'lS per foot of penetration (BPF) l/'le re recorded; The hollow-stem augers then eliminated the driving of casing and the use of jetting \~later, lYfineral soils encountered in. the boring were visually classified In accordance with the U.So Bu"reau of Chemistry' and Soils Classification S)TstemC! _A copy of that chart 15 at tacl1ed ~ Some soil samples 'viII be retained in this office for a period of 60 clays to be available for exaluina t ion 0 OUR LETTERS AND REPORTS ARE FOR THE EXCLUSIVE USE Of THE CLIENT TO WHOM THEY ARE ADDRESSED. AND THEIR COMMUN1CAT!ON TO ANY OTHERS. OR PUBLICATION OF STATEMENTS, CONCLUSIONS, OR EXTRACTS FROM OR REGARDING OUR REPORTS IS RESERVED. PENDING OUR VVRITTEN APPROVAL. SO R I N G S · TES T S · j N S P E CT ION 0 A N A L Y S IS. R E PO R TS · R E COM f\~ END A T ION S 67-277 OrT~Schelen-Mayeron & Assoc. -2- 10/18/67 Immediately after completion of the final boring, both of the borings \-vere probed to check for the presence of ground water, RESULTS Logs of soils encountered and penetration resistances are plotted on the attached soil boring log sheetc Boring ST-l encountered a fine to medium sand between the 44 and 50- foot termination depths, Boring ST-2 encountered a fine loamy sand with a little fine gravel between the 19 and 34-foot depths, and a medium sand with a little fine gravel between the 34 and 50-foot termination deptho Above these materials, generally cohesive soils were encountered. These cohesive materials included clay loams~ sandy clay loarns, al1d sandy loams ranging from non plastic to plastic~ All of the materials encountered thruout these borings were brown in COIOT; Penetration resistances recorded in the two borings were a minimum of 16 BPF, and ranged upward to 62 BPFo Water was not encountered in probing either boring ST-l or ST-2 to the 35 and 23-foot depths respectivelYll Both borings had caved-in at that levelo Judging from the moisture content of the samples obtained from the borings, water would probably be expected at about ele'\lation 6Son the assumed datum. RECOldl~El/DAT IOlvS We understand that a IDS million gallon elevated water tank is to be built at this site and footings will be on the order of 6 feet below gradeo Based on the Tesults of these two borings, it appears that footings could be designed for an allowable soil pressure or 5000 pounds per square foot and the resulting safety factor would be above the normal 3 0 0 0 Based upon the results of probing of these two borings, it does not appear that ground water difficulties will be encountered. If we can be of further assistance, kindly contact us at your convenience~ ~ Very tr~ly yours, ~ CJ ~_~~~RING SERVICES, INC. ;< ., ~vAA.A ~... .'? ~.....'i<~. ~, ~Uil, fl.E. JSB/DLG:mlk ~lS Engineer Enclosures SOIL ENGINEERING SERVICES, JfJC- - I -'_ ;:p- ----== =====~:-_====:===:::: SOIL ENGINEERING SERVICES, INC. LOG OF TE S TS 0 RI N G S -=---.~::---::.==:::l=~:'--==~-,--- 6 7 - 2 7 7 = "--=~::~_-==:~~-_-:==~ PRO J E C T : E 1 e y ate d \V ate r T An k ~OCAjION: E of Co Rd 18 @ 29th Ave No Ne\4 Hope, fv1innesota VERT f CAL SCALE: 1" ::: 6' .~ , S T - 1 II S T - 2 45' radius @ 2250 Azimuth I 45' radius @ 450 Azimuth jE P T H 'IBPF I OE P T M -. BPF o Surface Elevat~on = 105. 6*. .1 0' Surface Elevation = 100. 9*1 Sandy Loam, slIghtly plastIc I Clay Loam to Sandy Clay Loaml t? plastic, \-vith a little I". brown, .. ~ I FIne Gravel, . moist I b r~wn , . ~ (ve ry~ 5 t iff) ..L mOIst 51 I UJl (very s t iff) I II 8' 36 1~8 an y Clay Loam to Clay Loam, L I f3 .with a little Fine Gravel, '391 G.o.. I b -.1. own. ,Iii mo i s tl 12 t . '_ .'1 (very stiff) 32. '.1 ..1. Sandy Loam, non plastic to 1.~~6 .., ,I I ~ ~ i gh t 1 y . P 1 as tic, wit h a ~ .1. .Ai I 11 ttle FIne Gravel'I-U I b r 0 \\7 n , , I Jj moist I o , ~ I 1 0 . . .- (v e Y)' S t iff) ISandy Loam, SlIghtly plastlc,_ I 19' I' br~wn,. ~ Fine Loamy. san. d ~ \\71." th a .1." 21 mOIst . I little Fine Gravel, I (very stlff) :1 ,i bro\vn, .' moist I J:i" 'Z .' ( ill e d i urn ) ..1-,.. '., rll II ~ ~ I I! 2 9 f I I tsandy Loam, non to slightly ["42.1 I .G-o- Iplastic, with a little I II I .IFine Gravel, and a few thin Ii,' '1'.' S a11 dIe n s e s , brown, 34' m..Oist 3 I..... l'v1edi.um SaIld, \~iith a little (very stiff) . Fine Gravel, **Water not encountered in i brown, probing boring to 35' depth-- ~I wet ca\red-i11 at that le\Tel. .' (medium to very dense) 22 . 36 *Surface elevation referenced 0 cerl erli11 of County RO::ld 18 due hest ,--- of center of tank, assumed as . levai.on 10 .0..'1 I 44 ' I I Fine to ~'1edium Sand, LA.:Ls 62 brown, I **Water not encountered In moist to wet probing boring to 23' depth-- (medium to dense) .~. .., . ca\Ted- in at that level. 50'1 ;.., 50' I .., ~~ I ** SOIL ENGINEERING SERVICES INC. 0 A... 4.J~ ~ (.)0 80 ~ ~ "9,L. <t 't, \ ~ 70 ~ ~ ~'b ~ '" CJ Q:~ ..,. '<. 0 4J ~(jt Ct) 0 / ~ ,,~ ~ -0 0 0 0 ~ ~ ~ 0 irJO ~ A..O ~ OjO 0 ~ ~ SILT-SIZE FRACTION IN PER CENT SOILS TEXTURAL CLASS IFICA TION CHART ADAPTED FROM U.S. BUREAU OF CHEMISTRY AND SOILS SIZES OF SOIL SEPARATES FRACTION PARTICLE OJ AMETE R SANO------c=$c=3 FROM 2.0 TO 0.074 MM. S I L T _.._c=o<=mc::8-==~FROM 0.074 TO 0.005 MM. CLAY __~=a__~_~ L.ESS THAN O.OOSMM. ,1 . ~ ., .. .1 ~ . %1-tU~ \; cc'lll:.'9 '-.7 , I-~ CCd; '# Contract Documents .-/v,t'zLL 7 - ~~~ ;tv 1 ~r / ~ ?(', .. "- FOR av~& c:-.--' ~ / to< '~ i , 1.5 Million Gallon Elevated Water Tank r'l .\. .-: . . iJ AND 1 Appurtenant Work 1 . . FOR THE .~ VILLAGE OF NEW HOPE MINNESOT A ~ WATER IMPROVEMENT NO. 194 ~ . .: I . , i.&' ~ il , ORR-SCHELEN-MA YERON & ASSOCIATES, INC. ,t CONSULTING ENGINEERS 't ~ MINNEAPOLIS, MINNESOTA 1~ .... ;) Date: October 30, 1967 Set No. .,. ( .. , :.: ; ~~(cffi:ni\ t7rE~ . ." I I J .... ... \ \ ....1.. n {/;(I'" ~ ~ J \3 ~ Ij L U"'0 L,:;l , L Of:^6 1967 lot,., M ' f" :\1 f) E P T 0 F tl F A I T H . .,1. ...., " 1_ ....... DIV. OF ENV. HEALTH C:;) ~t> '9 - rj el:;j '951 ; '~ABT~ OF ..c.~~~ ~~ ::-". J... .'~ ' -; ;Se(~tion ;' .r ... ~~~, "~' ~.".'~ ,;;;,.. -~ """';;'-'" .-.~ ~.-...~~~~~ Ins':Gr.uctions to Bi.dders p .~ \;t .....-- 0_= INSTRUCTIONS TO BIDDERS Table of Contents Article Page 1. Examination of Plans, Specifications and Site of Work 1 2. Bid Secu.I'i t~l 1 3. Contract Documents 1 4c Preparation of Proposal 1 5. Conditions in Bidder!s Proposal 2 6. Interpretation of Estimates 2 7. Delivery of Proposals 2 8~ Rejection of Proposals 2 90 Withdrawal of Proposals 2 10. Public Opening of Proposals 3 11. Disqualification of Bidders 3 12;1 Eqllipraent 3 13~ Furnishing of Evidence of Responsibility 3 14. Requirements of Contract Bond 3 150 Failure to Execute Contracts 3 INSTRUCTIONS TO BIDDERS 1. EXAMINATION OF PLAI'lS~, SPECIFICATIONS AND SITE OF WORK The bidder sha,ll examine to his satisfaction the quanti-ties of work to be done as determined from the plan~ and specifications. Quantities indicated by the Engineer on drawings or elsewhere are estirnated only, and bidders must rely on their own calculations. Bidders shall be thoroughly famillar with the Contract Docwnents including all General Conditions, Special Provisions and Special Conditions~ Bidders shall inform themselves of the character and magnitude of 1-'Jork and the condi tions u.nder v'lhich the "lork is to be performed concerning the site of the work) the structure of the gro~nd, the existance of surface and ground water, availability of drainage, the obstacles which may be encountered, means of approach to the site, manner of delivering and handling materials, facilities of transporting and installing construction plant and equipment and all other relevant matters pertaining to the complete execution of this contract 0 No plea of ignorance of conditions that exist or that may hereafter exist, or of difficulties that will be encount- ered in the execution of the work hereunder which result from the failure to make necessary examinations and investigationsJ will be accepted as a sufficient excuse for any failure or omission on the part of the Contractor to fulfill in every detail all the require- ments of this contract, or 1tlill be accepted as a basis for any claim whatsoever for extra compensation or for an extension of time. No bidder may rely upon any statements or representations of any officer, agent, or employee of the 01tlner \vi th ~eference to the conditions of the work or the character of the sailor other hazards which may be encountered in the course of construction. 20 BID SEC1JRITy- Each bid_ s]:1allbe 8~ccompanied by- a cash deposi t, certified or cashierts check, or bid bortd with a corporate surety in an amount at least equal to five (5%) per cent of the total amount of the base bid, payable to th~ ~~ner as a guaranty that the bidder will enter into a contract vlith t,h.e O\tJnel~ for the 'VJork described in the proposalJ and the amount of the bid security of a successful bidder shall be forfeited to the Owner as liquidated damages in the event that such bidder fails to enter into a contract and furnish Contractor's bondc 3~ CONTPiliCT DOC1JMErJTS The Contract Doclunerlts 1,Qill consist of the Adv-ert.isement for Bids, Instructions to Bidders, General Conditions~ Special Provisions, Special Conditionsj Proposal Form, Form of Contract and all plans and d.I'a,illings c These dOCUInents are 011 file vJi th the OVJner, 40 PRE PA R.AT IOl'J OF PROPOSAL The bidcler shall su.brfli t 11i-8. PI'oposal on the forms provided. by t,f1e - 1 - IB Engineer wi thout removi.t1g them from the bound Contract Documents 0 He shall also submit a duplicate proposal on the additional un- b'ound fO':rnls provided by the Engineer 0 The b.1ank sp.aces in the proposa..ls shall be filled. in correctly wi th ink where indic"ated for each and every item for which a quanti ty is gi ven, and the bidder shall state the prices fOl~ which he proposes to do each item of the work contemplatedc The bidder! s propcJsal shal.l be sigrled correctly wi th inko If the p'<rup-o'sa'l is made b~lan indi \lidual, his r.lame and post office address shall be showno If made by a firm or partnership, the name and post office address of each member of the firm or partnership shall be sho1JJno If made by a corporation, the person signing the proposal shall show the name of the state under the law of which the {:;orporat.ion \vas chart.ered and names, ti tIes and business addresses of the Presi.dent., Secretary 3 and Treasur"er" All bids from Corporations shall bear the official seal of the Corporationo 50 CONDITIONS IN BIDDER'S PROPOSAL The bidder shall not stipulate in his proposal any conditions not provided for on the proposal forme 60 INTERPRETATION OF ESTIMATES The Engineer! s estima,t.e c,f ,quarrti ties as shovln in thepropo'sal shall be llsed as a b.asisof calClllation upon \llhich the a\vard of contract. 'will be made, bttt. t,hese quanti ties are not guaranteed to be accurate arldw are fD~rnished llli thout any liabili ty on t:he part of the Owner 0 7. DELrvERY OF PROPOSALS All bids shall be placed in a sealed envelope with a statement thereon showing the work covered by the bid, and addressed to the Owner, as shown in Article 2 of the Special Provisionso Proposals may be mailed or submitted in persouQ No bids will be received after th,e -time set. for~ rec:ei\Tirlg t~hemo Bids arriving by m&il at the office of the Owner aftBr the hour designated for receiving bids will be returned to the sender unopened 0 8e REJECTION OF PROPOSALS Proposals may be re"jected if -the:v sho\i\T any omission, alteration of form, addi t.ions not c8Jlled f"o:r ~ contji tior2.a,l bids or al te'rnate bids not. specified or ir:reg'ulari t,ies of arlY kind 0 Proposals in "tvhich the pri.ces a,r\8 (J~b\lic)lIS1y. 'Ctnbalanced may be rej ected 0 90 WITrlDBAWAL OF PROPOSALS A bidder may withdraw his proposal without prejudice to himself, provided he files a written request with the Owner b~fore the hour of letting, and such thdraJtJn pr~oposal lllay be rI10dified and resu_bmi,tt.ed ~O~l t.he 'bidwd.sr at~ a~rlY ti:m.e prior t,o the hour set for the opening or bidso ........ IB - ~ - 10. PUBLIC OPENING OF PROPOSALS Proposals will be opened publicly and read aloud in such place as designated at the time and the date set in the "Ad'vertisement If. Bidders or their authorized agents are invited to be present. 11. DISQUALIFICATION OF BIDDERS More than one proposal for the same project from an individual firm, partnership or corporation under the same or different names will not be consideredo Evidence that any bidder is interested in more than one proposal for the same work will cause rejection of all such proposals. Collusion between the bidders will be considered sufficient cause for the rejection of all bids so affected. Failure on the part of any bidder to carry out previous contracts satisfactorily or his lack of the experience or equipment neces- sary for the satisfactory completion of the work may be deemed sufficient cause for his disqualification. 12. EQUIP:MENT When requested by the Owner, t-he bidder shall furnish a complete statement of the make, size, weight (where weight is one of the specified requirements) condition and previous length of service of all equipment to be used in the proposed work. 13. FURNISHING OF EVIDENCE OF RESPONSIBILITY When requested by the Owner the Bidder shall furnish a balance sheet, certified by a certified public accountant as to a date not more than sixty (60) days prior to date of the opening of proposals which shall set forth outstanding assets and liabilities in reasonable detail. The bidder shall also furnish a list of 'ttJork of siIl1ilar nature performed wi th dates of completion thereof /I The bidder shall also furnish any other additional information relative to financial responsibility and competence to do the work as may be requested by the Owner prior to acceptance of any proposalo 14. REQUIRE:MENTS OF C01TTRA.CT BOND The successful bidder, at the time for the execution of the con-. tract shall furnish and at all times maintain a satisfactory and su.fficient bond in fo.11 amount of the contract as required by law with a corporate surety satisfactory to the Owner. The Form of Bond is that required by statute. Personal sureties will not be approved 0 15. FAILURE TO EXECUTE CO~TTRA.CTS Failure to furnish the contl~act bond in a sum equal to the amount of the award, or to execute the contract within ten (10) days, as specified, shall be just cause for the annulment of the award, and it shall be understood by the bidder that in the event of the annulment of the a1~Jard, the amount of the guaranty deposi ted with the proposal shall be retained by the Owner, not as a penalty, but as Liquidated Damages. - 3 - IE ", GENERAL CONDITIONS TAELE.OF' CONTENTS Article rage 4 In Gen,e ral 1 2ft Definitions ~ 3. Interpretation of Proposal Contract Docuaents 2 4a Form of Contract 2 5~ Contractor's Insurance 3 6. Compliance with Laws~ Building Codes and 4 Regulations 78 Permits and Licenses 5 8. Assignment of Contract 5 90 Sub-contracting 5 100 Contractor's Respensibilities ~ 110 Termination of Contractor"' s Responsibili ty 12. Prosecu~1on of Work 6 .....' 1~0 Limdtations of Operations 7 1~f1 Conformity with Plans and Allowable Deviations 7 15.6 Co-ordi11at.ion of Plans and Specifications e 168 Contractor! s Right to Request. 'Changes 170 Alterations of Plans or Character of Work 8 18e Increased or Decreased Quanti ties of..\iDrk 8 19b Changes in the Work 9 206'1 Claims. and Protests 10 -21", Superintendence and Supervision 10 ! 22~ _i.neer~ s status 1,1 I 2~/) Inspection of Work 11; 2 e Delays and Extension of Time '. -" 12 .250 Oorrection of Work before Final Payment l3 26t) Corre&tirm. of "Jark after Final Payment 13 2~e Failure to Complete Work on Time 13 2 0 The Right o.f~:-'the Owner to do the Work 14 2~@ Right of Owner to Declare Contractoroin Default 14 306 Exercise ~, the Right to Declare in Default 15 31@ Quitting the Site 15 32& Completion of the Work after Default 15 33~ P'art.ial Default 16 340 Scope of Payment 16 3~t) Applic~tio~s for Payments 17 300 Partial Payments 17 37<) Certificates of Paymentp 18 38& Payments Withheld 18 ~ge Final Inspection 18 Oa Fit~l PG1~ymes.Tt}t 19 410 No'Waiver of L~gal Rights 19 420 Defense ~",._C~ims of Sui ts 20 ""~-=- ~ \" I Article Page 430 Patented Devices, Materials and Processes 21 41+0 1v!aterials 21 450 Defective Work 23 460 Protection of the Work 23 470 Damage to Existing Improv~ments 25 480 Protection and Restoration of Property 25 490 Privilages of Contractor in streets, Alleys and Right-of....Way 26 500 Wor~k in storms 27 510 Night, Work 27 520 Use of Rxplosives 27 " 530 l'loise El'imination 28 54v Water~ 28 550 Sanitary Provisions 28 560 Fossils 28 570 Accident Prevention 28 580 HO!t; Equal!~ Clause 28 590 Labor 29 600 ,Di8crJimination on .J.!\ccorunt of..Rac~3 Creed;\ or 29 Color Prohibited in Contract 610 Sites to be Kept Clean 29 62~ IvleaSll,remel1 t s 30 630 G'll,a..rarltee 30 I .-. ,. GEI{ER,.AL C01JDITI01\JS ~ ..~~....j;j;~u4+ V~IL~li;GE .O~ HOP?; IVII~\Jl\fJSSQT.A 1 .~ I}J GE}JERi}..L :y:.,,:,~-..oc~:~~_~.4:~~=~~.z- ~~e sta~~ard form i~f.c~~:~e Amerj_can Ingt i te of 6~~~;'~~~~~~~S :}4r~~~i~ ~ed 1 to inclusive, lS ifieati0DS, except that ~~;~ i~~l anyi~~a~:::~~~ of the n pr>ece!~~n~~e o~~~t~~~t n and shall be used in connection -the Contract Documents. A copy of these General the Contract 18 on file in the Engineers' Offices and is ject to inspection by this Contractoro Unfamiliarity with the terms of these General Corld.itic:<.clSo1~ tile, tJorltl~aet 1lJl~Ll :(-e t:11is Cf)XTtract.or~ oftl1e ter111SCorltal11ed tr1ere ill {;; Tl1-18 ltJ ..D:.rlcl~li t>ect tt .lrl t 112 Gerleral C:ondi.tiol1S of tYle C011tr~act shall "be cOIJ.str1...1ed. .to mean the same as " Erlgil1.eel-.i! in ~tlli.s s~oeci:f'icatiorlc ~ - 2 0 DEFI.l'~J='J:IOl~:S i::,::~~~~~~;O.~~ '/111e11 l..1sed 11'1 these SI)ecific;at a11c1 C()Ylt.raet trle folloVJi11g terms, or if pronouns in place of them are used, the intent and meaning shall be interpreted as follows: a lIlea'rlS tfleH'ope~, rflirlnesots..i> lnecn~s .t:lle \; "Clllg Er1girleers as designated for r, in this case Orr=Schelen~Mayeron & Associa S j apolisJ Minnesotao ~ an authorized representative of the Engineer, or all necessary inspections of the anct tIle rIla terial.s f-ctrnisll.8cl by theCon= d testing laboratory which may be approved ct ae suitab l~Y \~ e ()l~ctt i()11 S l.-1.bnl :Lt t illg_~a ac~ directly br Ol~a. t i ()ll vV' i t11 isespecified 6 form on which the ~priOrJ i:)S 8.1 ()1~o 1:.e}.}r~{J{Jl1c t 1011 ()f' dJ~a1j'l ings) JG 1'1 e V:J': () 1-: Ie a 11d~a l:)~01J..r t e =~ cor:d.ii''cloD.S Q l)rovisiorls al~d togetrler \i;lith a.l]4 v~f-ri ttren - the method J Ql12.l1t.:ities . C()lltl-;8oC t -- ti C, . , " . . ,', ,';~.;:f ,:,;" <:.i:A:..~ ~'E:'1 . ~ t ~ (j.) "Proposal ti J the written Pr)oposal of the bidder on the Form . furnished for the ~lork contemplatedt~ (k) '"Proposal GuarantyH the security designated in the Prop'osal . to be f~rnlshed by the Bidder as a gurantee of good faith \to enter 'into a contract w lth the Owner)' if the work is awarded to him~ ' (1) f'Contra'ot t1:1 the~reement covering the performance of the vlork and the fur:nishing of materials in the construction of ,the work,~ 'The Contract shal,l include the "Contract Documentsl1 and HContract Bond It, also q.ny and &11 supple- mental agreements which reasonably may be required to . complete the construction of the work in a substantial . and acceptable mannero (m) tlContract Bond t!} the approved form of 'security furnished by the Contractor and his Surety or Sureties as a guaranty of good faith on the part of the Contractor to execute the work in accordance with the terms of the Contract$ (n)' "Surety":/ the individual or co'r'p'orate body which is bound ..~ with and for the Contractor for the acceptabl~ performance of the Contract and for his payment of all obligations pertaining to the work (0) The term "~t/orklt of the Contractor or sub-contractor includes labor or materials or both ~ (p) ,tlA,:S,~T M"u, American Society for Testing Mat,erialso (q) Meaning of expressions In order to avoid cumbersome and con- fusing repetition of expressions in these specifications, and whenever it is provided that anything is, or is to be done) if) or as~, or 'ltihen) or lflhere ltcontemplatedttJ f1re- qu ired H ;; "d ire c ted II, 11 spe c if ied ii j fj author i zed U J II orde red 11 J ~ "givenr1, OdesignatedU, nindicatedti) "c~onsidered necessary", Ilpermittedff, t!suspendedtlj tlapprovedllj "acceptable", "un- 'acceptableU; IIsuitablenj !!unsuitablel!" Hsatisfactorytl)' "unsatisfactoryH} or nsufficientf1j it shall be taken to mean and intend, by or to the Engineer~ 3 ~ INTERPRETATIOI\I OF PR,OPOSEDCONTRACT DOC'UMENTS ~tf any person contemp'latirlg submitting a bia for the proposed contract 15 in doubt as to the true meaning of any part of the plans, specifioat~ons or 'other proposed contract documents; he may submit to the Engineer) a written request for an interpretation thereof:;, ,The person submitting the request will be responsible for its prompt delivery i A.D-Y in,ter'pretation of the proposed document's will be made only by addendum duly issued and copy of such addendum will be mailed or ~elivered to each person receiving a set of such contractdocu,ment,sand sucn other pr4Qspective bidder as have requested that they be furnished with a copy of each addendum~ The Owner will not be respon-sible for any other explanation or interpretations of the proposed contract documents~ 4~ FORM OF CONTRACT The Form of Contract to be used shall be the form prescribed and provided by the, Owner in the Contract Documentsb -2- GC 5. CONTRACTOR'S INSURANCE No Contractor nor sub-contra,ctor shall comrnence vJork under this contract until he has obtained at his own cost and expense, all insurance required by this Article, such insurance to be approved by the Owner and maintained by the Contractor until final completion of the iJJork. Completed Operations Insurance shall also be maintained by the contractor for a period of one (1) year after final completion "date. A. Workmen's Compensation Insurance The Contractor shall take out and maintain for the duration of this contract statutory Workmenls Compensation Insurance and Employerls Liability Insurance as shall be required under the laws of the state of Minnesota. B. General Liability Insurance (l) Public Liability Insurance The Contractor shall take out and maintain during the life of this contract such Public Liability and Property Damage Insurance as shall protect him from all claims for bodily injury including accidental death as well as from all claims for Pro- perty Damage arising from operations under this contract. The' minimum limits which are required are: $200,000 for injuries including accidental death to anyone person, and $500,000 for injuries including accidental death resulting from one accident; Property Damage in the amount of not less than $300,000 per accident and the same amount in the aggregate. Such policy shall include coverage for: (a) Injury to or destruction of any property arising out of the collapse of/or structural injury to any building or structure due: (1) To grading of land, excavation, ~orrowing, filling, backfilling, tunneling, .,-pile driving, coffer~dam work or caisson work, or, (2) To moving, shoring, underpinning, raising or demo- lition uf any building or strucure or removal or rebuilding of any structural support thereof (1:5) Injury to or destruction of wires, conduits, pipes, mains, sewers, tanks, tunnels, any similar property, and any -apparatus in connection therevJi th, beneath the sur- face of the ground or water, caused by and occurring during the use of mechanical equipment for the purpose of grading land, paving, excavating, drilling, borrowing, ufilling, back-filling or pile dri ving or injury to or destruction of property at any time resulting therefrom. (c) Injury to or destruction of any property arising out of blasting or explosion. - 3 - GC (2) Automobile. Insurance The Contractor shall carry Automobile Insurance on all automotive equipment owned, rented or borrowd in the minimum amounts of $200,000 for injuries including accidental death to anyone person and $500,000 for injuries including death resulting from anyone accident. Th~s policy must also provide $100,000 Property Damage coverage. (3) C.ontractual Liabili ty Insurance 'The Contractor agrees to hold harmless and indemnify the Owner, the Engineer and their agents from every claim, action, ; cause of action, liability, damage, expense or payment incurred by reasons of any bodily injury including death, or property damage resulting from the- Contractor-Is operations on this project. '4 O"t'Jner r s Protecti ve Liabili ty and Property Damage "Ins urance T e Con rac or s a provi e Ownerts Protective Liabili y and rroperty Damage Insurance in the name of the Owner and the Engineer, insuring against bodily injury and -property damage liability in the limits set forth above for which they may become legally obligated to pay as damages sustained by any persons, caused by accident and arising out of operations performed for the named insured b~l inde"pendent - contractorsB.nd general super- vision thereof. c. Build~r's Risk-Fire and Extended Coverage Insurance If the nature of the entire installation or portion thereof, is such that it is insurable against the perils of fire, extended coverage, vandalism and malicious mischief, such insurance shall be proc ured and maintained by the Contractor in behalf of himself, the OvJner and his sub-contractors, on a complete value formo Insurance certificates evidencing that the above insurance is in force with companies acceptable to the Owner and in the amounts required shall be submitted to the Owner for examination and approved concurrently with the execution of the contract, after which they shall be filed with the Owner. In addition to the normal information provided on the insurance certificates, they shall specifically provide that: (a) A certificate will not be modified except upon ten day's prior written notice to the Owner. (b) Coverage is included for bl~sting, collapse and underground hazards, and (c) The contractual liability hazard has been insured. 6. COMPLIANCE WITH LAWS, BUILDING CODES AND REGULl-iTIONS The Bidder is assumed to have made himself familiar with all - 4 - GC -" ~ . . Codes~ state Laws, Ordinanees and Regulations which in any manner affect tho~e engage~ or employed in the work, or the materials or equipment used in or upon" the improveaent, or in any way affect the conduet of the work and no plea of "misunderstanding rl11 be,conlidered on account of the ignorance thereofo The prOvis1GnJI of: such codes, laws or ordinancel are deemed to be a part of these specifications and the Contractor will be bound by the prov1~i;~athereofG The aont~ctor. shall and al~o by a Surety agree to indemnify and saveh~e3z the ,owner and all of "its of.ficers, agents and serv-~ts against ~ claim or liability arising from or based on ~he viol.ation of any such law" ordinance, regulation or decrees?i Whether by himself or his employees 0 If the Contractor shall discover any provisions in the Plans, "Contract~ or these Specifications or. any. direct~on of the Engineer or !rl~pector which is contrary.to or inconsistent with any such l&wj)o~inance$t regulation or decree; he shall forthwith report its inconsistency to the Engineer in writingo +E: P:ERMITS AND .LICENSES '..4> e Contrac;tor sh!Ul procure all permi ts and licenses!) pay all charge~ ad fe~s and give all notices necessary and incidental to the due arl,d lanul prosecution of worko 80 ASSIG:IXENT OF CONTRf.\CT No a.ss71gnment by the Contractor of any principal construction contraet or,' any . part thereof. or of the funds to be received th.reunder by the Contractor, ~ill be recognized unless such a.lignm.enth&~ had the written approval of the OWner, amd".;the iu'rety . .~~b.enii ven due notice ofsuehaalii~t an'd. has furnishedwritteneonsent thereto 0 In addition, to the usual F~1tal:. ':b1 ~r:!"1giOtent contracts, the follOW-ing language must be ~et forlbg ~:l:t is ~:reed that the funds to be paid to the ~.t5ignee under this assignment a~~ liubject to It prior lien for services" r~de~e4 or materials supplied for the perle~nc.of the work called for in Jia1d~ontra,et 1Jlfavor of all persons, fl~ or COJ:po,rations rendering such sfifrrl~e!B or" supplying such materials 0 It tI S.UB=CO~CTmG .' :':1~uli~<:_tri~tct,03Ihal;l be subject to the approval .of the Owner &rid th@ mgineer and n.o sub=-contract5 shall be let without such &pprov~lo 100 COJlrBACTORR S RESPONSIBILITIES ~e Cont~tor shall.furnish all necessary machinery, tools, labor - 5 - GC and m~terial of every character r~quired, and shall fully complete the work in accor4ance with the plan, specificatiBns L~d detail drawings, for the price!sbidc The entire work to be performed under the contract for this improvement is to be at the Contractoris risk, and he is ~o assume the responsibility for and risk of all d~ages to the work or to property adj~cent to or on the line of said W'orko The Contractor shall have charge of and be responsible for the entire improvement until its completion and accepte.nceo He shall be liable for 3.ny'defects which may appear or be discovered on hif5" worko : Whenever the C€i>:atraetor is not present on the work, directions will b@ given to the Superintendent or Forem~n who m~y h~ve immediate charge thereof, and &hall by him be received and strictly obeyedo The Contractor shall designate one person who shall have charge of t.he job and to whom. the inspector ~hall gi ve directions II If any person employed on the work shall refuse or neglect to obey the directiong o.f the Engineer, or hili duly &uthorizedrepresenta- tivej in anything relating to the work, or $hall appear to be incomp~tentj eiilioraerly or unfaithful, he sha.ll, upon the request of the Engineer~ be at once di8charged and not a~ain employed upon any p!lrt of the work.o' 110 TE~~NATION OF CONTRACTOR~5 RESPONSIBILITY Except ~}j othenlise provided for in theie :specifica.tions &nd in the ContractorE$ Bondj the ContractoriB respon3ibility on his contract ~h~ll continue until final acceptance of his work by the Engineer3 ~uch ~cceptance to be made pr~ptly after fin~l co~plet1on of the work, ~nd thereafter until all obligations contained in ~uch contrac~ shall have be~n fully performed by the Contractor, according to the terms of the contract 0 120 PROSECUTION OF WORK All dealings or".'the Owner will be wi th the Contractor 0 No work shall be started until the Contract has been executedo Definite notice of intention to start work shall be given to the Owner at lea8t fiv~ (5) days in advance of beginning the workQ Such starting ti.e $hall be within ten (10) calendar d&y~ after the date of receipt by him of netice to proceedo The, official ~t~rting time .hall be taken as the' date on which the Cori.tractor i~ notified by the Engineer that he h~a fulfilled all preliminary r~quirements of the Owner 0 The official completion date will be calculated from the number of calendar daym between the ~t~rting d&te and t~ completion date or time allowed for completion, u~ing th~ 6ffici&1 st~rting date &8 hereinbefore definedo Should the prosecution of the work for any re~ion be discontinued temporarily, by the Contractor, with ~~con8ent of the Engineer, he sh~ll notify th~ ~~gineer at l~&mt tw~nty-rour (24) hours tlefore ag~in re:stWing operation~ () The Contractor ~hilll ~ru.bmi t, at such ti.e~ ai may reasonablt' be - 6 - GC requested by the' Engineer, schedules which shall show the order in which the Contractor proposes to carryon the work, with dates at which the Contractor will start the several parts of the work, and estimated dates of completion of the several partso If deemed necessary by the Engiheer, he shall have the right to change such schedule of operation as required 0 The work shall be prosecuted in such manner as to insure its completion within the time set for it in the Contracto In case of failure to prosecute the work in such a manner as to insure its completion within the date specified, the Engineer shall have the right to 'require the contractor to place in operation such additional force and equipment as is deemed ,necessaryo 130 LIMITATIONS OF OPERATIONS In' case of a dispute aTising between two or more Contractors engaged on .the same work, as tq the respective rights of each under these Specifications, the Engineer shall determine the matters at issue and shall define the respective rights of th~ various interest involved, in order to secure the completion of all parts of the work in general harmony, and with satisfactory results, and his decisions sha~l be final and binding on all parties concerned and shall not in any way be a cause for claim for extra compensation by any of t~e partieso 140 CONFORMITY WITH PLANS AND ALLOWABLE DEVIATIONS No deviation from the plans for the work or the approved working drawings of the structures will be permitted without the written order of the Engineero 150 CO-ORDINATION OF PLANS AND SPECIFICATIONS This Contractor shall tAke no advantage of any apparent error or omission in the Plans or.'Specifications, but the Engineer shall be permitted to make such corrections and interpretations as may be deemed necessary for the fulfillment to the intent of the Plans and Specificationso Any work not herein or on the plans speCifically specified but which may be fairly implied or understood as included in the Contract, shall be done by the Contractor without extra charge 0 Any ambiguity or discrepancy in the Plans and Specifications shall be adjusted by using the best class of work or materialso LA the case of any discrepancy between the scale and figures on all plans, drawings, etco, 'the figured dimensions shall governo In the case of any discrepancy between the quantities shown in the proposal and those shown on the plans, the plans shall pre- vailo In case any other discrepancy occurs between the plans and these Specifications, the decision of the Engineer shall be decisive thereono - 7 - GC 160 CONTRACTOR'S RIGHT TO REQUEST CHANGES If the Contractor shall discover prior to or during construction anything in the plans or specifications or in supplementary direc- tions by the 'Engineer which in the opinion of the Contractor appears..'to be faulty engineering. or design, he shall forthwi th advise the Engineer in writing of the particularso It is under- stood and agreed that, if no objection is raised by the . Contractor under the provisions of this paragraph, the Contractor waives any right to contest the provisions of his Contract on the basis of faulty engineering or designo : 170 ALTERATIONS OF PLANS OR CHARACTER OF WORK The ~ngineer is given the right as the work progresses, to make such alterations in the plans or in the character of the work as may"be considered necessary or desirable, in order to complete fully and perfect the construction of the wo~ko Such changes shall in no way invalidate the contract 0 The Contractor will be informed in writing of all or any such alterations in character of work, before being ordered to perform such worko After rece~pt of such notice, the Contractor will be given a reasonable length of time to accept or to protest the performance of work covered by such alterationso Should the Contractor, after having been notified and before any agreement has been reached, perform any of the work covered by such alterations, it will be construed that he has accepted such alterations of the work~ The plans and specifications show the work to be performed 0 Construction conditions may require that minor changes be made in location and installation of the work and equipment to be furnished and other work to be performed hereunder and the Contractor when ordered by the Engineer shall make such adjustments and changes in said locations and work as may be necessary without additional cha~ge, provided such adjustments and changes do not alter th~ character, quantity or cost of work as a whole and provided further the plans and specifications showing such adjustments and changes are furnished the Contractor by the Engineer within a reasonable time and before any work involving such adjustments and changes are made 0 18a INCREASED OR DECREASED QUANTITIES OF WORK The Engineer is given the right to increase or decrease any or all of the items specified in the Plans, Proposal and Contract, in- cluding the elimination of one or more of such iteinso Such changes shall in no way invalidate the Contract 0 The Ovmer through the Engineer reserves the right to terminate the Contract as it applies to the item or items in question and to make such arrangement as he may deem necessary to complete such item or items of worko - 8 - GC No allowance for anticipated profits will be madeo 190 CHANGES IN THE WORK The Owner, to the extent authorized by law, may order extra work or make changes by altering, adding to, or deducting from the work without invalidating the contract, and the contract sum will be adjusted accordinglyo No such order for extra work or change shall be valid unless authorized by official action of the Owner, and communicated to the Contractor in writinga All such work shall be executed under the conditions of the original contract, except that any claim for extension of time caused thereby shall be adjusted at the time of ordering such change. The value of any authorized extra work or change shall be determined for purpose of compensating the Contract in one or mO,re of the following ways: 1) By unit prices names in the contract wherever such unit prices are applicable to the extra work or changeo 2) By an acceptable lump sum proposed from the Contractoro 3) By force account paid for in the following manner: a) For all labor and foreman in the direct change of the specific work". tl1e Contractor w"ill receive the actual wages paid for each and every hour that said labor and foreman are actually engaged in sudh work, plus the cost of bond, insurance, and taxes allowable to such wage cost, to which cost shall be added 15% of the sum thereofo No charge shall be made by the Contractor for organization or overhead expenses 0 b) For all materials used the Contractor will receive the actual cost of such materials including freight charges as shown by original receipted bills, to which cost,; :shall be added ten (10%) per cent of the sum thereofo Where materials are not specifically purchased for "Force Account" work, but are taken from the Contractor's stock." the Contractor shall submit an affidavit of the quantity, price and freight on such materials in lieu of original bills, and invoicesCl This affidavit shall be approved by the Engineero c) For any machinery, trucks, or equipment including fuel and lubricants, wh~ch it may be deemed necessary or desirable to use, the Contractor will receive a reasonable rental price, for each and every hour that said machinery, trucks and equipment are in use on such work, and to which sum no percentage will be addedo Such rental price shall not exceed the rates established by the AoGoCo for this district for comparable rentals and shall be subject to the EngineersY approval 0 - 9 - GC d) The compensation as herein provided shall be received by the Cont.ractor as payment in full for work done by"Force Accounttt and said fifteen (15%) per cent for labor and said ten (10%) per cent for materials shall be agreed to cover profit, superintendence, general expense, overhead, bond premiums, insurance and the use of small tools and equipment for which no rental is.allowedo e) The Contractor or his representative and the Engineer or his representative shall compare records of work on a : "Force Account" basis at the end of ea1';h day 0 Copies of tn-e records shall be made in triplicate on ftForce Accounttr forms, provided for this purpose by the Engineer and signed by both partiesQ To all such claims for Force Account Work, the Contractor shall attach receipted bills for, or affidavits of, materials used and freight receipts covering freight on such materials used, and said claims shall be presented to the Engineer for payment not later than the twentieth (20) day of the month following that in which the work was actually performed and shall inciliude a,ll labor charges and material charges insofar as they can be verifiedo Should the Contractor refuse "or fail to execute the work as directed, or to submit his claim as required, the Owner may ( withhold payment of all current estimates until the Contractor's refusal or failure is eliminated, or after giving the Contractor due noti,ce the Owner may make payment for said work on a basis of a rea,sonable estimate of the value of the work performed 0 200 CLAIMS AND PROTESTS If the Contractor claims that any instructions by drawings or otherwise to be unfair or involve extra cost under this contract for which he would claim extra compensation, he shall give the Engineer written notice thereof within a reasonable time after the receipt of such instructions, and in any event before proceeding to execute the work, except in emergency endangering life or ~roperty, and the procedure shall then be as provided for changes in the worko No such elaim will be valid unless so madec 210 SUPERINTENDENCE AND SUPERVISION The Cop.tractorshal keep on his work during its progress a compe- tent' superintendent and any necessary assistants, all satisfactory to" the Engineer 0 The superintendent shall not be changed except with the c9nsent of the Erigirleer unless the superintendent proves unsatisfactory to the Contractor and ceases to be in his employ 0 The superintendent shall represent the Contractor in his absence, and all directions given to him shall be as Qinding as if given to the Contractoro Important directions shall be. confirmed in wri ting to the Contractoro Other directions shall be so confirmed on written request in each caseo - 10 - GC & The Cont'ractor shall gi ve efficient supervision to the work, using his best skill and attention, shall carefully study and compare all drawings, specifications and other instructions and shall at once report to the Engineer any error, inconsistency, or omission which he may discover, but he shall"not be held responsible for their existence or discoveryo The Contractor will be supplied, by the Engineer, copies of the Plans and Specifications~ He shall have said Plans and Specifications available on the work, at all times, during the prosecution of the worko He shall give the work his constant attention to facilitate the progress thereof and shall cooperate with the Engineer in setting and preserving stakes:J bench marks~ etca, and in all other things that are necessary for satisfactory completion of the work contemplatede 220 ENGINEERiS STATUS The Engineer shall have general supervision and direction of the work" He is the agent of the Owner only to the extent provided in tne contract documents and as authorized by lawo He has authority to stop the work whenever such stoppage may be necessary to insure proper execution of the contr~cto He is recognized by both parties to the contract as the interpreter of the contract documentso He shall~ within a reasonable time, make decisions on all claims of the Owner, or the Contractor, on all matters relating to the execution and progress of the work, or the interpretation of the contract documents~ The Engineer shall decide any and all questions as to quality of material furnished for the work, and shall decide allqu.est,ions regarding the interpretations of specifications or plans relating to the work, and shall determine the amount ana quantity of the several kinds of work performed, and materials furnished, which are to be paid for under the contracto Any work not specifically specified on the plans, but which may be fairly implied, or understood, as included~n the contract, shall be done by the Contractor without extra charge, and the Engineer shall be permitted to make such corrections and interpretations as may be deemed necessary for the fulfillment to the extent of the plans and specificationso In the case of any discrepancy occuring between the plans and specifications, the decision of the Engineer is final 0 230 INSPECTION OF WORK The Engineer and his representatives shall at all times have access to the work wherever it is in preparation or progress, and the Contractor shall provide proper facilities for such access and for inspectiono An inspector may be stationed on the work to report to ~he Engineer as to the progress of the. work and the ~anner in which it is performed~ also to report when it appears that the materials fur- nished, or the work performed by the Contractor fail to fulfill ~lle requirements of the contract and to call to the attention of - 11 - GC the Contractor any such failure or infringemento In case of any dispute arising between the Contractor and the Inspector as to the material furnished3 or the manner of performing the work, the Inspector shall have the authority to reject materials or suspend the work until such matter can be referred to, and decided by the Engineero No advice which the Inspector may gi ve the Contractor shall be. construed as binding upon the Owner nor will. such advice release the Contractor from the fulfillment of the terms of the contract 0 If the specifications, the Engineerts instructions, laws, ordinances, or any public authority require any work to be specially tested or approved, the Contractor shall give the Engineer timely notice of its readiness for the inspection, and if the inspection is by another authority than the Engineer, o~ the date fixed for such inspectiono Inspections by the Engineer shall be promptly made and where practicable at the source of supplYQ If any work shall be covered up without approval or consent of the Engineer, it must~ if required by the Engineer, be uncovered for examination at the Contractoris expense 0. Re-examination of questioned work may be ordered by the Engineer, and if 8'0 ordered,. the work must be uncovered by the Contractor6 , If such work be found in accordance with the contract documents, the Owner shall pay the cost of re-examination and replacemento If such work be found not in accordance with the contract documents, the Contractor shall pay such cost unless he shall show that the defect in the work was caused by another Contractor, in which event the Owner shall pay the cost. 24. DELAYS AND EXTENSION OF TIME If the Contractor be delayed at any time in the progress of the work by any act or neglect of the Owner or the Engineer or any employee of either, or by any other Contractor employed by the Owner~ or by changes ordered in the work, or by strike, fire .unusual delay in transportation, unavoidable casualties or other causes beyond the Contractor@s contro~, or by any cause which the Engineer shall decide to justify the delay, then the time . of completion shall be extended for such reasonable time as the Owner may decide;; and the decision of the Owner shall be binding on both part.ies and shall not be arbitrary or unreasonableo No such extension shall be made for delay unless claim therefore is made in writing to the Engineer within seven (7) days after the period of delay shall have commenced~ The Contractor shall not be entitled to extension of time for each one of several causes of delay operative concurrently, but only for the actual period of delay, nor shall the Contractor be entitled to an extension fo'r causes of delay if one of such causes for which extension is authorized abov8o The Contractor shall have no claim for damages against the Owner for delay in performance of the contract due to any actor omission of the Owners or any of i tsrepreserltati ves, arid his sole remedy on account thereof shall - 12 - GC be his right 'to apply tC3 the Engineer for extension of time as provided herein. 250 CORRECTION OF WORK BEFORE FINAL PAYMENT The Contractor shal.lpromptly,remove '~ ~he premises all materials condemned by the Engineer as failing to' con:(orm to the contract., whether incorpot'atecl in the work or not and the Contractor shaU prarn:ptly replace andre~exe,cute his own work in ,accordance with the ed,ntr:act document~sand wi thoutexpense to the OWner and shall bear the expense of making good all',work of the other Contractors destroyed or damaged' by such' removal or replacement 0 All materials not conforming to the requirements of these specifi- ... cations shall be consid.ered as defecti ve and all such materials, whether in place or not, will be rejected and shall be removed immediately from the right of way, unless otherwise permittedo No material which has been rejected, the defects of which have been corrected or removed, shall be used until approval' has been givene If the Contractor does not remove such condemned work and materials wi thin a re-asonable time fixed by wri ttennotice, the Owner may remove them and maystore.the material at the expense of the ContractorcIf the Contractor does not pay the expense of such removal within ten (10) days thereafter, the Owner may upon ten (10) days written notice sell such materials at auction or at pri vate s;aleand shall account for the net proceeds thereof, after decluctingal1 ,theeosts and expen.ses that should have been borne by the Contractorf 260 CORRECTION OF WORK AFTER FINAL PAYMENT Neither the final certificate, nor payment, nor any provision of the contract documents, shall relieve the Contract-or of respon- sibilityfor faulty material or workmanship, e.and unless bther\vise specified he shall rem"edy any defects due thereto and pay for any damage to other .1ftlork resulting therefrom which shall appear wi thin a period of one year from the date of substantial completiono The Owner s:hall give notiee of observed defects with reasonable pro1nptnesso Allques:ti.ons arisin:g under this article shall be decided by the Engineero 27() FAILURE TO COMPLETE WORK ON TIME The Contractor guarantees that he can 'and will complete the \qork within th;e time limi t stated in the 'Agreement, or within the tim.eas . extended as provide'd elsewhere in the contract documents a Inasmuch as the damage and loss to the Owner which will result from the failure of the Contractor to complete the work within the stipulated time, wi ,11 be most difficult or impossible of ac-curate assessment, the damage to the Owner for such delay and failure on the part of the Contractor shall be liquidated at a daily rate in an amount. as specified in the Special Conditions for each calendar day, Sundays and holidays included, by \vhich the Contractor sh,all fail to complete the work or any part thereof in - 13 - GC accordance with the provisions hereof, and such liquidated damages shall not be considered as a penaltyo The Owner will deduct and retain out of any money d"ue or become 'd~e hereunder the amount of liquidated damages, and in case those amounts are less than the amount of liquidated damages the Contractor shall be liable to pay the difference upon demando Permitting the Contractor to continue and finish the work or any part of it after the time fixed fo.r its completion, or after the date to which the time for completion may" have been extended, shall in no way operate as a waiver on the part of the Owner of any of its rights under the contracto : Neither by the" taking over of the work by the Owner, nor by the termination of the contract, shall the Owner forfeit the right to recover liquidated damages from the Contractor or his Surety for failure to complete the contracto 280 THE RIGHT OF THE OWNER TO DO THE WORK ~f the Contractor should neglect to prosecute the work properly, or "fail to perform any provision of the~contract, the Owner after three (3) days written notice- to the Contractor, may without prejudice to any other remedy the Owner may have, make good such deficiencies and may deduct the cost thereof from the payment then or thereafter due the Contractor, provided, however, that the Engineer shall approve both such action and the amount charged to the Contractoro 290 RIGHT OF THE OWNER TO DECLARE CONTRACTOR IN DEFAULT In addition to those instances specifically referred to in other ar~icles herein, the Owner shall have the right to declare the Contractor in default of.~the whole or any part of the work if~ 1) The Contractor becomes insolvent; or if 2) The Contractor makes an assignment for the benefit of creditors pursuant to the statutes of the state of Minnesota; or if 3) A voluntary or involuntary petition in bankruptcy be filed by or against the Contractor; of if 4) The Contractor fails to commence work when notified to do so by the Engineers; or if 5) The Contractor shall abandon the work; or if 6) The Contractor shall refuse to proceed with the work when and as directed by the Engineer; of if 7) The Contractor shall without just cause reduce his working force to a number which, if maintained, would be insufficient$ in the opinion of the Engineer, to complete the work in accord- ance with the approved Progress Schedule, and shall fail or - 14 - GC refu~e sufficiently t~ increase such working force when ordered to do so by the Engineer; or if 8) The Contra.~tor shall sublet, as'sign, transfer, conveyor otherwise dispose of his contract other. than as herein speci~ fied; or if 9) A receiver or receivers are appointed to take charge of the Contractor U s prop'erty or affairs; or if 10) The Engineer shall be of the opinion th'at the Contractor is or has been 'wilfully ori~ bad faith violating any of the ptovis1~n! of this contract; or if --... 11) Th.e EDg1ne'er shall b'e of the opinion. that. the Contractor ial or has been unnecf~ssarily or unreasonably or wilfully delaYi~ the performance and '~ompletion . of the work, or the. . / awar~ 0 necessary sub-contracts, or the placing of necessary materia~ and equipment orders; or if 12) The ErJ.gineer shall be of the opinion that the work cannot be cQm.pletedwithin the time herein provided therefore1or ~th1n the time to .wh'ich 'such' completion may have been extfilfAded; provided, however, that the impossibility of timely e~pletion is in the Engineeris opinion, attributa.ble to co~ti:itiO!li, within the Contractor's control; or if 13) ~e ~ineer5hall be of the opinion that the Contractor is ~ mot or na~ not been executing the contra~t in good faith and in- .accordance with. its terms.; or if +4) ~.. work 1ti mot complet'ed wi thin the time herein provided . the:ret,0re orwitb1n the time to which the Contractor may be ~t1tl~d. to h&v!i such co~pletion extended. 15):B'~~re .the Owner.hall exercise its right to declare the .. .Co.t1"l.~t~r :in. default br r-eason of the condi tions set forth 1. 1~~ A\lmbered 1).'1 4 >> 5), 6), 7).'1 10).'1 11).'1 12), 13) . ~. 14>;9 he sha,ll give the Contractor as opportuni ty to be lil~rdj ~o.n tW.Q day~ 9 notic'e at which hearing the Contractor ~::h&V41 a stenographer l~)resent; provided, however, that a eopy Qfauch stenographic notes, if any, shall be furnished tC;l the Ownere " \ 300 .IDRCISE OF THE BIGHT TO DECLARE IN DEFAULT The -right to declare in default for' a..ny of the grounds specified orr.f.r>r.d~o in Articl~ 29 hereof, shall be exercised by sending the~Goilt'ractor a notic,e!j signed by the Engin.eer, setting forth tAe grc~d or ground~ upon which such default is declaredo .,.""- 31()Q~I)lG mE SITE ~~'Ji~~_~fI.t ef~ such notice the Contractor shall immediately dis- con:t.'1nue"'al~ further operation under this contract and shall . - 15 - GC ""IIIIIIt ~., ..... - 1~ediil,te1y ~~it the lite, leaving uatouehed All plant ;materials, equipment" tooll aDd su"lieSl "then on the a1teo 320 CO:KP~I01V OF mE YOM AFTElt nXFAtJ11r The Owner, after Qeclaring the Contract@r in ..f&ult~ may then have the work. cGilpletea by lJuch Bleana aAd. in flueh lBllllller, by contract with or without ,uBlic lett1D&,or otherwi~e, a~ it may deem ~dvisable, utilizinc for luch purpo.. luch of the Contractoris ! pl&nt~ Raterials, e~uip.ent, toolfi and lupp11es remaining on the ~1tej and alee such 8ub"'con~ractor!i 1\1 it may deem adviaableo After such cOBpletionj the Dng1neer ~hal1 Make a certificate stating the expen~e incurred in such coapletion, which ~hall include the COlt of reletting ana also the total ~ount of . ... liquidated daaale~ (at the rate provided for in the Specifications) frOJi t~he date when the work should have been. coapleted by the Contractor in accordance with the te~ hereof to the date of actu&l completion of the work 0 Such certificate ~hall De binding and co~clusi ve upon theContr&ctor" his Sureties, and any person cla~A1g under th~ Contr&ctor, a. to the amount thereofo The ~xpen~e of such co~plet1en, &8 80 certifiea by the Enginelr _hall be charged again~t and deducted out of luch mon1efi &S woUld h&ve be~n payable to the Contractor, if he had cORpleted the work~ the balance of ~uch _onies, if &ny, ~ubject to the other provision~ of this contractj to be paid to the Contractor without inter~~t after ~uch completiono Should the expense of such coapletionj so certified by the qineer, exceed the total sum which would have been paya~le under thi! contract if the s~e hit.d 'been completed by the Contractor; any luch exceSf! shall be p&id by the Contractor to the OWner upon d~ando 330 PARTIAL DEFAULT ~ case th~ Owner lihall declare the Contractor in default ai to it . pa.rt of the work only, the Contrllctor lihall di~continue such part, ~hall continue performing the r~inder of the work in strict comfo~ty with the ter~. of the contract, and ~hall in no way hind.eror interter~ with &1AY other ContractQrli or persons whom the Olmer ~,ay e~~e to cOiiplete the work 1.1 to which the Con- trac.tor W&li declared in df;faulto The pr@vi~ior~ of the e~au~e~ herein r~lat1ng to declaring the Contr~ctor in default as to the entire work shall be e~ually &pp11cable to a d~clar~tiofl of part1~1 default~ except that the Owner 8hall be entitled to util1z~ for caRpletion of the part of the work as to which the Contt~ctor va. declareQ in default only ~uch plantj FEiftterii.ls9 equipment, tool~ and suppliell aa had been previou~ly u~ed by the Contractor Oft such parto ~o SCOPE OF PA~ . e Contr~ctor ~h&ll receive and accept the compen~ation a~ hereiri provided, 1~ full payRent for furn1shin& all material~, labor3 tools, ~quipment, royaltie8, tees, 1naurance, permit8, ~ondfj, etc 0' and for perfonllIll all work conteaplated and ~braced und~r the Contractj alao for all lOI~ or damage &r1I\ir~ out of' the nature of the work, or from the action of =- 16 - GC the elements, until its final acceptance by the Owner, and for all risks connected with the" prosecution of the work, also for all expenses incurred by, or in consequence of, the suspension or discOk'lt1huance of said pros.ecution of t.he work as herein specified and for ~o~pleting all ofth,e ,work embraced in the Contractc The Contractor shall under this contract price furnish and pay for all material and incidental w,ork, furnish all accessories, and do everything which may be necessary to carry out the contract in good faith, which contemplates everything completed, in good working order, of good material with accurate workmanshipo 350 APPLICATION FOR PAYMENTS The Contractor spall ~ubmit 'to the Engineer an application for each pa:yment verified as required by law for claims against the Owner, and; if required, receipts or other vouchers showing his payments for materials and labor, including payments to sub- contractors 0 Application for progress payments authorized by the contract shall be submitted at least twenty (20) days before each paynient fallsduej) and, if required, the Contractor shall, before the first application, submit to the ,Engineer a schedule of values of the various parts of work, including the quantities, aggregatir~ the tot~l sum of the contract divided so as to facili tate payment,;! to sub-cont^ractors j made out in such form, and suppc~rted 'by sU..ch evidence as to i ts cor~ectness as the Engineer may directo In applying for payments the contractor shall submit a statement based upon this schedule, supported by such evidence as the Erlgineer may direct, showing his right to payment claimed 0 Payment claimed on account of materials delivered and suitably stored at the site, but not incorporated in the work, shall, if required by the Engineer, be conditioned upon sub- mission by the Contractor of bills of salej or such procedure as will estCiblish the title of the 01tTner to such material, or othel~ise adequately pl~otect the interest of t.he O'Wnero The Er~ineer \\Till excamine claim.s for payment prompt.ly j and his determination of the amount due on progress payment will be finalo 36 0 PARTIAL PAYl(El'TS t1nle~s payTdent~ !lre.wi~Jr.J1.eld by the Owner for reaf50ns hereinbefore stated,9 pity:ment vIllI be mad.e at least onc~ a month on a basis of ninety (9~~) per ce~t of the work. doae, provided the work is progressing to the ~ati~fact1on of the Engineero Monthly estimates may include the Value of acceptable materials required in the construction, which have been delivered on the 81 te of the work or itdjacent ra11ltlay siding,S} and for which acc@pta,ble proviB1on~ ha.ve been made for their preservation and stor&geo From the total value of the materials so reported, ten (10%) per cent will be retained 0 Such material:" when so paid for by the OWner~ ~h~ll become the property of the Owner, and in the event of the default on the part of the Contractor~ the Owner may use or cause to be used ~uch materials in the construction of the - 17.- GC work provided for in the contract 0 The amount tAus paid by the Owner for materials ahall go to reduce estimates due the Contractor as the material is us~d in~the worko Vouchers will be passed for payment by the Owner not later than the tenth (lOth) of the following month, unless delayed by requirements for examination or aud~ting by other authoritieso 370 CERTIFICATES OF PAYMENT If the Contractor has made application as above, the Engineer shall, not lat~r than the date. when each payment falls due, issue : to the Contractor a certificate for such amount as he decides to be properly dueo No certificate issued nor payment made to the Contractor J. not partial, or entire, use, or occupancy of the work by the Owner, shall be acceptance of the work or materials not in accordance with this contracto 38. PAYMENTS WITHHELD The Owner may withhold, in addition to retained percentages, from paym.ent to the Contractor such an amount or amounts as may be necessary to cover: 1) Defective work not remediedo 2) Claims for labor or materials furnished the Contractor or sub-contractor, or reasonable evidence indicating probable filing of such claimso 3) Failure of the Contractor to make payments properly to sub-contractors or for material or laboro 4) A reasonable doubt that the contract can be completed for the balance then unpaid~ 5) Evidence of dam'age alleged to be caused by the Contractor to other persons or property in connection with the work under the contract for which claim 'has been or will be asserted against --the Contractor, the Ow~er or the Engineer () The Owner may disburse and shall have the right to act as agent for the Contractor in disbursing such funds as have been withheld pursuant to this paragraph to the party or parties who are entitled to payment therefrom, but the Owner assumes no obligation to make such disbursement 0 The Owner will render to the Contractor a proper accounting of all such funds disbursedo 39. FINAL INSPECTION The Engineer will make final inspection of all work included in the Contract or any portion thereof, as soon as practicable after notification by the Contractor that such work is nearing completiono If such work is not acceptable to the Engineer at the time of his - 18 - GC .. : .-~ '" inspection, he will advise the Contractor i'n writing. as to the particulardefectl to be remedied before such work can be a,cceptedo ,r.f; wi:tPin a period of ten (10) days after such not:1,fication, the Contraetor hill! not taken steps to speedily. complete the work as directed, the Engineer m~y,without further notice and without in allY ,wa,Y iJipai,ring theco'ntract, make sucfl othe,r arrangements as he may deem neces,sary to have B.uch wo.r~completed in a satisf~etory Ranhero The. cost of so c~plet1.ngsuch work shall be deducted trom any monies due,or which may become due the Cont.rae.tor on his Gontract 0 4o~ F IliA!: P A IHENT 0\ i Upon completion of the work and i ts ace eptanc.e by the Eng ineer 0 ; the - En.gii1.ee'~W'ill pr€?pare.a final estimat'.econtaining ,complete 'quan-ti ties of each and every item of'Workperfomed < by the Contractor~ ar~d the value thereof, upon &c,ceptanc,e of s.aid finatl estimate by the Contractor J the <Engineer will certi.fy in wri tin.g to .the O'W'neras to the completion and his acceptan.ce of the workjand to the ,entire amount and value of each and everyi tem o.f work per- fOl;m€!d in I,~Cordance with the terms of the cont:ract 0 'Unles s as herein pro"l"ifideoj) theO~!lerwill accept the Certifica~e and Fina.~ Estimate for -final payinent and will notify the'.:Col'ltractor and his Surety or Suiet,ies 'ofthe acceptance of the 'worko . The action Qrthe~ner and t.he Engineer,' by which the Contractor ill to be b'olmd and the contract concluded according to the terms thereof, shall be evidenc~d by the aforesaid Certificate and Final PtLymen t 0 All prior certificates ore-stimates upon which P&\,ym~n.tBmayhave been made are mer~ly partial estimates and fS.ub.ject to correction in the final paymento -, Beforefia.al paY1i~t i~ made for'-~the work on this Proj ect, the Con'" tractor IlU!t JAake a satisfactory showing th~t he has complied with t'h-e provisiOiilJofMinnefSota sta tutes An.,,1J.otated 290092. requiring t,he : W1tInholding of state income tax for wages paid employees on this :r~oj@ct~ Receipt by tbe Clerk of the '<:owner of at Certificate Qt C~p11~nce freE. the CommiBsioner of ~I'axation will satisfy this requirement" Tl'ieContractor is advised that before such certifi- cate C~. be 1.~ued, he mu~t rirst place on file with ~he Commissione~ of Tax.~t1on a.n affidavit that he has complied with the provisions of MoS'o.Ao 290Q92o The required affidavit form will be supplied by "thfiC~~!ioner of Taxation, Centennial Building, st. Paul 1, N1nneljotai on. reque5to Fi.na.l p.aymeflltwil1 not be made until the Corltractor shall have filed with the Ollnerev1dence in the form of an affidavit and such other .videnceati may be required that all claims ag&inst him ~' reasons or the otmtraet have been' f1...l'lly paid or satisfactorily secured I) In ea~~e luC17i ev1denceil. not 'furnished, the Owner may retain out of a.ny.~ount due Siaid c~tr~ctor sums sufficient to cover all claims \1npa'id b 410 NO' WA~ OF LEGAL RIGHTS \ Vflle 4}Ymer, or 1. ts Eng1:rteer, sha.ll not be precluded or stopped by l..~ J - 19 - GC .'1- .. :~ '- ';~.'-.A~_._-- ---_._-:'. . . .-- r I.OJ ~aijureaant~ 8llt_te or, certificate, IIIlde 'or g;1ven by them., or by any of their ag~t& or egployees9 UDder any 'provilion of provi- sions~ of the Coatraet,. any t~e either betore or after the ~amplet1on aDJd. acceptance of the 'Work anel p..yaent thereof pursuant · ,to ~ .ea~ureRent., 'est~te @r certificate, trae ~~ at any time, that any lIuch Rea8Urel\entl, e8tiute or certitiea,te 11 u.ntrue or incorrectly ma~. 1ft any particular or that th~ work or ~terials or any part th~reot do not ~anform in fact to Specifications and Contract" a.nd the OWner ~hall have the right to rejt!ct'~,:.t:&e whole or any pArt of the aforetlilid work or BAterial, !hould the 8aid mea.uremant; e~timate, certificate or payment be foundj or be known to be incons1;tent with the terms of the Contract, or other- : wise ~ro,erly glven~ and the Owner shall not be'precluded or 8topped notw1th~ta.d1ng any such .eaaurement, estiMate, certificate and pa~ent 1ft accordance herewith, from d~di~~ and recovering fr~ the Contr~ctor and his Surety such damagelJ a~ it may su~tain by.rea_ons of his failure to comply with the term~ of the Specifi- cationi ~nd Contract 0 Neither the acceptaIice of the Owner or it~ Er!gineer or any of their ag~nt~ or employee~, nor any certificates by the Engineer, for pa~eD.t of money JJ nor any paYJIent for jj nor acceptance of the whole :: or &!fiY part. of the work by the ~er, or i t~ Elagineer, nor any , exten~ion of ti.e, nor any possession take. by the OWner or its ~ploYE?e~:# ~h~ll operate a~ a w~i ver of ~n:r'.:portion of the Contract or any power herein re~erved by the Owner, or any right to damages herein provided, nor shall any waiver of any breach of the Contract be held to be It wltiv"er of any other or .ubtiequent brelLChe 420 DEFENSE O:F CUDiS OR SUITS The Contractor .hall ind~ify and sa.ve harll.le~s the Owner and all .t its officerl, agents and employees, from any and all loss, d~gejj expenfiej including C08t and expense ~nd attorney@s fees of litigation ari.ing from all ~uit~j actiona, or claim~ of any character, n&meand description, brought for, or on &cco~~t of any injuriel or d~ge~ received or sustained by any per~onj or persons or prop@rty by "or froil the sa.id Contrac.tor or by or in consequence of any negleqt i~ ~ate~ardi~ the work, or through the Uie of un- &ceeptitble materials in conltrJ.ct1ng the work or by or on account @t any act or a&i~~ion9 ~e&lect or m1~conduct of ~aid Contractor, or 'bt or on accou.nt of ilny claiBti or l\.Ilounts recovered for any infringe- .ent of p~tent~ traQ~rk or copy right or from any claims or ' ~ount~ arising or recovered under the ~Workaeng~compen.ation Law"~ or &ny oth~r laws bylaw, ordin&nce, order or decree and so Rucho! the money Que the ~aid Contractor under and by virtue of ~ ~:t Contract &Ui l!II~~~~e ~,~d~JUllli' nec___ary by the ...._ .Y ,,'e re ained for the U:ie of ~aid Owner, or in cafSe no mOtley :1i due hi. Surety ~hall" b~ held until ~uch suit or suits, action or &ct1or~ J claim or claifA1~ j for injuries or d~ges, &S afore8ilid "j}h~ll Mve been ~ettled ana ~uitable ev1d~nce to that affect rurni~hed to the' Own"er 0 :rh,'e unauthorized Ujie by the Contractor of public or private property for any purpo~e RaY be considered an injury or d~age to the property ~o u.e~o .... 20 CO> GC ) No monies, payable under the Contract" "~: j or any part thereof except the estim~te for the first month, or periodj .hall became due and payable, if the Owner 30 electlj until the Contractor .hall "satisfy the f!aid Owner that he has made It. latisfaLctory settlement for a.11 materials and equipaent used in or upon the work and labor done for the preceding Month in connection therewith 0 430 PATENTED DEVICES.9 MA.TERIALS AND PROCESSES If the Contract requires, or the Contractor desire$, the use of any design, device, material or proces! covered by letters patent or COPyri~tJ trade mark or trade name, he ~hi\.ll provide for such use by su table legal agreement with the patentee or owner and a copy of said agreement ahall be filed with the Ownero If no such agreement. is made ~rfiled as noted, the Contractor and the Surety shall indemnify and save harmless the Owner from any and all claims for infringement by reason of the use of any ~uch patented deiign, device, material or process, or any t.rade m&rk or trade name or copyright in connection with the work agreed to be performed under the Contract, and shall indemnify the Owner for any costs, expenses a.nd damages which i t may be obliged to pay j inclll.ing COlt j expense, and" attorneyg s fees incident to litigation by refi~on of any such infringement, ~t any time during the proaecution or after the completion of the workc .44- W\TERIALS . . 0 Unles~ ot.herwise specified all materials shall be new, and bOM workmanship and material shall be of good quality 0 The Contractor shal13 if required, furnish satisfactory evidence as to the kind and quality of mat~rials or tools used by him. 0 The source of supply of the materials to be u.ed shall be approved by the Engineer before delivery" is startedo The approval of the fiource of any m~terial will stand only 10 long as the ma~erial it~elf conforms to the specifications 0 Only .aterial~ conforming to the requirements of these specific~tion8 ~hallbe used in the worko -The source of any material ahall not be changed at any time without the writ~en approval of the Engineero The Contractor may be required &t any ti1l.e to furnish 1\ complete fjtatement of the origin$ compo~itio~ and manufacturer of any or all mAterial~ required in the workj or to submit s~ples of the same 0 Matel")ial~ !hatll be tit.ore<;i so all to insure the p,re~ervation of their quali t,y aK1d ff tneCls for the work and .uch ma.terials, even though a.pproved before" Itor&gej !ihall be subject to tejlt and mUltmeet the requirementa of these specifications at the time it it5.propo~ed to u~e them in the worko Materials .hall be stored in a maaner that will facilitate in3pection~ The portibn of the ~ite or right-of-way not required for public travel m~~y;; wi th the consent of the Ent;ineer, b@ u~ed tor atora.ge purpo~es~ and for the placing of the ContractorSs pl!LI1t and ~quipment, but any additional space required, unless otherwi!e- - 21 - GC - "-- st1pulatedj shall be provided by t~e Contractor at his expense 0 All materials, supplies, andarticle~ furnished shal13 whenever ~o specified, and otherwise wherever practicable, be the standard stock produ~~of ~ecogn1zed reputable aanufacturerso r . From tl;l~ cOBIlencement of the work until the completion of the same9 the Contractor~shall be solely responsible for .the carre of the work covered by this contract and for the .ater1als delivered at the site intended to be used in work and all injury or damage to the .ame from. whatever cause, shall be made good at his exp.ense before the tinal estimate is made 0 He shall provide 'suitable ~eans of protection for and shall protect all materials intended to 'be uaed in the work and all work in progreuiJl as we"llas completed work.o He shal1:.~take all necessary precautions to prevent injury or da.ma.ge to the work in progress of construction by flood, freezing or from inclemencies of the weather at any and all timel and only approved method; ~hall he used for this purpoeJ e 0 When t@ltl of materials are necessary, such test~ shall be made by and at the expense of the Contractor unless otherwise providedo The Contractor fihall afford such facili ties as the Engineer may requi.re for collecti!1g and forwarding samples, and shall not use t'he Baterials' represented by the samples until testa have been made and the m&teri~ls have been found to satisfy the requirements of these specification~o The Contractor in all case~ shall furnish the required slJI.ples without charge 0 . All ~aterial~ not conforming to the requirements of these specifi- ,cationi fJhall be considered as defecti ve and all such materials, whether in place or not, will be rejected and shall be removed immediately from the right~of-way, unless otherwise permittedo Nq m.teri~~ which has been rejected, the defects on which have been corrected or removed, shall be used until approval has been given~ If the Contractor does not remove such condemned work and materials within a reason~ble time fixed ,by written notice, the Owner may remove th~ and may 3tore the materials at the expense of the Contractor 0 If the Contractor does nd pay the expense of such removal within ten days there~fter, the Owner may, upon ten daysR written notice, sell such materials at auction, or at private sale a,nd shall accou.nt for the net proceeds thereof, after deducting all the costs and expenses that should have been borne by the Contractor 0 The Contractor shall promptly remove from the premises all Rat~ri&ls condemned by the Engineer as failing to conform to the c~tract~ whether incorporated in the work or not and the Contractor Bh~ll ,~tly replace and re-execute his own work in accordance with the Contr&ct Documents without expense to.the Owner and shall bear the expense of mak.ing good all work of the other Cont;rsact~ors - 22 - GC ~. destroyed or damaged by sucn removal or replacemento 450 DEFECTIVE WORK All work not conforming to the requirements of these Specifications shall be considered as defective and will be rejectedo The Contractor shall remove and renew or repair all such defective work as ordered, in writing, by the Engineer 0 Should the Contractor fail, or refuse to remove or renew any defecti ve work PE?rformed p.reviously, or to make any necessary repairs in an acceptable manner and in accordance with the re- quirements of these Specifications, within the time indicated in writing,.the .E.l1gineer shall have th-e authori~y to cause the un- acceptable or defecti ve',. work to be removed and renewed or repaired at the Contractor's expense. Any expense incurred by the Owner in making these removals, renewals, or repairs, w~ich the Contractor has failed or refused to make, shall be paid for out of. any monies due or which may become due the Contractor, or may be charged against t;he ItContract Bond" deposi ted; and continued failure or refus.al on the part of"..the Contractor to make any or all necessary repairs promptly, fully and in acceptable manner shall be sufficient cause for the Owner at his option, to purdhase mateti,als ~ tools and equipment, and employ labor or to contract with any o,ther individual, firm or corporation to perform the worko All costs and expenses incurred thereby shall be charged against the Contractor, and the amount thereof deducted from any monies due or which may become due him under this contract, or shall be charged against the "Contract Bondt! depositedo Any work performed, as descr:Lbed in this paragraph, shall not relieve the Contractor in any way from his responsibility for the work performed by himo The Owner shall also have authority to take over and use defective work without compensation to the Contractor when the Contractor fails or refuses to rebuild such faulty worko 460 PROTECTIbN OF THE WORK The Contractor shall furnish, erect a-nd maintain good and sufficient lighted barricades at all approaches to the work and as necessary to protect the work and the publicQ He shall protect all portions of the improvements from damage or defacament~ and shall keep all traffic and extraneous loads off from the several parts of the .improvement for the periods of time herein specified or as required by the Engineero Whe're the work is car.ried on in, or adjacent to, any street" alley or public place, the Contractor shall at his own expense furnish and erect such barricades, fences, "lights and da,nger signals and shall provide such watchmen and shall take such other pre- cautionary measures for the protection of persons and propertY9 and of the work, as are necessaryo Excavations in or adjacent to public streets or alleys in which water stands more than one (1) - 23 - GC . -. foot deep shall be securely barricaded with snow fence so as to prevent access.by small children at all times work is not being carried on at the site of excavationo Barricades shall ,be painted in a color ~hat will be visible at nighta From"sunset to sunrise, the Contractor shall furnish and maintain at least two (2) flashing amber lights at each barricadeo A oufficient number of barricades shall be ereCted to keep vehicles from being driven on or into any work under constructiono The Contractor shall furnish watch- men in sufficient numbers to protect the work 0 When a detour is necessary because a str~et ,is blocked by the work : the Engineer shall designate its route and the Contractor shall furnish and post detour sign.s of type and size as required by the Owner, at places designated by the Engineer~ When existing sewers have to' be taken up and removed, the Contractor shall at his own cost and expense provide and maintain temporary outlets and connections for all private or public drains and sewerso The Corttractorshall aI,so take care of all sewage and drainage which will be r$ceived from these drains and sewers; and for this purpose he shall provide and maintain, at his own expense, adequate pumping facilities and temporary outlets or diversionso The Contractor at his own expense shall" construct such troughs, pipes, or other necessary structures, and bepr.epared at. all tinre.s to dispose of drainage and sewage received from these temporary connections until such time as the permanent connections are built and in serviceo The existing sewe'r.s and connections shall be kept in servie~ anq.maintained under the contract, e~cept where specified or ordered to be abandoned by the Engineer 0 All water or sewage shall be disposed of in a satisfactory manner so that no nuisance is created and so that the work under construction will be adequately protected~ At all shaft sites and on all open cut workJ the Contractor shall provide and m~intain free access to fire hydrants, water and gas valves, manholes and similar facilitieso Gutters and waterways shall be kept open or other satisfactory provisions. made for the removal of storm watero The Contractor shall provide at his own cost and expense all methods for adequately draining the work ~and shall assume f~ull responsib,ility and liability for damage to any persons or property resulting from such' damageo No separate compensation will be paid for sub-drains, or other methods of' draining, but thee'ost thereof shall be merged wi th such contract pay items as are provided in the proposal and c6ntracte No trees shall be cut except upon the specific authqrity of the Engineer" Trees adjacent to the work shall be protected from all damage b~ the construction operations1) - 24 ~ GC \' '\ .... 470 DAMAGE TO EXISTING IMPROVEMENTS Al~ damage done to exist~ng lmprovements during the progress of this improvement shall be repaired by the Contractor under the direction of the Er~ineero Such repair:? shall be made according to the requirements of the standard specifications of the Village pr~"'City for various types of improvement:$ or classes of work :requi~edQ The Contractor shall be entirely responsible for the protection of all improvements that are" not designated ,by the" Engineer to be removed for proper construction of the projecto 480 PROTECTION AND RESTORATION OF PROPERTY " Where the. work passes over or through private property, the Owner will secure right-of-way or easemento The Contractor shall not receive any extra compensation or"be entitled to any extras because of delay on the part of the Owner in obtaining right-of- way or easement 0 The Contractor shall not enter upon private property for any purpose without having previously obtained pe:rmission from the Owner 0 The Contractor shall be responsible for the preservation of, and shall use every precaution to prevent damage to all trees, shrubbery!) plants, lawns, fences, culverts, bridge, pavements, driveways, sideWalks, etco; all water, sewer and gas lines; all conduits, ~ll overhead pole lines or appurtenances thereof; and all other public or private property along or adjacent to the worko " The Contractor shall notify the proper representati:ves of any public utility, corporationj and company or individual, not less than forty-eight hours in advance of any work which might damage or interfere with the operation of their or his property ~long or adjacent to the worko The Contractor shall be reS?Po~siblefor all , "" ,~\o damages or injury tCf'-p;r"Operty of' any character result,ing .from any act, omission, neglect or misconduct i:n' the manner or method of executing the work, or du"e to his non-execution of the work, or at any t,1me due to defective work or materialso He shall restore", or have restored at his own cost and expense" such property to a condition ~imilar or equal to that existing before ~uch damage or injury was done, by repairing, rebUilding, or otherwise restoring as ~ay be directed, or he shall make good such damage from injury ... " in. a lMnner acceptable to the Owner or the Engineero In case of failure on the part of the Contractor to restore such ~roperty or make good such dall\age or injury, the Engineer may, upon forty-eight" , hour~~ written notice under ordinary circumstances and without notice when a nuisance or hazardous condition results, proceed to repair" rebuild, or othenqise restore such property as may be _ ~ ' determined necessary, and the cost thereof will be deduct"ed from :~": arty.monies due to the Contractor ,under this contract and' if not so deducted~ the Con.tractor will be obligated to forthwith reimburse the Owner for the cost thereof 0 ..' Prior to const~ction" the Contractor shall obtain field locations or other assistance as may be required to determine the existance , - 25 - GC and location of gas main and oth~r private utilities as. well. as public utilities of th~ Village', .City, County or State which may be under- ground or overhead within street and hig,hway right ~of.-way or within easements. and Which may be interf~~ed with under this contract. Existing underground, surface, qr overhead structures are not necessarily shown on ~e plans, and those shown are only approxi- mately correct and no responsibility is assumed by the Owner or the Engineer for the accuracy of location. The Contractor shall make such investigations as are necessa~y to determine the extent to which existing structures may interfere with the work contemplated under this contracto The sizes) locations and depths of ~uch structures as are shown on the plans and. profiles are only approximately correct and the Contractor shall satisfy himself as to the accura~y of the information giveno The Contractor .shall not claim or be entitled to rece ive compen- sation for any.damages sustained. by reason of the inaccuracy or the omission of any of the information given on the drawings, relative to the surface3 overhead, or underground structures or by reason of his failure to properly protect and to maintain suc.h structures n The Contractor is to exercise extreme care in crossing or working adjacent to all utilities and shall be responsible to protect and maintain their operation during t"he time the work is in progressij The Contractor shall restore, at his own expense, any p~b,lic structures such as water mains, water connections and appurtenances, . sewers, .manholeS,. .~atch basins 'and sewer connections which a~e damaged or injured in any way by. his acts~ The Owner shall be indemnified and saved harmless, from any suit or expense claim brought for or on account of any damage, ma i.n - tenance, removal and/or replacement, or relocation of mains, cond,uits, pipes, poles,' wires, cables or other such structures of ''''''-;0." "p~rivate utility firms or corporationsJ- whether underg'round or .-- ov'e~n.eadJ . tliati:.triay. .'be'.' (sau.sed".c5r"'"~requirecr~"by the .Contractor during the t irne the work is in progress.Q"'However, in cases where. the alignmentJ as shown on the plans, coincides with'..the existing location of either an overhead or underground privately owned utility (installed and located in accordance with a permit issued by the Village or City) so that, in the opinion of the Engineer the re- location of saAd utility is required to complete the installation, the Owner shall provide for such relocation4 4ge PRIVILEGES OF CONTRACTOR IN STREETS., "ALLEY,S AND RIGHTS-OF-WAY For the performance of the contract,t~e Contractor will be ~permitted to occupy such portions of streets or alleys, or other public places, .or other rights.c-ofe...way, as shown on the plans! ~ . or as permitted by the Engineer 0'." '.A reason.able amount of tools, materials and equipment for construction purposes may be stored - 26 - GC . ~ .<<~.c~'"':,;:,~-~-~~~~,'7':~T:;~';":::i;l~~'~'~~:::"d]::;~:?~~':,_ ",.;l~:~':<...:~fi(~~~?~;~~~ . . w . .- ... --,/' . in su-ch space, but not more than is 'necessary to avoid ,delays in the c@nstructiono Excavated and waste ma,terials sha-ll be piled or stacked in such a way a.3 not to interfere wi th spaces that may b-e designated to be left free and unobs.tructed, nor inconvenience o.ccupants of . adjoining propertyo · Other Contractors .of the Owner .rrJiAY, tor all purposes, r'equired -by their 'contracts i enter upon .the work and premises used by the Contractor, ~nd the Contractor shall give to other contractors of the Owner allrea50nable fa9ilities~da,ssistance for the completion of adjoining worko Any addi tional g.rounds de8ired by the Contractor for hisuBe shall be provided. by him at his own cost and expense 0 Where th~'work .~ncroache3 'upon an;;yright--ofcoway of ?lny railway or State or County Highway 3 the Owner. w,ill secure the necessary easement or pennit 'for the worko There railway tracks or'sllch highway are to be crossed, the Contractor shall observe all ,the regulations and :Lnstructions of the railway company and Highway DelDa.rtme"At. as to methods of doing the workj or precautions for safety of property except the right-of-way, shall be ~made,by the Contractor at h1~ expense 0 The Contractor'will not be paid . direct. cOO1.pen~ation for ~uch railway or highway crossings, unles's so provided in the special proviaio.na and prop'osala ~o WORK IN STOF.MS '~e En.g1J.leer may :nave .the righ.t to stop work during rai.n or snow storms ~nd illl,freshly pla.ced work, unles3 otherwise protected~ .hall beproteeted by canvas or other auitable covering in such -Ii ~er :a~ to prevent:ru.rming water from coming in contact wi th ita Suffi'cieln.t coveringahallbe provided and kept ready for this pu-rposeo ~eContractor will not be entitled to extra. campenf!ation for work so stopped o.rdelayed by the Engineer 0 i1 " NIGHT WORK . . . ,ark shallbeaone at night- only in theeafie of emergency and only ! upon the direction of the Engineero 'The Engineer hitS the rj,ght, to order work to .be c~rried on at night,9 if in his opinion" it i~ for the best inter~~t of the ~ers Wo-rk pe;rformed after dark shall 'b~ adequately 1:111lminated.9 &n4 sui tag Ie andl\ufficient lighting . facilities shall be provided for this worko No extra compen~ation will beallolfed 'the.Contractor for work under this item~ f2 0 USE 0:1' EXPLOSIVES . -:fi t is neeetisary to urle explosi yes in the perfo~!ce of the work, the CCJr1t~ctor lihall take out pe:rm:i t.and corIply wi thall ".. the laws, ordinancefi and regulationa governing iI&Lme 0 He shall fully protect a.llc<.1fnpleted works &S well as all overhead, surface or underground itructures and shall be liable for any damage done to the work or to other structures on public or priva.te property and injurie$ sus,tained by persons, by reason of the use of explosives in hi~ operationso Explosives shall be handled, used and fired oIlly by experienced ,meno All fi"ring shall be done by elect,r1citYoAllexplosive supplies iJhall be safely stored and protected in an ~pproved mannero All ~uch storage places shall be =c 27 .- GC ... , . . .marke~ clearll NDAHGEROUS ~ EIPLOSIYISfie Cap. or other exploders shall llot b. ItlJred at the pl$ce mere dywlldte or other explosives are .toredo ~ 0 !fOrSE ELIi(IJ'ATIO)f . e .Contractor ahall eliminate no18e to &8 great &n extent &1 possible at &11 t1Belo Air compressing plant shall be equ1pped . wi th silencers Ibnd the exhauat. of all gasoline m.otors or ether power equipment sh&ll be provided with .ufflerlo .; o WATER or City e Contractor ~ha11 make arrangeR~nts with the proper Village officials and/or p~T&te partiel for obtaining any water which f.iVAy be, neededo i 0 SAlfITARY PROVISIONS . e Contractor shall comply with all l&ws, rules and regulations of the State and Lee,.,l Health Authorities and. shall take the necelsary precaution. to avoid uaaanitary conditio_so Suita~le janit~ry convan1e.ce~ for the use of all persons employed on the work, properly ~creened frOB public observation, shall be provided and ~intained by the Contractoro t6. FOSSILS f arty fO~8ils or treasure or other unusual or valuable ~eol~gical formation! are found in the progress of excavating, such fossils, treasure or ~~ples of geological fo~t1on! shall be carefully pre,served by the Contractor who ahall convey such item. to Engineer 0 , These items shall become the property of the Ownero ;7" ACCIDENT PREVENTION 'recaution .hall be exercised at all ti.es for the protection of per,sons (includir~ employee.) and property 0 The safety provision. of a,plicable law~i building and construction codes shall be ob&ervedo MaChinery, equipment, and all hazard~ shall be luarded in accordance with the eafety provisions of the Manual <sf Accident Prevention in C~n~tructionj published~1 th. Aaa.eiated.Gener&l Contr&ctor8 or A.ericaj to th. extent that ~uch ,rovi~1on. are not in contravention of applic&ble lawso ~" "OR EQUAL" CLAUSE . ~ever in any of the contract docuaent~ any &rticle, appliance, aevice or :ma.terial is de$igne.ted by .the naae of the manufacturer or verifior or by any proprietary naJl!e and suc.h Jl&1I4e is not followed QY the wordfJ it or equal u, i t shall be deelled tha. t fiuch woral\ nor equll,lOO do follow rfuch designation, unleiji the context cl@arly rGlilu1refj & IlWAtrary constructiono Any article @r material equalling the standard~ fixed Ji&Y be used in place of tMt. 8pecifical17~;.B.tiltigned by the apeeifici&tioJfia, proTidiD& that the material pr~o~ed 1~ first .ubmitted to and accepted by the OWner or his authorized reprel~ntat1veo -::.~'. .~.. - 28 - GC 590 LABOR None but competent labor shall be employe,d on this worko Wherever mechanical work is required, it shall be perform.ed by skilled laborG The foreman or other person directing the work shall be competent, sober, and reliable, and s:hall extend every facili ty to the Engineer to enable him to properly discharge his duties, and shall furnish such help as may be necessary to facili ta,te the inspection of materialso The 01vner reserves the right to require the removal of any particular workman or ~lork:men on the job, if in the judgment of the Engineer, it shall be :for the best inte!~ests of the work that such pa,rticular \'lorkman or workmen be removed s Wherever possible, local workers shall be given preference over imported 1\Iorkers, provi.ding that they are equally competent at the work applied foro T:he Contractor '\-'lill not be allowed added compensation for any work performed on Saturday~, Sundays or Legal Holidayso 600 DISGRIMIR~TION ON ACCOUNT OF RACE, CREED, OR COLOR PROHIBITED ItICO~1TB_A.CT "Every- contract for or on behalf of theO~mer shall be deemed to contain provisions by which the Contractor agrees o Q 0 0 0 Q 000 0 0 0 0 (1) That, in the hiring of cornmon oX' skilled labor for the performance of any 1tJork under any contract, or any sub- contract hereunder, no contractor, material supplier, or vendor, shall, by reason of race, creed, or color dis- criminate against the person or persons '41ho are ci tizens of the United States 'Vlho are qualified and available t.o perform the 'V/ork to vlhich such emplo:Yillent relates g (2) ThatnoContra-ctor, material supplierJ or vendor sll.all, in ap:ymanner9 discriminate against, or intimida,te, or prevent the employment of any such person or persons:; or on being hired, prevent, or conspire to prevent, any such person or persons from. the performance of work under any contract on account of race, creed or colorg (3) Any violation of this section shall bea misdemeanorg and (4) That.this contract may be cancelled or terminated by the OWner, and alIL money due~ or to become due hereunder" may be fo'rfeit'ed' fora second or anysubse'quent violation .ofth'e terms or condi tior:tS of thiscon.tractU (Section I8le 59 :Minnesota statutes) 610 S,.:rrESTO BE J<EPTCL.EAll. Th.eCon,traet~or snali:l'clean and keep clean from-waste, materials - 29- GC or 'rerase resulting, from his oper'ationsc9 th,e -81 te of work" the streets fP the work and public p-~~rty occupied by himo Equip- ment not usable oo.the wOrk sl1all '~e-pramptly removed and the adjacent premises ~mta1ned" in a-fl:eat antl oroerly condition at all timeso Advertising signs in genefalwill not be permitted on the works Upon completion of the work a~d before acceptance and final payment shall be made,- theCop,tractot 'shall remove from the street and adjacent prop-erty, all surplus and discarded' materials, equipment, rubbish and tempor~ry strUctures~ restore in an acceptable manner all property ",'both public a,nd pri vate, which has been damaged during the prosecution of the work, and shall leave the site in a neat and presentable conditiono 620 1\ffiJ.\.81JRE.MENTS B,eforeordering any material or doing any work~ each Contractor~ shall verify all measurements ,and shall be responsible for the sameo I No extra charge or compensation will be allowed, on 6;ccount 'of diffe~ap~e between actual dimensions and measurements indicated on. the draYdngs$ 8:JJ:Ydifference which ,may be fOlLYld shall be subnti t,ted to the Engineer for canside~tion before proceeding ttll th tuhe worko U l' S 0 Starid~r.d Mea~ures will be used in the measurement of all 1-\fork a~ceptably completed and such measurements will be u$ed as abasis:for the .computation of the ~uanti ties of work perfolm,ed,o Linear measurements 'Will be taken horizontally on all work except strtlctu..~S which 1rlill be measuredaceording to the n.eat lines sho1tm. on the plans or as orderedQ Wher,e 1iork is to be . paj. d. ~Qr-by ,units of length:,. area" vo:Lume., or : :-weight,,' only, tb~ net amount of worka,ctual1y done, as it shall appear in the fipished work s.n.dmeasur>ed as hereinafter specified shall be. paid for;} loca':L customs to the contrary not wi thstanding6 For the estimatir~ of quantities in,:wh1chthe computatio.n of areas by geometric methods would be eomparatively laboriotJ..s 9 it is stip:ulatedand agreed that t"he plltn1metershal1 .be considered a:n ir~trument of precision adapted t.o the measurement of SL1Ch areaSe 6 3G GUA-1l.~rlVEE 'The -Contracto~:r s,hall be held responsible for any and all defects in 1tIo~~~hipsmaterialsand equ~en,t lmichmii,y bed-eveloped in any 'p.aj;t of the entire installation fu-rn.ished by him~ ~t~~on written notice by the 'Engineer shall immediately replace .'and make g~'d withoute.xpense to the Owner any such faulty part or parts and d~gedoneby reason ofEialne~ during the period of one (1) ya:ar freill trse d~te of final acceptance o:f the installation6 g!\~d the CC1fltra~tol1) fail to make goo,d t~he de;fecti ve parts ldrtiiin ..it p,e~oo ~f tl1.i~y (30). days of msuch, notif1'catio~s>, :after 1?1rltteftnot1ee M$ been gi'ra-q him9th,e '~.erm~y replace the~'e part~, charging the expense of same to theCbntractor~ - 30 - GC ~- .!PECLEtL "P~'GVI~TftlliB - 4". - _- -" - ~~~ '.h~.'f~ I FOR T~lE - E-IB\?A!i:ED i14~BR srA-B j,1:\]p '-~p~ifi.1~'$~ltrq t~-.,itl0RKK 4., '.if ~-r 1& ----- - - ~c=i;a~~ ~h4.."<: -- -Wi -, - - --<;:>- ....... FOR ~~ Imil_____-~~~~-d> L~!IiilmSm!A E~rt,l,~JLe ~A_~, -J~~ "- ~ "..:. .". ""-;. .....~. ~ =.=:u ~ "t. ....:. .m,..."...""., ~.'~ ~ '......~w ~. ...!!: ~ ~~--...;!;::;. ~ J.",. 2,y aJlct 9i' J., ~ -"'j:"'_^ -"j ~o tlV .~~ of 1 ~~ .1 2 7 :2 -~ -,<> 8" 2 90 5 100 F:lll --~ '-""'S ~~ " :f*l1>:aDsrrd ~ ....'==-0 J 12-$ ':1,30 '& PrepaL:t~t.ion '.~ ~Ge d' 0 liotQl~ iGl"Z-adillg -~ J 150 s --~ J 160 Pr'o~hect-io:n e -J' l7e Affid,av1 t a*"4 Jion-C-ol-l:u-s i-all .~ ' -t dI 180 R.e,Otlirements for Final 5 .. SPECIAL PR'OVIS-IO!iS 4~ FOR crr1iE ELJ:ivATED 1'lJ\ TEE. TAift{ c.c.:::. ~ aND APlJiWTENllNT ,lORK ~~. '4J~\. . __~ _ .,=~- ~~l HOPE Q. JII!IiImSOTA ~J,;,J ;I tL~. ., ._ J..<> } GENERAL E'iine ~7:at'~o"'al Conditions ~nd the Special COlldi~tions as enlboaleo. s1......... . . ,:' ~ ""~ ~,_, .. ,.' in .t.', Co:n.trs<fet Doc'Lunents ,.-s11a11 be 'el,pplied to tUl 11i'O:t~J:\. and line fi124~ teria,l furnished ~lndel~ ~the':se Specia:l ProvisioDJ3 , " . . b as here=- excep to.- ina~fter modified 0 20 STf~~Tnm AiID COlifFI:E4J: ION DATES Tne: Cont,raI(;~oi:,~usnall contrllence ' liork \~11 ~thin -t '6 t1. i ~ ()~' e~alendar \ J.,.U ) r1 r~ . "'1""if:t 'aft~~er 1'?e_~e1pt aD no*tif.i.cat.ion ~to p:eoeeed f lr)om the E.ngine'el~ 0 ..,;;.Q~.:~ J.. A'~ ~ 1tlOl~l): to be eonst~ruc.ted uncler "'chi s pr-oject 13118.,11 -be comple"~ed ca..L& ill p,l'8...ee and accepted OD..or berol-;e ~O'ctober 1m .- 1968 ~) cL ::>: 30 FAI1t)11~E TO CObfPLETE ~~-l ORE: SliOtrI(r.=-t!)Ja='Collt;rac~eOi:~ fa;1! ' to 'cOr!lp:te~t e hadve accepted a.ll ' ~ "Glle l~Of~kono~? the 'e~;.taJ:flistledcorap]tOtion iSe1itG~ G th~ sum 0'" ~;~~~T',~~';-,~~ .(i)~~ ~~(., ~~~'-Q~~ <='~'~f~'~~r1;~ ;~-~~;~i~; .'~;;::'lAV~ 8..nd :--:~,~:( ~JOet~;:>.~~a::~j.~'~VOOOl P~b ~ cQ:~':O~naa_ Us.:4'., .k.L....CJ__d.-1Jo ~~!...aC~4~ Hol"l..aa~ra ::sna~..t D.e -cled!lC1;8a fl~Om~~t};1yt10n.l.eS d'ue !;no"Gas a ass liqlti.dat;ed ttexuages; M.l ill aecolr.:dculce tll *t116 ti'O'!lS ..~ t;he"s.e- C'on.'cl<aa.c1~ Documen:'cs 6 O.ti,. Dr $ S(;OPE M\m ORDER OF ~l,ORK ar!le.-d~Y'ork 'un:.de'l~ tliis ~'-~ '.' ~.,~.~ sllall a:;onsis.;t 0""[> furlli shirl:g a.ll pro dJ-~V .... neeess SJrjt -I!lerl :; eq uipPlent :afio maJGel~ia1s. .1;0 irlst~;l..,11 a 1,500;000 ~a1'Of7l 'elevat.ed tanl~ and ;al,l aJpp.uri~erlGtnc.es 0 o ,.... ~:::!iC::> ," ......om, The 'C:ontra<ictoT m34Y sclledtl1e ~Glle clraer o&~ 7:t!.Alnl? as l1.e deems necss .c=> J. !ifir V i;;~ L.l:. e:~eept tlla.1; certai!~ req ui ramei~~Cg c<?9 hel'";)eillaf;te'r ~ .~~. ... .sarjr :spec:tI :Lea slia;l.l be f~o11ot;~ed 0 ~i ~ COi.~rt~l~actor ells-,ll, be requ ilne'd ., submit~ ....':,c; -i;O ll>i:ritte'n schedtlle .bGO ., '" Engi rua 61'"' 0" a olGne 50 lfATER iTa.,t~e:~-:fol? dl~inlt:ing pltrposes , laydros Jeat-; 5..C ebs'S.Gs and tal11\. t.es.-t~ ii1.g ~J.illbe sup .j;llied b~r the OwlneIit 0 The Cor.rt r8~c.;t.or shall raake nee~ess'ar9 aJ:<l~,erJ:igemen t.S vii th i;ne En~gineer for the :toc'ation l,here liS/cis:(-' m.~y be obted.neclo T}~~ City J:'aeserves tl"le l~igh t tiQ c.r-large ,""~- t:tle Contr~5M~tor the eost of t~le!it;er l~jhich is u..s,ed over nOl'7mal require~man. ts 0 It is anticipeltted that a~11e Ta~rdc Con i;l~aC~c,or l~Jill .". .'. ~sJ-&~Ge!-:. ir.rl:..C) the te~n.~ J?or ~tes tine; PUi"ipos:es <;; na,"?Vt., ~&O pVlAt.p ~ , '-::'11 S~~Ji~T ~ 6...'.... c.~n1\"tc:1m~?1,Rm""W"'^~;( .L. r. 1tE?m.~...... c .... ...Vk~$I;:i ,., J;\Uv .it. ..A.\:.it\ .. ,'" ~.t>;~J; Q Tlle"'co'ntractor s~.JUlc-areful1y note the limits of COllstrllction a.sshollnonthe pl~Y1soAllc ODJ3t ?'llctionaeti vi ty including tempora,ry ,storage ofeonstrtlct1on ma.)Gerialsanaex'cess excava.te,d mater.:l.&,ls ,directly connecte;d~lith the ,constr'uc.l;j.onof the el,e-= vate'dtaiL.tt ,shall be eo~~in,ed to the area desig:nat'ed ,on the pla:n,s a,s ':nC,onstl~~lctiori.Limi .1,;,s no \70 ROpX; Al\lt) PARmiG PaP&CONSTtruCTIO! ;T:~o' .~,o. ,or1 eX~:rf' ~p.,.'':'e1''%l~''i V%.~ ..~~..t:)C")6~@n~#"\1,~~ ,l""!.r. "'~n,~ fl~e.V'1l .pzhe 1 '1 .Jk Ll~, ..... .i;Ar\o.i. eL$;.,;iiU ,...~ t'b~~ ~~~~'~ Q&.;.V~; ~J. \..of ~LrJoAQ J:1JoQ<t,,~. ~4-1.CAt~~ con:stru..cted lJl aceorclance 'litll the follol*lii1g spec,ificaJ&ionsg ]A rJSps(;1fications ;111ioh c" ..... .... .". -,"t...., . e!.~1 ..~...t. ~'4;~A' 1'" ~k~"'4=-.. ~1.. .~.. h." >, rt' 1 ."'., ...... -::'"]..~ ..AR vons1:tJ:uc \1..:.v,nQt;,~~d~'Ue l.n u.n tiea1:Jp=1caDeb~S'C\;- .-tioi1J; ,of ltiri.nesot,aSpec 1f1cati one ~ 1 'Oh,~i4 A....~ k Jjc:o: J~"T . y_ :; lJo on ,9;J c=2 = '\. ;... ~ l.tl -. .,...::> ~ "= __41 ,Certi,ficateofComp,li,anaefr,om the CoJtm1ission'er of'Taxatio,n \1'il1 sSftis'fythia requireme.nt <) TheContrac"'tor 1sadvi,s'ed tba:JG bS.fore suchQert:tfic,atec~be iSisued, he must first ~}:laceon file lfith the Commiss:t,onel~ofTaxatioll anaffidav:tt tbatner~seompliedtfith th.e provis:ton,sof l~lGS(!iA 02900920 ~ 6 ~ ,SP~ET c c - ..;.: 0 ,.;jM"y,s .0 ~..; ~., {~. h"....... ~,~';- : ~~.... c~~*::~ :../ ?,y~ :(~ Qt2~r ^ . c , () -j .~ t '. } ; .. I. e Q - G ~ -<;"" '. I,.. .... """" ~-'""~ ~ <:::::> =~ :::'...":? .', "' i r1 cL C01!61" r. .....:"..,:.:.... u _ .. ~/nY' v .' ..;;.....,,'~/,-~:;:....:;.-,y........~~~..''':!}~.:::'~:~~t;';?:"m~~~If(..;,:,~_.:::"tIv,~,~~~:~'_....~.::'l';~,....'.::;;.;4:---'~./~!'!O~~""":;"~ ,,;.... '--....,:::::/y~, .,. AFFIDAVIT AND INFORMATION REQUIRED OF BIDDERS Affidavit of non-collusion: I hereby swear (or affirm) under the penalty for perjury: (1) That I am the bidder (if the bidder is an individual), a partner in the bidder (if the bidder is a partnership), or an officer of employee of the bidding corporation having authority to sign on its behalf (if the bidder is a corporation); (2) That the attached bid or bids have been arrived at by the bidder independently, and h&ve been submitted without collu- sion with, and without any agreement, understanding, or planned common course of action with, any other vendor of materials, supplies, equipment or services described in the invitation to bid, designed to limit independent bidding or competition; (3) That the contents of the bid or bids have not been communicated by the bidder or its employees or agents to any person not an employee or agent of the bidder or its surety on any bond furnished with the bid or bids, and will not be commu- nicated to any such person prior to the official opening of the bid or bids; and (4) That I have fully informed myself regarding the accuracy of the statements made in this affidavit. Signed: Firm Name: Subscribed and sworn to before me this day of 19 . Notary Public My commission expires 19 . - Bidder's E.I. Number (Number used on Employer'S Quarterly Federal Tax Return, u. S. Treasury Department Form 941): . - 1 - AFFIDAVIT Fair Trade Items: List below each item upon. which a bid is made, the price of which is affected by a resale price maintenance or flfair trade" contract between the bidder and the person or firm ,supplying the item to the bidder. (Use reverse side if necessary) 0 - 2 - AFFIDAVIT CO~~R4CT FOR CONSTRUCTION FOR THE VILLAGE OF NEVJ HOPE, MINNESOTA IIJ1PROVEMENT NO 0 THIS AGREENENT, Made and entered into as of the day of by and between the VILhAGE OF NEW HOPE, MINNESOTA, a municipal corporation under the laws of the state of Minnesota, hereinaft.er called the tio1t?nertJ and , hereinafter called the "contractor tt, vlITNESSETH ~ That in consideration of their mutual covenants and agree- ments as hereinafter set forth, the owner for itself and the contractor for itself, its successors and assigns, covenants and agrees as follows; to wit: 1. The contractor agrees to furnish all the necessary materials~ labor~ use of tools, equipment~ plant and every other thing necessary to perform the work designated and referred to in this contract, including all contractor's superintendence and to furnish everything necessary for the completion of the improvement which is the subject of this agreement (except such things as the owner has specifically agreed to provide, according to the contract documents); and agrees under penalty of a public contractor's corporate surety bond in the amount of $ to perform and complete the work shown in the plans and drawings, entitled If , Improvement No. 11 prepared by Orlr.l-Schelen-Mayeron & Associates, Inc. of Minneapolis, ~linnesota and dated , and to - 1 - Fe conform in all respects with the provisions and requirements of the general conditions, special conditions and special provisions for said improvement, which are entitled ttContract Documents for for the Village of New Hope, Minnesota" prepared by said Orr-Schelen-Mayeron & Associates, Inco and dated . 2. The Contractor agrees that performance shall be in accordance with the terms, requirements and conditions of this instrument, the laws of the state of Minnesota, and the following documents: Advertisement for bids for said Improvement No. of the Village of New Hope. Proposal by the contractor, presented to the Village Council of the owner on and accepted by the o't-lner on . Contract Documents for said Improvement No. , dated referred to in the preceding paragraph of this Agreement and made a part of the aforementioned proposalo Plans and DravJings for said Imprc.\remerlt No ~ , as identified in the preceding paragraph of this Agreement and which are dated Any Addenda to the plans, drawings, general conditions and specifications for said Improvement NOe :; 1tJhich addendlJ~m was prepared by orr-Schelen-Mayeron & Associates, Ine.. Public contractor's surety bond in the principal 811-111 of the amOllnt bid. - 2 - Fe Each and all of the aforementioned contract documents are hereby incorporated into this Agreement by specific reference and the terms and provisions thereof are and constitute a part of this Agreement as though attached hereto or fully set forth herein. 3. The owner agrees to pay the contractor for the performance of this Agreement and the contractor agrees to accept in full compensation therefor!) the sums set forth within the aforementioned proposal of the contractor for each unit and each type of unit of work to be performed. It is understood and agreed that the said proposal is for the construction of said Lmprovement Noo on a unit price basis in accordance with said proposa13 and that swn of $ as set out in said proposal, is the sum of the unit prices~ multiplied by the estimated quantities of the respective units of work listed thereinQ IN WITNESS WHEREOF, the parties hereto have hereunto set their hands and seals as of the day and year first above writteno .-. Contractor' By By ( Carpor-ate seal) THE VILLAGE OF NKvJ HOPE B~l B~l (New Hope Village Seal) - 3 - Fe A PPEIID IX ~.::._. -..-.:.- De"Gs...il Plate 1::r 0 0 ~ Blocking for \~late14 Mctil'l 1 Typical l\[~vt~er Main Beddi11g in clay, hardpan or rock excavation conditions 2 Typica~l Hydrant Ins~Gal1atio11 3 ':"-. ....". . ... "'::':n-;...~~.N :-\ i -- .;t\G A !J :r'-~4 S NEW HOPE, MINNESOTA T' v ,- --" r ~' ~- NEW HOPE t MINNESOTA ~ T YPI CAL